Loading...
HomeMy WebLinkAboutExhibitI of 3 RESTRICTIVE COVENANTS Project Name: Olympia Theater Facade Restoration, Phase I Grant Number: 18.h.se.100.079 THESE COVENANTS are entered into this _ day of 20_, by hereinafter referred to as the Owner, and the Olympia Center Inc. hereinafter referred to as the Grant Recipient, and shall be effective for a period of ten years from the date of recordation by the Clerk of the Circuit Court of Miami -Dade County, Florida. WHEREAS, the Owner is the fee simple titleholder of the Property located at 174 E. Flagler Street, Miami, Miami -Dade County, Florida, as described in Exhibit A, attached to and made a part hereof and WHEREAS, the Grant Recipient is to receive State Historic Preservation Grant assistance fluids administered by the State of Florida, Department of State, Division of Historical Resources, R.A. Gray Building, 500 South Bronough Street, Tallahassee, Florida 32399-0250, beremafter referred to as the Department, in the amount of $500,000, to be used for the restoration and preservation of the property of the Owner as described in Exhibit A, and WHEREAS, said State fluids have been or will be expended for the purpose of preserving the historic qualities of the property or contributing to the historic character of the district in which the property is located, Now THEREFORE, as part of the consideration for the State grant, the Owner and the Grant Recipient hereby make and declare the following restrictive covenants which shall run with the title to said Property and be binding on the Owner and its successors in interest, if any, for a period stated in the preamble above: 1. The Owner and the Grant Recipient agree to maintain the property in accordance with good preservation practices and the Secretary of the Interior's Standards for Rehabilitation. 2. The Owner and the Grant Recipient agree that no modifications will be made to the Property, other than routine repairs and maintenance, without advance review and. approval of the plans and. specifications by the Department's Bureau of Historic Preservation. 3. The Owner and the Grant Recipient agree that every effort will be made to design any modifications to the Property in a manner consistent with the Secretary of the Interior's Standards for Rehabilitation. 4. The Owner and the Grant Recipient agree that the Department, its agents and its designees shall have the right to inspect the Property at all reasonable times in order to ascertain whether the conditions of the Grant Award Agreement and these covenants are being observed. 5. The Owner and the Grant Recipient agree that these restrictions shall encuunber the property for a period of ten years from the date of recordation, and that if the restrictions are violated within the ten year period, the Department shall be entitled to liquidated damages pursuant to the following schedule: a. If the violation occurs within the first five years of the effective date of these covenants, the Department shall be entitled to return of the entire grant amount. b. If the violation occurs after the first five years, the Department shall be entitled to return of the entire grant amount, less 10% for each year past the first five. For instance, if the violation occurs after the sixth anniversary of the effective date of these covenants, but prior to the seventh anniversary, the Department shall be entitled to return of 80% of the original grant amount. C. The Owner agrees to file these covenants with the Clerk of the Circuit Court of (Name of County) County, Florida, and shall pay any and all expenses associated. with their filing and recording. 7. The Owner and Grant Recipient agree that the Department shall incur no tax liability as a result of these restrictive covenants. 2of3 IN WITNESS WHEREOF, the Owner and Grant Recipient have read these Restrictive Covenants and have hereto affixed their signatures. WITNESSES: Witness Signature Witness Nance Typed/Printed Witness Signature Witness Naive Typed/Printed The State of Florida County of OWNER Owner's Address City State Zip I certify that on this date before me, an officer duly authorized in the state and county named. above to take acknowledgments, that personally (Name) appeared as for (Officer) (Name of Corpora tion/Partnership) known to me to be or who proved to my satisfaction that he/she is the person described in and who executed the foregoing instrument. Type of Identification Produced Executed and sealed by me at , Florida on , 20 Notary Public in and. for The State of My commission expires: [SEAL] Witness Signature Witness Name Typed/Printed Witness Signature Witness Name Typed/Printed The State of Florida County of GRANT RECIPIENT Grant Recipient's Address City State zip I certify that on this date before me, an officer duly authorized in the state and county named above to take acknowledgments, that personally (Name) appeared as for (Officer) (Name of Corporation/Partnership) known to me to be or who proved to my satisfaction that he/she is the person described in and who executed the foregoing instrument. Type of Identification Produced Executed and sealed by me at , Florida on , 200 Notary Public in and for The State of My commission expires: [ SEAL] 3 of 3 AGREEMENT BETWEEN THE STATE OF FLORIDA, DEPARTMENT OF STATE AND OLYMPIA CENTER, INC. 18.h.sc.100,079 This Agreement is by and between the State of Florida, Department of State, Division of Historical Resources hereinafter referred to as the "Division," and the Olympia Center, Inc. hereinafter referred to as the "Grantee." The Grantee has been awarded a Special Category Grant by the Division, grant number 18.h.sc.100.079 for the Project "Olympia Theater Facade Restoration, Phase I," in the amount of $500,000 ("Grant Award Amount"). The Division enters into this Agreement pursuant to Line Item 3112A contained in the FY2017-2018 General Appropriations Act, SB 2500, Laws of Florida. The Division has the authority to administer this grant in accordance with Section 267.0617, Florida Statutes. In consideration of the mutual covenants and promises contained herein, the parties agree as follows: 1. Grant Purpose. This grant shall be used exclusively for the "Olympia Theater Facade Restoration, Phase I," the public purpose for which these fiords were appropriated.. a) The Grantee shall perform the following Scope of Work: Grant funds will be used to restore the fagade of the Olympia Theater and Office Building, located in Miami, Miami -Dade County, as the first phase of a multiple phase project. This phase of the project entails the development of a complete set of construction documents suitable for bid and permitting purposes for the restoration of the structural system and. the exterior fagade of the building, including preliminary evaluation of existing conditions, stabilization work, research of historic documentation, and preparation of construction drawings and a bid package. Grant funds will also be used for grant administration and project management. All tasks associated with this project, as outlined in the Project Description (see Attachment A), will be completed by June 30, 2019. b) The Grantee agrees to provide the following Deliverables and Performance Measures related to the Scope of Work for payments to be awarded.. Payment 1: Payment 1 will be fixed price advance in the amount of 25 percent of the grant award. Payment 2, Deliverable/Task 1: • Payment 2 will be fixed price in the amount of 25 percent of the grant award.. The Grantee will have completed. at least 30 percent of the project prior to this payment. The performance measure documenting satisfactory completion of Deliverables will be a completed Application and Certificate for Payment Grant Award Ad eenrent (Form GAA001), Effective 05/2017 Rule 1A-39.001, Florida Administrative Code (AIA Document G702) and Schedule of Contract Values (AIA Document G703), or its equivalent, showing at least 30 percent of the project completed. Payment 3, Deliverable/Task 2: • Payment 3 will be fixed price in the amount of 25 percent of the grant award.. The Grantee will have completed at least 60 percent of the project prior to this payment. The performance measure documenting satisfactory completion of Deliverables will be a completed Application and Certificate for Payment (AIA Document G702) and Schedule of Contract Values (AIA Document G703), or its equivalent, showing at least 60 percent of the project completed.. Payment 4, Deliverable/Task 3: • Payment 4 will be fixed price in the amount of 25 percent of the grant award. The Grantee will have completed 100 percent of the Project prior to this payment. The performance measure documenting satisfactory completion of Deliverables will be a completed Application and Certificate for Payment (AIA Document G702), Schedule of Contract Values (AIA Document G703), and. a Certificate of Substantial Completion (AIA Document G704), or its equivalent, showing 100 percent of the Project completed, including all retainage amounts paid. The performance measure documenting satisfactory completion of Deliverables will also be submission and acceptance of a Final Project Progress Report that certifies that all project grant fiends and. required match have been expended in the way here agreed upon and the Project has been closed out. In addition, a Single Audit Foran shall be completed by the Grantee and submitted along with the Final Progress Report prior to final payment. c) The Grantee has provided an Estimated Project Budget based upon reasonable expenditures projected to accomplish the Grantee's Scope of Work and Deliverables for fiscal years 2017-2019. The Budget provides details of how grant funds will be spent and all expenditures shall be in accordance with this budget (which is incorporated as part of this Agreement and entitled Attachment B). 2. Length of Agreement. This Agreement shall begin on July 1, 2017, and shall end June 30, 2019, unless terminated in accordance with the provisions of Section 33 of this Agreement. Contract extensions will not be granted unless Grantee is able to provide substantial written justification and. the Division approves such extension. The Grantee's written request for such extension must be submitted to the Division no later than thirty (30) days prior to the termination date of this Agreement. 3. Contract Administration. The parties are legally bound by the requirements of this Agreement. Each party's contract manager, named below, will be responsible for monitoring its performance under this Agreement, and will be the official contact for each party. Any notice(s) or other communications in regard to this agreement shall be directed to or delivered to the other party's contract manager by utilizing the information below. Any change in the contact information below should be submitted in writing to the contract manager within 10 days of the change. 2 Grant Award Agreement (Forra GAA001), Effective 05/2017 Rule 1A-39.001, Florida Adrninisn-a ive Code For the Division of Historical Resources: Kechia Herring Florida Department of State R.A. Gray Building 500 South Bronough Street Tallahassee, FL 32399 Phone: 850.245.6310 Email: Kechia.Herring@DOS.MyFlorida.com For the Grantee: Contact: Robert Geitner Address: 169 E. Flagler Street, 9837, Miami, FL 33131 Phone: 305.374.2444 Email: rgeitner@olympiatheater.org 4. Grant Payments. All non -advance grant payments are requested by submitting a payment request, expenditure log and documentation that the deliverable has been completed. The total grant award shall not exceed the Grant Award Amount, which shall be paid by the Division in consideration for the Grantee's minimum performance as set forth by the terms and conditions of this Agreement. The grant payment schedule is outlined below: a) The first payment will be a fixed price of 25 percent advance of the Grant Award Amount. b) The second payment will be a fixed price of 25 percent of the Grant Award. Amount. Payment will be made in accordance with the completion of the Deliverables. c) The third payment will be a fixed price of 25 percent of the Grant Award Amount. Payment will be made in accordance with the completion of the Deliverables. d) The fourth payment will be a fixed price of 25 percent of the Grant Award Amount. Payment will be made in accordance with the completion of the Deliverables. 5. Electronic Payments. The Grantee can choose to use electronic funds transfer (EFT) to receive grant payments. All grantees wishing to receive their award through electronic funds transfer must submit a Direct Deposit Authorization form to the Florida Department of Financial Services. If EFT has already been set up for the organization, the Grantee does not need. to submit another authorization form unless the organization has changed bank accounts. To download this form visit http://www.myfloridacfo.com/Division/AA/Forins/DFS-A1-26E.pdf. This page also includes tools and information that allow you to check payment status. Grant Award Agreement (Form GAA001), Effective 05/2017 Rule lA-39.001, Florida Administrative Code 6. Florida Substitute Form W-9. A completed Substitute Form W-9 is required from any entity that receives a payment from the State of Florida that may be subject to 1099 reporting. The Department of Financial Services (DFS) must have the correct Taxpayer Identification Number (TIN) and other related information in order to report accurate tax information to the Internal Revenue Service (IRS). To register or access a Florida Substitute Form W-9 visit http://www.flvendor.myfloridacfo.coin/. A copy of the Grantee's Florida Substitute Form W-9 must be submitted to the Division in advance of or with the executed Agreement. 7. Amendment to Contract. Either party may request modification of the provisions of this Agreement by contacting the Division to request an Amendment to the Contract. Changes which are agreed upon shall be valid only when in writing, signed by each of the parties, and attached to the original of this Agreement. If changes are implemented without the Division's written approval, the organization is subject to noncompliance, and the grant award is subject to reduction, partial, or complete refund to the State of Florida and termination of this agreement. 8. Financial Consequences. The Department shall apply the following financial consequences for failure to perform the minimum level of services required by this Agreement in accordance with Sections 215.971 and 287.058, Florida Statutes. a) The frill amount of the first payment (fixed price advance in the amount of 25 percent of the grant award) will be returned to the Division if any Deliverables (Deliverable 1, 2, or 3) are not satisfactorily completed. b) Second payment will be withheld for failure to complete services as identified in the Scope of Work and Deliverables or to submit a Grant Funds Expenditure Log demonstrating appropriate use of state funds. c) Third payment will be withheld for failure to complete services as identified. in the Scope of Work and Deliverables or to submit a Grant Funds Expenditure Log demonstrating appropriate use of state funds. d) Fourth payment will be withheld. for failure to complete services as identified in the Scope of Work and Deliverables or to submit a Grant Funds Expenditure Log demonstrating appropriate use of state fiends. If the Grantee has spent less than the Grant Award Amount in state fiends to complete the Scope of Work, the Fourth Payment will be reduced by an arnouurt equal to the difference between spent state dollars and the Grant Award Amount. e) The Division may reduce individual payments by 10 percent if the completed Deliverable does not meet the Secretary of Interior's Standards and. Guidelines or other industry standards applicable to the Scope of Work for the Project. The Division shall reduce total grant fiunding for the Project in direct proportion to match contributions not met by the end of the grant period. This reduction shall be calculated by dividing the actual match amount by the required. match amount indicated in the Agreement and multiplying the product by the Grant Award Amount indicated in the Agreement. Pursuant to Section 17, Grantee shall refund to the Division any excess fimds paid out prior to a reduction of total grant ffind.ing. Grant Award Agreement (Forra GAA001), Effective 0513017 Rule 1A-39.001, Florida.4drninisercrtive Code 9. Additional Special Conditions. Development Projects. a) All project work must be in compliance with the Secretary of the Interior's Standards and Guidelines available online at www.nps.gov/tps/standards.htn-1. b) The Grantee shall provide photographic documentation of the restoration activity. Guidelines regarding the photographic documentation is available online at www.flherita,go.coin/grants/categories/smalhuatching.cfm. c) Architectural Services 1. All projects shall require contracting for architectural/engineering services. 2. The Grantee may request a waiver of this requirement from the Division if they believe that the architectLl:ral/engineering services are not needed. for the Project. The Division shall make a reconnnendation to the Grantee after review of the proposed work. d) Architectural Documents and Constriction Contracts The Grantee shall submit the architectural services contract to the Department for review and. approval prior to final execution. In addition, pursuant to Section 267.031(5)(i), Florida Statutes, the Grantee shall submit architectural planning documents to the Department for review and approval at the following stages of development: 1. Upon completion of schematic design; 2. Upon completion of design development and outline specifications; and 3. Upon completion of 100% construction documents and project manual, prior to execution of the constriction contract. e) For the construction phase of the Project, in addition to the review submissions indicated above, a copy of the constriction contract must be submitted to the Department for review and approval prior to final execution. Department review and approval of said contracts shall not be construed as acceptance by or imposition upon the Department of any financial liability in connection with said contracts. f) For projects involving ground disturbance (examples include: historic building or structure relocation, grading and site work, installation of sewer and water lines, subgrade foundation repairs or damp proofing, construction of new foundations and installation of landscape materials), the Grantee shall ensure that the following requirements are included in all contracts for architectural and engineering services: 1. Ground. disturbance around. historic buildings or elsewhere on the site shall be minimized, thus reducing the possibility of damage to or destruction of significant archaeological resources. Grant Award Agreement (Form GAA001), Effective 05/2017 Rule 1A-39.001, Florida Administrative Code 2. If an archaeological investigation of the Project site has not been completed, the architect or engineer shall contact the Department for assistance in determining the actions necessary to evaluate the potential for adverse effects of the ground disturbing activities on significant archaeological resources. 3. Significant archaeological resources shall be protected and preserved in place whenever possible. Heavy machinery shall not be allowed in areas where significant archaeological resources may be disturbed or damaged. 4. When preservation of significant archaeological resources in place is not feasible, a mitigation plan shall be developed in consultation with and approved by the Department's Compliance Review Section (contact information available online at www.flheritaae.com). The mitigation plan shall be implemented wider the direction of an archaeologist meeting the Secretary of the Interior,s'Professional Qualifcation Standards for Archeology. 5. Documentation of archaeological investigation and required mitigation actions shall be submitted to the Compliance Review Section for review and approval. This documentation shall conform to the Secretary of the -Interior's Standards f )r Archaeological Documentation, and the reporting standards of the Compliance Review Section set forth in Charter IA -46, Florida Administrative Code. 10. Acknowledgement of Grant Funding. Pursuant to Section 286.25, Florida Statutes, in publicizing, advertising, or describing the sponsorship of the program the Grantee shall include the following statement: a) "This project is sponsored in part by the Department of State, Division of Historical Resources and the State of Florida." Any variation in this language must receive prior approval in writing by the Department. b) All site-specific projects must include a Project identification sign, with the aforementioned language, that must be placed on site. The cost of preparation and erection of the Project identification sign are allowable project costs. Routine maintenance costs of project signs are not allowable project costs. A photograph of the aforementioned sign must be submitted to the Division as soon as it is erected. 11. Encumbrance of Funds. The Grantee shall execute a binding contract for at least a part of the Scope of Work by September 30, 2017, except as allowed below. a) Extension of Encumbrance Deadline: The encumbrance deadline indicated above may be extended by written approval of the Division. To be eligible for this extension, the Grantee must demonstrate to the Division that encumbrance of grant funding and the required match by binding contract(s) is achievable by the end. of the requested extended encumbrance period. The Grantee's written request for extension of the encumbrance deadline must be submitted to the Department no later than fifteen (15) days prior to the encumbrance deadline indicated above. The maximum extension of the encumbrance period shall be sixty (64) days. 6 Grant Award Agreement (Fo ni GAA001), Effective 05/2017 Rule 1A-39.001, Florida Administrative Code b) Encumbrance Deadline Exception: For projects not involving contract services the Grantee and the Department shall consult on a case-by-case basis to develop an acceptable encumbrance schedule. 12. Grant Reporting Requirements. The Grantee must submit the following reports to the Division. All reports shall document the completion of any deliverables/tasks, expenses and activities that occurred. during that reporting period. All reports on grant progress will be submitted online through www. dos grants.com. a) First Project Progress Report is due by October 31, 2017, for the period ending September 30, 2017. b) Second Project Progress Report is due by January 31, 2018, for the period ending December 31, 2017. c) Third Project Progress Report is due by April 30, 2018, for the period ending March 31, 2018. d) Fourth Project Progress Report is due by July 30, 2018, for the period ending June 30, 2018. e) Fifth Project Progress Report is due by October 31, 2018, for the period ending September 30, 2018. f) Sixth Project Progress Report is due by January 3.1, 2019, for the period ending December 31, 2018. g) Seventh Project Progress Report is due by April 30, 2019, for the period. ending March 31, 2019. h) Final Report. The Grantee must submit a Final Report to the Division by July 30, 2019 for the period ending June 30, 2019. 13. Matching Funds. The Grantee is required. to provide a $50,000 or 50% match of the grant amount request, whichever is greater unless exempted, as described in this section. Of the required match, a minimum 25% of the snatch must be a cash match. The remaining match may include in-kind services, volunteer labor, donated, materials, and additional cash. Projects located in Rural Economic Development Initiative (REDI) counties or communities that have been designated. in accordance with Sections 288.0656 and. 288.06561, Korida Statutes, may request a reduction of the match amount. Certified Local Government (CLG) Applicant Organizations and Main Street Program Applicant Organizations no dot require a match. Additionally, Special Statewide Solicitation Projects do not require a match. 14. Grant Completion Deadline. The grant completion deadline is June 30, 2019 The Grant Completion Deadline is the date when all grant and matching fiunds have been paid out and expended in accordance with the work described in the Scope of Work, detailed in the Estimated Project Budget. If the Grantee finds it necessary to request an extension of the 7 Grant Award Agreement (Form GAA001), Effective 05/2017 Rule 1A-39.001, Florida Administrative Code Grant Completion Deadline, the extension may not exceed one hundred and. twenty (120) days, unless the Grantee can demonstrate extenuating circumstances as described in Section 15 of this Agreement. 15. Extension of the Grant Completion Deadline. An extension of the completion date must be requested at least thirty (30) days prior to the end of the Grant Period and may not exceed one hundred and twenty (120) days, unless the Grantee can clearly demonstrate extenuating circumstances. An extenuating circumstance is one that is beyond the control of the Grantee, and one that prevents timely completion of the Project such as a natural disaster, death or serious illness of the individual responsible for the completion of the Project, litigation related to the Project, or failure of the contractor or architect to provide the services for which they were contracted to provide. An extenuating circumstance does not include failure to read or understand the administrative requirements of a grant or failure to raise sufficient matching funds. Prior written approval is required for extensions. 16. Non -allowable Grant Expenditures. The Grantee agrees to expend all grant fiends received under this agreement solely for the purposes for which they were authorized and appropriated. Expenditures shall be in compliance with the state guidelines for allowable Project costs as outlined in the Department of Financial Services' Reference Guide for State Expenditures, which are incorporated. by reference and are available online at http://www.myfloridacfo.cam/aadir/reference guide/. The following categories of expenditures are non -allowable for expenditure of grant funds and. as contributions to required snatch: c) Expenditures for work not included. in the Scope of Work of the executed Grant Award Agreement; d) Costs of goods and. services not procured. in accordance with procurement procedures set forth in the Grant Award Agreement; c) Expenses incurred or obligated prior to or after the Grant Period; d) Expenditures for work not consistent with the applicable historic preservation standards as outlined in the Secretary of the Interior's Guidelines, http://www.nps.gov/tps/standards.htiii and pps.gov/history/local-law/arch_stnds_O.htm or applicable industry standards; e) Furniture and Equipment. (a) Expenditures for furniture and equipment such as features not physically attached to a structure, including but not limited to: desks, tables, chairs, area rugs, window treatments, computers, kitchen appliances, portable lighting fixtures, and components of portable sound or projection systems, unless specific prior approval has been granted by the Division. (b) If special equipment is required for completion of the Project and said equipment is included in the Scope of Work for the Project as an eligible grant expense, it shall be rented for the grant term, unless it can be shown that acquiring the equipment is cheaper than renting the equipment and approval has been provided by the Division. If the value of special equipment is to be used as a match contribution, the value of the match contribution shall be limited to the cost of rental for the Grant Period at the market rate for such rental in the region; Grant Award Agreement (Form GAA001), Effective 05/2017 Rule 1A-39.001, Flavida Administrative Code f) Expenses associated with lobbying or attempting to influence federal, state, or local legislation, the judicial branch, or any state agency; g) Private entertainment, food, beverages, plaques, awards, or gifts;, h) Costs or value of donations or In-kind Contributions not documented in accordance with the provisions of the Grant Award Agreement; i) Indirect costs including but not limited to Grantee overhead, management expenses, general operating costs and. other costs that are not readily identifiable as expenditures for the materials and services required to complete the work identified in the Scope of Work in the Grant Award Agreement. Examples of indirect costs include: rent/mortgage, utilities, janitorial services, insurance, accounting, non -grant related administrative and clerical staffing, and fiind.raising activities; J) Costs for projects having as their primary purpose the fulfillment of federal or state historic preservation regulatory requirements, specifically, costs of consultation and mitigation measures required under Section 106 of the National Historic Preservation Act of 1966, as amended through 2006, or under Section 267.031, F.S.; k) Projects which are restricted to private or exclusive participation, which shall include restricting access on the basis of sex, race, color, religion, national origin, disability, age, pregnancy, handicap, or marital status; 1) Project administrative expenditures such as expenditures that are directly attributable to management of the grant -assisted Project and meeting the reporting and associated requirements of the Grant Award. Agreement, whether grant expenditures or match contributions, which in aggregate exceed 5% of the grant award amount; m) Grantee operational support (i.e., organization salaries not related to grant activities; travel expenditure; or supplies); n) Vehicular circulation (drives) and parking (Exception: provision of code -required handicapped parking pad); o) Sidewalks, landscape features, planting, irrigation systems and site lighting (Exception: sidewalk required to link code -required handicapped parking pad to the accessible entry, planting required to halt erosion, and limited site lighting required for security, if included in the Scope of Work); p) Capital improvements to non -historic properties; q) Capital improvements to the interior of religious properties (Exception: repairs to primary elements of the structural system. Examples include: foundation repairs, repairs to columns, load. bearing wall framing, roof framing, masonry repairs, and window and exterior door repairs); Grant Award Agreement (Form GAA001), Effective 05/2017 Rule 1A-39.001, Florida Administm ive Code r) Code -required accessibility improvements for religious properties; s) Insurance costs (Exception: costs for builder's risk, workers' compensation and contractor's liability insurance); and t) Travel expenditures, including those of personnel responsible for items of work approved by the Division, administrative personnel, contracted or subcontracted employees, either for purposes of work on-site or research off-site. 17. Unobligated and Unearned Funds and Allowable Costs. In accordance with Section 215.971, Florida Statutes, the Grantee shall refund to the State of Florida any balance of unobligated funds which has been advanced or paid. to the Grantee. In addition, funds paid in excess of the amount to which the recipient is entitled under the terms and conditions of the agreement must be refunded to the state agency. Further, the recipient may expend. funds only for allowable costs resulting from obligations incurred during the specified agreement period. Expenditures of state financial assistance must be in compliance with the laws, rules, and regulations applicable to expenditures of State finds, including, but not limited. to, the Reference Glide for State Expenditures. 18. Repayment. All refinds or repayments to be made to the Department under this agreement are to be made payable to the order of the "Department of State" and mailed directly to the following address: Florida Department of State, Attention: Yasha Rodriguez, Grants Program Supervisor, Division of Historical Resources, 500 South Bronough Street Tallahassee, FL 32399. In accordance with Section 215.34(2), Florida Statutes, if a check or other draft is returned to the Department for collection, Grantee shall pay to the Department a service fee of $15.00 or five percent (5%) of the face amount of the returned check or draft, whichever is greater. 19. Single Audit Act. Each Grantee, other than a Grantee that is a State agency, shall submit to an audit pursuant to Section 215.97, Florida Statutes. See Attachment C for additional information regarding this requirement. 20. Retention of Accounting Records. Financial records, supporting documents, statistical records, and all other records including electronic storage media pertinent to the Project shall be retained for a period of five (5) years after the close out of the grant. If any litigation or audit is initiated, or claim made, before the expiration of the five-year period., the records shall be retained until the litigation, audit, or claim has been resolved. 21. Obligation to Provide State Access to Grant Records. The Grantee must make all grant records of expenditures, copies of reports, books, and related documentation available to the Division or a duly authorized representative of the State of Florida for inspection at reasonable times for the purpose of making audits, examinations, excerpts, and transcripts. 22. Obligation to Provide Public Access to Grant Records. The Division reserves the right to unilaterally cancel this Agreement in the event that the Grantee refuses public access to all documents or other materials made or received. by the Grantee that are subject to the provisions of Chapter 119, Florida Statutes, known as the Florida Public Records Act. The 10 Grant Award Agreement (Forni GAAOOI), Effective 05/2017 Rule 1A-39.001, Florida Administr afitie Code Grantee must immediately contact the Division's Contract Manager for assistance if it receives a public records request related to this Agreement. 23. Investment of Funds Received But Not Paid Out. The Grantee may temporarily invest any or all grant fluids received but not expended, in an interest bearing account pursuant to Section 216.181(16)(b), Florida Statutes. Interest earned on such investments should be returned. to the Division quarterly, except that interest accrued less than $100 within any quarter may be held until the next quarter when the accrued. interest totals more than $100. All interest accrued and not paid to the Division, regardless of amount, must be submitted with the Grantee's final Progress Report at the end of the Grant Period. 24. Noncompliance with Grant Requirements. Any applicant that has not submitted required. reports or satisfied other administrative requirements for other Division of Historical Resources grants or grants from any other Florida Department of State (DOS) Division will be in noncompliance status and subject to the DOS Grants Compliance Procedure. Grant compliance issues must be resolved before a grant award agreement may be executed, and before grant payments for any DOS grant may be released. 25. Accounting Requirements. The Grantee must maintain an accounting system that provides a complete record of the use of all grant funds as follows: a) The accounting system must be able to specifically identify and provide audit trails that trace the receipt, maintenance, and expenditure of state funds; b) Accounting records must adequately identify the sources and application of funds for all grant activities and must classify and identify grant funds by using the same budget categories that were approved in the grant application. If Grantee's accounting system accumulates data in a different format than the one in the grant application, subsidiary records must document and reconcile the amounts shown in the Grantee's accounting records to those amounts reported to the Division. c) An interest-bearing checking account or accounts in a state or federally chartered institution may be used for revenues and expenses described in the Scope of Work and detailed in the Estimated Project Budget. d) The name of the account(s) must include the grant award number; e) The Grantee's accounting records must have effective control over and accountability for all funds, property, and other assets; and f) Accounting records must be supported by source documentation and be in sufficient detail to allow for a proper pre -audit and post -audit (such as invoices, bills, and canceled checks). 26. Availability of State Funds. The State of Florida's performance and obligation to pay a ider this Agreement are contingent upon an annual appropriation by the Florida Legislature, or the United. States Congress in the case of a federally funded. grant. In the event that the state or federal funds upon which this Agreement is dependent are withdrawn, this Agreement will be It Grant Award Agreement (Forni GAA001), Effective 05/2017 Rule 1A-39.001, Florida Administrative Code automatically terminated and the Division shall have no further liability to the Grantee, beyond those arnounts already released prior to the termination date. Such termination will not affect the responsibility of the Grantee under this Agreement as to those funds previously distributed. In the event of a state revenue shortfall, the total grant may be reduced accordingly. 27. Independent Contractor Status of Grantee. The Grantee, if not a state agency, agrees that its officers, agents and. employees, in performance of this Agreement, shall act in the capacity of independent contractors and not as officers, agents, or employees of the state. The Grantee is not entitled to accrue any benefits of state employment, including retirement benefits and any other rights or privileges connected with employment by the State of Florida. 28. Grantee's Subcontractors. The Grantee shall be responsible for all work performed and all expenses incurred. in connection with this Agreement. The Grantee may subcontract, as necessary, to perforin the services and to provide commodities required by this Agreement. The Division shall not be liable to any subcontractor(s) for any expenses or liabilities incurred under the Grantee's subcontract(s), and the Grantee shall be solely liable to its subcontractor(s) for all expenses and. liabilities incurred under its subcontract(s). The Grantee must take the necessary steps to ensure that each of its subcontractors will be deemed to be "independent contractors" and will not be considered or permitted to be agents, servants, joint ventures, or partners of the Division. 29. Liability. The Division will not assume any liability for the acts, omissions to act, or negligence of, the Grantee, its agents, servants, or employees; nor may the Grantee exclude liability for its own acts, omissions to act, or negligence, to the Division. a) The Grantee shall be responsible for claims of any nature, including but not limited to injury, death, and. property damage arising out of activities related to this Agreement by the Grantee, its agents, servants, employees, and subcontractors. The Grantee, other than a Grantee which is the State or the State's agencies or subdivisions, as defined in Section 768.2 8, Florida Statutes, shall indemnify and hold the Division harmless from any and. all claims of any nature and shall investigate all such claims at its own expense. If the Grantee is governed. by Section 768.28, Florida Statutes, it shall only be obligated in accordance with that Section. b) Neither the state nor any agency or subdivision of the state waives any defense of sovereign imrmunity, or increases the limits of its liability, by entering into this Agreement. c) The Division shall not be liable for attorney fees, interest, late charges or service fees, or cost of collection related to this Agreement. d) The Grantee shall be responsible for all work performed and all expenses incurred in connection with the Project. The Grantee may subcontract as necessary to perform the services set forth in this Agreement, including entering into subcontracts with vendors for services and. commodities; and provided that it is understood by the Grantee that the Division shall not be liable to the subcontractor for any expenses or liabilities incurred 12 Grant Award Agreement (Fenn GAA001), Effective 0512017 Rule 1A-39.001, Florida AdminimutiveCode under the subcontract and that the Grantee shall be solely liable to the subcontractor for all expenses and liabilities incurred under the subcontract. 30. Strict Compliance with Laws. The Grantee shall perform all acts required. by this Agreement in strict conformity with all applicable laws and regulations of the local, state and federal law. 31. No Discrimination. The Grantee may not discriminate against any employee employed under this Agreement, or against any applicant for employment because of race, color, religion, gender, national origin, age, pregnancy, handicap or marital status. The Grantee shall insert a similar provision in all of its subcontracts for services under this Agreement. 32. Breach of Agreement. The Division will demand the return of grant fil.nds already received, will withhold subsequent payments, and/or will terminate this agreement if the Grantee improperly expends and manages grant funds, fails to prepare, preserve or surrender records required by this Agreement, or otherwise violates this Agreement. 33. Termination of Agreement. a) Termination by the Division. The Division will terminate or end this Agreement if the Grantee fails to fiilfill its obligations herein. In such event, the Division will provide the Grantee a notice of its violation by letter, and shall give the Grantee fifteen (15) calendar days from the date of receipt to cure its violation. If the violation is not cured within the stated period, the Division will terminate this Agreement. The notice of violation letter shall be delivered to the Grantee's Contract Manager, personally, or mailed. to his/her specified address by a method that provides proof of receipt. In the event that the Division terminates this Agreement, the Grantee will be compensated for any work completed in accordance with this Agreement, prior to the notification of termination, if the Division deems this reasonable under the circumstances. Grant funds previously advanced and not expended on work completed in accordance with this Agreement shall be returned to the Division, with interest, within thirty (30) days after termination of this Agreement. The Division does not waive any of its rights to additional damages, if grant funds are returned under this Section. b) Termination for convenience. The Division or the Grantee may terminate the grant in whole or in part when both parties agree that the continuation of the Project would. not produce beneficial results conmmens-u ate with the fin-ther expenditure of fimds. The two parties will agree upon the termination conditions, including the effective date, and in the cause of partial terminations, the portion to be terminated. c) Termination by Grantee. The Grantee may unilaterally cancel the grant at any time prior to the first payment on the grant although the Department must be notified in writing prior to cancellation. After the initial payment, the Project may be ternlinated, modified, or amended by the Grantee only by mutual agreement of the Grantee and the Division. Request for termination prior to completion must fully detail the reasons for the action and the proposed disposition of the uncompleted. work. 13 Grant Award Agreement (Form GAAOO1), Effective 05/2017 Rule 1A-39.001, Florida Adtniniszrcrtive Cade 34. Preservation of Remedies. No delay or omission to exercise any right, power, or remedy accruing to either party upon breach or violation by either party under this Agreement, shall impair any such right, power or remedy of either party; nor shall such delay or omission be construed as a waiver of any such breach or default, or any sinular breach or default. 35. Non -Assignment of Agreement. The Grantee may not assign, sublicense nor otherwise transfer its rights, duties or obligations under this Agreement without the prior written consent of the Division, which consent shall not unreasonably be withheld. The agreement transferee must demonstrate compliance with the requirements of the Project. If the Division approves a transfer of the Grantee's obligations, the Grantee shall remain liable for all work performed and all expenses incurred in connection with this Agreement. In the event the Legislature transfers the rights, duties, and. obligations of the Division to another governmental entity pursuant to Section 20.06, Florida Statutes, or otherwise, the rights, duties, and. obligations under this Agreement shall be transferred. to the successor governmental agency as if it was the original party to this Agreement. 36. Required Procurement Procedures for Obtaining Goods and Services. The Grantee shall provide maximum open competition when procuring goods and services related to the grant - assisted project in accordance with Section 287.057, Florida Statutes. 37. Conflicts of Interest. The Grantee hereby certifies that it is cognizant of the prohibition of conflicts of interest described in Sections 112.311 through 112.326, Florida Statutes, and affirms that it will not enter into or maintain a business or other relationship with any employee of the Department of State that would violate those provisions. In addition, no Grantee official, employee, or consultant who is authorized in his or her official capacity to negotiate, make, accept, approve, or take part in decisions regarding a contract, subcontract, or other agreement in connection with a grant assisted project shall take part in any decision relating to such contract, subcontract or other agreement in which he or she has any financial or other interest, or in which his or her spouse, child., parent, or partner, or any organization in which he or she is serving as an officer, director, trustee, partner, or employee of which he or she has or is negotiating any arrangement concerning employment has such interest. Grantees shall avoid circumstances presenting the appearance of such conflict. Furthermore, the spouse, child, parent, or partner of an officer, director, trustee, partner, or employee of the Grantee shall not receive grant fiends, unless specifically authorized in writing by the General Counsel for the Department of State to avoid. a potential violation of those statutes. 38. Binding of Successors. This Agreement shall bind the successors, assigns and legal representatives of the Grantee and of any legal entity that succeeds to the obligations of the Division of Historical Resources. 39. No Employment of Unauthorized Aliens. The employment of unauthorized aliens by the Grantee is considered a violation of Section 274A (a) of the Immigration and Nationality Act. If the Grantee knowingly employs unauthorized. aliens, such violation shall be cause for unilateral cancellation of this Agreement. 14 Grant Award Agreement (Form GAA001), Effeetive 05/2017 Rule 1A-39.001, FloridaAdministrative Code 40. Severability. If any term or provision of the Agreement is found to be illegal and unenforceable, the remainder will remain in full force and effect, and such tern or provision shall be deemed stricken. 41. Americans with Disabilities Act. All programs and facilities related to this Agreement must meet the standards of Sections 553.501-553.513, Florida Statutes, and the Americans with Disabilities Act of 1990. 42. Governing Law. This Agreement shall be construed, performed, and enforced in all respects in accordance with the laws and rules of Florida. Venue or location for any legal action arising under this Agreement will be in Leon County, Florida. 43. Entire Agreement. The entire Agreement of the parties consists of the following documents: a) This Agreement b) Project Description (Attachment A) c) Estimated Project Budget (Attachment B) d) Single Audit Act Requirements and Exhibit I (Attachment C) 15 Grant Award Agreement (Form GAA001), Effective 05/2017 Rule 1A-39.001, Florida Administrative Code In acknowledgment of this grant, provided from funds appropriated in the FY 2017-2018 General Appropriation Act, I hereby certify that I have read this entire Agreement, and will comply with all of its requirements. Department of State: Grantee: C Dr. Timothy Parsons, Division Director Date Grant Award Agreement (Foran G AA001), Effective 05/2017 Rule IA -39.001, Florida Administrative Code By: Authorizing Official for the Grantee Typed name and title Date 16 ATTACHMENT A Project Description Grant fiords will be used to restore the approximately 29,400 square foot fagade of the Olympia Theater and Office Building, located in Miami, Miami -Dade County, as the first phase of a multiple phase project. This phase of the project entails the development of a complete set of construction documents suitable for bid and permitting purposes for the restoration of the structural system and the exterior fagade of the building, including preliminary evaluation of existing conditions, stabilization work, research of historic documentation, and preparation of construction drawings and a bid package. Grant fiinds will also be used for grant administration and project management. 17 Grant Award Agreement (Foran GAA001), Effective 05/2017 Rule 1 A-39.001, Florida .4dministrative Code ATTACHMENT B Estimated Project Budget Budget Grant Cash In Kind Item Description Funds Match Match Total Number 1 Preliminary Evaluation of $50,000 $125,000 $0 $175,000 Existing Conditions 2 Stabilization Work $0 $75,000 $0 $75,000 3 Research of Historic $40,000 $0 $15,000 $55,000 Documentation 4 Preparation of Construction $360,000 $640,000 $0 $1,000,000 Drawings and Bid. Package 5 Project Management $0 $0 $25,000 $2.5,000 6 Grant Administration $50,000 $0 $0 $50,000 7 Sign Acknowledging Grant $0 $0 $0 $0 Fund Assistance Total $500,000 $840,000 $40,000 $1,380,000 18 Grant Award Agreement (Form GAA001), Effective 05/2017 Rule 1A-39.001, Flovida _4dminisoydive Code ATTACHMENT C FEDERAL AND STATE OF FLORIDA SINGLE AUDIT ACT REQUIREMENTS AUDIT REQUIREMENTS The administration of resources awarded by the Department of State to the Grantee may be subject to audits and/or monitoring by the Department of State as described in this Addendum to the Grant Award Agreement. MONITORING In addition to reviews of audits conducted in accordance with 2 CFR 200.501 Section 215.97, Florida .Statittes, monitoring procedures may include, but not be limited to, on-site visits by Department of State staff, limited scope audits as defined by 2 CFR 2 §200.425, and/or other procedures. By entering into this agreement, the recipient agrees to comply and cooperate with any monitoring procedures/processes deemed appropriate by the Department of State. In the event the Department of State d.etennines that a limited scope audit of the recipient is appropriate, the recipient agrees to comply with any additional instructions provided by the Department of State staff to the recipient regarding such audit. The recipient firther agrees to comply and cooperate with any inspections, reviews, investigations, or audits deemed necessary by the Chief Financial Officer or Auditor General. AUDITS PART I: FEDERALLY FUNDED This part is applicable if the recipient is a State or local government or a non-profit organization as defined in 2 CFR 200.90, 200.64 & 200.70 as revised. 1. In the event that the recipient expends $750,000 for fiscal years ending after December 31, 2014 or more during the non -Federal entity's fiscal year in Federal awards in its fiscal year, the recipient must have a single or program -specific audit conducted in accordance with the provisions of 2CFR 200.501. Exhibit I to this agreement indicates Federal resources awarded through the Department of State. The determination of amounts of Federal awards expended should be in accordance with the guidelines established by 2 CFR 200.502. An audit of the recipient conducted by the Auditor General in accordance with the provisions of 2 CFR 200.514, as revised, will meet the requirement of this part. 2. In connection with the audit requirements addressed in Part I, paragraph 1, the recipient shall fulfill the requirements relative to auditee responsibilities as provided in 2 CFR 200.508. 3. If the recipient expends less than $750,000 for fiscal years ending after December 31, 2014 in Federal awards in its fiscal year, an audit conducted in accordance with the provisions of 2 CFR 200.501 is not required. In the event that the recipient expends less 19 Grant Award Agreement (Form GAA001), Effective 05/2017 Rule 1A-39.001, Florida _4dministrative Code than $750,000 for fiscal years ending after December 31, 2014 in Federal awards in its fiscal year and elects to have an audit conducted in accordance with the provisions of 2 CFR 200.501, the cost of the audit must be paid from non -Federal resources (i.e., the cost of such an audit must be paid from recipient resources obtained from other than Federal entities). (d) Exemption when Federal awards expended are less than $750, 000. A non -Federal entity that expends less than $750,000 during the non -Federal entity's fiscal year in Federal awards is exempt from Federal audit requirements for that year, except as noted in 2 CFR §200.503 Relation to other audit requirements, but records must be available for review or audit by appropriate officials of the Federal agency, pass-through entity, and Government Accountability Office (GAO). The Internet web addresses listed below will assist recipients in locating documents referenced in the text of this agreement and the interpretation of compliance issues. U.S. Government Printing Office www.ecfi•.gov PART II: STATE FUNDED This part is applicable if the recipient is a nonstate entity as defined by Section 215.97(2) (1), Florida Statutes 1. In the event that the recipient expends a total amount of state financial assistance equal to or in excess of $750,000 in any fiscal year of such recipient (for fiscal years ending after June 30, 2016), the recipient must have a State single or project -specific audit for such fiscal year in accordance with Section 215.97, Florida Statutes; applicable rules of the Executive Office of the Governor and the Chief Financial Officer; and Chapters 10.550 (local governmental entities) or 10.650 (nonprofit and for-profit organizations), Rules of the Auditor General. EXHIBIT 1 to this agreement indicates state financial assistance awarded through the Department of State by this agreement. In determining the state financial assistance expended in its fiscal year, the recipient shall consider all sources of state financial assistance, including state financial assistance received from the Department of State, other state agencies, and. other nonstate entities. State financial assistance does not include Federal direct or pass-through awards and. resources received by a nonstate entity for Federal program matching requirements. 2. In connection with the audit requirements addressed in Part II, paragraph 1, the recipient shall ensure that the audit complies with the requirements of Section 215.97(7), Florida Statutes. This includes submission of a financial reporting package as defined by Section 215.97(2) (d), Florida Statutes, and. Chapters 10.550 (local governmental entities) or 10.650 (nonprofit and for-profit organizations), Rules of the Auditor General. 3. If the recipient expends less than $750,000 in state financial assistance in its fiscal year (for fiscal years ending after June 30, 2016), an audit conducted in accordance with the provisions of Section 215.97, Florida Statutes, is not required. In the event that the recipient expends less than $750,000 in state financial assistance in its fiscal year ending after June 30, 2016 and elects to have an audit conducted in accordance with the provisions of Section 215.97, Florida Statutes, the cost of the audit must be paid from the nonstate entity's resources (i.e., 20 Grant Award Agreement (Foran GAA001), Effective 05/2017 Rule 1A-39.001, Florida Administra live Code the cost of such an audit must be paid from the recipient's resources obtained from other than State entities). The Internet web addresses listed below will assist recipients in locating documents referenced in the text of this agreement and the interpretation of compliance issues. State of Florida Department Financial Services (Chief Financial Officer) http://www.fldfs, coin/ State of Florida Legislature (Statutes, Legislation relating to the Florida Single Audit Act) htlp://www.leiz.state.fl.us/ PART III: REPORT SUBMISSION Copies of reporting packages for audits conducted in accordance with OMB Circular A- 133, as revised, and required by PART I of this agreement shall be submitted, when required by Section .320 (d), OMB Circular A-133, as revised, by or on behalf of the recipient directly to each of the following: A. The Department of State at each of the following addresses: Office of Inspector General Florida Department of State R. A. Gray Building, Room 114A 500 South Bronough St. Tallahassee, FL 32399-0250 B. The Federal Audit Clearinghouse designated in OMB Circular A-133, as revised. (the number of copies required by Sections .320 (d)(1) and (2), OMB Circular A-133, as revised, should be submitted. to the Federal Audit Clearinghouse), at the following address: Federal Audit Clearinghouse Bureau of the Census 1201 East 10th Street Jeffersonville, IN 47132 C. Other Federal agencies and pass-through entities in accordance with Sections .320 (e) and (f), OMB Circular A-133, as revised. 2. Copies of financial reporting packages required by PART II of this agreement shall be submitted by or on behalf of the recipient directly to each of the following: A. The Department of State at each of the following addresses: 21 Grant Award Agreement (Form GAA001), Effective 05/2017 Rule 1A-39.001, Florida Administrative Code Office of Inspector General Florida Department of State R. A. Gray Building, Room 114A 500 South Bronough St. Tallahassee, FL 32399-0250 B. The Auditor General's Office at the following address: Auditor General's Office Room 401, Pepper Building 111 West Madison Street Tallahassee, Florida 32399-14.50 Any reports, management letter, or other information required to be submitted. to the Department of State pursuant to this agreement shall be submitted timely in accordance with OMB Circular A-133, Florida Statutes, and Chapters 10.550 (local governmental entities) or 10.650 (nonprofit and. for-profit organizations), Rules of the Auditor General, as applicable. 4. Recipients, when submitting financial reporting packages to the Department of State for audits done in accordance with OMB Circular A-133 or Chapters 10.550 (local governmental entities) or 10.650 (nonprofit and. for-profit organizations), Rules of the Auditor General, should indicate the date that the reporting package was delivered to the recipient in correspondence accompanying the reporting package. PART V: RECORD RETENTION The recipient shall retain sufficient records demonstrating its compliance with the terms of this agreement for a period of five years from the date the audit report is issued, and shall allow the Department of State, or its designee, CFO, or Auditor General access to such records upon request. The recipient shall ensure that audit working papers are made available to the Department of State, or its designee, CFO, or Auditor General upon request for a period of at least three years from the date the audit report is issued., unless extended in writing by the Department of State. 22 Grant Award Agreement (Forni GAA001), Effective 05/2017 Rule IA -39.001, Florido Adminisrraiive Code EXHIBIT —1 FEDERAL RESOURCES AWARDED TO THE RECIPIENT PURSUANT TO THIS AGREEMENT CONSIST OF THE FOLLOWING: Not applicable. COMPLIANCE REQUIREMENTS APPLICABLE TO THE FEDERAL RESOURCES AWARDED PURSUANT TO THIS AGREEMENT ARE AS FOLLOWS: Not applicable. STATE RESOURCES AWARDED TO THE RECIPIENT PURSUANT TO THIS AGREEMENT CONSIST OF THE FOLLOWING: MATCHING RESOURCES FOR FEDERAL PROGRAMS: Not applicable. SUBJECT TO SECTION 215,97, FLORIDA STATUTES: Florida Department of State Historic Preservation Grants; CSFA Number 45.032. Award Amount: $500,000 COMPLIANCE REQUIREMENTS APPLICABLE TO STATE RESOURCES AWARDED PURSUANT TO THIS AGREEMENT ARE AS FOLLOWS: The compliance requirements of this state project may be found in Part Four (State Project Compliance Requirements) of the State Projects Compliance Supplement located at https://apps.fldfs.conl/fsaa/. 23 Grant Award Agreement (Foran GAA001), Effective 05/2017 Rule 1A-39.001, Florida.ldministrative Code