HomeMy WebLinkAboutRequest for QualificationsREQUEST FOR QUALIFICATIONS
MISCELLANEOUS LANDSCAPE ARCHITECTURAL SERVICES
RFQ No.: 12-13-019
ISSUE DATE
FRIDAY, MARCH 1, 2013
ADDITIONAL INFORMATION & CLARIFICATION DEADLINE
FRIDAY, MARCH 22, 2013
@ 5:00 P.M.
RESPONSE SUBMISSION DUE DATE, TIME & LOCATION
MONDAY, APRIL 1, 2013
@ 2:00 P.M.
CITY OF MIAMI
OFFICE OF THE CITY CLERK
CITY HALL
3500 PAN AMERICAN DRIVE, 1ST FLOOR
MIAMI, FLORIDA 33133
CONTACT
MARCIA LOPEZ
CAPITAL IMPROVEMENTS PROGRAM
CITY OF MIAMI
444 SW 2ND AVENUE, 8TH FLOOR
MIAMI, FLORIDA 33130
FAx:305.416.2153 EMAIL: MLOPEZ@MIAMIGOV.COM
TABLE OF CONTENTS
PUBLICNOTICE................................................................................................................ Pg. 2
SECTION 1
INTRODUCTION TO REQUEST FOR QUALIFICATION (RFQ)............................................. Pg. 4
SECTION 2
RFQ SCOPE OF SERVICE .............................
SECTION 3
RFQ GENERAL CONDITIONS ......................
SECTION 4
INSTRUCTIONS FOR SUBMITTING A RESPONSE.
SECTION 5
INFORMAL EVALUATION/ SELECTION PROCESS
...................................................... Pg. 10
........................................................... Pg. 12
.................... I........................... Pg. 17
SECTION 6
SUPPLEMENTAL RFQ RESPONSE FORMS .............................
2
...... I ... ... I ................. Pg. 24
.................. Pg. 26
City ®f Miami
CITY OF MIAMI
REQUEST FOR QUALIFICATIONS ("RFQ")
Miscellaneous Landscape Architectural Services
RFQ NO: 12-13-019
Completed Responses must be delivered to the Office of the City Clerk, City Hall, 3500 Pan
American Drive, 1St Floor, Miami, Florida 33133 by 2:00 PM, on Monday, April 1, 2013
("Response Submission Date"). Any Responses received after the above date and time or
delivered to a different address or location will not be considered.
RFQ documents may be obtained on or after Friday, March 1, 2013 from the City of Miami,
Capital Improvements Program (CIP) webpage at:
www.miamigov,com/capitalimprovements/pages/ProcurementOpportunities/Default.asp. It is the
sole responsibility of all firms to ensure the receipt of any addendum(s) and it is definitely
recommended that firms periodically check the CIP webpage for updates and the issuance of
addenda.
The City of Miami reserves the right to accept any Responses deemed to be in the best interest of
the City, to waive any minor irregularities, omissions, and/ or technicalities in any Responses, or to
reject any or all Responses, and to re -advertise for new Responses, in accordance with the
applicable sections of the Solicitation Documents, City Code and State Statutes.
THIS SOLICITATION IS SUBJECT TO THE "CONE OF SILENCE" IN ACCORDANCE WITH
SECTION 18-74 OF THE CITY CODE.
DP: 009142
SECTION 1
Johnny Martinez, P.E., City Manager
1.0 INTRODUCTION TO REQUEST FOR QUALIFICATIONS
1.1 INVITATION
Thank you for your interest in this Request for Qualifications ("RFQ"). The City of
Miami (the "City"), through its Capital Improvements Program ("CIP") invites
responses ("Responses") which offer to provide the services described in Section
2.0: "Scope of Services." This RFQ is being issued pursuant to Florida Statute
287.055: the "Consultants' Competitive Negotiation Act." All references to Florida
Statutes, City Codes and other laws/ regulations will be interpreted to include "as
amended from time to time". All references to approvals or decisions by the City
in this RFQ, when no other contrary expression is used, will be interpreted to
mean the City Manager.
1.2 AGREEMENT TERMS AND CONDITIONS
The Respondents selected to provide the services requested herein (the
"Successful Respondents") shall be required to execute a Professional
Services Agreement ("Agreement") with the City in substantially the same form
as the Agreement included as part of the RFQ. Please note: the terms
Respondent(s) and Proposer(s) are used interchangeably in connection with this
RFQ.
1.3 SUBMISSION OF RESPONSES
Sealed written Responses must be received by the Capital Improvements
Program no later than the date, time and at the location indicated in the Public
Notice on page 2, above, and on the cover of this RFQ in order to be responsive.
Faxed documents are not acceptable. One (1) original and seven (7) bound
copies plus one (1) copy in digital form (on CD-ROM in pdf format), of your
Response and sets of Response forms must be returned to the City or your
Response may be disqualified.
1.4 PRE -SUBMITTAL CONFERENCE
Capital Improvements Program has not scheduled a pre -submittal conference for
this RFQ.
1.5 CONE OF SILENCE
Pursuant to Section 18-74 of the City of Miami Code (Ordinance No. 12271), a
"Cone of Silence" is imposed upon this RFQ.
Written communications may be in the form of fax, mail or e-mail to Marcia Lopez,
Capital Improvements Program, at 444 SW 2nd Avenue, 8t" Floor, Miami, FL
33130, Fax 305-416-2153, e-mail mlopezp_miamigov.com with a copy to the
Office of the City Clerk to Miriam Arcia at marcia@miamigov.com.
4
Respondents are hereby cautioned not to contact any member of the Evaluation
Committee or any staff (except as provided herein) regarding this RFQ until such
time as the Cone of Silence is lifted. Failure to abide by this condition of the RFQ
shall be cause for rejection of your Response.
Please review City of Miami City Code Section 18-74 for a complete version of the
Cone of Silence.
1.6 ADDITIONAL INFORMATION OR CLARIFICATION
Requests for additional information or clarifications must be made in writing.
Respondents may fax or e-mail their requests for additional information or
clarifications in accordance with Section 1.5 Cone of Silence, above. Facsimiles
must have a cover sheet that includes the Respondent's name, the RFQ number
and title, the specific project title and the number of pages transmitted. Any
request for additional information or clarification must be received in writing no
later than 5:00 P.M. on Friday, March 22, 2013.
The City's CIP will issue responses to inquiries and any other corrections or
amendments it deems necessary in written addenda issued prior to the Response
Submission Date. Respondents should not rely on any representations,
statements or explanations other than those made in this RFQ or in any written
addendum to this RFQ. Where there appears to be conflict between the RFQ and
any addenda issued, the last addendum issued shall prevail.
It is the Respondent's responsibility to assure submission and receipt of all
addenda. Prior to submitting the Response, the Respondent should check the
City of Miami, Capital Improvements Program's webpage, where all addenda will
be posted. The webpage is located at:
http://www. miamigov.com/Capitali mprovements/pages/ProcurementOpportunities.
1.7 AWARD OF AN AGREEMENT
A City furnished Professional Services Agreement ("Agreement"), may or may not,
be awarded to the Successful Respondent for the project by the City Commission
or City Manager, as applicable, based upon the qualification requirements
reflected herein. The City reserves the right to execute or not execute, as
applicable, an Agreement with the Successful Respondent when it is determined
to be in the City's best interests. By submitting a proposal the Respondent agrees
that it has no expectation, entitlement or interest in obtaining an Agreement with
the City or any work pursuant to the Agreement. Respondent shall have no
recourse against the City from the operation of this Section. The award and
execution of the Agreement shall comply with the Consultants' Competitive
Negotiation Act, Florida Statute §287.055, as amended, codified in the City of
Miami Code as §18-87 AGREEMENT EXECUTION.
By submitting a Response, Respondents agree to be bound to and execute the
Agreement for Miscellaneous Landscape Architectural Services. Without
diminishing the foregoing, Respondents may request clarification and submit
comments concerning the Agreement for the City's consideration. Only
clarification requests and comments and proposed revisions included within the
Response will be considered by the City. Any comments identified after the
Response has been received need not be considered by the City. Furthermore,
any requests to negotiate provisions of the Agreement not identified in the
Response after the Response has been received may be grounds for dismissal.
None of the foregoing shall preclude the City from seeking to negotiate changes
to the Agreement during the negotiation process.
The City shall require Successful Respondents to provide, for themselves, and
their Sub -Consultants, any or all of the following documentation to support the
Price Proposal as a condition precedent to execution of an Agreement:
• Current financial statement(s), preferably an audited financial
statement(s) prepared by a Certified Public Accountant ("CPA") for the
most recently completed fiscal year clearly showing the costs (not
percentage) of direct labor, indirect labor, fringe benefits, general
administrative costs and overhead and a statement of profit or
operating margin requested.
• Raw labor rates by labor or professional classification certified as
accurate by an officer of the company.
• Breakdown of the fee by task/ labor classification and raw or billable
hourly rate/ number of hours.
• Updated information reflecting information resulting from negotiation of
the Agreement.
• Copy of current Florida Department of Transportation (Notice of
Qualification)
The forms for submission of portions of the information contained above are
available on the CIP webpage:
http://www. miamigov.com/cal2italimprovements/pages/ProcurementOpportunities/
asp. Where the City does not provide specific forms to be utilized the Respondent
shall provide the information in a format acceptable to the City.
1.8 UNAUTHORIZED WORK
Successful Respondents shall not begin work until the City issues a Notice to
Proceed. Such Notice to Proceed shall constitute the City's authorization to begin
work. Any unauthorized work performed by a Successful Respondent shall be
deemed non -compensable by the City and the Respondent will not have any
recourse against the City for performing unauthorized work.
1.9 SUBMITTAL INSTRUCTIONS
Careful attention must be given to all requested items contained in this RFQ.
Respondents are invited to submit Responses in accordance with the requirements
of this RFQ. PLEASE READ THE ENTIRE SOLICITATION BEFORE SUBMITTING A
RESPONSE. Respondents shall make the necessary entry in all blanks and forms
provided for the Response.
Responses shall be submitted in a sealed envelope or package with the RFQ
number and opening date clearly noted on the outside of the envelope.
1.10 CHANGES/ALTERATIONS
Respondent may change or withdraw a Response at any time prior to the Response
Submission Deadline. All changes or withdrawals shall be made in writing to the
point of contact specified in Section 1.5, Cone of Silence. Oral/ verbal changes,
modifications or withdrawals will not be recognized and will be disregarded. Written
modifications will not be accepted after the Response Submission Deadline.
Respondents shall not assign or otherwise transfer their Response.
1.11 SUB -CONSULTANTS
A Sub -Consultant is an individual or firm contracted by the Respondent or
Respondent's firm to assist in the performance of services required under this
RFQ. A Sub -Consultant shall be paid through Respondent or Respondent's firm
and not paid directly by the City. Sub -Consultants are allowed by the City in the
performance of the services delineated within this RFQ.
Respondents must clearly reflect in its Response the major Sub -Consultants to be
utilized in the performance of required services. The City retains the right to
accept or reject any Sub -Consultant proposed in the Response of Successful
Respondents or proposed prior to Agreement execution. Any and all liabilities
regarding the use of a Sub -Consultant shall be borne solely by the Successful
Respondent and insurance for each Sub -Consultant and must be maintained in
good standing and approved by the City throughout the duration of the
Agreement. Neither the Successful Respondent nor any of its Sub -Consultants
are considered to be employees or agents of the City. Failure to list all major
Sub -Consultants and provide the required information may disqualify any
proposed Sub -Consultants from performing work under this FRA.
Respondents shall include in their Response the requested Sub -Consultant
information and include all relevant information required of the Respondent.
Respondents are expressly prohibited from substituting any Sub -Consultant
contained in the Response. Respondents shall not change any Sub -Consultants
without just cause and prior written approval by the City. If approved, the City
reserves the right to request additional required documentation as specified in the
RFQ. If the City does not accept the proposed change(s) the Response will be
rejected and not considered for award.
1.12 DISCREPANCIES, ERRORS, AND OMISSIONS
Any discrepancies, errors, or ambiguities in the RFQ or addenda (if any) should be
reported in writing to the City's Capital Improvements Program in the manner
prescribed in RFQ Section 1.5, Should it be necessary, the City will issue a written
addendum to the RFQ clarifying such conflicts or ambiguities.
7
1.13 DISQUALIFICATION
This RFQ requires the use and submission of specific City of Miami Forms. In
addition, this RFQ requires the submission of additional documents and
information. Failure to utilize the City Forms and/ or submit the required
documents may result in the rejection of the Response as non-responsive and it
may not be considered for award.
The City reserves the right to disqualify Responses before or after the submission
date, upon evidence of collusion with intent to defraud or other illegal practices on
the part of the Respondent. It also reserves the right to waive any immaterial
defect or informality in any Response, reject any or all Responses in whole or in
part or reissue this Request for Qualifications.
Any Response submitted by a Respondent who is in arrears, e.g., money owed or
otherwise in debt by failing to deliver goods or services to the City (including any
agency or department of the City) or where the City has an open claim against a
Respondent for monies owed the City at the time of Response submission, will be
rejected as non-responsive and shall not be considered for award.
Any Respondent who submits in its Response any information that is determined
by the City, in its sole opinion, to be substantially inaccurate, misleading,
exaggerated or incorrect shall be disqualified from consideration for award of the
Agreement.
The City reserves the right to reject Responses submitted by limited liability
corporations or any other business entities not deemed to be in the City's best
interests.
1.14 RESPONDENT'S EXPENDITURES
Respondents understand and agree that any expenditure they make in
preparation and submittal of Responses or in the performance of any services
requested by the City in connection with the Responses to this RFQ are
exclusively at the expense of the Respondents. The City shall not pay or
reimburse any expenditure or any other expense incurred by any Respondent in
preparation of a Response and/or anticipation of a contract award and/ or to
maintain the approved status of the Successful Respondent(s) if an Agreement is
awarded, and/ or administrative or judicial proceedings resulting from the
solicitation process.
1.15 EXECUTION OF RESPONSE
The Response must be manually and duly signed by an authorized Corporate/
Partnership/ Limited Liability Company ("LLC"), Professional Association ("PA")
officer, principal, general manager or partner (as applicable) with a signature in
full. When a firm is the Respondent, the Response shall be signed in the name of
the firm by one or more of the officers, mangers or partners (as applicable).
When a corporation is the Respondent, the officer signing shall set out the
corporate name in full beneath which he shall sign his name, give title of his office
0
and affix the corporate seal. When the Respondent is a LLC or PA a managing
partner or managing member with stated authority, by resolution, to bind the
business entity shall sign in the name of the LLC or PA, as applicable. Anyone
signing the Response as agent must file with it legal evidence of signature
authority. Respondent entities shall furnish with their Response to the City a copy
of their registration to transact business in the State of Florida. Failure to promptly
submit this evidence or qualification to do business in the State of Florida may be
basis for rejection of the Response. Respondent understands that submitting a
Response to this RFQ does not constitute an agreement or contract with the City.
SECTION 2
2.0 RFQ SCOPE OF SERVICES
2.1 PURPOSE
The City of Miami is seeking landscape architecture design services from qualified
and experienced firms with a minimum of three (3) year experience under its
current business name in the performance of landscape architectural services to
assist the City in fulfilling its responsibilities under the Miami 21 Zoning Code and
all other relevant State, County and City ordinances. Respondents should refer to
Article 9 ® "Landscape Requirements," but should become familiar with the Miami
21 Code overall by visiting the City's website at the address below:
http://www.miamigov,com/Planning/pages/miami2l/default.asp.
The selected firms must have successfully completed at least three (3) landscape
architectural projects in South Florida within the last three (3) years. These
referenced projects shall be located in South Florida and shall have been
completed for governmental or institutional clients and should include examples of
parks, public spaces, buildings and/or public rights-of-way. For purposes of this
RFQ South Florida shall mean Miami -Dade, Monroe, Broward and/or Palm Beach
Counties.
The City anticipates that these services will be provided for an initial term of two
years with an option to renew for two years on a year to year basis, which shall be
at the sole discretion of the City.
It is anticipated that the Respondent's team will consist of the following disciplines:
o Lead Architect
o Project Manager
o Civil, Structural and MEP Engineers
o Arborist
o Landscape Architect (to include irrigation)
o CADD
o Miscellaneous Consultants as needed
2.2 PROJECT SERVICES
The Successful Respondent shall provide one or more of the following services,
among others, in an on-going and as -needed basis with respect to various project
sites to be identified by the City. Further details concerning the Scope of Services
are contained in the Agreement for Miscellaneous Landscape Architectural
Services, included as part of this RFQ, and will be further specified and clarified in
Work Order Proposals solicited as project sites are identified.
10
• Inspecting sites and analyzing factors such as site function, existing natural
features such as climate, soil, flora, fauna, surface and subsurface water and
drainage, and human -generated elements,;
• Creating and conducting landscape programming activities and design
studies;
• Developing landscape designs, site plans, schematics, working drawings,
written specifications, cost estimates, time schedules and post design
services;
• Review and plan check of landscape plans prepared by third -party
consultants;
• Conducting environmental and visual impact landscape assessments;
• Advising the City regarding methods of work and sequences of operations for
landscape projects;
• Obtaining required permits;
• Developing landscapes schematics and figures for review and for public l
community meetings or Homeowner Association (HOA) or charrettes;
• Monitoring and inspecting the structure and detail of landscape proposals to
ensure compliance with plans, specifications of work, cost estimates, and time
schedules;
• Site Plan;
• Planting plan;
• Layout and Pavement Plan;
• Irrigation Plan;
• Grading and Drainage;
• Construction Details;
• Specifications;
• Project management of small scale landscape planning and design projects,
including management, coordination, and oversight of the work of other
consultants such as engineers, architects and planners;
11
SECTION 3
3.0 RFQ GENERAL CONDITIONS
3.1 ACCEPTANCE/REJECTION
The City reserves the right to accept or reject any or all Responses or to select
the Respondent(s) that, in the opinion of the City, is/ are in its best interests. The
City also reserves the right to reject any Respondent who has previously failed to
properly perform under the terms and conditions of a contract; to deliver on time
any contractual requirements with the City; and who is not in a position to perform
the requirements defined in this RFQ. Further, the City may waive informalities,
technicalities, minor irregularities, and/ or may request new Responses for the
services specified in this RFQ and may, at its discretion, withdraw and/or re -
advertise the RFQ.
3.2 LEGAL REQUIREMENTS
This RFQ is subject to all applicable federal, state, county, city and local laws,
codes, ordinances, rules and regulations that in any manner affect any and all of
the services covered herein. Lack of knowledge of such laws, codes, ordinances,
rules, and regulations by the Respondent shall in no way be cause for relief from
responsibility.
3.3 NON -APPROPRIATION OF FUNDS
In the event that insufficient funds are appropriated and budgeting or funding is
otherwise unavailable in any fiscal period for this Project, then the City shall have
the unqualified right to terminate the Work Order(s) or Agreement upon written
notice to the Consultant without any penalty or expense to the City. No
guarantee, warranty or representation is made that any particular work or any
project(s) will be assigned to any Respondent firm(s). The Respondents shall
have no recourse from such termination other than to be paid at the Agreement
rate for any work done prior to the date of termination.
3.4 BUSINESS TAX RECEIPT
Respondents shall meet the City's Business Tax Receipt ("BTR") requirements in
accordance with Chapter 31, Article II of the City of Miami Code, as amended and
any applicable Miami -Dade County BTR requirement. Respondent(s) with a
business location outside the City of Miami shall meet the applicable local BTR
requirements. A copy of the license should be submitted with the Response. The
City may, at its sole option, allow the Respondent to submit a copy of their BTR
after the Response Submission Date.
12
3.5 MINIMUM QUALIFICATION REQUIREMENTS
The City of Miami is seeking to procure a qualified landscape architectural firm
with experience in completing comprehensive landscape architectural projects for
governmental and/or institutional clients in South Florida. Firms responding to this
RFQ must have been licensed, registered and practicing in Florida as a landscape
architecture firm for at least the last three (3) years under its current business
name and must have completed at least three (3) landscape design projects in
South Florida within the last three (3) years. These reference projects shall be
located in South Florida, shall have been completed for governmental or
institutional clients, and should include examples of parks, public spaces,
buildings and/or public rights-of-way. Respondents must have a proven track
record of successfully completing projects. Failure to meet the above -stated
requirements will result in the Respondent's response being rejected as non-
responsive. For purposes of this RFQ, South Florida shall mean Miami -Dade,
Monroe, Broward and/or Palm Beach Counties.
Respondents must utilize Form RFQ-PP-R for the above -required reference
projects and the form must be signed by the Owner of the project. Failure to
submit the reference forms may result in the Response being deemed non-
responsive.
In addition,
a. Respondents must have at least one (1) staff or team member who has
been licensed and practicing as a Landscape Architect in accordance
with Florida Statute 481.311 for at least three (3) years and who will serve
as Project Manager for the City's projects;
b. Respondents must identify at least one (1) staff or team member who is
an International Society of Arboriculture (ISA) Certified Arborist.
Each firm interested in responding to this RFQ must provide information on the
firm's qualifications and experience; qualifications of the Project team, members
and staff; Project Manager's experience; and previously completed projects. See
Section 4,0 "Instructions for Submitting a Response: Submission Requirements"
for further direction. Responses that do not completely adhere to all requirements
may be considered non-responsive and eliminated from the process. Additional
minimum qualifications may be stated in Section 4.0, "Instructions for Submitting a
Response."
The City will consider a Response as responsive where a Respondent has less
than the stipulated minimum number of years of experience solely where the
Respondent has undergone a name change and such change -of -name has been
filed with the State of Florida, or where the Respondent was a subsidiary of a
larger firm and the Respondent's firm has been merged into the larger firm.
Respondent must include documentation substantiating such name change or
merger as part of its Response for the City to consider crediting the years of
experience from the Respondent under its previous name. Failure to include
13
such documentation with the Response may result in a determination that
the submission is non-responsive.
3.6 COMMUNITY BUSINESS ENTERPRISE ("CBE") PARTICIPATION
REQUIREMENTS
Prospective Firms must adhere to the following requirements:
1) Assign a minimum of fifteen percent (15%0) of the contract value to
firms currently certified by Miami -Dade County as a Community
Business Enterprise ("CBE");
2) Place a specific emphasis on utilizing local small businesses from
within the City's municipal boundaries.
Respondents who meet the CBE participation requirement through
use of the Firms from within the City's municipal boundaries will be
awarded five (5) bonus points.
SEC. 18-73 CITY OF MIAMI CODE
Local office means a Business which conducts all or a portion of its operations
from a permanent structure that is located within the corporate limits of the City of
Miami, and has operated legally pursuant to all applicable zoning and licensing
laws for a minimum of six months prior to the date Bids or Proposals were
received for the Purchase or Contract at issue. A Post Office Box shall not be
sufficient to constitute a Local Office within the City of Miami. If the Business is
located in the permanent structure pursuant to a lease, such lease must be in
writing, for a term of no less than one year, have been in effect for no less than six
months prior to date Bid or Proposal was received, and be available for review
and approval by the Chief Procurement Officer or its Designee.
To verify the above requirements, the City has provided Form "C-1 List of Sub -
Consultants" to identify all sub -consulting firms (including CBE certified firms) that
are part of the Respondent's team. This Form can be found posted on the CIP
webpage with the solicitation documents. Failure to include this completed form
with your Submittal may result in your response being deemed non-responsive.
For information on the City's CBE requirements, visit the CIP website at:
htta://dev.miamiaov.com/capitalimprovements/pages/ProcurementOpl2ortun
ities/ProiectPacies/CBE forms.as
In addition to submitting the required CBE forms, (Refer to Section 4.1- Section A,
"Contents of Qualification Statement", Article 13), to qualify to receive the five (5)
bonus points Respondent's must:
1) Attach copies of both a current City of Miami Business Tax
Receipt and a current Miami -Dade County Business Tax Receipt
with the submittal.
14
3.7 PUBLIC ENTITY CRIMES
A person or affiliate who has been placed on the convicted Respondent/Bidder list
following a conviction for a public entity crime may not submit a Response on a
contract to provide any goods or services to a public entity, may not submit a
Response on a contract with a public entity for the construction or repair of a
public building or public works project, may not submit a Response on a lease of
real property to a public entity, may not be awarded or perform work as a
contractor, supplier, subcontractor, or consultant under a contract with any public
entity, and may not transact business with any public entity in excess of the
threshold amount provided in §287.017, Florida Statutes, as amended, for
Category Two for a period of 36 months from the date of being placed on the
convicted Bidder/Respondent list. § 287.133, Florida Statutes, as amended.
3.8 RESOLUTION OF PROTESTS
Any actual or prospective contractual party who feels aggrieved in connection with
the solicitation or award of a contract may protest in writing to the Chief
Procurement Officer who shall have the authority, subject to the approval of the
City Manager and the City Attorney, to settle and resolve a protest subject to final
approval by the City Commission. Respondents are alerted to Section 18-103
through 18-107 of the City Code (Article III, Chapter 18, City Code City of Miami -
Procurement Ordinance,) describing the protest procedures. Protests failing to
meet the requirements for filing shall NOT be accepted. Failure of a party to
timely file shall constitute a forfeiture of such party's right to file a protest. NO
EXCEPTIONS TO THESE REQUIREMENTS.
3.9 REVIEW OF RESPONSES FOR RESPONSIVENESS
Each Response will be reviewed to determine if it is responsive to the submission
requirements outlined in the RFQ. A "responsive" Response is one which meets
the requirements of the RFQ, is submitted in the format outlined in Section 4.1 —
Section B of this RFQ, is of timely submission, and has appropriate
signatures/attachments as required on each document.
3.10 COLLUSION
The Respondent, by submitting a Response, certifies that its Response is made
without previous understanding, agreement or connection either with any person,
firm, or corporation submitting a Response for the same services, or with any City
department. The Respondent certifies that its Response is fair, without control,
collusion, fraud, or other illegal action. The Respondent further certifies that it is
in compliance with the conflict of interest and code of ethics laws. The City will
investigate all situations where collusion may have occurred and the City reserves
the right to reject any and all Responses where collusion may have occurred.
15
3.11 CLARIFICATIONS
The City reserves the right to request clarifications of information submitted and to
request any necessary supporting documentation or information of one or more
Respondents after the deadline for submission of Responses.
3.12 KEY PERSONNEL
Subsequent to submission of a Response and prior to award of an Agreement,
Key Personnel shall not be changed.: Respondents shall not change any member
of their Key Personnel without just cause and must obtain prior written approval
by the City. The City reserves the right to request additional documentation as
required by the RFQ. If the City does not accept the proposed change(s) the
Response will be rejected and not considered for award.
3.13 ADDITIONAL TERMS AND CONDITIONS
No additional terms and conditions included as part of your solicitation response
shall be evaluated or considered, and any and all such additional terms and
conditions shall have no force or effect and are inapplicable to this solicitation. If
submitted either purposely, through intent or design, or inadvertently, appearing
separately in transmittal letters, specifications, literature, price lists or warranties,
it is understood and agreed that the General Conditions and Special Conditions in
this solicitation are the only conditions applicable to this solicitation and that the
bidder's/respondent's authorized signature affixed to the bidder's/respondent's
acknowledgment form attests to this Professional Services Agreement (PSA) is
provided by the City and is expressly included as part of this solicitation, no
additional terms or conditions which materially or substantially vary, modify or
alter the terms or conditions of the PSA or Agreement, in the sole opinion and
reasonable discretion of the City will be considered. Any and all such additional
terms and conditions shall have no force or effect and are inapplicable to this PSA
or Agreement.
16
SECTION 4
4.0 INSTRUCTIONS FOR SUBMITTING A RESPONSE
Submit the following information and documents with Respondent's Response to
this RFQ. Failure to do so may deem your Responses non-responsive. Non-
responsive submittals will receive no further consideration.
4.1 SUBMISSION REQUIREMENTS
Each Response must contain the following documents and forms required by
Section 4.1 - Sections A & B, each fully completed, and signed as required.
Respondents shall prepare their Responses utilizing the same format outlined
below in Section 4.1 - Section B. Each section of the Response as stipulated in
Section 4.1 — Section B shall be separated by a tabbed divider identifying the
corresponding section number. Respondents are not to submit any information in
response to this RFQ that has not been requested or which the Respondent
considers confidential. Submission of any confidential information will be deemed
a waiver of any confidentiality or other such protection, which would otherwise be
available to the Respondent, except as specifically permitted under Florida
Statute. Respondents are not to include any documents not specifically required
or requested, including, but not limited to; media and public relations literature,
annual reports, pictures, etc. Such documentation may not be considered and
may be redacted from the copies provided to the Evaluation Committee. The
submission of such documentation may adversely affect the evaluation of the
Response by the Evaluation Committee.
Hard cover binders are not to be used in the submission of the Response. Only
heavy stock paper, not exceeding 100#, is to be used for the front and back
covers as well as the required section dividers. Respondents should also make
every effort to utilize recycled paper in preparing its response. Double sided
printing is permitted provided that the Response complies with the format set forth
in Section 4.1 - Section B. Other than the .pdf fillable City forms, Respondent
shall use the font style Times New Roman or Arial, with a font size of 11 or 12 for
any other information or documents to be submitted. Anything exceeding the
page limit maximum will be discarded.
®o not include additional information not requested in this RFQ unless specified in
the form of an Addendum. This RFQ requires the use and submission of specific
City Forms. These City Forms shall not be expanded or altered. Additional pages
may not be added unless the form specifically states that pages can be added.
Failure to utilize the City Forms will result in the rejection of the Response as non-
responsive.
17
A. CONTENTS OF QUALIFICATION STATEMENT
Required RFQ forms for Section A - Articles 1-10 are available on the CIP website:
http://www.miamigov.com/capitalimprovements/pages/Procurement0pportunities/Pro'
ectPaaes/RFQ Forms.asp.
1. Proposal Letter
Respondent shall complete and submit Form RFQ-PL for this section of the
Response. (1 page maximum)
2. Narrative
Respondent shall complete and submit Form RFQ-N for this section of its
Response. Provide a brief overview of the Respondent's firm and why the
Respondent should be selected for this Project. (1 page maximum)
3. Qualifications of Respondent
Respondent shall complete and submit Form RFQ-QP for this section of its
Response. This shall be limited to one (1) Form RFQ-QP. (1 Form consists of 3
pages)
Respondent shall include copies of Company Business and Professional
Licenses, Certifications and Florida Corporate Registration.
Respondent shall also submit Form RFQ-PP for this section of its Response.
Separate RFQ-PP forms must be submitted for a minimum three (3) reference
maximum of five (5) projects completed within the past five (5) years.
Respondent must also submit Form RFQ-PP-R for each Form RFQ-PP submitted.
Respondents shall submit for a minimum three (3) reference maximum of five (5)
prior reference projects. This section shall be limited to a maximum of one (1)
Form RFQ-QP, five (5) Forms RFQ-PP and five (5) Forms RFQ-PP-R.
4. Qualifications of Respondent's Team
Respondent shall complete and submit Form RFQ-QT for this section of its
Response (1 form - 3 page maximum).
5. Resumes
A one (1) page resume is required for all key personnel (exclude Project Manager
and include the ISA Certified Arborist) that reflect each individual's education,
experience, professional licenses and/or certifications and qualifications as they
relate to this Project. An organizational chart of the Project Team shall also be
provided along with resumes for key personnel.
18
6. Qualifications of Project Manager
Project Manager must have been licensed and practicing as a Landscape
Architect in accordance with Florida Statute 481.311 for at least three (3) years in
South Florida.
Respondent shall complete and submit Form(s) RFQ-PM for the Project Manager
for this section of its Response.
Respondent shall also submit Form RFQ-PM-R for each Form RFQ-PM
submitted. This section shall be limited to three (3) Forms - RFQ-PM and three
(3) Forms - RFQ-PM-R.
A one (1) page resume is also required to be submitted that reflects the Project
Manager's education, experience, professional licenses and/or certifications and
qualifications as they relate to this Project.
7. Team Organizational Chart (Key Personnel Only)
8. Workload Capacity
Respondent shall complete and submit Form RFQ-WC for this section of its
Response. This section does not have a page limit.
Design Philosophy and Process
Respondent shall complete and submit Form RFQ-DPP for this section of its
Response. Respondent shall include a brief explanation of its design philosophy
& process as it relates to this Project. (2 page maximum)
10. Technical Capabilities
Respondent shall complete and submit Form RFQ-T for this section of its
Response. Respondent shall include a brief explanation of its technical
capabilities as it relates to this Project in the following areas:
➢ Computer aided design and drafting capabilities;
➢ Capacity to provide on-call services in a timely manner;
➢ Quality control and assurance, including coordination between design
disciplines, compliance with program requirements, professional/industry
standards, and conformance with all applicable code requirements.
(2 page maximum)
11. Professional Service Agreement "PSA" Provisions (Exhibit A)
Provide comments on, and exceptions to the attached Agreement terms and
conditions. Proposed changes to the Agreement must be returned to the City in
Microsoft Word format with comments reflected by "red -lining" the original
document utilizing the tracking feature. The Microsoft Word document must be
6R
included in the proposal in both printed format and electronically on a CD-ROM.
The City will only consider the identified comments and exceptions during
negotiations. Where a proposal is returned without comments it will be deemed
that the Respondent has no comments or exceptions to the draft Agreement. If
the Respondent has no comments, a statement to that effect shall be included in
the proposal in this section. As noted certain sections of the Professional
Services Agreement ("PSA"), including, without limitation, Hold
Harmless/Indemnity, Insurance, Cancellation for Convenience, Funding Out,
Ethics, Conflicts, Public Records, Sunshine, Lobbying and Compliance with Laws,
Rules and Regulations Sections are long standing City practices and cannot be
modified.
12. Acknowledgment of Addenda
13. Respondent Information Forms (Section 6.0)
14. Community Business Enterprise Forms
Letter of Agreement(s) ("LOA")
➢ Form C-1 List of Sub -Consultants*
Certificate of Compliance
NOTE'
Sub -Consultants Information Form C-1
Respondents shall list all proposed Sub -Consultants to be used, regardless of
racial or gender grouping, to include names, addresses, phone numbers, type of
work (service or commodity) and Certified Small Business Certification ("CBE") by
Miami -Dade County (if applicable).
15. Form A ® Joint Venture (If applicable)
20
B. RESPONSE SUBMISSION FORMAT
Section A
The following documents shall be included in the order listed.
1. RFQ-PL — Proposal Letter
2. RFQ-N — Narrative
3. RFQ-QP — Qualifications of Respondent
4. RFQ-PP — Respondent's Project Experience
5. RFQ-PP-R — Respondent's Reference Forms
Section B
1. RFQ-QT - Qualifications of the Team
2. Resumes of the Team (exclude Project Manager and include ISA Arborist)
3. RFQ-PM — Qualifications of Project Manager
4. RFQ-PM-R— Project Manager Reference Forms
5. Resume of the Project Manager
6. Team Organizational Chart
7. RFQ-WC — Workload Capacity
Section C
1. RFQ-DPP- Design Philosophy & Process
2. RFQ-T Technical Capabilities
Section D
1. Professional Service Agreement "PSA" Provisions (Exhibit A)
2. Acknowledgment of Addenda
Section E
1. Supplemental Response Forms (Section 6.0)
Section F
1. Letter of Agreement ("LOA") 1 page for each Sub -Consultant firm
2. Form C-1 List of Sub -Consultants
3. Certificate of Compliance
4. Form A — Joint Venture (if applicable)
21
4.2 RESPONSE SUBMISSION
One (1) original and seven (7) bound copies, plus one digital copy (in .pdf file
format), of your complete response to this RFQ must be delivered to:
Mr. Todd Hannon, City Clerk
City of Miami
Office of the City Clerk
3500 Pan American Drive, 1st Floor
Miami, Florida 33133
Responses must be clearly marked on the outside of the package referencing:
RFQ No. 12-13-019
MISCELLANEOUS LANDSCAPE ARCHITECTURAL SERVICES
Responses received at any other location than the aforementioned or after
the Response Submission Date and Time shall be deemed non-responsive
and shall not be considered.
Responses should be signed by an official authorized to bind the Respondent to
the provisions given in the Responses. Responses are to remain valid for at
least 180 days. Upon award of an Agreement, the contents of the Responses of
the Successful Respondent(s) may be included as part of the Agreement, at the
City's discretion.
SUBMITTAL GUIDELINES
1. General
Only one (1) Response from an individual, firm, partnership, corporation, joint
venture or limited liability corporation will be considered in response to this RFQ.
Sub -Consultants, a business entity, or Sub -Contractors may be included in more
than one Response submitted by more than one Respondent. A firm, partnership,
corporation or joint venture that submits a Response may not be a Sub -
Consultant on another Response submitted under this RFQ.
Joint venture firms must complete and submit with their Response the form titled
"Information for Determining Joint Venture Eligibility", (Form A) and submit a copy
of the formal agreement between all joint -venture parties. This joint venture
agreement must indicate their respective roles, responsibilities and levels of
participation for the Project. Failure to timely submit Form A, along with an
attached written copy of the joint venture agreement may result in disqualification
of your Response.
Joint Venture Submissions will be evaluated based on the combined team. Each
member of a Joint Venture shall provide the information listed above.
22
Respondent must clearly reflect in its Response any Sub -Consultants proposed to
be used, and provide for the Sub -Consultant the same information required of the
Respondent. The City retains the right to accept or reject any proposed Sub -
Consultants.
Throughout this RFQ, the phrases "must" and "shall" will denote mandatory
requirements. Any Response that does not meet the mandatory requirements is
subject to immediate disqualification.
It is the policy of the City that the Successful Respondents register as a
BidderNendor indicating the commodities/services which the Respondent can
regularly supply to the City. Should the Successful Respondent not be currently
listed on the City's Respondent/bidder's list, they may register via the internet at:
http://egov.ci.miami.fl.us/bids/bids.asp. For any questions, contact the Purchasing
Department at (305) 416-1900. Proposers shall be registered as a BidderNendor
prior to submitting its Response. It is the sole responsibility of the Proposer(s) to
insure that they are properly registered with the City.
23
SECTION 5
5.0 INSTRUCTIONS FOR SUBMITTING A RESPONSE
A. Evaluation Procedures
The procedure for response evaluation and selection is as follows:
1. Request for Qualifications issued.
2. Receipt of Responses.
3. Opening and listing of all Responses received.
4. Preliminary review by City staff for compliance with the submission
requirements of the RFQ, including verification that each Response
includes all documents required.
5. An Evaluation Committee comprised of appropriate City Staff and/or
members of the community, as deemed necessary with the appropriate
technical expertise and/or knowledge, shall meet to evaluate each
response in accordance with the requirements of this Solicitation and
based upon the evaluation criteria as specified herein.
6. The Evaluation Committee reserves the right, in its sole discretion, to
request Respondents to make oral presentations before the Committee
as part of the evaluation process. The presentation may be scheduled at
the convenience of the Evaluation Committee.
7. The Evaluation Committee reserves the right to rank the Responses and
shall submit its recommendation to the City Manager for acceptance and
award upon certification of compliance with competitive negotiations
method by the Chief Procurement Officer, pursuant to Section 18-86 (b)
of the City of Miami Code.
8. Upon successful negotiation of an Agreement, CIP will forward the
recommended Agreement to the City Manager for approval and the City
Manager upon acceptance of the negotiated Agreement will approve the
award or recommend that the City Commission, when required by the City's
Procurement Code, approve the recommendation of the Selection
Committee and the award of the Agreement. Where CIP is not able to
successfully negotiate an Agreement with the top ranked Respondent CIP
will recommend to the City Manager that such negotiations be terminated
and that CIP enter into negotiations with the next ranked Respondent until
an Agreement is negotiated or all Responses are rejected.
24
C. EVALUATION CRITERIA
Responses shall be evaluated according to the following criteria and respective
weight:
➢ Respondent's Experience and Qualifications Maximum 25 points
Experience of Project Manager Maximum 20 points
➢ Respondent's Team Experience Maximum 35 points
Design Philosophy and Process Maximum 10 points
Technical Capabilities Maximum 10 points
D. BONUS POINTS — COMMUNITY BUSINESS ENTERPRISE ("CBE")
PARTICIPATION
Bonus points will be awarded to Respondents who agree to use Miami -Dade County
CBE Firms from within the City of Miami municipal boundaries.
Must meet the requirements in Section 3.6 - General Conditions.
➢ Agreement to assign ? 15% of the contract value to certified CBE firms
who maintain a "Local Office", as defined in City Code Section 18-73.
5 Bonus Points
25
SECTION 6
6.0 SUPPLEMENTAL RFQ RESPONSE FORMS
6.1 SUPPLEMENTAL RFQ INFORMATION FORM
REQUEST FOR QUALIFICATIONS
RFQ No.: 12-13-019
RFQ NO.: 12-13-019: Miscellaneous Landscape Architectural Services
I certify that any and all information contained in this RFQ is true. I certify that this RFQ is
made without prior understanding, agreement, or connections with any corporation, firm or
person submitting a RFQ for the same materials, supplies, equipment, or services and is in
all respects fair and without collusion or fraud. I agree to abide by all terms and conditions
of the RFQ, and certify that I am authorized to sign for the Respondent's firm. Please print
the following and sign your name:
Firm's Name
Principal Business Address
Telephone
Fax
Email Address
Name
Title
Authorized Signature
26
ON
J
6.2
(IF CORPORATION)
STATE OF )
SS:
COUNTY OF )
REQUEST FOR QUALIFICATIONS
RFQ No.: 12-13-019
I HEREBY CERTIFY that a meeting of the Board of Directors of the
a corporation existing under the laws of the State of , held on
, 20 , the following resolution was duly passed and adopted:
'RESOLVED, that, as President of the Corporation, be and is hereby authorized to execute the
Response dated, , 20 , to the City of Miami and this Corporation and
that their execution thereof, attested by the Secretary of the' Corporation, and with the Corporate Seal
affixed, shall be the official act and deed of this Corporation,"
I further certify that said resolution is now in full force and effect.
IN WITNESS WHEREOF, I have hereunto set my hand and affixed the official seal of the corporation
this , day of , 20
Secretary:
(SEAL)
FAILURE TO COMPLETE, SIGN, AND RETURN THIS FORM MAY DISQUALIFY YOUR RESPONSE
27
REQUEST FOR QUALIFICATIONS
RFQ No.: 12-13.019
6.2.1
CERTIFICATE OF AUTHORITY
(IF PARTNERSHIP)
STATE OF
SS:
COUNTY OF )
I HEREBY CERTIFY that a meeting of the Partners of the
organized and existing under the laws of the State of , held on
, 20 , the following resolution was duly passed and adopted:
"RESOLVED, that, , as of the Partnership, be
and is hereby authorized to execute the Response dated, 20 to the City of
Miami and this Partnership and that their execution thereof, attested by the
shall be the official act and deed of this Partnership."
I further certify that said resolution is now in full force and effect.
IN WITNESS WHEREOF, I have hereunto set my hand this day of
Secretary:
(SEAL)
20®
FAILURE TO COMPLETE, SIGN AND RETURN THIS FORM MAY DISQUALIFY YOUR RESPONSE
28
6.2.2
REQUEST FOR QUALIFICATIONS
RFQ NO.: 12-13-019
CERTIFICATE OF AUTHORITY
(1F JOINT VENTURE)
STATE OF )
SS:
COUNTY OF )
I HEREBY CERTIFY that a meeting of the Principals of the
organized and existing under the laws of the State of ,
held on 20 , the following resolution was duly passed
and adopted:
"RESOLVED, that, as
Venture be and is hereby authorized to execute the Response dated,
to the City of Miami official act and deed of this Joint Venture."
I further certify that said resolution is now in full force and effect.
of the Joint
® 20_,
IN WITNESS WHEREOF, I have hereunto set my hand this day of
20_
Secretary:
(SEAL)
FAILURE TO COMPLETE, SIGN AND RETURN THIS FOR MAY DISQUALIFY YOUR RESPONSE
29
4' WIs IiMi�#/a/W
REQUEST FOR QUALIFICATIONS
RFQ No.: 12-13-019
6.2.3
CERTIFICATE OF AUTHORITY
(IF LIMITED LIABILITY CORPORATION)
STATE OF
SS:
COUNTY OF )
I HEREBY CERTIFY that a meeting of the Principals of the
organized and existing under the laws of the State of ,
held on 20 , the following resolution was duly passed
and adopted:
"RESOLVED, that, I as of the
Limited Liability Corporation be and is hereby authorized to execute the Response dated,
20 , to the City of Miami official act and deed of this Limited Liability
Corporation."
I further certify that said resolution is now in full force and effect.
IN WITNESS WHEREOF, I have hereunto set my hand this day of
, 20
Secretary:
(SEAL)
FAILURE TO COMPLETE, SIGN, AND RETURN THIS FORM MAY DISQUALIFY YOUR RESPONSE
30
6.2.4
CERTIFICATE OF AUTHORITY
(IF INDIVIDUAL)
STATE OF )
SS:
COUNTY OF )
I HEREBY CERTIFY that as an individual, I
(Name of Individual)
UEST FOR PROPOSALS
RFQ NO.: 12-13-019
and as a d/b/a (doing business as)
(If applicable)
exist under the laws of the State of Florida.
"RESOLVED, that, as an individual and/or d/b/a (if applicable), be and is hereby authorized to
execute the Response dated, , 20 , to the City of Miami as an individual
and/or d/b/a (if applicable) and that my execution thereof, attested by a Notary Public of the State,
shall be the official act and deed of this attestation."
I further certify that said resolution is now in full force and effect.
IN WITNESS WHEREOF, I have hereunto set my hand and affixed the official seal of Notary Public
this day of , 20
NOTARY PUBLIC:
Commission No.:
I personally know the individual / do not know the individual (Please circle)
Driver's License #
(SEAL)
FAILURE TO COMPLETE, SIGN, AND RETURN THIS FORM MAY DISQUALIFY YOUR RESPONSE
31
6.3 DEBARMENT AND SUSPENSION
(a) Authority and requirement to debar and suspend:
REQUEST FOR PROPOSALS
RFQ No.: 12-13-019
After reasonable notice to an actual or prospective contractual party, and
after reasonable opportunity to such party to be heard, the City Manager,
after consultation with the Chief Procurement Officer and the City Attorney,
shall have the authority to debar a contractual party for the causes listed
below from consideration for award of city contracts. The debarment shall be
for a period of not fewer than three (3) years. The City Manager shall also
have the authority to suspend a contractor from consideration for award of
City contracts if there is probable cause for debarment. Pending the
debarment determination, the authority to debar and suspend contractors
shall be exercised in accordance with regulations, which shall be issued by
the Chief Procurement Officer after approval by the City Manager, the City
Attorney, and the City Commission.
(b) Causes for debarment or suspension include the following:
1. Conviction for commission of a criminal offense incident to obtaining
or attempting to obtain a public or private contract, subcontract, or
license, franchise or similar agreement incident to the performance of
such contract or subcontract.
2. Conviction under state or federal statutes of embezzlement, theft,
forgery, bribery, falsification or destruction of records, receiving stolen
property, or any other offense indicating a lack of business integrity or
business honesty.
3. Conviction under state or federal antitrust statutes arising out of the
submission of bids or Responses.
4. Violation of contract provisions, which is regarded by the Chief
Procurement Officer to be indicative of non -responsibility. Such
violation may include failure without good cause to perform in
accordance with the terms and conditions of a contract or to perform
within the time limits provided in a contract, provided that failure to
perform caused by acts beyond the control of a party shall not be
considered a basis for debarment or suspension.
5. Debarment or suspension of the contractual party by any federal,
state or other governmental entity.
6. False certification pursuant to paragraph (c) below.
7. Any other cause judged by the City Manager to be so serious and
compelling as to affect the responsibility of the contractual party
performing City contracts.
32
(c) Certification:
REQUEST FOR PROPOSALS
RFQ No.: 12-13-019
All contracts for goods and services, sales, and leases by the City shall
contain a certification that neither the contractual party nor any of its principal
owners or personnel has been convicted of any of the violations set forth
above or debarred or suspended as set forth in paragraph (b) (5).
The undersigned hereby certifies that neither the contractual party nor any of its
principal owners or personnel has been convicted of any of the violations set forth
above, or debarred or suspended as set forth in paragraph (b) (5).
Company Name:
Signature:
Date:
FAILURE TO COMPLETE, SIGN, AND RETURN THIS FORM MAY DISQUALIFY YOUR RESPONSE.
ADDITIONALLY, THIS FORM IS REQUIRED OF ALL SUB CONSULTANTS LISTED ON THE RESPONDENT'S
TEAM AND FORMS SIGNED BY A REPRESENTATIVE OF EACH FIRM SHALL BE SUBMITTED WITH THE
RESPONDENTS'RFQPACKAGE.
33
IWO
FORM A
REQUEST FOR PROPOSALS
RFQ No.: 12-13.019
INFORMATION FOR DETERMINING JOINT VENTURE ELIGIBILITY
If the Respondent is submitting as a joint venture, please be advised that this form (2 pages) MUST be
completed and the REQUESTED written joint -venture agreement MUST be attached and submitted with
this form.
1. Name of joint venture:
2. Address of joint venture:
3. Phone number of joint venture:
4. Identify the firms that comprise the joint venture:
5. Describe the role of the MBE firm (if applicable) in the joint venture:
6. Provide a copy of the joint venture's written contractual agreement.
7. Control of and participation in this Agreement. Identify by name, race, sex, and "firm" those
individuals (and their titles) who are responsible for day-to-day management and policy decision
making, including, but not limited to, those with prime responsibility for:
(a) Financial decisions:
(b) Management decisions, such as:
(1) Estimating:
(2) Marketing and sales:
(3) Hiring and firing of management personnel:
(4) Purchasing of major items or supplies:
(c) Supervision of field operations:
34
f
EST FOR PROPOSALS
RFQ NO.: 12-13-019
NOTE: If, after filing this form and before the completion of the joint venture's work on the Subject
Contract, there is any significant change in the information submitted, the Joint Venture must inform the
County in writing.
AFFIDAVIT
"The undersigned swear or affirm that the foregoing statements are correct and include all material
information necessary to identify and explain the terms and operation of our joint venture and the
intended participation by each joint venturer in the undertaking. Further, the undersigned covenant and
agree to provide to the County current, complete and accurate information regarding actual joint venture
work and the payment therefore and any proposed changes in any of the joint venturer relevant to the
joint venture, by authorized representatives of the County. Any material misrepresentation will be
grounds for terminating any Contract which may be awarded and for initiating action under Federal or
State laws concerning false statements."
Name of Firm:
Name of Firm:
Signature: Signature:
Name:
Title:
Date:
Name:
Date:
FORM A
35