Loading...
HomeMy WebLinkAbout26231AGREEMENT INFORMATION AGREEMENT NUMBER 26231 NAME/TYPE OF AGREEMENT STAR CONTROLS, INC. DESCRIPTION PROFESSIONAL SERVICES AGREEMENT/TELEMETRY & SUPERVISORY CONTROL & DATA ACQUISITION ("SCADA") SERVICES FOR THE CITY'S STORMWATER PUMP STATION SYSTEMS/FILE I D : 19316/R-26-0276/MATTER I D : 25-2910 EFFECTIVE DATE August 6, 2026 ATTESTED BY TODD B. HANNON ATTESTED DATE 8/6/2026 DATE RECEIVED FROM ISSUING DEPT. 8/6/2026 NOTE DOCUSIGN AGREEMENT BY EMAIL City of Miami DOCUMENT ROUTING FORM ORIGINATING DEPARTMENT: Department of Procurement DEPT. CONTACT PERSON: Aimee Gandarilla/Tahlia Gray NAME OF OTHER CONTRACTUAL PARTY/ENTITY: Star Controls, Inc. EXT. 1906/1912 IS THIS AGREEMENT TO BE EXPEDITED/RUSH: TOTAL CONTRACT AMOUNT: $ TYPE OF AGREEMENT: ❑ MANAGEMENT AGREEMENT ❑■ PROFESSIONAL SERVICES AGREEMENT ❑ GRANT AGREEMENT ❑ EXPERT CONSULTANT AGREEMENT ❑ LICENSE AGREEMENT OTHER: (PLEASE SPECIFY) ■ FUNDING INVOLVED? YES YES ❑ PUBLIC WORKS AGREEMENT ❑ MAINTENANCE AGREEMENT ❑ INTER -LOCAL AGREEMENT ❑ LEASE AGREEMENT ❑ PURCHASE OR SALE AGREEMENT D SUPPLEMENTAL AGREEMENT NO NO PURPOSE OF ITEM (DETAILED SUMMARY): Telemetry and Supervisory Control and Data Acquisition ("SCADA) services for the City's storm water pump station systems. RFP No. 2046386 COMMISSION APPROVAL DATE: 6/25/2026 FILE ID: 19316 ENACTMENT NO.: 26-0276 IF THIS DOES NOT REQUIRE COMMISSION APPROVAL, PLEASE EXPLAIN: ROUTING INFORMATION Date PLEASE PRINT AND SIGN APPROVAL BY DIRECTOR/CHIEF PROCUREMENT OFFICER July 21, 2026 1 08:20:36 Annie Perez, EDT SIGNATURE: CPPO —oo...,.�: -4—f h1w.,r SUBMITTED TO RISK MANAGEMENT July 22, 2026 I 15:30:20 David Ruiz EDT SIGNATURE: Signed by: [ r GOwitlii 27395C6318214E7... SUBMITTED TO CITY ATTORNEY Matter ID 25-291 (Matter 25-2910) Initial �t Ka July 28, 2026 112:55:55 George K. Wysong III EDT .®n�v: SIGNATURE: At.or ‘. (Ilsowd III Caa»s�a��a APPROVAL BY ASSISTANT CITY MANAGER/CHIEF FINANCIAL OFFICER July 28, 2026 I 12:59:04 Erica T. Paschal Darling, CPA EDT ,—DocuSrgnetl , - P--" SIGNATURE: _�_ APPROVAL BY ASSISTANT CITY MANAGER/CHIEF OF OPERATIONS Barbara Hernandez, MPA SIGNATURE: APPROVAL BY ASSISTANT CITY MANAGER/CHIEF OF INFRASTRUCTURE July 29, 2026 1 07:16:04 Asael Marrero EDT SIGNATURE: APPROVAL BY DEPUTY CITY MANAGER August 6, 2026 Natasha Colebrook -Williams SIGNATURE: N/A- Natasha on vacation RECEIVED BY CITY MANAGER August 5, 2026 I James Reyes 13:44:46 EDT SIGNATURE: C a SUBMITTED TO THE CITY CLERK August 6, 2026 09:15:1 Todd Hannon EDT _ SIGNATURE: PLEASE ATTACH THIS ROUTING FORM TO ALL DOCUMENTS THAT REQUIRE EXECUTION BY THE CITY MANAGER AGREEMENT/AMENDMENT OVERVIEW AGREEMENT TITLE: Contract No. 2046386 - Telemetry and SCADA Services 1. AWARD DELEGATED AUTHORITY: O Chief Procurement Officer — Authority level of $ ❑ City Manager — Authority level of $ 8 City Commission — RESOLUTION No. 26-0276 2. PROCUREMENT METHOD: 8 RFP/RFQ 0 IFB 0 ITB 0 SOLE SOURCE 0 PIGGY -BACK O COOPERATIVE 0 PROFESSIONAL SERVICES UNDER $25,000 3. TYPE OF AGREEMENT: 8 PROFESSIONAL SERVICES AGREEMENT ❑ EXPERT CONSULTANT AGREEMENT 0 SOFTWARE AS A SERVICE AGREEMENT ❑ LEASE AGREEMENT 0 OPERATOR AGREEMENT 0 CONCESSION AGREEMENT O OTHER (Please explain): 4. IF THIS IS AN AMENDMENT, WHAT IS THE NUMBER OF THE AMENDMENT AND WHAT DOES THIS AMENDMENT DO (INCREASE CAPACITY, CHANGE IN TERMS, ETC) BE SPECIFIC AND INCLUDE THE PAGE NUMBER(S) THAT SPECIFIES WHAT IS BEING AMENDED ON THE CONTRACT. N/A 5. WAS THE AMENDMENT APPROVED BY THE CITY COMMISSION? 0 YES 0 NO IF YES, WHAT IS THE RESOLUTION NUMBER? N/A 6. WHAT IS THE SCOPE OF SERVICES? Telemetry and supervisory control and data acquisition ("SCADA") services for the City's storm water pump station systems. 7. IF CITYWIDE, WHAT ARE THE MOST FREQUENT USER DEPARTMENTS? Resilience and Public Works 8. IS THE AWARDEE INCUMBENT? N/A Updated 1/29/2025 9. IS THE PRICING HIGHER, LOWER OR THE SAME AS THE CURRENT CONTRACT? N/A 10.WHEN DOES THE CURRENT CONTRACT EXPIRE? N/A 11.WHAT WAS THE PREVIOUS SPEND ON THE CURRENT CONTRACT? No previous spend. New services. 12.WHAT IS THE METHOD OF AWARD (Group, Item by Item etc.)? Highest ranked responsive and responsible proposer. Updated 1/29/2025 LClear Form CITY OF MIAMI Vendor Responsibility Checklist Name of Firm: STAR CONTROLS, INC. Use the "Upload" button to attach PDF documentation for each section. To delete attachment(s), use the appropriate "Delete" button to the right and then use the "Clear" button for the corresponding attachment box to clear that field. CATEGORY City Vendor Registration Affirmation YES State of Florida Corporation (Sunbiz) Select D&B Pacer Bid/Proposal Bond NO N/A N/A Upload Clear Upload F Clear Upload Clear Upload * Clear RESPONSE View All Attachments Delete Last Delete All iSupplier Number: 55279 5 Sunbiz.pdf Use the "Upload" button to attach PDF documentation for each section. To delete attachment(s), use the appropriate "Delete" button to the right and then use the "Clear" button for the corresponding attachment section to clear that field. Delete Last Dele PERFORMANCE/REFERENCE CHECKS ATTACHMENTS System of Award Managment (SAM) N/A Convicted Vendor List NO Debarred Contractors N/A Suspended Contractors NO Suspended Vendors -State: NO Upload Clear I Upload Clear I Upload Clear Upload Clear I Upload Clear Upload Scrutinized Companies List: NO I Clear Google Search: YES I Upload Clear Convicted Vendor List_ SCADA.pdf (iami-Dade County- STAR.pdf gaspended Vendor List_ SCADA.pdf 2026_06_09_web_update_pfia_proh ibited_list. pdf star controls - Google Search.pdf Contract No. 2046386 PROFESSIONAL SERVICES AGREEMENT BY AND BETWEEN THE CITY OF MIAM( AND STAR CONTROLS. INC, This Professional Services Agreement ("Agreement") is entered into this 6th day of August , 2026, ("Effective Date") by and between the City of Miami, a municipal corporation of the State of Florida, whose address is 444 S.W. 2nd Avenue, Miami, Florida 33130 ("City"), and Star Controls, Inc., a foreign profit corporation authorized to conduct business in Florida, whose principal address is 11555 Heron Bay Blvd, Suite 200, Coral Springs, FL 33076 ("Contractor"). RECITALS: WHEREAS, the City issued Request for Proposals No. 2046386 on November 14, 2025 (the "RFP"), attached hereto and incorporated herein as Exhibit "A", for the provision of telemetry and supervisory control and data acquisition ("SCADA") services for the City's stormwater pump station systems (the "Services"), as more particularly described in the scope of work addendum attached hereto and incorporated herein as Exhibit "C" (the "SOW"); and WHEREAS, Contractor submitted a proposal in response to the RFP, attached hereto and incorporated herein as Exhibit "B" (the "Proposal"); and WHEREAS, the Evaluation/Selection Committee appointed by the City Manager determined that the Proposal was responsive to the requirements of the RFP and recommended that the City negotiate with Contractor for the provision of the Services; and WHEREAS, the City desires to retain Contractor to perform the Services, and Contractor desires to provide the Services, in accordance with the terms and conditions of this Agreement; and WHEREAS, the parties desire to enter into this Agreement to set forth their respective rights and obligations with respect to the Services; NOW, THEREFORE, in consideration of the mutual covenants and promises contained herein, the City and Contractor agree as follows: 1. RECITALS AND INCORPORATIONS: DEFINITIONS: The above recitals are true and correct and are hereby incorporated into and made a part of this Agreement. The order of precedence whenever there is conflicting or inconsistent language between documents is as follows in descending order of priority: 1) This Agreement document. 2) Exhibit "C", the SOW. 1 Telemetry/SCADA Services Contract No. 2046386 3) Exhibit "A", the RFP. 4) Exhibit "B", the Proposal. 5) Exhibits "D" through "F". 2. TERM: The Agreement shall commence on the Effective Date and shall continue for a period of one (1) year ("Initial Term") with options to renew for three (3) additional one (1) year periods ("Renewal Term(s)"). The City, acting by and through its City Manager, shall have the option to extend or terminate the Agreement for convenience, that is, for any or no cause. 3. SCOPE OF SERVICES: A. Contractor agrees to provide the Services and such other related tasks as may from time to time be assigned. B. Contractor represents to the City that: (i) it possesses all qualifications, licenses, certificates, authorizations, and expertise required for the performance of the Services, including but not limited to full qualification to do business in Florida, and meet all requirements of Section 468.385, et seq., Florida Statutes; (ii) it is not delinquent in the payment of any sums due the City, including payment of permits, fees, occupational licenses, etc., nor in the performance of any obligations or payment of any monies to the City; (iii) all personnel assigned to perform the Services are and shall be, at all times during the term hereof, fully qualified and trained to perform the tasks assigned to each and possess the licenses, registrations, and certifications required by law to perform such tasks; (iv) the Services will be performed in the manner described in this Agreement; and (v) each person executing this Agreement on behalf of Contractor has been duly authorized to so execute the same and fully bind Contractor as a party to this Agreement, as shown in Contractor's Corporate Resolution, attached hereto and incorporated herein as Exhibit C. Contractor shall always provide fully qualified, competent, and physically capable employees to perform the Services under this Agreement. Contractor shall possess and maintain any required licenses, permits, and certifications to perform the Services under this Agreement. City may require Contractor to remove any employee the City deems careless, incompetent, insubordinate, intoxicated on the job, or otherwise objectionable and whose continued services under this Agreement is not in the best interest of the City. 4. COMPENSATION: A. The amount of compensation payable by the City to the Contractor for all Services performed under this Agreement includes all costs associated with such Services and shall be as stated in the Contractor's proposal. The City shall have no obligation to pay the Contractor any additional sum in excess of this amount set forth, except for a change and/or modification to the 2 Telemetry/SCADA Services Contract No. 2046386 Agreement, which is approved and executed in writing by the City and the Contractor. All Services undertaken by the Contractor before City's approval of this Agreement and any subsequent Work Order shall be at the Contractor's risk and expense. B. Payment shall be made in arrears based upon work performed to the satisfaction of the City within forty-five (45) days after receipt of Contractor's invoice for Services performed, which shall be accompanied by sufficient supporting documentation and contain sufficient detail, to allow a proper audit of expenditures, should the City require one to be performed. Invoices shall be sufficiently detailed so as to comply with the "Florida Prompt Payment Act", Sections 218.70— .79, Florida Statutes, and other applicable laws. No advance payments shall be made at any time. C. Contractor agrees and understands that (i) any and all subcontractors providing Services related to this Agreement shall be paid through Contractor and not paid directly by the City, and (ii) any and all liabilities regarding payment to or use of subcontractors for any of the Services related to this Agreement shall be borne solely by Contractor and not be a debt or default of the City. The City only has privity of contract with the named Contractor. 5. OWNERSHIP OF DOCUMENTS: Contractor understands and agrees that any information, document, report, data, or other digital record, or any other material whatsoever which is given by the City to Contractor, its employees, or any subcontractor, or which is otherwise obtained or prepared by Contractor solely and exclusively for the City pursuant to or under the terms of this Agreement, is and shall always remain the property of the City. Contractor agrees not to use any such information, document, report, data, or material for any other purpose whatsoever without the written consent of the City Manager, which may be withheld or conditioned by the City Manager in his/her sole discretion. Contractor is permitted to make and to maintain duplicate copies of the files, records, documents, etc. if Contractor determines copies of such records are necessary after the termination of this Agreement; however, in no way shall the confidentiality as permitted by applicable laws be breached. The City shall maintain and retain ownership of any and all documents which result upon the completion of the work and Services under this Agreement as per the terms of this Section. 6. AUDIT AND INSPECTION RIGHTS AND RECORDS RETENTION: A. Contractor agrees to provide access to the City or to any of its duly authorized representatives, to any books, documents, papers, and records of Contractor which are directly pertinent to this Agreement, for the purpose of audit, examination, excerpts, and transcripts. The City may, at reasonable times, and for a period of up to five (5) years following the date of final payment by the City to Contractor under this Agreement, audit and inspect, or cause to be audited and inspected, those books, documents, papers, and records of Contractor which are related to 3 Telemetry/SCADA Services Contract No. 2046386 Contractor's performance under this Agreement. Contractor agrees to maintain all such books, documents, papers, and records at its principal place of business in Miami -Dade County, or its local office in Miami -Dade County or to otherwise make them available in Miami -Dade County for a period of five (5) years after final payment is made under this Agreement and all other pending matters are closed. Contractor's failure to adhere to, or refusal to comply with, this condition shall result in the immediate cancellation of this Agreement by the City. B. The City may, at reasonable times during the term hereof, inspect the Contractor's facilities and perform such tests, as the City deems reasonably necessary, to determine whether the goods or services required to be provided by Contractor under this Agreement conform to the terms hereof. Contractor shall make available to the City all reasonable facilities and assistance to facilitate the performance of tests or inspections by City representatives. All audits, tests, and inspections shall be subject to, and made in accordance with, the provisions of Sections 18-100, 18-101, and 18-102 of the Code of the City of Miami, Florida ("City Code"), which apply to this Agreement, as same may be amended or supplemented, from time to time. 7. AWARD OF AGREEMENT: Contractor represents and warrants to the City that it has not employed or retained any person or company employed by the City to solicit or secure this Agreement and that it has not offered to pay, paid, or agreed to pay any person any fee, commission, percentage, brokerage fee, or gift of any kind contingent upon or in connection with the award of this Agreement. 8. PUBLIC RECORDS: A. Contractor understands that the public shall have access, at all reasonable times, to all documents and information pertaining to City agreements, subject to the provisions of Chapter 119, Florida Statutes, and agrees to allow access by the City and the public to all documents subject to disclosure under applicable laws. Contractor's failure or refusal to comply with the provisions of this section shall result in the immediate cancellation of this Agreement by the City. B. Contractor shall additionally comply with Section 119.0701, Florida Statutes, including without limitation: (1) keep and maintain public records that ordinarily and necessarily would be required by the City to perform this service; (2) upon request from the City's custodian of public records, provide the City with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in Chapter 119, Florida Statutes, or as otherwise provided by law; (3) ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the Agreement if the Contractor does not transfer the records to the City; (4) upon 4 Telemetry/SCADA Services Contract No. 2046386 completion of the Agreement, transfer, at no cost, to the City all public records in possession of the Contractor or keep and maintain public records required by the City to perform the service, if the Contractor transfers all public records to the City upon completion of the Agreement, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements, if the Contractor keeps and maintains public records upon completion of the Agreement, the Contractor shall meet all applicable requirements for retaining public records, all records stored electronically must be provided to the City, upon request from the City's custodian of public records, in a format that is compatible with the information technology systems of the City. Notwithstanding the foregoing, Contractor shall be permitted to retain any public records that make up part of its work product solely as required for archival purposes, as required by law, or to evidence compliance with the terms of the Agreement. C. Should Contractor determine to dispute any public access provision required by Florida Statutes, then Contractor shall do so at its own expense and at no cost to the City. D. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THE CONTRACT, CONTACT THE DIVISION OF PUBLIC RECORDS AT (305) 416-1800, VIA EMAIL AT PUBLICRECORDS@MIAMIGOV.COM, OR REGULAR MAIL AT CITY OF MIAMI OFFICE OF THE CITY ATTORNEY, 444 SW 2ND AVENUE, 9TH FLOOR, MIAMI, FL 33130. THE CONTRACTOR MAY ALSO CONTACT THE RECORDS CUSTODIAN AT THE CITY OF MIAMI DEPARTMENT WHO IS ADMINISTERING THIS CONTRACT. 9. COMPLIANCE WITH FEDERAL. STATE AND LOCAL LAWS: Contractor understands that agreements with local governments are subject to certain laws and regulations, including laws pertaining to public records, conflict of interest, record keeping, etc. City and Contractor agree to comply with and observe all such applicable federal, state and local laws, rules, regulations, codes, and ordinances, as they may be amended from time to time. Contractor further agrees to include in all of Contractor's agreements with subcontractors for any Services related to this Agreement this provision requiring subcontractors to comply with and observe all applicable federal, state, and local laws rules, regulations, codes, and ordinances, 5 Telemetry/SCADA Services Contract No. 2046386 as they may be amended from time to time. Local laws in accordance with this Section shall mean the applicable laws of the City of Miami and Miami -Dade County. 10. INDEMNIFICATION: Contractor shall indemnify, hold and save harmless, and defend (at its own cost and expense), the City, its officers, agents, directors, and/or employees, from all liabilities, damages, losses, judgements, and costs, including, but not limited to, reasonable attorneys' fees, to the extent caused by the negligence, recklessness, negligent act or omission, or intentional wrongful misconduct of Contractor and persons employed or utilized by Contractor in the performance of this Agreement. Contractor shall further, hold the City, its officials and employees, indemnify, save and hold harmless for, and defend (at its own cost), the City its officials and/or employees against any civil actions, statutory or similar claims, injuries or damages arising or resulting from the permitted Services, even if it is alleged that the City, its officials, and/or employees were negligent. In the event that any action or proceeding is brought against the City by reason of any such claim or demand, the Contractor shall, upon written notice from the City, resist and defend such action or proceeding by counsel satisfactory to the City. The Contractor expressly understands and agrees that any insurance protection required by this Agreement or otherwise provided by the Contractor shall in no way limit the responsibility to indemnify, keep and save harmless and defend the City or its officers, employees, agents, and instrumentalities as herein provided. The indemnification provided above shall obligate the Contractor to defend, at its own expense, to and through trial, administrative, appellate, supplemental or bankruptcy proceeding, or to provide for such defense, at the City's option, any and all claims of liability and all suits and actions of every name and description which may be brought against the City, whether performed by the Contractor, or persons employed or utilized by Contractor. These duties will survive the cancellation or expiration of the Contract. This Section will be interpreted under the laws of the State of Florida, including without limitation and interpretation, which conforms to the limitations of Sections 725.06 and/or .08, Florida Statutes, as applicable and as amended. Contractor shall require all subcontractor agreements to include a provision that each subcontractor will indemnify the City in substantially the same language as this Section. The Contractor agrees and recognizes that the City shall not be held liable or responsible for any claims which may result from any actions or omissions of the Contractor in which the City participated either through review or concurrence of the Contractor's actions. In reviewing, approving or rejecting any submissions by the Contractor or other acts of the Contractor, the City, in no way, assumes or shares any responsibility or liability of the Contractor or subcontractor under this Contract. 6 Telemetry/SCADA Services Contract No. 2046386 Ten dollars ($10) of the payments made by the City constitute separate, distinct, and independent consideration for the granting of this indemnification, the receipt and sufficiency of which is voluntarily and knowingly acknowledged by the Contractor. 11. DEFAULT: If Contractor fails to comply with any term or condition of this Agreement or fails to perform in any material way any of its obligations hereunder and fails to cure such failure after reasonable notice from the City, then Contractor shall be in default. Contractor understands and agrees that termination of this Agreement under this section shall not release Contractor from any obligation(s) accruing prior to the effective date of termination. Should Contractor be unable or unwilling to commence to perform the Services within the time provided or contemplated herein, then, in addition to the foregoing, Contractor shall be liable to the City for all expenses incurred by the City in preparation and negotiation of this Agreement, as well as all costs and expenses incurred by the City in the re -procurement of the Services, including consequential and incidental damages. Upon the occurrence of a default hereunder the City, in addition to all remedies available to it by law, may immediately, upon written notice to Contractor, terminate this Agreement whereupon all payments, advances, or other compensation paid by the City to Contractor while Contractor was in default shall be immediately returned to the City. If the City fails to comply with any term or condition of this Agreement or fails to perform in any material way any of its obligations hereunder and fails to cure such failure after reasonable notice from Contractor, the City shall be in default, which shall be treated as a termination pursuant to Section 13. 12. RESOLUTION OF AGREEMENT DISPUTES: Contractor understands and agrees that all disputes between Contractor and the City based upon an alleged violation of the terms of this Agreement by the City shall be submitted to the City Manager for his/her resolution, prior to Contractor being entitled to seek judicial relief in connection therewith. In the event that the amount of compensation hereunder exceeds Twenty - Five Thousand and 00/100 Dollars ($25,000.00), the City Manager's decision shall be approved or disapproved, as applicable, by the City Commission, whose decision shall be final. Contractor shall not be entitled to seek judicial relief, recourse, remedy or to file a civil action unless: (i) it has first received City Manager's written decision, approved or disapproved, as applicable, by the City Commission if the amount of compensation hereunder exceeds Twenty -Five Thousand and 00/100 Dollars ($25,000.00), or (ii) a period of sixty (60) days has expired, after submitting to the City Manager a detailed statement of the dispute, accompanied by all supporting documentation one hundred twenty (120) days if City Manager's decision is subject to City Commission approval); or (iii) City has waived compliance with the procedure set forth in this section by a written 7 Telemetry/SCADA Services Contract No. 2046386 instrument clearly waiving compliance, signed by the City Manager. The adherence to this Section is the condition precedent to the institution of any civil action by the Contractor against the City. 13. TERMINATION: OBLIGATIONS UPON TERMINATION: A. The City, acting by and through its City Manager, shall have the right to terminate this Agreement, in its sole discretion, and without penalty, at any time, by giving written notice to Contractor at least thirty (30) calendar days prior to the effective date of such termination. In such event, the City shall pay to Contractor compensation for Services rendered and approved expenses incurred prior to the effective date of termination. In no event shall the City be liable to Contractor for any additional compensation and expenses incurred, other than that provided herein, and in no event shall the City be liable for any consequential or incidental damages. The Contractor shall have no recourse or remedy against the City for a termination under this subsection except for payment of fees due prior to the effective date of termination. B. The City, by and acting through its City Manager, shall have the right to terminate this Agreement, in its sole discretion, and without penalty, upon the occurrence of an event of a material breach hereunder, and failure to cure the same within thirty (30) days after written notice of default. In such event, the City shall not be obligated to pay any amounts to Contractor for Services rendered by Contractor after the date of termination, but the parties shall remain responsible for any payments that have become due and owing as of the effective date of termination. In no event shall the City be liable to Contractor for any additional compensation and expenses incurred, other than that provided herein, and in no event shall the City be liable for any direct, indirect, special, consequential, or incidental damages. 14. JNSURANCE: A. Contractor shall, always during the term hereof, maintain such insurance coverage(s) as may be required by the City. The insurance coverage(s) required as of the Effective Date of this Agreement are attached hereto as Exhibit "D" and incorporated herein by this reference. The City RFP number and title of the RFP must appear on each certificate of insurance. The Contractor shall add the City of Miami as an additional insured to its commercial general liability, and auto liability policies, and as a named certificate holder on all policies. Contractor shall correct any insurance certificates as requested by the City's Risk Management Administrator. All such insurance, including renewals, shall be subject to the approval of the City for adequacy of protection and evidence of such coverage(s) and shall be furnished to the City Risk Management Administrator on Certificates of Insurance indicating such insurance to be in force and effect and any cancelled or non -renewed policy will be replaced with no coverage gap and a current Certificate of Insurance will be provided. Completed Certificates of Insurance shall be filed with the City prior to the performance of Services hereunder, provided, however, that 8 Telemetry/SCADA Services Contract No. 2046386 Contractor shall at any time upon request file duplicate copies of the Certificate of Insurance with the City. B. If, in the judgment of the City, prevailing conditions warrant the provision by Contractor of additional liability insurance coverage or coverage which is different in kind, the City reserves the right to require the provision by Contractor of an amount of coverage different from the amounts or kind previously required and shall afford written notice of such change in requirements thirty (30) days prior to the date on which the requirements shall take effect. Should the Contractor fail or refuse to satisfy the requirement of changed coverage within thirty (30) days following the City's written notice, this Agreement shall be considered terminated on the date that the required change in policy coverage would otherwise take effect. C. Contractor understands and agrees that all liabilities regarding the use of any of Contractor's employees or any of Contractor's subcontractors for Services related to this Agreement shall be borne solely by Contractor throughout the term of this Agreement and that this provision shall survive the termination of this Agreement. Contractor further understands and agrees that insurance for each employee of Contractor and each subcontractor providing Services related to this Agreement shall be maintained in good standing and approved by the City Risk Management Director throughout the duration of this Agreement. D. Contractor shall be responsible for assuring that the insurance certificates required under this Agreement remain in full force and effect for the duration of this Agreement, including any extensions hereof. If insurance certificates are scheduled to expire during the term of this Agreement and any extension hereof, Contractor shall be responsible for submitting new or renewed insurance certificates to the City's Risk Management Administrator as soon as coverages are bound with the insurers. In the event that expired certificates are not replaced, with new or renewed certificates which cover the term of this Agreement and any extension thereof: (i) the City shall suspend this Agreement until the new or renewed certificate(s) are received in acceptable form by the City's Risk Management Administrator; or (ii) the City may, at its sole discretion, terminate the Agreement for cause and seek re -procurement damages from Contractor in conjunction with the violation of the terms and conditions of this Agreement. E. Compliance with the foregoing requirements shall not relieve Contractor of its liabilities and obligations under this Agreement. 15. NONDISCRIMINATION: Contractor represents to the City that Contractor does not and will not engage in discriminatory practices and that there shall be no discrimination in connection with Contractor's performance under this Agreement on account of race, color, sex, religion, age, handicap, marital 9 Telemetry/SCADA Services Contract No. 2046386 status, or national origin. Contractor further covenants that no otherwise qualified individual shall, solely due to his/her race, color, sex, religion, age, handicap, marital status, or national origin, be excluded from participation in, be denied services, or be subject to discrimination under any provision of this Agreement. 16. ASSIGNMENT: The Contractor's services are considered specialized and unique. This Agreement shall not be assigned, sold, transferred, pledged, or otherwise conveyed by Contractor, in whole or in part, and Contractor shall not assign or otherwise subcontract any part of its operations performing these services under this Agreement, without the prior written consent of the City Manager, which may be withheld or conditioned, in the City Manager's sole discretion. 17. NOTICES: All notices or other communications required under this Agreement shall be in writing and shall be given by hand -delivery or by registered or certified U.S. Mail, return receipt requested, addressed to the other party at the address indicated herein or to such other address as a party may designate by notice given as herein provided. Notice shall be deemed given on the day on which personally delivered; or, if by mail, on the fifth day after being posted or the date of actual receipt, whichever is earlier. TO CONTRACTOR: Star Controls, Inc. 11555 Heron Bay Blvd Suite 200 Coral Springs, FL 33076 10 TO THE CITY OF MIAMI: James Reyes City Manager 444 SW 2nd Avenue, 10th Floor Miami, FL 33130-1910 George K. Wysong III City Attorney 444 SW 2nd Avenue, 9th Floor Miami, FL 33130-1910 Juvenal Santana, P.E. Director Resilience & Public Works 444 SW 2nd Avenue, 8th Floor Miami, FL 33130-1910 Annie Perez, CPPO Procurement Director 444 SW 2nd Avenue, 6th Floor Miami, FL 33130-1910 Telemetry/SCADA Services Contract No. 2046386 18. MISCELLANEOUS PROVISIONS: A. This Agreement shall be construed and enforced according to the laws of the State of Florida. Venue in any proceedings between the parties shall be in Miami -Dade County, Florida. Each party shall bear its own attorneys' fees. Each party waives any defense, whether asserted by motion or pleading, that the aforementioned courts are an improper or inconvenient venue. Moreover, the parties consent to the personal jurisdiction of the aforementioned courts and irrevocably waive any objections to said jurisdiction. The parties irrevocably, knowingly and voluntarily waive any rights to a jury trial in any action or proceeding between them arising out of this Agreement. B. No waiver or breach of any provision of this Agreement shall constitute a waiver of any subsequent breach of the same or any other provision hereof, and no waiver shall be effective unless made in writing. C. Should any provision, paragraph, sentence, word, or phrase contained in this Agreement be determined by a court of competent jurisdiction to be invalid, illegal, or otherwise unenforceable under the laws of the State of Florida or the City of Miami, such provision, paragraph, sentence, word, or phrase shall be deemed modified to the extent necessary in order to conform with such laws, or if not modifiable, then the same shall be deemed severable, and in either event, the remaining terms and provisions of this Agreement shall remain unmodified and in full force and effect or limitation of its use. D. Contractor shall comply with all applicable laws, rules, and regulations in the performance of this Agreement, including but not limited to licensure, and certifications required by law for professional service Contractors. E. No modification or amendment hereto shall be valid unless in writing and executed by properly authorized representatives of the parties hereto. Except as otherwise set forth in Section 2 above, the City Manager shall have the sole authority to extend, amend, or modify this Agreement on behalf of the City. 19. SUCCESSORS AND ASSIGNS: This Agreement shall be binding upon the parties hereto, their heirs, executors, legal representatives, successors, or assigns, if any. 20. JNDEPENDENT CONTRACTORS: Contractor has been procured and is being engaged to provide Services to the City as an independent contractor, and not as an agent or employee of the City. Accordingly, neither Contractor, nor its employees, nor any subcontractor hired by Contractor to provide any Services under this Agreement shall attain, nor be entitled to, any rights, emoluments, or benefits under the Civil Service or Pension Ordinances of the City, nor any rights afforded classified or 11 Telemetry/SCADA Services Contract No. 2046386 unclassified employees of the City. Contractor further understands that Florida Workers' Compensation benefits available to employees of the City are not available to Contractor, its employees, or any subcontractor hired by Contractor to provide any Services hereunder, and Contractor agrees to provide or to require subcontractor(s) to provide, as applicable, workers' compensation insurance for any employee or agent of Contractor rendering Services to the City under this Agreement. Contractor further understands and agrees that Contractor's or subcontractors' use or entry upon City properties shall not in any way change its or their status as an independent contractor. 21. CONTINGENCY CLAUSE: Funding for this Agreement is contingent on the availability of funds and continued authorization for program activities and the Agreement is subject to amendment or termination due to lack of funds, reduction of funds, failure to allocate or appropriate funds, and/or change in program directions, applicable laws or regulations, upon thirty (30) days written notice. 22. FORCE MAJEURE: A "Force Majeure Event" shall mean an act of God, act of governmental body or military authority, fire, explosion, power failure, flood, storm, hurricane, sink hole, other natural disasters, epidemic, riot or civil disturbance, war or terrorism, sabotage, insurrection, blockade, or embargo not within the control of the Contractor. In the event that either party is delayed in the performance of any act or obligation pursuant to or required by the Agreement because of a Force Majeure Event as herein defined, the time for required completion of such act or obligation shall be extended by the number of days equal to the total number of days, if any, that such Force Majeure Event actually delay such party. The party seeking delay in performance shall give notice to the other party in writing, within two (2) days of the Force Majeure Event, specifying the anticipated duration of the delay, and if such delay shall extend beyond the duration specified in such notice, additional notice shall be repeated no less than monthly so long as such delay due to a Force Majeure Event continues. Any party seeking delay in performance due to a Force Majeure Event shall use its best efforts to rectify any condition causing such delay and shall cooperate with the other party to overcome any delay that has resulted. 23. CITY NOT LIABLE FOR DELAYS: Contractor hereby understands and agrees that in no event shall the City be liable for, or responsible to Contractor or any subcontractor, or to any other person, firm, or entity for or on account of, any stoppages or delay(s) in work herein provided for, or any damages whatsoever related thereto, because of any injunction or other legal or equitable proceedings or on account of any delay(s) for any cause over which the City has no control. The sole remedy 12 Telemetry/SCADA Services Contract No. 2046386 which may be granted to the Contractor, in the reasonable discretion of the City Manager, following a prompt and detailed request to be officially transmitted by the Contractor is an extension of time. No other recourse or remedy will be available to the Contractor against the City. 24. USE OF NAME: Contractor understands and agrees that the City is not engaged in research for advertising, sales promotion, or other publicity purposes. Contractor is allowed, within the limited scope of normal and customary marketing and promotion of its work, to use the general results of this project and the name of the City. The Contractor agrees to protect any confidential information provided by the City and will not release information of a specific nature without prior written consent of the City Manager or the City Commission. 25. NO CONFLICT OF INTEREST: Pursuant to City of Miami Code Section 2-611, as amended ("City Code"), regarding conflicts of interest, Contractor hereby certifies to the City that no individual member of Contractor, no employee, and no subcontractor under this Agreement nor any immediate family member of any of the same is also a member of any board, commission, or agency of the City. Contractor hereby represents and warrants to the City that throughout the term of this Agreement, Contractor, its employees, and its subcontractors will abide by this prohibition of the City Code. 26. NO THIRD -PARTY BENEFICIARY: No persons other than the Contractor and the City (and their successors and assigns) shall have any rights as an express or implied third -party beneficiary whatsoever under this Agreement. 27. SURVIVAL: All obligations (including but not limited to indemnity and obligations to defend, save and hold harmless) and rights of any party arising during or attributable to the period prior to expiration or earlier termination of this Agreement shall survive such expiration or earlier termination. 28. TRUTH -IN -NEGOTIATION CERTIFICATION. REPRESENTATION AND WARRANTY: Contractor hereby certifies, represents and warrants to the City that on the date of Contractor's execution of this Agreement, and so long as this Agreement shall remain in full force and effect, the wage rates and other factual unit costs supporting the compensation to Contractor under this Agreement are and will continue to be accurate, complete, and current. Contractor understands, agrees, and acknowledges that the City shall adjust the amount of compensation and any additions thereto to exclude any significant sums by which the City determines the contract price of compensation hereunder was increased due to inaccurate, incomplete, or non -current wage rates and other factual unit costs. All such contract adjustments shall be made within one (1) year of the end of this Agreement, whether naturally expiring or earlier terminated pursuant to the 13 Telemetry/SCADA Services Contract No. 2046386 provisions hereof. 29. COUNTERPARTS: This Agreement may be executed in counterparts, each of which shall constitute an original, but all of which, when taken together, shall constitute one and the same agreement. This Agreement may be executed in counterparts, each of which shall be an original as against either party whose signature appears thereon, but all of which taken together shall constitute but one and the same instrument. An executed facsimile or electronic scanned copy of this Agreement shall have the same force and effect as an original. The parties shall be entitled to sign and transmit an electronic signature on this Agreement (whether by facsimile, PDF or other email transmission), which signature shall be binding on the party whose name is contained therein. Any party providing an electronic signature agrees to promptly execute and deliver to the other parties an original signed Agreement upon request. 30. ENTIRE AGREEMENT: This instrument and its attachments constitute the sole and final agreement of the parties relating to the subject matter hereof and correctly set forth the rights, duties, and obligations of each to the other as of its date. Any prior agreements, promises, negotiations, or representations not expressly set forth in this Agreement are of no force or effect. 31. VENDOR LISTS: The following lists are maintained by the Florida Department of Management Services and are available at https://www.dms.myflorida.com/. By accepting this Agreement, Contractor affirms it is not included in any of the following lists. Convicted Vendor List. Pursuant to § 287.133, F.S., "[a] person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity; may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list." Discriminatory Vendor List. Pursuant to § 287.134, F.S., "[a]n entity or affiliate who has been placed on the discriminatory vendor list may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity; may not be awarded or perform 14 Telemetry/SCADA Services Contract No. 2046386 work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity." Antitrust Violator Vendor List. Pursuant to § 287.137, F.S., "[a] person or an affiliate who has been placed on the antitrust violator vendor list following a conviction or being held civilly liable for an antitrust violation may not submit a bid, proposal, or reply for any new contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply for a new contract with a public entity for the construction or repair of a public building or public work; may not submit a bid, proposal, or reply on new leases of real property to a public entity; may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a new contract with a public entity; and may not transact new business with a public entity." Forced Labor Vendor List. Pursuant to § 287.1346, F.S., "[a]n agency may not accept a bid, proposal, or reply from; award a contract to; or transact business pertaining to the provision of commodities with a company on the forced labor vendor list, or an entity under the control of such company, for a period of 365 days after the date the company was placed on the list unless the company is removed from the list pursuant to paragraph (5)(d)." Suspended Vendor List. Pursuant to § 287.1351, F.S., "[a]n agency may not accept a bid, proposal, or reply from, or enter into or renew any contract with, a vendor on the suspended vendor list until such vendor has been removed from the suspended vendor list and returned to the vendor list maintained by the department pursuant to s. 287.042(1)(a) and (b) and the vendor has reimbursed the agency for any re -procurement costs." 32. SCRUTINIZED COMPANIES LISTS: The following lists are maintained by the Florida State Board of Administration and are available at https://www.sbafla.com/. Scrutinized Companies that Boycott Israel List. Pursuant to § 287.135, F.S., by accepting this Agreement, the Contractor certifies that it is not participating in a boycott of Israel. Scrutinized Companies with Activities in Sudan and in Iran Terrorism Sectors Lists; Business Operation in Cuba and Syria. Pursuant to § 287.135, F.S., if this Agreement is valued at one million dollars ($1,000,000) or more, by accepting this Agreement, the Contractor certifies that it is not on the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in Iran Terrorism Sectors List and that it does not have business operations in Cuba or Syria. 33. FOREIGN COUNTRY OF CONCERN ATTESTATION: Pursuant to § 287.138, F.S., a governmental entity may not enter into, extend, or renew a contract with an entity that would give access to an individual's personal identifying information if: (a) The entity is owned by the government of a foreign country of concern; (b) The government of a foreign country of concern has a controlling interest in the entity; or 15 Telemetry/SCADA Services Contract No. 2046386 (c) The entity is organized under the laws of, or has its principal place of business in, a foreign country of concern. If this Agreement involves access to an individual's personal identifying information, Contractor must execute and submit to the City an affidavit in compliance with § 287.138, F.S., attached and incorporated into this Agreement as "Foreign Country of Concern Attestation." Failure to comply entitles the City to suspend or terminate this Agreement immediately and without prior notice, and the City will have no liability to Contractor for any additional, consequential, or incidental damages arising from such suspension or termination. 34. ANTI -HUMAN TRAFFICKING AFFIDAVIT: The Contractor confirms and certifies that it is not in violation of Section 787.06, Florida Statutes, and that it does not and shall not use "coercion" for labor or services as defined in Section 787.06, Florida Statutes. The Contractor shall execute and submit to the City an Affidavit, of even date herewith, in compliance with Section 787.06(13), Florida Statutes, attached an incorporated herein as Exhibit "F", Anti -Human Trafficking Affidavit. If the Contractor fails to comply with the terms of this Section, the City may suspend or terminate this Agreement immediately, without prior notice, and in no event shall the City be liable to Contractor for any additional compensation or for any consequential or incidental damages. 35. E-Verify Employment Verification: The Contractor shall E-Verify the employment status of all employees and subconsultants to the extent required by federal, state, and local laws, rules, and regulations. The City shall consider the employment by Contractor of unauthorized aliens a violation of Section 274A(e) of the Immigration and Nationality Act. If the Contractor knowingly employs unauthorized aliens, such violation shall be cause for termination of this Agreement. Furthermore, Contractor agrees to utilize the U.S. Agency of Homeland Security's E-Verify System, https://e-verify.uscis.gov/emp, to verify the employment eligibility of all employees during the term of this Agreement. The Contractor shall also include a requirement in subconsultant agreements that the subconsultant shall also utilize the E-Verify System to verify the employment eligibility of all employees of the subconsultant during the term of this Agreement. 16 Telemetry/SCADA Services Contract No. 2046386 IN WITNESS WHEREOF, the parties have executed this Agreement, or have caused the same to be executed, as of the date and year first above written. "Contractor" STAR CONTROLS, INC., a Florida profit corporation ATTEST: By: By: Name: Emma Light Name: Tzvi Magril Title: Operations Manager ATTEST: By: c— Signed by: 'Easo��o�_„5� Todd B. Hannon' City Clerk Title: President "CITY" CITY OF MIAMI, a Florida municipal corporation By: James Reyes City Manager APPROVED AS TO LEGAL FORM AND APPROVED AS TO INSURANCE CORRECTNESS: By: -sI9ned by ar (A st III ,a�tdd�aae George K. Wysong III Matter ID 25-2910 City Attorney 17 Telemetry/SCADA Services REQUIREMENTS: By: rSigned by FroaAk GOwtGA) David Ruiz, Interim Director Risk Management Contract No. 2046386 EXHIBIT A RFP 2049386 THIS PAGE INTENTIONALLY LEFT BLANK 18 Telemetry/SCADA Services Request for Proposals (RFP) Issued by: City of Miami Procurement Department Miami Riverside Center 444 SW 2"dAve, 6th Floor Miami, Florida 33130 Web Site Address: www.miamigov.com/procurement RFP Number: Title: Issue Date/Time: RFP Closing Date/Time: Pre-Bid/Pre-Proposal Conference: Pre-Bid/Pre-Proposal Date/Time: Pre-Bid/Pre-Proposal Location: Deadline for Request for Clarification: Contracting Officer: Hard Copy Submittal Location: Contracting Officer E-Mail Address: Contracting Officer Facsimile: 2046386 Request for Proposals for Storm Pump Station Telemetry and Supervisory Control and Data ("SCADA") System November 14, 2025 December 19, 2025, at 5:00 PM Voluntary November 19, 2025, at 2:00 PM Virtual December 2, 2025, at 2:00 PM Gray, Tahlia HARDCOPY SUBMITTALS NOT ALLOWED FOR THIS SOLICITATION tgray@miamigov.com 305-400-5019 Certification Statement Please quote on this form, if applicable, net prices for the item(s) listed. Return signed original and retain a copy for your files. Prices should include all costs, including transportation to destination. The City reserves the right to accept or reject all or any part of this submission. Prices should be firm for a minimum of 180 days following the time set for closing of the submissions. In the event of errors in extension of totals, the unit prices shall govern in determining the quoted prices. We (I) certify that we have read your solicitation, completed the necessary documents, and propose to furnish and deliver, F.O.B. DESTINATION, the items or services specified herein. The undersigned hereby certifies that neither the contractual party nor any of its principal owners or personnel have been convicted of any of the violations or debarred or suspended as set in section 18-107 or Ordinance No. 12271. By signing below, the Proposer also certifies, pursuant to section 287.135(5), Florida Statutes, that at the time of submitting its Proposal it: (a) is not on the "Scrutinized Companies with Activities in Sudan List" or the "Scrutinized Companies with Activities in Iran Terrorism Sectors List"; (b) does not have business operations in Cuba or Syria; and (c) is not participating in a boycott of Israel. The Proposer further acknowledges that a false certification may subject it to contract termination, civil penalties, and debarment as provided under section 287.135. All exceptions to this submission have been documented in the section below (refer to paragraph and section). EXCEPTIONS: We (I) certify that any and all information contained in this submission is true; and we (I) further certify that this submission is made without prior understanding, agreement, or connection with any corporation, firm, or person submitting a submission for the same materials, supplies, equipment, or service, and is in all respects fair and without collusion or fraud. We (I) agree to abide by all terms and conditions of this solicitation and certify that I am authorized to sign this submission for the submitter. Please print the following and sign your name: PROPOSER NAME: ADDRESS: PHONE: FAX: EMAIL: CELL(Optional): SIGNED BY: TITLE: DATE: FAILURE TO COMPLETE, SIGN, AND RETURN THIS FORM SHALL DISQUALIFY THIS RESPONSE. Certifications Legal Name of Firm: Entity Type: Partnership, Sole Proprietorship, Corporation, etc. Year Established: Office Location: City of Miami, Miami -Dade County, or Other Business Tax Number/Occupational License Number: Business License Issuing Agency/Occupational License Issuing Agency: Business License Expiration Date/Occupational License Expiration Date: Federal Employee Identification Number (FEIN): Will Subcontractor(s) be used'? (Yes or No) Please list and acknowledge all addendum/addenda received. List the addendum/addenda number and date of receipt (i.e. Addendum No. 1, 1/1/25). If no addendum/addenda was/were issued, please insert N/A. If Proposer has a Local Office, as defined under Chapter 18/Article III, Section 18-73 of the City Code, has Proposer filled out, notarized, and included with its RFP response the "City of Miami Local Office Certification" form? YES OR NO? (The City of Miami Local Office Certification form is located in the BidNet Procurement Solutions Platform ("BidNet"), under the Attachments Section of this solicitation.) The Proposer has reviewed the attached Sample Professional Service Agreement ("Agreement"). Does Proposer acknowledge that the attached Agreement is an example of the standard Agreement used in conjunction with the provisions of these services? Yes or No. IMPORTANT NOTICE TO PROPOSERS: • FAILURE TO COMPLETE, SIGN AND UPLOAD THE CERTIFICATION STATEMENT AND CERTIFICATIONS SECTION WILL RENDER YOUR PROPOSAL NON -RESPONSIVE. • FAILURE TO SIGN, NOTARIZE, AND UPLOAD ATTACHMENT E - ANTI -HUMAN TRAFFICKING AFFIDAVIT WILL RENDER YOUR BID NON -RESPONSIVE. • CONTACT BIDNET VENDOR SUPPORT TOLL -FREE NUMBER 800-835-4603 OPTION 2, OR EMAIL SUPPORT(&,BIDNET.COM, FOR BIDNET TECHNICAL DIFFICULTIES AND PROBLEMS. HAVE YOU INCLUDED: COMPLETED: CHECKLIST ❑ Yes Certification Statement This form must be completed, signed, and returned with Response. ❑ Yes Certifications Sheet. All items are to be completed. ❑ Yes Local Office Location Affidavit, if applicable. ❑ Yes Completed, signed and notarized Attachment E - Anti -Human Trafficking Affidavit ❑ Yes Completed, signed, and notarized Attachment F, Affidavit of Responsibility ❑ Yes Completed price proposal packet. All sheets must be completed. Failure to submit all forms in the Attachment C - Pricing Packet, as required, shall disqualify Proposer from consideration, and Proposer shall be deemed non -responsive. Only one Price Packet is acceptable, deviation from the forms in the packet will render the proposal non -responsive. ❑ Yes Complete Response with all required documentation: Includes all requirements as listed in Section 4.0 Submission Requirements and takes into consideration the evaluation criteria outlined in Section 5.0 Evaluation/Selection Process. Terms and Conditions 1.General Conditions GENERAL TERMS AND CONDITIONS Intent: The General Terms and Conditions described herein apply to the acquisition of goods/equipment/services with an estimated aggregate cost of $25,000.00 or more. Definition: A formal solicitation is defined as issuance of an Invitation for Bids, Request for Proposals, Request for Qualifications, or Request for Letters of Interest pursuant to the City of Miami Procurement Code and/or Florida Law, as amended. Formal Solicitation and Solicitation shall be defined in the same manner herein. 1.1 ACCEPTANCE OF GOODS, EQUIPMENT OR SERVICES - Any good(s), equipment or services delivered under this formal solicitation, if applicable, shall remain the property of the seller until a physical inspection and actual usage of the good is made, and thereafter is accepted as satisfactory to the City. It must comply with the terms herein and be fully in accordance with specifications and of the highest quality. In the event the goods/equipment supplied to the City are found to be defective or does not conform to specifications, the City reserves the right to cancel the order upon written notice to the Contractor and return the product to the Contractor at the Contractor's expense. In terms of this Solicitation the use of the word "services" includes without limitation professional and personal services as that term professional and personal services is defined by the City of Miami Procurement Ordinance and as set forth in the Definitions Section 18-73 of the City Code. 1.2 ACCEPTANCE OF OFFER - Subject to prior occurrence of all condition's precedent set forth in Section 1.88, The signed or electronic submission of your solicitation response shall be considered an offer on the part of the Proposer; such offer shall be deemed accepted upon the occurrence of all conditions precedent and issuance by the City of a purchase order or notice to proceed, as applicable. In summation, execution of a Professional Services Agreement and/or Agreement, approval by a referendum as stated in this RFP, and issuance by the City of a purchase order, and/or notice to proceed, as applicable. 1.3 ACCEPTANCE/REJECTION - The City reserves the right to accept or reject any or all responses or parts of after opening/closing date and request re -issuance on the goods/services described in the formal solicitation. In the event of such rejection, the Director of Procurement shall notify all affected Proposers and make available a written explanation for the rejection. The City also reserves the right to reject the response of any Proposer: 1) Who has previously failed to properly perform under the terms and conditions of a Professional Services Agreement ("PSA") and/or Agreement, 2) Who failed to deliver on time, contracts of a similar nature, 3) Who is not in a position to perform the requirements defined in this formal solicitation, 4) Who has been debarred, 5) Who is on the convicted vendors list, 6) Who is indebted to the City, or 7) Who is otherwise determined to be non -responsive or non -responsible. The City further reserves the right to waive any irregularities, minor informalities, or technicalities in any or all responses and may, at its discretion, re -issue this formal solicitation. 1.4 ADDENDA - It is the Proposer's responsibility to ensure receipt of all Addenda. Addenda are available on the BidNet Procurement Solutions Platform ("BidNet") only. 1.5 ALTERNATE RESPONSES WILL NOT BE CONSIDERED. 1.6 ASSIGNMENT - Contractor agrees not to subcontract, assign, transfer, convey, sublet, or otherwise dispose of the resulting Contract, or any or all its rights, title, or interest herein, without the City of Miami's prior written consent. 1.7 ATTORNEY'S FEES - In connection with any litigation, mediation and arbitration arising out of this Contract, each party shall bear their own attorney's fees through and including appellate litigation and any post judgment proceedings. 1.8 AUDIT RIGHTS AND RECORDS RETENTION - The Successful Proposer agrees to provide access at all reasonable times to the City, or to any of its duly authorized representatives, to any books, documents, papers, and records of Contractor which are directly pertinent to this formal solicitation, for the purpose of audit, examination, excerpts, and transcriptions. The Successful Proposer shall maintain and retain any and all of the books, documents, papers and records pertinent to the Contract for three (3) years after the City makes final payment and all other pending matters are closed. Contractor's failure to or refusal to comply with this condition shall result in the immediate cancellation of this contract by the City. The audit and inspection provisions set forth in Sections 18- 100 to 18-102, City Code, are deemed as being incorporated by reference herein as set forth in full. 1.9 AVAILABILITY OF CONTRACT STATE-WIDE - Any governmental, not -for -profit, or quasi - governmental entity in the State of Florida, may avail itself of this Contract and purchase any, and all goods/services, specified herein from the Successful Proposer at the Contract price(s) established herein, when permissible by Federal, State, and local laws, rules, and regulations. Additionally, any governmental entity outside of the State of Florida but, within the Continental United States of America, may avail itself to this Contract and purchase any and all goods/services, specified herein from the Successful Proposer at the Contract price(s) established herein, when permissible by Federal, State, and local laws, rules, and regulations. Each governmental, not -for -profit, or quasi -governmental entity which uses this Formal Solicitation and resulting Contract will establish its own Contract, place its own orders, issue its own purchase orders, be invoiced there from and make its own payments, determine shipping terms and issue its own exemption certificates as required by the Successful Proposer. 1.10 AWARD OF CONTRACT: A. The PSA and/or Agreement, the Formal Solicitation, the Proposer's response, any addenda issued, and the blanket purchase order shall constitute the entire contract, unless modified in accordance with any ensuing amendment or addenda. B. The award of this contract may be preconditioned on the subsequent submission of other documents as specified in the Special Conditions or Technical Specifications. Proposer shall be in default of its contractual obligation if such documents are not submitted in a timely manner and in the form required by the City. Where Proposer is in default of these contractual requirements, the City, through action taken by the Department of Procurement, will void its acceptance of the Proposer's Response and may accept the Response from the next lowest responsive, responsible Proposal most advantageous to the City or re -solicit the City's requirements. The City, at its sole discretion, may seek monetary restitution from Proposer and its proposal bond or guaranty, if applicable, as a result of damages or increased costs sustained as a result of the Proposer's default. C. The term of the contract shall be specified in one of three documents which shall be issued to the Successful Proposer. These documents may either be a blanket purchase order, notice of award and/or contract award sheet. D. The City reserves the right to automatically extend this contract for up to one hundred eighty (180) calendar days beyond the stated contract term in order to provide City departments with continual service and supplies while a new contract is being solicited, evaluated, and awarded. If the right is exercised, the City shall notify the Proposer, in writing, of its intent to extend the contract at the same price, terms and conditions for a specific number of days. Additional extensions over the first one hundred eighty (180) day extension may occur if, the City and the Successful Proposer are in mutual agreement of such extensions. E. Where the contract involves a single shipment of goods to the City, the contract term shall conclude upon completion of the expressed or implied warranty periods. F. An PSA and/or Agreement shall be awarded to the Proposer by the City Commission based upon the minimum qualification requirements reflected herein. As a result of an RFP, RFQ, or RFLI, the City reserves the right to execute or not execute, as applicable, a PSA and/or Agreement with the Proposer, whichever is determined to be in the City's best interests. Such PSA and/or Agreement which will be furnished by the City, will contain certain terms as are in the City's best interests, and will be subject to approval as to legal form by the City Attorney. All conditions precedent identified in Section 1.88 before any Agreement is binding. 1.11 BID BOND/ BID SECURITY - A cashier's or certified check, or a Bid Bond signed by a recognized surety company that is licensed to do business in the State of Florida, payable to the City of Miami, for the amount bid is required from all Proposers, if so, indicated under the Special Conditions. This check or bond guarantees that the Proposer will accept the order or contract/agreement, as proposed, if it is awarded to the Proposer. Proposer shall forfeit proposal deposit to the City should the City award the contract/agreement to the Proposer and if Proposer fails to accept the award. The City reserves the right to reject any and all surety tendered to the City. Proposal deposits are returned to unsuccessful Proposers within ten (10) days after the award and Successful Proposer's acceptance of award. If sixty (60) days have passed after the date of the formal solicitation closing date, and no contract has been awarded, all deposits will be returned on demand. 1.12 RESPONSE FORM - All forms should be completed, signed, and submitted accordingly. 1.13 BID SECURITY FORFEITED LIQUIDATED DAMAGES - Failure to execute a PSA and/or Agreement and/or file an acceptable Performance Bond, when required, as provided herein, shall be just cause for the annulment of the award and the forfeiture of the Bid Security to the City, which forfeiture shall be considered, not as a penalty, but in mitigation of damages sustained. Award may then be negotiated with the next highest -ranked responsive and responsible Proposal most advantageous to the City or all responses may be rejected. 1.14 BRAND NAMES - If and wherever in the specifications brand names, makes, models, names of any manufacturer, trade names, or Proposer catalog numbers are specified, it is for the purpose of establishing the type, function, minimum standard of design, efficiency, grade, or quality of goods only. When the City does not wish to rule out other competitors' brands or makes, the phrase "OR EQUAL" is added. When bidding/proposing an approved equal, Proposers will submit, with their response, complete sets of necessary data (factory information sheets, specifications, brochures, etc.) in order for the City to evaluate and determine the equality of the item(s) bid/proposed. The City shall be the sole judge of equality, and its decision shall be final. Unless otherwise specified, evidence in the form of samples may be requested if the proposed brand is other than specified by the City. Such samples are to be furnished after formal solicitation opening/closing only upon request of the City. If samples should be requested, such samples must be received by the City no later than seven (7) calendar days after a formal request is made. 1.15 CANCELLATION - The City reserves the right to cancel all formal solicitations before its opening/closing. In the event of proposal cancellation, the Director of Procurement shall notify all prospective Proposers and make available a written explanation for the cancellation. 1.16 CAPITAL EXPENDITURES - Proposer understands that any capital expenditure that the firm makes, or prepares to make, in order to deliver/perform the goods/services required by the City, is a business risk which the Contractor must assume. The City will not be obligated to reimburse amortized or unamortized capital expenditures, or to maintain the approved status of any Contractor. If Contractor has been unable to recoup its capital expenditures during the time it is rendering such goods/services, it shall not have any claim upon the City 1.17 CITY NOT LIABLE FOR DELAYS - It is further expressly agreed that in no event shall the City be liable for, or responsible to, the Proposer/Consultant, any sub-contractor/sub-consultant, or to any other person for, or on account of, any stoppages or delay in the work herein provided for by injunction or other legal or equitable proceedings or on account of any delay for any cause over which the City has no control. 1.18 COLLUSION - Proposer, by submitting a response, certifies that its response is made without previous understanding, agreement, or connection either with any person, firm or corporation submitting a response for the same items/services or with the City of Miami's Procurement Department or initiating department. The Proposer certifies that its response is fair, without control, collusion, fraud, or other illegal action. Proposer certifies that it is in compliance with the Conflict of Interest and Code of Ethics Laws. The City will investigate all potential situations where collusion may have occurred, and the City reserves the right to reject any and all responses where collusion may have occurred. 1.19 COMPLIANCE WITH FEDERAL, STATE AND LOCAL LAWS - Contractor understands that contracts between private entities and local governments are subject to certain laws and regulations, including laws pertaining to public records, conflict of interest, records keeping, competitive solicitations etc., et. al., as applicable. City and Contractor agree to comply with and observe all applicable laws, codes, and ordinances as that may in any way affect the goods or equipment offered, including but not limited to: A. Executive Order 11246, which prohibits discrimination against any employee, applicant, or client because of race, creed, color, national origin, sex, or age with regard to, but not limited to, the following: employment practices, rate of pay or other compensation methods, and training selection. B. Occupational, Safety and Health Act (OSHA), as applicable to this Formal Solicitation. C. The State of Florida Statutes, Section 287.133(3)(A) on Public Entity Crimes. D. Environment Protection Agency (EPA), as applicable to this Formal Solicitation. E. Uniform Commercial Code (Florida Statutes, Chapter 672). F. Americans with Disabilities Act of 1990, as amended. G. National Institute of Occupational Safety Hazards (NIOSH), as applicable to this Formal Solicitation. H. National Forest Products Association (NFPA), as applicable to this Formal Solicitation. I. City Procurement Ordinance City Code Section 18, Article III. J. Conflict of Interest, City Code Section 2-611;61. K. Cone of Silence, City Code Section 18-74. L. The Florida Statutes Sections 218.73 and 218.74 on Prompt Payment. M. City Financial Policies, City Code Chapter 18, Article IX. N. City of Miami Charter Sections 3(f) (iii) and 29-B. O. City of Miami Sale or Lease of Real Property, City Code Chapter 18, Article V. P. City of Miami Living Wage Ordinance, Chapter 18, Article X, City Code. Q. Alcoholic beverage, food and beverage laws, approvals and permits as required by state and local laws. R. Miami -Dade County Shoreline Review Ordinance Chapter 33D, Article III, Miami -Dade County Code. Lack of knowledge or notice by the Proposer will in no way be a cause for relief from responsibility. Non- compliance with all local, state, and federal directives, orders, regulations, and laws may be considered grounds for termination of contract(s). Copies of the City Ordinances may be obtained from the City Clerk's Office. 1.20 CONE OF SILENCE - Pursuant to Section 18-74 of the City of Miami Code, a "Cone of Silence" is imposed upon each RFP, RFQ, or RFLI after advertisement and terminates at the time the City Manager issues a written recommendation to the Miami City Commission. The Cone of Silence shall be applicable only to Contracts for the provision of goods and services and public works or improvements for amounts greater than $200,000. The Cone of Silence prohibits any communication regarding RFPs, RFQs, or RFLIs between potential vendors, service providers, Proposers, lobbyists, or consultants (among others) and the City's professional staff including, but not limited to, the City Manager and the City Manager's staff; the Mayor, City Commissioners, or their respective staffs and any member of the respective selection/evaluation committee. The provision does not apply to, among other communications, oral communications with the City's Procurement staff, provided the communication is limited strictly to matters of process or procedure already contained in the formal solicitation document. The provisions of the Cone of Silence do not apply to oral communications at duly noticed site visits/inspections, pre -proposal conferences, oral presentations before selection/evaluation committees, contract negotiations during any duly noticed public meeting, or public presentations made to the Miami City Commission during a duly noticed public meeting; or communications in writing or by email at any time with any City employee, official or member of the City Commission unless specifically prohibited by the applicable RFP, RFQ, or RFLI documents; or communications in connection with the collection of industry comments or the performance of market research regarding a particular RFP, RFQ, or RFLI, by City Procurement staff. Proposers must file a copy of any written communications with the Office of the City Clerk, which shall be made available to any person upon request. The City shall respond in writing and file a copy with the Office of the City Clerk (clerks@miamigov.com), which shall be made available to any person upon request. Written communications may be in the form of e-mail, with a copy to the Office of the City Clerk. In addition to any other penalties provided by law, violation of the Cone of Silence by any Proposer shall render any award voidable. A violation by a particular Proposer, Offeror, Respondent, lobbyist, or consultant shall subject same to potential penalties pursuant to the City Code. Any person who has personal knowledge of a violation of these provisions shall report such violation to the State Attorney and/or may file a complaint with the Miami -Dade County Ethics Commission. Proposers should reference Section 18-74 of the City of Miami Code for further clarification. This language is only a summary of the key provisions of the Cone of Silence. Please review City of Miami Code Section 18-74 for a complete and thorough description of the Cone of Silence. You may contact the City Clerk at 305-250-5360, to obtain a copy of same. 1.21 CONFIDENTIALITY - As a political subdivision and Florida municipality, the City of Miami is subject to the Florida Sunshine Act and Public Records Law. If this Contract/Agreement contains a confidentiality provision, it shall have no application when disclosure is required by Florida law or upon court order. 1.22 CONFLICT OF INTEREST - Proposers, by responding to this Formal Solicitation, certify that to the best of their knowledge or belief, no elected/appointed official or employee of the City of Miami is financially interested, directly or indirectly, in the purchase of goods/services specified in this Formal Solicitation. Any such interests on the part of the Proposer or its employees must be disclosed in writing to the City. Further, you must disclose the name of any City employee (or former employee of the City who left City service within the past two (2) years), who owns, directly or indirectly, an interest of five percent (5%) or more of the total assets of capital stock in the Proposer's firm. A. Proposer further agrees not to use or attempt to use any knowledge, property or resource which may be within their trust, or perform their duties, to secure a special privilege, benefit, or exemption for itself, or others. Proposer may not disclose or use information not available to members of the general public and gained by reason of their position, except for information relating exclusively to governmental practices, for their personal gain or benefit or for the personal gain or benefit of any other person or business entity. B. Proposer who is a person (every officer, official and employee of the City, including every member of any board, commission or agency of the City) as defined in Section 2-611 of the City Code, hereby acknowledges that it has not contracted or transacted any business with the City or any person or agency acting for the City and has not appeared in representation of any third party before any board, commission or agency of the City within the past two years. Proposer further warrants that they are not related, specifically the spouse, son, daughter, parent, brother, or sister, to: (i) any member of the commission; (ii) the mayor; (iii) any City employee; or (iv) any member of any board or agency of the City. C. A violation of this section may subject the Proposer to immediate termination of any Professional Services Agreement with the City, imposition of the maximum fine and/or any penalties allowed by law. Additionally, violations may be considered by and subject to action by the Miami -Dade County Commission on Ethics. 1.23 COPYRIGHT OR PATENT RIGHTS - Proposers warrant that there has been no violation of any intellectual property, copyright, or patent rights in manufacturing, producing, or selling the goods or equipment shipped or ordered and/or services provided as a result of this formal solicitation, and Proposers agree to hold the City harmless from any and all liability, loss, or expense occasioned by any such violation. 1.24 COST INCURRED BY PROPOSER - All expenses involved with the preparation and submission of Responses to the City, or any work performed in connection therewith shall be borne by the Proposer(s). 1.25 DEBARMENT AND SUSPENSIONS (Sec 18-107) (a) Authority and requirement to debar and suspend. After reasonable notice to an actual or prospective Contractual Party, and after reasonable opportunity for such party to be heard, the City Manager, after consultation with the Chief Procurement Officer and the City Attorney, shall have the authority to debar a Contractual Party, for the causes listed below, from consideration for award of City Contracts. The debarment shall be for a period of not fewer than three years. The City Manager shall also have the authority to suspend a Contractual Party from consideration for award of City Contracts if there is probable cause for debarment, pending the debarment determination. The authority to debar and suspend contractors shall be exercised in accordance with regulations which shall be issued by the Chief Procurement Officer after approval by the City Manager, the City Attorney, and the City Commission. (b) Causes for debarment or suspension. Causes for debarment or suspension include the following: (i) Conviction for commission of a criminal offense incident to obtain or attempting to obtain a public or private Contract or subcontract, or incident to the performance of such Contract or subcontract. (ii) Conviction under state or federal statutes of embezzlement, theft, forgery, bribery, falsification/destruction of records, receiving stolen property, or any other offense indicating a lack of business integrity or business honesty. (iii) Conviction under state or federal antitrust statutes arising out of the submission of Bids or Proposals. (iv) Violation of Contract provisions, which is regarded by the Chief Procurement Officer to be indicative of non -responsibility. Such violation may include failure without good cause to perform in accordance with the terms and conditions of a Contract or to perform within the time limits provided in a Contract, provided that failure to perfonn caused by acts beyond the control of a party shall not be considered a basis for debannent or suspension. (v) Debarment or suspension of the Contractual Party by any federal, state, local, or other governmental (public) agency or entity. (vi) False certification pursuant to paragraph (c) below. (vii) Found in violation of a zoning ordinance for which the violation remains noncompliant. (viii) Found in violation any City ordinance or regulation and for which a civil penalty or fine is due and owing to the City. (ix) Any other cause judged by the City Manager to be so serious and compelling as to affect the responsibility of the Contractual Party performing City Contracts. (c) Certification. All Contracts for goods and services, sales, and leases by the City shall contain a certification that neither the Contractual Party nor any of its principal owners or personnel have been convicted of any of the violations set forth above or debarred or suspended as set forth in paragraph (b)(v). (d) Debarment and suspension decisions. Subject to the provisions of paragraph (a), the City Manager shall render a written decision stating the reasons for the debarment or suspension. A copy of the decision shall be provided promptly to the Contractual Party, along with a notice of said party's right to seek judicial relief. 1.26 DEBARRED/SUSPENDED VENDORS - An entity or affiliate who has been placed on the State of Florida debarred or suspended vendor list may not: 1) submit a response fora contract to provide goods or services to a public entity; 2) Submit a response on a contract with a public entity for the construction or repair of a public building or public work; 3) Submit response on leases of real property to a public entity; 4) award or perform work as a contractor, supplier, subcontractor, or consultant under contract with any public entity; and 5) transact business with any public entity. 1.27 DEFAULT/FAILURE TO PERFORM - The City shall be the sole judge of nonperformance, which shall include any failure on the part of the successful Proposer to accept the award, to furnish required documents, and/or to fulfill any portion of this contract within the time stipulated. Upon default by the successful Proposer to meet any terms of this agreement, the City will notify the Proposer of the default and will provide the contractor with three (3) days (weekends and holidays excluded) to remedy the default. Failure on the contractor's part to correct the default within the required three (3) days shall result in the Contract being terminated and upon the City notifying in writing the contractor of its intentions and the effective date of the termination. The following shall constitute default: A. Failure to perform the work or deliver the goods/services required under the Contract and/or within the time required or failing to use the subcontractors, entities and personnel as identified and set forth, and to the degree specified in the Contract. B. Failure to begin the work under this Contract within the time specified. C. Failure to perform the work with sufficient workers and equipment or with sufficient materials to ensure timely completion. D. Neglecting or refusing to remove materials or perform new work where prior work has been rejected as nonconforming with the terms of the Contract. E. Becoming insolvent, being declared bankrupt, or committing any act of bankruptcy or insolvency, or making an assignment for the benefit of creditors, if the insolvency, bankruptcy, or assignment renders the successful Proposer incapable of performing the work in accordance with and as required by the Contract. F. Failure to comply with any of the terms of the Contract in any material respect. All costs and charges incurred by the City as a result of a default or a default incurred beyond the time limits stated, together with the cost of completing the work, shall be deducted from any monies due or which may become due on this Contract. 1.28 DETERMINATION OF RESPONSIVENESS AND RESPONSIBILITY - Each proposal will be reviewed to determine if it is responsive to the submission requirements outlined in the Formal Solicitation. A. Responsive Proposal is one which follows the requirements of the Formal Solicitation, includes all documentation, is submitted in the format outlined in the Formal Solicitation, is of timely submission, and has appropriate signatures as required on each document. Failure to comply with these requirements may deem a Proposal non -responsive. B. Determination of Responsibility. A Responsible Proposer shall mean a Proposer who has submitted a proposal and who has the capability, as determined under Section 18-95 of the City Code, in all respects to fully perform the Contract requirements, and the integrity and reliability of which give reasonable assurance of good faith and performance. 1. Proposals will only be considered from any person or firm who is regularly engaged in the business of providing the good(s)/service(s) required by the Formal Solicitation. Proposer must be able to demonstrate a satisfactory record of performance and integrity, and have sufficient financial, material, equipment, facility, personnel resources, and expertise to meet all contractual requirements. 2. The City may consider any information available regarding the financial, technical, and other qualifications and abilities of a Proposer, including past performance (experience) with the City or any other governmental entity, in making the award. 3. The City may require the Proposer(s) to provide documentation that they have been designated as an authorized representative of a manufacturer or supplier which is the actual source of supply, if required by the Formal Solicitation. 1.29 DISCOUNTS OFFERED DURING TERM OF CONTRACT - Discount Prices offered in the response shall be fixed after the award by the Commission, unless otherwise specified in the Special Terms and Conditions. Price discounts off the original prices quoted in the response will be accepted from successful Proposer(s) during the term of the contract. Such discounts shall remain in effect for a minimum of 120 days from approval by the City Commission. Any discounts offered by a manufacturer to Proposer will be passed on to the City. 1.30 DISCREPANCIES, ERRORS, AND OMISSIONS - Any discrepancies, errors, or ambiguities in the Formal Solicitation or addenda (if any) should be reported in writing to the City's Procurement Department. Should it be found necessary, a written addendum will be incorporated in the Formal Solicitation and will become part of the purchase agreement (contract documents). The City will not be responsible for any oral instructions, clarifications, or other communications. A. Order of Precedence -Any inconsistency in this formal solicitation shall be resolved by giving precedence to the following documents, the first of such list being the governing documents. 1) PSA and/or Agreement and/or any Amendments to the PSA and/or Agreement 2) Specifications 3) Special Conditions 4) General Terms and Conditions 1.31 EMERGENCY / DISASTER PERFORMANCE - In the event of a hurricane or other emergency or disaster situation, the successful vendor shall provide the City with the commodities/services defined within the scope of this formal solicitation at the price contained within vendor's response. Further, successful vendor shall deliver/perform for the City on a priority basis during such times of emergency. 1.32 ENTIRE BID CONTRACT OR AGREEMENT - The Bid Contract or Agreement consists of this City of Miami Formal Solicitation and specifically this General Conditions Section, Contractor's Response and any written agreement entered into by the City of Miami and Contractor in cases involving RFPs, RFQs, and RFLIs, and represents the entire understanding and agreement between the parties with respect to the subject matter hereof and supersedes all other negotiations, understanding and representations, if any, made by and between the parties. To the extent that the agreement conflicts with, modifies, alters, or changes any of the terms and conditions contained in the Formal Solicitation and/or Response, the Formal Solicitation and then the Response shall control. This Contract may be modified only by a written agreement signed by the City of Miami and Contractor. 1.33 ESTIMATED QUANTITIES - Estimated quantities or estimated dollars are provided for your guidance only. No guarantee is expressed or implied as to quantities that will be purchased during the contract period. The City is not obligated to place an order for any given amount subsequent to the award of this contract. Said estimates may be used by the City for purposes of determining the most advantageous Proposer meeting specifications. The City reserves the right to acquire additional quantities at the prices bid/proposed or at lower prices in this Formal Solicitation. 1.34 EVALUATION OF RESPONSES A. Rejection of Responses The City may reject a Response for any of the following reasons: 1) Proposer fails to acknowledge receipt of addenda; 2) Proposer misstates or conceals any material fact in the Response; 3) Response does not conform to the requirements of the Formal Solicitation; 4) Response requires a conditional award that conflicts with the method of award; 5) Response does not include required samples, certificates, licenses as required; and 6) Response was not executed by the Proposer's authorized agent. The foregoing is not an all-inclusive list of reasons for which a Response may be rejected. The City may reject and re -advertise for all or any part of the Formal Solicitation whenever it is deemed in the best interest of the City. B. Elimination from Consideration 1) A contract shall not be awarded to any person or firm which is in arrears to the City upon any debt or contract, or which is in default on a bid, payment/ performance, bond they have submitted or as the surety bond or certificate furnished has not performed despite demand they do so or otherwise upon any obligation to the City. 2) A contract may not be awarded to any person or firm which has failed to perform under the terms and conditions of any previous contract with the City or deliver on time contracts of a similar nature. 3) A contract may not be awarded to any person or firm which has been debarred by the City in accordance with the City's Debarment and Suspension Ordinance. C. Determination of Responsibility 1) Responses will only be considered from entities who are regularly engaged in the business of providing the goods/equipment/services required by the Formal Solicitation. Proposer must be able to demonstrate a satisfactory record of performance and integrity; and have sufficient financial, material, equipment, facility, personnel resources, and expertise to meet all contractual requirements. The terms "equipment and organization" as used herein shall be construed to mean a fully equipped and well -established entity in line with the best industry practices in the industry as determined by the City 2) The City may consider any evidence available regarding the financial, technical, and other qualifications and abilities of a Proposer, including past performance (experience) with the City or any other governmental entity in making the award. 3) The City may require the Proposer(s) to show proof that they have been designated as an authorized representative of a manufacturer or supplier which is the actual source of supply, if required by the Formal Solicitation. 1.35 EXCEPTIONS TO GENERAL AND/OR SPECIAL CONDITIONS OR SPECIFICATIONS - Exceptions to the specifications shall be listed on the Response and shall reference the section. Any exceptions to the General or Special Conditions shall be cause for the bid (IFB) to be considered non -responsive. It also may be cause for an RFP, RFQ, or RFLI to be considered non -responsive; and, if exceptions are taken to the terms and conditions of the resulting agreement it may lead to terminating negotiations. 1.36 F.O.B. DESTINATION - Unless otherwise specified in the Formal Solicitation, all prices quoted/proposed by the Proposer must be F.O.B. DESTINATION, inside delivery, with all delivery costs and charges included in the bid/proposal price, unless otherwise specified in this Formal Solicitation. Failure to do so may be cause for rejection of bid/proposal. 1.37 FIRM PRICES - The Proposer warrants that prices, terms, and conditions quoted in its response will be firm throughout the duration of the contract unless otherwise specified in the Formal Solicitation. Such prices will remain firm for the period of performance or resulting purchase orders or contracts, which are to be performed or supplied over a period of time. 1.38 FLORIDA MINIMUM WAGE AND CITY OF MIAMI LIVING WAGE ORDINANCE - A. Florida Minimum Wage. In accordance with the Constitution of the State of Florida, Article X, Section 24, employers shall pay employee wages no less than the minimum wage for all hours worked in Florida. Accordingly, it is the Successful Proposer's/Contractor's and their subcontractor's responsibility to understand and comply with this Florida minimum wage requirement and pay its employees the current established hourly minimum wage rate. This minimum wage rate is subject to change or adjusted by the rate of inflation using the consumer price index ("CP1") for urban wage earners and clerical workers, CPI-W, or a successor index as calculated by the United States Department of Labor. Each adjusted minimum wage rate calculated shall be determined and published by the Agency Workforce Innovation on September 30th of each year and take effect on the following January 1st. It is the Proposer's and their subcontractor's (if applicable) full responsibility to determine whether any of their employees may be impacted by this Florida Minimum Wage Law, at any given point in time during the term of the Bid Contract. If impacted, Proposer must provide, with its bid, employee name(s), job title(s), job description(s), and current pay rate(s). Failure to submit this information at the time of bid submittal constitute Successful Proposer's/Contractor's acknowledgement and understanding that the Florida Minimum Wage Law will not impact its prices throughout the term of the Bid Contract, and a waiver of any contractual price increase request(s). The City reserves the right to request, and the Successful Proposer/Contractor must provide for any, and all information to make a wage and contractual price increase(s) determination. B. City of Miami Living Wage Ordinance. The City of Miami adopted a Living Wage Ordinance for competitively solicited City Service Contracts with a total contract value exceeding $100,000 annually, that were also awarded on, or after January 1, 2017, by the City Commission. "Service Contract" means a contract to provide services to the City, excluding, however, professional services as defined by the "Consultants Competitive Negotiation Act" set forth in F.S. § 287.055, and Section 18-87 of the City Code, and/or the other exclusions provided by Section 18-557 of the City Code. If a solicitation requires services, effective on January 1, 2017, Contractors must pay to all its employees, who provide services, a living wage of no less than $15.00 per hour without health benefits; or a wage of no less than $13.19 an hour, with health benefits. This language is only a summary of the key provisions of the City of Miami Living Wage Ordinance. Please review Section 18-557 of the City Code, for a complete and thorough description of the City of Miami Living Wage Ordinance. 1.39 GOVERNING LAW AND VENUE - The validity and effect of this Contract shall be governed by the laws of the State of Florida. The parties agree that any action, mediation, or arbitration arising out of this Contract shall take place in Miami -Dade County, Florida. In any action or proceeding each party shall bear their own respective attorney's fees. 1.40 HEADINGS AND TERMS - The headings to the various paragraphs of this Contract have been inserted for convenient reference only and shall not in any manner be construed as modifying, amending, or affecting in any way the expressed terms and provisions hereof. 1.41 HEALTH INSURANCE PORTABILITY AND ACCOUNTABILITY ACT (HIPPA) - Any person or entity that performs or assists the City of Miami with a function or activity involving the use or disclosure of "individually identifiable health information (1THT) and/or Protected Health Information (PHI) shall comply with the Health Insurance Portability and Accountability Act (HIPAA) of 1996 and the City of Miami Privacy Standards. HIPAA mandates privacy, security, and electronic transfer standards, which include but are not limited to: A. Use of information only for performing services required by the contract or as required by law; B. Use of appropriate safeguards to prevent non -permitted disclosures; C. Reporting to the City of Miami of any non -permitted use or disclosure; D. Assurances that any agents and subcontractors agree to the same restrictions and conditions that apply to the Proposer and reasonable assurances that 11HI/PHI will be held confidential; E. Making Protected Health Information (PH1) available to the customer; F. Making PHI available to the customer for review and amendment; and incorporating any amendments requested by the customer; G. Making PHI available to the City of Miami for an accounting of disclosures; and H. Making internal practices, books and records related to PHI available to the City of Miami for compliance audits. PHI shall maintain its protected status regardless of the form and method of transmission (paper records, and/or electronic transfer of data). The Proposer must give its customers written notice of its privacy information practices including specifically a description of the types of uses and disclosures that would be made with protected health information. 1.42 INDEMNIFICATION - Contractor shall indemnify, hold and save harmless, and defend (at its own cost and expense), the City, its officers, agents, directors, instrumentalities, and/or employees (collectively "Indemnitees"), from all claims, actions, liabilities, injuries, damages, losses, judgements, and costs, including, but not limited to, reasonable attorney's fees, (collectively "Damages") that arise or result from (i) the negligence, recklessness, negligent act or omission, or intentional wrongful misconduct of Contractor, its officers, agents, directors, employees, and/or subcontractor(s) or other persons employed or utilized by Contractor in the performance of this Agreement (collectively "Contractor's agents") even if it is alleged that the Indemnitees were negligent; (ii) Contractor's agents' performance or non-performance of the Services; or (iii) Contractor's agents' alleged non- compliance with legal or contractual requirements relative to the Services. In the event that any action or proceeding is brought against the City by reason of any such claim or demand, the Contractor shall, upon written notice from the City, resist and defend such action or proceeding by counsel satisfactory to the City Attorney. The Contractor expressly understands and agrees that any insurance protection required by this Agreement or otherwise provided by the Contractor shall in no way limit the Contractor's responsibility to indemnify, keep and save harmless, and defend the Indemnitees as herein provided. The indemnification provided above shall obligate the Contractor to defend, at its own cost and expense, to and through trial, administrative, regulatory, appellate, supplemental or bankruptcy proceeding, or to provide for such defense, at the City's option, any and all claims of liability and all suits and actions of every name and description that may be brought against the City, whether performed by the Contractor, or persons employed or utilized by Contractor. Contractor shall require all subcontractor agreements to include a provision that each subcontractor will indemnify the City in substantially the same language as this Section. The Contractor agrees and recognizes that the City shall not be held liable or responsible for any claims that may result from any actions or omissions of the Contractor in which the City participated either through review or concurrence of the Contractor's actions. In reviewing, approving, or rejecting any submissions by the Contractor or other acts of the Contractor, the City, in no way, assumes or shares any responsibility or liability of the Contractor or subcontractor under this Agreement. Ten dollars ($10.00) of the payments made by the City constitute separate, distinct, and independent consideration for the granting of this Indemnification, the receipt and sufficiency of which is voluntarily and knowingly acknowledged by the Contractor. Contractor understands and agrees that all liabilities regarding the use of any subcontractor, supplier, laborer, or material person for Services related to this Agreement shall be borne solely by Contractor throughout the duration of this Agreement and that this provision shall survive the termination or expiration of this Agreement, as applicable. The obligations in this Section will survive the cancellation or expiration of the Agreement. if the City must file a suit to enforce Contractor's obligations under this Section, the City may recover its costs, including reasonable attorney's fees. Nothing herein is intended to be construed as a waiver of the City's sovereign immunity beyond the limitations set forth in Section 768.28, Florida Statutes. 1.43 FORMATION AND DESCRIPTIVE LITERATURE - Proposer must furnish all information requested in the spaces provided in the Formal Solicitation. Further, as may be specified elsewhere, each Proposer must submit for evaluation, cuts, sketches, descriptive literature, technical specifications, and Material Safety Data Sheets (MSDS)as required, covering the products offered. Reference to literature submitted with a previous response or on file with the Buyer will not satisfy this provision. 1.44 INSPECTIONS - The City may, at reasonable times during the term hereof, inspect Contractor's facilities and perform such tests, as the City deems reasonably necessary, to determine whether the goods and/or services required to be provided by the Contractor under this Contract conform to the terms and conditions of the Formal Solicitation. Contractor shall make available to the City all reasonable facilities and assistance to facilitate the performance of tests or inspections by City representatives. All tests and inspections shall be subject to, and made in accordance with, the provisions of the City of Miami Ordinance No. 12271 (Section 18-79), as same may be amended or supplemented from time to time. 1.45 INSPECTION OF RESPONSE - Responses received by the City pursuant to a Formal Solicitation will not be made available until such time as the City provides notice of a decision or intended decision or within 30 days after bid closing, whichever is earlier. Bid/Proposal results will be tabulated and may be furnished upon request via fax or e-mail to the Procurement Contracting Officer issuing the Solicitation. Tabulations also are available on the City's Web Site following recommendation for award. 1.46 INSURANCE - Within ten (10) days after receipt of Notice of Award, the Successful Proposer, shall furnish Evidence of Insurance to the Procurement Department, if applicable. Submitted evidence of coverage shall demonstrate strict compliance to all requirements listed on the Special Conditions entitled "Insurance Requirements". The City shall be listed as an "Additional Insured." Issuance of a Purchase Order is contingent upon the receipt of proper insurance documents. If the insurance certificate is received within the specified time frame but not in the manner prescribed in this Solicitation the Proposer shall be verbally notified of such deficiency and shall have an additional five (5) calendar days to submit a corrected certificate to the City. If the Contractor fails to submit the required insurance documents in the manner prescribed in this Solicitation within fifteen (15) calendar days after receipt Notice of Award, the contractor shall be in default of the contractual terms and conditions and shall not be awarded the contract. Under such circumstances, the Proposer may be prohibited from submitting future responses to the City. Information regarding any insurance requirements shall be directed to the Risk Administrator, Department of Risk Management, at 444 SW 2nd Avenue, 9th Floor, Miami, Florida 33130, 305-416-1604. The Proposer shall be responsible for assuring that the insurance certificates required in conjunction with this Section remain in effect for the duration of the contractual period; including any and all option terms that may be granted to the Proposer. 1.47 INVOICES - Invoices shall contain purchase order number and details of goods and/or services delivered (i.e. quantity, unit price, extended price, etc.); and in compliance with Chapter 218 of the Florida Statutes (Prompt Payment Act). 1.48 LOCAL PREFERENCE A. City Code Section 18-85, states, "when a responsive, responsible non -local bidder submits the lowest bid price, and the bid submitted by one or more responsive, responsible local bidders who maintain a local office, as defined in Section 18-73, is within fifteen percent (15%) of the price submitted by the non -local bidder, then that non -local bidder and each of the aforementioned responsive, responsible local bidders shall have the opportunity to submit a best and final bid equal to or lower than the amount of the low bid previously submitted by the non -local bidder. Contract award shall be made to the lowest responsive, responsible bidder submitting the lowest best and final bid. In the case of a tie in the best and final bid between a local bidder and a non -local bidder, contract award shall be made to the local bidder." B. City Code Section 18-86, states, "the RFP, RFLI or RFQ, as applicable, may, in the exercise of the reasonable professional discretion of the City Manager, director of the using agency, and the Chief Procurement Officer, include a five (5%) percent evaluation criterion, towards the technical score, in favor of proposers who maintain a local office, as defined in Section 18-73. In such cases, this five (5%) percent evaluation criterion in favor of proposers who maintain a local office will be specifically defined in the RFP, RFLI or RFQ, as applicable; otherwise, it will not apply. 1.49 MANUFACTURER'S CERTIFICATION - The City reserves the right to request from Proposers a separate Manufacturer's Certification of all statements made in the bid/proposal. Failure to provide such certification may result in the rejection of bid/proposal or termination of contract/agreement, for which the Proposer must bear full liability. 1.50 MODIFICATIONS OR CHANGES IN PURCHASE ORDERS AND CONTRACTS - No contract or understanding to modify this Formal Solicitation and resultant purchase orders or contracts, if applicable, shall be binding upon the City unless made in writing by the Director of Procurement of the City of Miami, Florida through the issuance of a change order, addendum, amendment, or supplement to the contract, purchase order or award sheet as appropriate. 1.51 MOST FAVORED NATIONS - Successful Proposer shall not treat the City of Miami ("City") worse than any other similarly situated local government and, in this regard, grants the City a "most favored nations clause" meaning the City will be entitled to receive and be governed by the most favorable terms and conditions that Successful Bidder/Proposer grants now or in the future to a similarly situated local government. 1.52 NO PARTNERSHIP OR JOINT VENTURE - Nothing contained in this Contract will be deemed or construed to create a partnership or joint venture between the City of Miami and Contractor, or to create any other similar relationship between the parties. 1.53 NONCONFORMANCE TO CONTRACT CONDITIONS - Items may be tested for compliance with specifications under the direction of the Florida Department of Agriculture and Consumer Services or by other appropriate testing Laboratories as determined by the City. The data derived from any test for compliance with specifications is public record and open to examination thereto in accordance with Chapter 119, Florida Statutes. Items delivered not conforming to specifications may be rejected and returned at the Proposer's expense. These non -conforming items not delivered as per delivery date in the response and/or Purchase Order may result in Proposer being found in default in which event any and all re -procurement costs may be charged against the defaulted contractor. Any violation of these stipulations may also result in the supplier's name being removed from the City of Miami's Supplier's list. 1.54 NONDISCRIMINATION, EQUAL EMPLOYMENT OPPORTUNITY, AND AMERICAN WITH DISABILITIES ACT — Successful Bidder/Proposer/Contractor shall not unlawfully discriminate against any person in its operations and activities or in its use or expenditure of funds in fulfilling its obligations under this Agreement. Successful Bidder/Proposer/Contractor shall affirmatively comply with all applicable provisions of the Americans with Disabilities Act (ADA) in the course of providing any services funded by City, including Titles 1 and 11 of the ADA (regarding nondiscrimination on the basis of disability), and all applicable regulations, guidelines, and standards. In addition, Successful Bidder/Proposer/Contractor shall take affirmative steps to ensure nondiscrimination in employment against disabled persons. Successful Bidder/Proposer/Contractor affirms that it shall not discriminate as to race, age, religion, color, gender, gender identity, sexual orientation, national origin, marital status, physical or mental disability, political affiliation, or any other factor which cannot be lawfully used in connection with its performance under the Formal Solicitation. Furthermore, Successful Bidder/Proposer/Contractor affirms that no otherwise qualified individual shall solely by reason of their race, age, religion, color, gender, gender identity, sexual orientation, national origin, marital status, physical or mental disability, political affiliation, or any other factor which cannot be lawfully used, be excluded from the participation in, be denied benefits of, or be subjected to, discrimination under any program or activity. In connection with the conduct of its business, including performance of services and employment of personnel, Successful Bidder/Proposer/Contractor shall not discriminate against any person on the basis of race, age, religion, color, gender, gender identity, sexual orientation, national origin, marital status, physical or mental disability, political affiliation, or any other factor which cannot be lawfully used. All persons having appropriate qualifications shall be afforded equal opportunity for employment. 1.55 NON-EXCLUSIVE CONTRACT/ PIGGYBACK PROVISION - At such times as may serve its best interest, the City of Miami reserves the right to advertise for, receive, and award additional contracts for these herein goods and/or services, and to make use of other competitively bid (governmental) contracts, agreements, or other similar sources for the purchase of these goods and/or services as may be available. It is hereby agreed and understood that this formal solicitation does not constitute the exclusive rights of the successful Proposer(s) to receive all orders that may be generated by the City in conjunction with this Formal Solicitation. In addition, any and all commodities, equipment, and services required by the City in conjunction with construction projects are solicited under a distinctly different solicitation process and shall not be purchased under the terms, conditions and awards rendered under this solicitation, unless such purchases are determined to be in the best interest of the City. 1.56 NOTICE REGARDING "CURES" - Proposals submitted with irregularities, deficiencies, and/or technicalities that deviate from the minimum qualifications and submission requirements of Request for Qualifications (RFQ), Request for Proposals (RFP), Invitation to Bid (ITB), Invitation for Bids (IFB), Invitation to Quote (ITQ), Requests for Letters of Interest (RFLI) and Request for Sponsorships (RFS) shall result in a non- responsive determination. any solicitation issued after May 6, 2019, shall comply with APM 2-19. APM 2-19 is attached hereto. Only minor irregularities, deficiencies, and technicalities may be allowed to be timely cured by the proposer at the sole discretion of the City. Material irregularities, deficiencies, and technicalities cannot be cured by the proposer, and are not waivable by the City. PROPOSALS SUBMITTED WITH IRREGULARITIES, DEFICIENCIES, AND/OR TECHNICALITIES THAT DEVIATE FROM THE MINIMUM QUALIFICATIONS AND SUBMISSION REQUIREMENTS OF THIS RFP/Q SHALL RESULT IN A NON -RESPONSIVE DETERMINATION. The City will not give consideration to the curing of any Proposals that fail to meet the minimum qualifications and submission requirements of this RFP/Q. Proposer understands that non -responsive Proposals will not be evaluated and, therefore, will be eliminated from the Evaluation/Selection Process. 1.57 OCCUPATIONAL LICENSE - Any person, firm, corporation, or joint venture, with a business location in the City of Miami and is submitting a Response under this Formal Solicitation shall meet the City's Occupational License Tax requirements in accordance with Chapter 31.1, Article I of the City of Miami Charter. Others with a location outside the City of Miami shall meet their local Occupational License Tax requirements. A copy of the license must be submitted with the response; however, the City may, at its sole option and in its best interest allow the Proposer to supply the license to the City during the evaluation period, but prior to award. 1.58 ONE PROPOSAL - Only one (1) Response from an individual, firm, partnership, corporation, or joint venture will be considered in response to this Formal Solicitation. 1.59 OWNERSHIP OF DOCUMENTS - It is understood by and between the parties that any documents, records, files, or any other matter whatsoever which is given by the City to the successful Proposer pursuant to this formal solicitation shall at all times remain the property of the City and shall not be used by the Proposer for any other purposes whatsoever without the written consent of the City. 1.60 PARTIAL INVALIDITY - If any provision of this Contract or the application thereof to any person or circumstance shall to any extent be held invalid, then the remainder of this Contract or the application of such provision to persons or circumstances other than those as to which it is held invalid shall not be affected thereby, and each provision of this Contract shall be valid and enforced to the fullest extent permitted by law. 1.61 PERFORMANCE/PAYMENT BOND - A Contractor may be required to furnish a Performance/Payment Bond as part of the requirements of this Contract, in an amount equal to one hundred percent (100%) of the contract price. 1.62 PREPARATION OF RESPONSES - Proposers are expected to examine the specifications, required delivery, drawings, and all special and general conditions. All bid/proposed amounts, if required, shall be either typewritten or entered into the space provided with ink. Failure to do so will be at the Proposer's risk. A. Each Proposer shall furnish the information required in the Formal Solicitation. The Proposer shall sign the Response and print in ink or type the name of the Proposer, address, and telephone number on the face page and on each continuation sheet thereof on which he/she makes an entry, where required. B. If so required, the unit price for each unit offered shall be shown, and such price shall include packaging, handling and shipping, and F.O.B. Miami delivery inside City premises unless otherwise specified. Proposer shall include in the response all taxes, insurance, social security, workmen's compensation, and any other benefits normally paid by the Proposer to its employees. If applicable, a unit price shall be entered in the "Unit Price" column for each item. Based upon estimated quantity, an extended price shall be entered in the "Extended Price" column for each item offered. In case of a discrepancy between the unit price and extended price, the unit price will be presumed correct. C. The Proposer must state a definite time, if required, in calendar days for delivery of goods and/or services. D. The Proposer should retain a copy of all response documents for future reference. E. All responses, as described, must be fully completed and typed or printed in ink and must be signed in ink with the firm's name and by an officer or employee having authority to bind the company or firm by his/her signature. Bids/Proposals having any erasures or corrections must be initialed in ink by the person signing the response or the response may be rejected. F. Responses are to remain valid for at least 180 days. Upon award of a contract, the content of the Successful Proposer's response may be included as part of the contract, at the City's discretion. G. The City of Miami's Response Forms shall be used at all times. Use of any other forms will result in the rejection of the response. 1.63 PRICE ADJUSTMENTS - Any price decrease effectuated during the contract period either by reason of market change or on the part of the contractor to other customers shall be passed on to the City of Miami. 1.64 PRODUCT SUBSTITUTES - In the event a particular good (that has been awarded and approved) becomes unavailable during the term of the Contract, the Contractor awarded that item may arrange with the City's authorized representative(s) to supply a substitute product at the awarded price or lower, provided that a sample is approved in advance of delivery and that the new product meets or exceeds all quality requirements. 1.65 CONFLICT OF INTEREST, AND UNETHICAL BUSINESS PRACTICE PROHIBITIONS - Contractor represents and warrants to the City that it has not employed or retained any person or company employed by the City to solicit or secure this Contract and that it has not offered to pay, paid, or agreed to pay any person any fee, commission, percentage, brokerage fee, or gift of any kind contingent upon or in connection with, the award of this Contract. 1.66 PROMPT PAYMENT - Proposers may offer a cash discount for prompt payment; however, discounts shall not be considered in determining the lowest net cost for response evaluation purposes. Proposers are required to provide their prompt payment terms in the space provided on the Formal Solicitation. If no prompt payment discount is being offered, the Proposer must enter zero (0) for the percentage discount to indicate no discount. If the Proposer fails to enter a percentage, it is understood and agreed that the terms shall be 2% 20 days, effective after receipt of invoice or final acceptance by the City, whichever is later. When the City is entitled to a cash discount, the period of computation will commence on the date of delivery, or receipt of a correctly completed invoice, whichever is later. If an adjustment in payment is necessary due to damage, the cash discount period shall commence on the date final approval for payment is authorized. If a discount is part of the contract, but the invoice does not reflect the existence of a cash discount, the City is entitled to a cash discount with the period commencing on the date it is determined by the City that a cash discount applies. Price discounts on the original prices quoted on the Price Sheet will be accepted from successful Proposers during the term of the contract. 1.67 PROPERTY - Property owned by the City of Miami is the responsibility of the City of Miami. Such property furnished to a Contractor for repair, modification, study, etc., shall remain the property of the City of Miami. Damages to such property occurring while in the possession of the Contractor shall be the responsibility of the Contractor. Damages occurring to such property while in route to the City of Miami shall be the responsibility of the Contractor. In the event that such property is destroyed or declared a total loss, the Contractor shall be responsible for replacement value of the property at the current market value, less depreciation of the property, if any. 1.68 PROVISIONS BINDING - Except as otherwise expressly provided in the resulting Contract, all covenants, conditions, and provisions of the resulting Contract shall be binding upon and shall inure to the benefit of the parties hereto and their respective heirs, legal representatives, successors and assigns. 1.69 PUBLIC ENTITY CRIMES - A person or affiliate who has been placed on the convicted vendor list, following a conviction for a public entity crime may not: A. Submit a Bid to provide any goods or services to a public entity. B. Submit a Bid on a contract with a public entity for the construction or repair of a public building or public work. C. Submit responses on leases of real property to a public entity. D. Be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity. E. Transact business with any public entity in excess of the threshold amount provided in Section 287.017, CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list. 1.70 PUBLIC RECORDS - Proposer understands that the public shall have access, at all reasonable times, to all documents and information pertaining to City contracts, subject to the provisions of Chapter 119, Florida Statutes, and City Code, Section 18, Article III, and agrees to allow access by the City and the public, to all documents subject to disclosure under applicable law. Successful Proposer shall additionally comply with the provisions of Section 119.0701, Florida Statutes, titled "Contracts; public records". Proposer shall additionally comply with Section 119.0701, Florida Statutes, including without limitation: A. Keep and maintain public records that ordinarily and necessarily would be required by the City to perform this service. B. Provide the public with access to public records on the same terms and conditions as the City would at the cost provided by Chapter 119, Florida Statutes, or as otherwise provided by law. C. Ensure that public records that are exempt or confidential and exempt from disclosure are not disclosed except as authorized by law. D. Meet all requirements for retaining public records and transfer, at no cost, to the City all public records in its possession upon termination of this Agreement and destroy any duplicate public records that are exempt or confidential and exempt from disclosure requirements. E. All electronically stored public records must be provided to the City in a format compatible with the City's information technology systems. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS AGREEMENT, CONTACT THE DIVISION OF PUBLIC RECORDS AT (305) 416-1800, VIA EMAIL AT PUBLICRECORDS@MIAMIGOV.COM, OR REGULAR MAIL AT CITY OF MIAMI OFFICE OF THE CITY ATTORNEY, 444 SW 2ND AVENUE, 9TH FL, MIAMI, FL 33130. THE CONTRACTOR MAY ALSO CONTACT THE RECORDS CUSTODIAN AT THE CITY OF MIAMI DEPARTMENT WHO IS ADMINISTERING THIS CONTRACT. 1.71 QUALITY OF GOODS, MATERIALS, SUPPLIES, PRODUCTS, AND EQUIPMENT - All materials used in the manufacturing or construction of supplies, materials, or equipment covered by this solicitation shall be new. The items bid/proposed must be of the latest make or model, of the best quality, and of the highest grade of workmanship, unless otherwise specified in this Solicitation. 1.72 QUALITY OF WORK/SERVICES - The work/services performed must be of the highest quality and workmanship. Materials furnished to complete the service shall be new and of the highest quality except as otherwise specified in this Solicitation. 1.73 REMEDIES PRIOR TO AWARD (Sec. 18-106) - If prior to Contract award it is determined that a formal solicitation or proposed award is in violation of law, then the solicitation or proposed award shall be cancelled by the City Commission, the City Manager, or the Chief Procurement Officer, as may be applicable, or revised to comply with the law. 1.74 RESOLUTION OF CONTRACT DISPUTES (Sec. 18-105) A. Authority to resolve Contract disputes. The City Manager, after obtaining the approval of the City Attorney, shall have the authority to resolve disputes between the Proposer and the City which arise under, or by virtue of, a Contract between them; provided that, in cases involving an amount greater than $25,000, the City Commission must approve the City Manager's decision. Such authority extends, without limitation, to disputes based upon breach of Contract, mistake, misrepresentation, or lack of complete performance, and shall be invoked by a Contractual Party by submission of a protest to the City Manager. B. Contract dispute decisions. If a dispute is not resolved by mutual consent, the City Manager shall promptly render a written report stating the reasons for the action taken by the City Commission, or the City Manager, which shall be final and conclusive. A copy of the decision shall be immediately provided to the protesting party, along with a notice of such party's right to seek judicial relief, provided that the protesting party shall not be entitled to such judicial relief without first having followed the procedure set forth in this Section. 1.75 RESOLUTION OF PROTESTED SOLICITATIONS AND AWARDS (SECTION 18-104): Right to protest. The following procedures shall be used for resolution of protested solicitations and awards except for purchases of goods, supplies, equipment, and services, the estimated cost of which does not exceed $25,000.00. Protests thereon shall be governed by the administrative policies and procedures of Procurement. Protest of solicitation. a. Any prospective proposer who perceives itself aggrieved in connection with the solicitation of a contract may protest to the Chief Procurement Officer. A written notice of intent to file a protest shall be filed with the Chief Procurement Officer within three days after the request for proposals, request for qualifications or request for letters of interest is published in a newspaper of general circulation. A notice of intent to file a protest is considered filed when received by the Chief Procurement Officer; or b. Any prospective bidder/proposer who intends to contest bid specifications or a bid solicitation may protest to the Chief Procurement Officer. A written notice of intent to file a protest shall be filed with the Chief Procurement Officer within three days after the bid solicitation is published in a newspaper of general circulation. A notice of intent to file a protest is considered filed when received by the Chief Procurement Officer. Protest of award. a. Any actual proposer who perceives itself aggrieved in connection with the recommended award of contract may protest to the Chief Procurement Officer. A written notice of intent to file a protest shall be filed with the Chief Procurement Officer within two days after receipt by the proposer of the notice of the City Manager's recommendation for award of contract. The receipt by proposer of such notice shall be confirmed by the City by facsimile or electronic mail or U.S. mail, return receipt requested. A notice of intent to file a protest is considered filed when received by the Chief Procurement Officer; or b. Any actual responsive and responsible bidder/proposer whose bid is lower than that of the recommended bidder/proposer may protest to the Chief Procurement Officer. A written notice of intent to file a protest shall be filed with the Chief Procurement Officer within two days after receipt by the bidder/proposer of the notice of the City's determination of non -responsiveness or non -responsibility. The receipt by bidder/proposer of such notice shall be confirmed by the City by facsimile or electronic mail or U.S. mail, return receipt requested. A notice of intent to file a protest is considered filed when received by the Chief Procurement Officer. c. A written protest based on any of the foregoing must be submitted to the Chief Procurement Officer within five days after the date the notice of protest was filed. A written protest is considered filed when received by the Chief Procurement Officer. The written protest may not challenge the relative weight of the evaluation criteria or the formula for assigning points in making an award determination. The written protest shall state with particularity the specific facts and law upon which the protest of the solicitation or the award is based and shall include all pertinent documents and evidence and shall be accompanied by the required filing fee as provided in subsection (f). This shall form the basis for review of the written protest and no facts, grounds, documentation, or evidence not contained in the protester's submission to the Chief Procurement Officer at the time of filing the protest shall be permitted in the consideration of the written protest. No time will be added to the above limits for service by mail. In computing any period of time prescribed or allowed by this section, the day of the act, event or default from which the designated period of time begins to run shall not be included. The last day of the period so computed shall be included unless it is a Saturday, Sunday or legal holiday in which event the period shall run until the end of the next day, which is neither a Saturday, Sunday or legal holiday. Intermediate Saturdays, Sundays and legal holidays shall be excluded in the computation of the time for filing. Authority to resolve protests; hearing officer(s). Hearing officers appointed by the City shall have authority to resolve protests filed under this chapter of the City Code. The City Manager shall appoint a hearing officer, from a separate list of potential hearing officers pre - approved by the City Commission, to resolve protests filed in accordance with this section, no later than five working days following the filing of a bid protest. The hearing officer shall have the authority to settle and resolve any written protest. The hearing officer shall submit said decision to the protesting party and to the other persons specified within ten days after he/she holds a hearing under the protest. (1) Hearing officer. The hearing officer may be a special master as defined in chapter 2, article X, section 2-811 of the City Code, or a lawyer in good standing with the Florida Bar for a minimum of ten years with a preference given to a lawyer who has served as an appellate or trial court judge. The hearing officer may be appointed from alternative sources (e.g. expert consulting agreements, piggyback contracts, etc.) where the City Commission adopts a recommendation of the City Attorney that such action is necessary to achieve fairness in the proceedings. The engagement of hearing officers is excluded from the procurement ordinance as legal services. The hearing officers appointed in the pre -qualified group should be scheduled to hear protests on a rotational basis. (2) Right of protest. Any actual bidder or proposer who has standing under Florida law dissatisfied and aggrieved with the decision of the City regarding the protest of a solicitation or the protest of an award as set forth above in this section may request a protest hearing. Such a written request for a protest hearing must be initiated with a notice of intent to protest followed by an actual protest as provided in subsection 18-104(a). The notice of intent to protest and the actual protest must each be received timely by the Chief Procurement Officer and must comply with all requirements set forth in subsection 18-104(a). Failure to submit the required notice of intent to protest and the actual protest within the specified timeframes will result in an administrative dismissal of the protest. (3) Hearing date. Within 30 days of receipt of the notice of protest, the Chief Procurement Officer shall schedule a hearing before a hearing officer, at which time the person protesting shall be given the opportunity to demonstrate why the decision of the City relative to the solicitation or the award, which may include a recommendation for award by the City Manager to the City Commission, as applicable, should be overturned. The party recommended for award, if it is a protest of award, shall have a right to intervene and be heard. (4) Hearing procedure. The procedure for any such hearing conducted under this article shall be as follows: a. The City shall cause to be served by certified mail a notice of hearing stating the time, date, and place of the hearing. The notice of hearing shall be sent by certified mail, return receipt requested, to the mailing address of the protester. b. The party, any intervenor, and the City shall each have the right to be represented by counsel, to call and examine witnesses, to introduce evidence, to examine opposing or rebuttal witnesses on any relevant matter related to the protest even though the matter was not covered in the direct examination, and to impeach any witness regardless of which party first called him/her to testify. The hearing officer may extend the deadline for completion of the protest hearing for good cause shown, but such an extension shall not exceed an additional five business days. The hearing officer shall consider the written protest and supporting documents and evidence appended thereto, supporting documents or evidence from any intervenor, and the decision or recommendation as to the solicitation or award being protested, as applicable. The protesting party, and any intervenor, must file all pertinent documents supporting his/her protest or motion to intervene at least five business days before the hearing, as applicable. The hearing officer shall allow a maximum of two hours for the protest presentation and a maximum of two hours for the City response. When there is an intervenor, a maximum of two hours will be added for the intervenor. In the event of multiple protests for the same project, the hearing officer shall allocate time as necessary to ensure that the hearing shall not exceed a total of one day. c. The hearing officer shall consider the evidence presented at the hearing. In any hearing before the hearing officer, irrelevant, immaterial, repetitious, scandalous, or frivolous evidence shall be excluded. All other evidence of a type commonly relied upon by reasonably prudent persons in the conduct of their affairs shall be admissible whether or not such evidence would be admissible in trial in the courts of Florida. The hearing officer may also require written summaries, proffers, affidavits, and other documents that the hearing officer determines to be necessary to conclude the hearing and issue a final order within the time limits set forth by this section. d. The hearing officer shall determine whether procedural due process has been afforded, whether the essential requirements of law have been observed, and whether the decision was arbitrary, capricious, an abuse of discretion, or unsupported by substantial evidence as a whole. Substantial evidence means such relevant evidence as a reasonable mind might accept as adequate to support a conclusion. e. Within ten days from the date of the hearing, the hearing officer shall complete and submit to the City Manager, the City Attorney, any intervenor, the Chief Procurement Officer, and the person requesting said hearing a final order consisting of his/her findings of fact and conclusions of law as to the denial or granting of the protest, as applicable. f. The decisions of the hearing officer are final in terms of City decisions relative to the protest. Any appeal from the decision of the hearing officer shall be in accordance with the Florida Rules of Appellate Procedure. Compliance with filing requirements. Failure of a party to timely file either the notice of intent to file a protest or the written protest, together with the required filing fee as provided in subsection (f), with the Chief Procurement Officer within the time provided in subsection (a), above, shall constitute a forfeiture of such party's right to file a protest pursuant to this section. The protesting party shall not be entitled to seek judicial relief without first having followed the procedure set forth in this section. Stay of procurements during protests. Upon receipt of a written protest filed pursuant to the requirements of this section, the City shall not proceed further with the solicitation or with the award of the contract until the protest is resolved by the Chief Procurement Officer or the City Commission as provided in subsection (b) above, unless the City Manager makes a written determination that the solicitation process or the contract award must be continued without delay in order to avoid an immediate and serious danger to the public health, safety or welfare. Costs. All costs accruing from a protest shall be assumed by the protestor. Filing fee. The written protest must be accompanied by a filing fee in the form of a money order or cashier's check payable to the City in an amount equal to one percent of the amount of the bid or proposed contract, or $5,000.00, whichever is less, which filing fee shall guarantee the payment of all costs which may be adjudged against the protestor in any administrative or court proceeding. If a protest is upheld by the Chief Procurement Officer and/or the City Commission, as applicable, the filing fee shall be refunded to the protestor less any costs assessed under subsection above. if the protest is denied, the filing fee shall be forfeited to the City in lieu of payment of costs for the administrative proceedings as prescribed by subsection (e) above. (Ord. No. 12271, § 2, 8-22-02; Ord. No. 13629, § 2, 9-8-16). 1.76 SAMPLES - Samples of items, when required, must be submitted within the time specified at no expense to the City. If not destroyed by testing, Proposer(s) will be notified to remove samples, at their expense, within 30 days after notification. Failure to remove the samples will result in the samples becoming the property of the City. 1.77 SELLING, TRANSFERRING OR ASSIGNING RESPONSIBILITIES - Proposer shall not sell, assign, transfer or subcontract at any time during the term of the Contract, or any part of its operations, or assign any portion of the performance required by this contract, except under and by virtue of written permission granted by the City through the proper officials, which may be withheld or conditioned, in the City's sole discretion. 1.78 SERVICE AND WARRANTY - When specified, the Proposer shall define all warranties, service and replacements that will be provided. Proposer must explain on the Response to what extent warranty and service facilities are available. A copy of the manufacturer's warranty, if applicable, should be submitted with your response. 1.79 SILENCE OF SPECIFICATIONS - The apparent silence of these specifications and any supplemental specification as to any detail or the omission from it of detailed description concerning any point shall be regarded as meaning that only the best commercial practices are to prevail and that only materials of first quality and correct type, size and design are to be used. All workmanship and services are to be first quality. All interpretations of these specifications shall be made upon the basis of this statement. If your firm has a current contract with the State of Florida, Department of General Services, to supply the items on this solicitation, the Proposer shall quote not more than the contract price; failure to comply with this request will result in disqualification of proposal. 1.80 SUBMISSION AND RECEIPT OF RESPONSES - Responses shall be submitted via BidNet at, or before, the specified closing date and time as designated in the Solicitation. NO EXCEPTIONS. A. Facsimile responses will not be considered. B. Failure to follow these procedures is cause for rejection of proposal. C. The responsibility for obtaining and submitting a response on or before the close date is solely and strictly the responsibility of Proposer. The City of Miami is not responsible for delays caused by any other occurrence. Responses received after the solicitation closing date and time will be returned unopened and will not be considered for award. D. Late responses will be rejected. E. All responses are subject to the conditions specified herein. Those which do not comply with these conditions are subject to rejection. F. Modification of responses already submitted will be considered only if received at the City before the time and date set for closing of solicitation responses. All modifications must be submitted via BidNet. Once a solicitation closes (closed date and/or time expires), the City will not consider any subsequent submission which alters the responses. 1.81 TAXES - The City of Miami is exempt from any taxes imposed by the State and/or Federal Government. Exemption certificates will be provided upon request. Notwithstanding, Proposers should be aware of the fact that all materials and supplies which are purchased by the Proposer for the completion of the contract is subject to the Florida State Sales Tax in accordance with Section 212.08, Florida Statutes, as amended and all amendments thereto and shall be paid solely by the Proposer. 1.82 TERMINATION -The City Manager on behalf of the City of Miami reserves the right to terminate this contract by written notice to the contractor effective the date specified in the notice should any of the following apply: A. The contractor is determined by the City to be in breach of any of the terms and conditions of the contract. B. The City has determined that such termination will be in the best interest of the City to terminate the contract for its own convenience. C. Funds are not available to cover the cost of the goods and/or services. The City's obligation is contingent upon the availability of appropriate funds. 1.83 TERMS OF PAYMENT - Payment will be made by the City after the goods and/or services awarded to a Proposer have been received, inspected, and found to comply with award specifications, free of damage or defect, and properly invoiced. No advance payments of any kind will be made by the City of Miami Payment shall be made after delivery, within 45 days of receipt of an invoice and authorized inspection and acceptance of the goods/services and pursuant to Section 218.74, Florida Statutes, and other applicable law. 1.84 TIMELY DELIVERY - Time will be of the essence for any orders placed as a result of this solicitation. The City reserves the right to cancel such orders, or any part thereof, without obligation, if delivery is not made within the time(s) specified in their Response. Deliveries are to be made during regular City business hours unless otherwise specified in the Special Conditions. 1.85 TITLE - Title to the goods or equipment shall not pass to the City until after the City has accepted the goods/equipment or used the goods, whichever comes first. 1.86 TRADE SECRETS EXECUTION TO PUBLIC RECORDS DISCLOSURE - All Responses submitted to the City are subject to public disclosure pursuant to Chapter 119, Florida Statutes. An exception may be made for "trade secrets." If the Response contains information that constitutes a "trade secret", all material that qualifies for exemption from Chapter 119 must be submitted in a separate envelope, clearly identified as "TRADE SECRETS EXCEPTION," with your firm's name and the Solicitation number and title marked on the outside. Please be aware that the designation of an item as a trade secret by you may be challenged in court by any person. By your designation of material in your Response as a "trade secret" you agree to indemnify and hold harmless the City for any award to a plaintiff for damages, costs, or attorney's fees and for costs and attorney's fees incurred by the City by reason of any legal action challenging your claim. 1.87 UNAUTHORIZED WORK OR DELIVERY OF GOODS - Neither the qualified Proposer(s) nor any of his/her employees shall perform any work or deliver any goods unless a change order or purchase order is issued and received by the Contractor. The qualified Proposer(s) shall not be paid for any work performed or goods delivered outside the scope of the contract, or any work performed by an employee not otherwise previously authorized. 1.88 USE OF NAME - The City is not engaged in research for advertising, sales promotion, or other publicity purposes. No advertising, sales promotion or other publicity materials containing information obtained from this Solicitation are to be mentioned, or imply the name of the City, without prior express written permission of the City Manager or the City Commission. 1.89 VARIATIONS OF SPECIFICATIONS - For purposes of solicitation evaluation, Proposers must indicate any variances from the solicitation specifications and/or conditions, no matter how slight. If variations are not stated on their Response, it will be assumed that the product fully complies with the City's specifications. 2.0 SPECIAL CONDITIONS 2.1 PURPOSE The purpose of this Solicitation is to establish a contract for a telemetry and supervisory control and data acquisition ("SCADA") system for the City of Miami's ("City") storm pump stations, as specified herein, from a source or sources, fully compliant with the terms, conditions, and stipulations of the solicitation. 2.2 PRE -PROPOSAL CONFERENCE A Virtual Voluntary pre -proposal conference will be held on November 19, 2025 at 2:00 PM, via Teams MEETING or via phone at 786-598-2961; Conference ID: 610070017#. A discussion of the requirements of the Solicitation will occur at that time. Each potential Proposer is required, prior to submitting a Proposal, to acquaint itself thoroughly with any and all conditions and/or requirements that may in any manner affect the work to be performed. All questions and answers affecting the scope of work/specifications of the RFP will be included in an addendum, that will be distributed through the BidNet Procurement Solutions Platform ("BidNet"), following the Pre -Proposal Conference to all the attendees. Because the City considers the Pre -Proposal Conference to be critical to understanding the Solicitation requirements, attendance is highly recommended. It is the Proposer's responsibility, prior to submitting a proposal, to acquaint themselves thoroughly regarding any and all conditions and/or requirements that may affect the work to be perfoiuied in any manner. No allowance will be made because of lack of knowledge of these conditions. 2.3 SUBMISSION REQUIREMENTS Electronic proposal submittals to this RFP shall be submitted through BidNet until the date and time as indicated in the Solicitation. The responsibility for submitting a proposal on/or before the stated closing time and date is solely and strictly the responsibility of the Proposer. The City will in no way be responsible for delays caused by technical difficulties or caused by any other occurrence. Electronic proposal submissions may require the uploading of electronic attachments. The submission of attachments containing embedded documents or proprietary file extensions is prohibited. All documents should be attached as individual files and labeled. Any proposals received and time stamped through BidNet, prior to the proposal submittal deadline, shall be accepted as a timely submittal and anything thereafter will be rejected. Additionally, BidNet will not allow for the electronic proposal submittal after the closing date and time has lapsed. Proposals will be opened promptly at the time and date specified. All expenses involved with the preparation and submission of proposals to the City, or any work performed in connection therewith, shall be borne by the Proposer. Accordingly, Proposer: 1. Must register, free of charge, with BidNet to establish an account in order to have access to view and/or respond to any solicitations issued by the City of Miami's Procurement Depai liuent ("City"). 2. Shall submit all proposals electronically. Hard copy proposals submittals will not be accepted. NO EXCEPTIONS. 3. Must submit the Certification Statement and associated solicitation documents which define requirements of items and/or services to be purchased and must be completed and submitted as outlined within the solicitation via BidNet. The use of any other forms and/or the modification of City forms will result in the rejection of the proposer's proposal submittal. 4. Shall ensure that the Certification Statement is fully completed and provided with your proposal. Failure to comply with these requirements may cause the proposal to be deemed non -responsive. 5. Must ensure that an authorized agent of the Proposer's firm signs the Certification Statement and submits it electronically. FAILURE TO SIGN THE CERTIFICATION STATEMENT SHALL DEEM THE PROPOSAL NON -RESPONSIVE. 6. Proposal may be considered non -responsive if proposal does not conform to the terms and conditions of this solicitation. 2.4 DEADLINE FOR RECEIPT OF REQUEST FOR ADDITIONAL INFORMATION/CLARIFICATION Any questions or clarifications concerning this solicitation shall be submitted via BidNet or email to the Contracting Officer on the title page of this solicitation, with a copy filed with the Office of the City Clerk via email at Clerks@miamigov.com, pursuant to Section 1.20. Cone of Silence. The solicitation title and number shall be referenced on all correspondence. All questions must be received no later than September 29, 2025 at 4:00 PM. All responses to questions will be sent to all prospective proposers in the form of an addendum. NO QUESTIONS WILL BE RECEIVED VERBALLY OR AFTER SAID DEADLINE. 2.5 PROPOSERS MINIMUM QUALIFICATION REQUIREMENTS The minimum qualification requirements for this Solicitation are that the Successful Proposer shall: A. Have at least five (5) years of experience in providing telemetry and SCADA services and equipment to a large organization/corporation or government entity of similar size and complexity as the City of Miami; B. Have the same Federal Employee Identification Number (FEIN) for the last five (5) consecutive years; C. Have no record of judgments, bankruptcy, pending lawsuits against the City or criminal activities involving moral turpitude and not have any conflicts of interest that have not been waived by the City Commission; D. Not have any principal, officer, owner, or stockholder of Proposer be in arrears or in default of any debt or contract involving the City, nor have failed to perform faithfully on any previous contract with the City; and E. Not be a "debarred vendor" or have been convicted of a public entity crime under § 287.133, Florida State Statute. Submittals that do not respond completely to all requirements may be considered non -responsive and eliminated from the process. 2.6 PREFERRED QUALIFICATIONS The Successful Proposer should: A. Be a turn -key solutions entity; B. Provide a sole source of responsibility for the services provided under the resultant contract. 2.7 CURES Please refer to Attachment A - APM Regarding Cures and Section 1.56, Notice Regarding "Cures" of the General Terms and Conditions of this Solicitation. 2.8 CHANGES/ALTERATIONS Proposer may change or withdraw a Proposal at any time prior to Proposal submission deadline; however, no oral modifications will be allowed. Written modifications shall take place in the BidNet e-procurement system. Written modifications by way of BidNet or otherwise, shall not be allowed following the proposal deadline. 2.9 ACCEPTANCE OF OFFER The signed submission of your solicitation response shall be considered an offer on the part of the Proposer; such offer shall be deemed accepted upon issuance by the City of a purchase order/executed agreement. All signatures shall NOT be typewritten on any document requesting a signature. 2.10 TERM OF CONTRACT The Proposer(s) qualified to provide the service(s) requested herein (the "Successful Proposer(s)") shall be required to execute an agreement ("Agreement") with the City, which shall include, but not be limited to, the following terms: A. The term of the Agreement(s) shall be for one (1) year with the option to renew for three (3) additional one (1) year periods. B. The City shall have the option to extend or terminate the Agreement. The renewal and any extensions of this contract are subject to the following: A. Continued satisfactory performance compliance with the specifications, terms and conditions established herein. B. Availability of funds. Continuation of the agreement beyond the initial period is a City prerogative, not a right of the Proposer. This prerogative will be exercised only when such continuation is clearly in the best interest of the City. The City reserves the right to automatically extend this contract for up to one hundred eighty (180) calendar days beyond the stated contract term in order to provide City departments with continual service and supplies while a new contract is being solicited, evaluated, and awarded. If the right is exercised, the City shall notify the Proposer, in writing, of its intent to extend the contract at the same price, terms and conditions for a specific number of days. Additional extensions over the first one hundred eighty (180) day extension may occur if the City and the Successful Proposer are in mutual agreement of such extensions. 2.11 EXECUTION OF AN AGREEMENT The Successful Proposer(s), evaluated and ranked in accordance with the requirements of this Solicitation, shall be afforded an opportunity to negotiate an Agreement ("Agreement"), Attachment B with the City. The City reserves the right to execute or not execute, as applicable an Agreement with the Successful Proposer(s) in substantially the same form as the draft Agreement included as part of this solicitation. Such Agreement will be furnished by the City, contain certain terms that are in the City's best interest, and be subject to approval as to legal form by the Miami City Attorney. Various terms including, without limitation, hold harmless/indemnity, insurance, conflicts, ethics, applicable law, and venue, etc. are not negotiable. Prior to the execution of the Agreement, the Successful Proposer shall be an approved, registered entity to do business in the State of Florida. Successful Proposer shall complete all steps necessary as determined by the State of Florida's Division of Corporations, which can be found by visiting www.sunbiz.org. Once documentation approval has been received, the Agreement and any resultant Purchase Order or Notice to Proceed shall be executed. 2.12 TRADE SECRET/CONFIDENTIAL INFORMATION When submitting a Proposal/Bid that will claim trade secret protection, Bidder/Proposer shall submit the protected portion of the proposal/bid in a separate envelope (physical submission) or upload as a separate document (electronically) with clear of identification of its confidentiality and the solicitation number. The entire proposal/bid may not be deemed as a trade secret or confidential information. Florida State Statute 812.081 - Definition of Trade Secret Pursuant to Florida State Statute 812.081: "Trade secret" means the whole or any portion or phase of any formula, pattern, device, combination of devices, or compilation of information, which is for use, or is used, in the operation of a business and which provides the business an advantage, or an opportunity to obtain an advantage, over those who do not know or use it. The term includes any scientific, technical, or commercial information, including financial information, and includes any design, process, procedure, list of suppliers, list of customers, business code, or improvement thereof, whether tangible or intangible, and regardless of whether or how it is stored, compiled, or memorialized physically, electronically, graphically, photographically, or in writing. Irrespective of novelty, invention, patentability, the state of the prior art, and the level of skill in the business, art, or field to which the subject matter pertains, a trade secret is considered to be: 1. Secret; 2. Of value; 3. For use or in use by the business; and 4. Of advantage to the business, or providing an opportunity to obtain an advantage, over those who do not know or use it, when the owner thereof takes measures to prevent it from becoming available to persons other than those selected by the owner to have access thereto for limited purposes. Availability of Proposal/Bid Information for Evaluation Purposes Trade Secret/Confidential labeling will not exempt the full document from being reviewed by the designated evaluator(s) during the solicitation process. Public Record Requests for Items Marked Trade Secret/Confidential Upon the completion of the evaluation process and the approved recommendation for award, all proposals become available to public record requests. When a public records request is received for the bid/proposals, the Proposer whose item was marked trade secret/confidential, will be notified via email of said request. At that time, the Proposer shall provide a response to the emailed letter within five (5) business days with all documentation requested in said letter. The records will then be issued pursuant to the State of Florida's Public Records Law. 2.13 NON -APPROPRIATION OF FUNDS In the event no funds or insufficient funds are appropriated and budgeted or are otherwise unavailable in any fiscal period for payments due under this contract, then the City, upon written notice to the Successful Proposer of such an occurrence, shall have the unqualified right to terminate the contract without any penalty to expense to the City. No guarantee, warranty, or representation is made that any project will be awarded to any firm. 2.14 PRICE PROPOSAL PACKET Proposer shall complete the Price Proposal Packet indicating pricing for providing all services and equipment as detailed in Section 3.0, Specifications/Scope of Work. Failure to submit all forms in the Attachment C - Pricing Packet, as required, shall disqualify Proposer from consideration, and Proposer shall be deemed non -responsive. Only one Price Packet is acceptable, deviation from the forms in the packet will render the proposal non -responsive. 2.15 LIVING WAGE ORDINANCE The City of Miami Living Wage Ordinance is not applicable to this service contract. Please refer to Section 1.38 of the General Terms and Conditions for further information. 2.16 PRICING PROPOSAL AND ESCALATION All services under this Contract shall be priced as stated in the Proposer's proposal. Proposer may request in writing, including a justification, an adjustment of the prices submitted in the pricing schedules based on changes in the CPI for All Urban Consumers (CPI-U), U.S. City Average, Miami -Ft. Lauderdale, FL., no more than sixty (60) days, but no less than thirty (30) days prior to the yearly contract anniversary. If requested, the pricing schedule may be increased/decreased, if necessary, based on review of the CPI criteria listed above. Any adjustments made will be for the following contract year and will not be combined with previous years that were not requested within the date parameters set above (i.e., rate increase requested within the date parameters above in 2025, if approved will be for year 2026). Should the Successful Proposer(s) not submit their request for any particular year, they will forgo any change in the CPI. The City may, after review, refuse to accept the adjusted costs if they are not properly documented, increases are considered to be excessive, or decreases are considered to be insufficient. In the event the City does not wish to accept the adjusted costs, and the matter cannot be resolved to the satisfaction of the City, the City reserves the right to cancel the contract upon giving thirty (30) days' notice to the Successful Proposer. The Procurement Department in consultation with the client department, may also, in its sole discretion, make an equitable adjustment in the contract terms and/or pricing if pricing or availability of supply is affected by extreme or unforeseen volatility in the marketplace, that is, by circumstances that satisfy all the following criteria: (1) the volatility is due to circumstances beyond the Successful Proposer(s) control, (2) the volatility affects the marketplace or industry, not just the particular contract source of supply, (3) the effect on pricing or availability of supply is substantial, and (4) the volatility so affects the Successful Proposer(s) that continued performance of the contract would result in a substantial loss. Successful Proposer(s) might have to supply documentation to justify any requested percentage increase in cost to the City of Miami. 2.17 INSURANCE REQUIREMENTS The proposer shall furnish to City of Miami, c/o Procurement Department, 444 SW 2nd Avenue, 6th Floor, Miami, Florida 33130, Certificate(s) of Insurance which indicate that insurance coverage has been obtained which meets the requirements as outlined below: Please see Attachment D, Insurance Addendum for insurance definitions, requirements, and conditions. Commercial General Liability A. Limits of Liability Bodily Injury and Property Damage Liability Each Occurrence $1,000,000 General Aggregate Limit $2,000,000 Personal and Adv. Liability $1,000,000 Products/Completed Operations $1,000,000 B. Endorsements Required City of Miami included as an additional insured Contingent and Contractual Liability Premises and Operations Liability Primary Insurance Clause Endorsement Business Automobile Liability A. Limits of Liability Bodily Injury and Property Damage Liability Combined Single Limit Combined Single Limit Owned/Scheduled Autos Including Hired, Borrowed or Non -Owned Autos Any One Accident $ 1,000,000 B. Endorsements Required City of Miami included as an additional insured Worker's Compensation A. Limits of Liability Statutory State of Florida Waiver of Subrogation Employer's Liability A. Limits of Liability $100,000 for bodily injury caused by an accident, each accident $100,000 for bodily injury caused by disease, each employee $500,000 for bodily injury caused by disease, policy limit Professional Liability/Errors and Omissions Combined Single Limit Each Occurrence $1,000,000 General Aggregate Limit $1,000,000 Retro Date Included Successful Proposer agrees to maintain Professional Liability/Errors and Omissions coverage, along with Network Security and Privacy Injury (Cyber) coverage, if applicable, for a minimum of 1 year after termination of the contract period subject to continued availability of commercially reasonable terms and conditions of such coverage. BINDERS ARE UNACCEPTABLE. The insurance coverage required shall include those classifications, as listed in standard liability insurance manuals, which most nearly reflect the operations of the bidder/proposer. All insurance policies required above shall be issued by companies authorized to do business under the laws of the State of Florida, with the following qualifications: The Company must be rated no less than "A" as to management, and no less than "Class V" as to financial strength, by the latest edition of Best's Insurance Guide, published by A.M. Best Company, Oldwick, New Jersey, or its equivalent. All policies and/or certificates of insurance are subject to review and verification by Risk Management prior to insurance approval. Certificates will indicate no modification or change in insurance shall be made without thirty (30) days' written advance notice to the certificate holder. Compliance with the foregoing requirements shall not relieve the bidder/proposer of their liability and obligation under this section or under any other section of this Agreement. If insurance certificates are scheduled to expire during the contractual period, the Bidder/Proposer shall be responsible for submitting new or renewed insurance certificates to the City at a minimum of ten (10) calendar days in advance of such expiration. In the event that expired certificates are not replaced with new or renewed certificates which cover the contractual period, the City shall: • Suspend the contract until such time as the new or renewed certificates are received by the City in the manner prescribed in the Request for Proposals. The City may, at its sole discretion, terminate this contract for cause and seek re -procurement damages from the Successful Bidder/Proposer in conjunction with the General and Special Terms and Conditions of the Solicitation. The Successful Bidder/Proposer shall be responsible for assuring that the insurance certificates required in conjunction with this Section remain in force for the duration of the contractual period; including any and all option terms that may be granted to the Successful Bidder/Proposer. See Attachment D — Insurance Addendum. ***THERE IS NO BID BOND ASSOCIATED WITH THE SUBMISSION OF A PROPOSAL OR THE EXECUTION OF AN AGREEMENT UPON AWARD OF CONTRACT.*** 2.18 LIQUIDATED DAMAGES Failure to complete the project in accordance with the specifications and to the satisfaction of the City within the time stated shall result in liquidated damages being assessed. The Successful Proposer shall be subject to an assessment of liquidated damages in the amount of one hundred dollars ($100) for each and every calendar day the work remains incomplete (not to exceed the total amount of the contract), as compensation due to the City for loss incurred by the City due to such incompletion of the work. The City shall have the right to deduct said liquidated damages from any amount due or that may become due to the Successful Proposer under this agreement or to invoice the Successful Proposer for such damages if the costs incurred exceed the amount due to the Successful Proposer. 2.19 METHOD OF PAYMENT Payment will be made within forty-five (45) calendar days, in accordance with Florida Statutes Sections 218.73 and 218.74 of the Prompt Payment Act for services rendered the previous month, upon submission of properly certified/approved invoices. All such information shall be provided to the City Project Manager, or designee. The City will pay the contract price minus any liquidated damages and/or other damages to Successful Proper upon completion and acceptance. Each invoice shall include total cost, proof of payment to subcontractors and suppliers with corresponding release of liens forms and affidavits, if applicable. 2.20 SUB-CONTRACTOR(S) OR SUB-CONSULTANT(S) A Sub -Consultant, herein known as Sub-Contractor(s) is an individual or firm contracted by the Proposer or Proposer's firm to assist in the performance of services required under this Solicitation. A Sub -Contractor shall be paid through Successful Proposer or Successful Proposer's firm and not paid directly by the City. Sub -Contractors are allowed by the City in the performance of the services delineated within this Solicitation. Proposer must clearly reflect in its Proposal the major Sub -Contractors to be utilized in the performance of required services. The City retains the right to accept or reject any Sub -Contractors proposed in the response of Successful Proposer or prior to agreement execution. Any and all liabilities regarding the use of a Sub -Contractor shall be borne solely by the Successful Proposer and insurance for each Sub -Contractors must be maintained in good standing and approved by the City throughout the duration of the Agreement. Neither Successful Proposer nor any of its Sub -Contractors are considered to be employees or agents of the City. Failure to list all Sub -Contractors and provide the required information may disqualify any proposed Sub -Contractors from performing work under this Solicitation. Proposers shall include in their responses the requested Sub -Contractor information and include all relevant information required of the Proposer. In addition, within five (5) working days after the identification of the award to the Successful Proposer, the Successful Proposer shall provide a list confirming the Sub -Contractors that the Successful Proposer intends to utilize in the Agreement, if applicable. The list shall include, at a minimum, the name, location of the place of business for each Sub -Contractor, the services Sub -Contractor will provide relative to any agreement that may result from this Solicitation, any applicable licenses, references, ownership, and other information required of Proposer. 2.21 PROJECT MANAGER Upon award, Successful Proposer(s) shall report and work directly with Arsslan Zafar, Engineer I, or designee, who shall be designated as the Project Manager for the Department of Resilience and Public Works. 2.22 UNAUTHORIZED WORK The Successful Proposer shall not begin work until a Purchase Order and/or a Notice to Proceed are received. 2.23 SPECIFICATION EXEMPTION Specifications are based on the most current literature available. Proposer shall notify the City of Miami Procurement Department, in writing, no less than fourteen (14) days prior to solicitation closing date of any change in industry specifications which conflict with the specifications. Proposers must explain any deviation from the specifications in writing as a footnote on the applicable specification page and enclose a copy of supporting data detailing the changed item(s) with his/her submission. Additionally, Proposers must indicate any options requiring the addition of other options, as well as those which are included as a part of another option. Failure of Proposers to comply with these provisions will result in Proposers being held responsible for all costs required to bring the item(s) in compliance with contract specifications. These specifications describe the various items or services required, enumerating or defining the extent of same, but failure to list any item or services under scope of the several sections shall not relieve the Successful Proposer from performing such work where required by any part of these specifications, or necessary to the satisfactory completion of services. 2.24 ADDITIONS/DELETIONS OF SERVICES/ITEMS Although this solicitation identifies specific suppliers to provide specific items/services, it is hereby agreed and understood that any service, or item may be added/deleted to/from this Contract at the option of the City. When an additional item/service is required, the Supplier(s) shall be invited to submit pricing to provide the new item/service. If the addition(s) is(are) in the best interest of the City, an amendment to the contract shall be issued by the City. 2.25 EVALUATION/SELECTION PROCESS AND CONTRACT AWARD The procedure for response evaluation, selection and award is as follows: 1. Solicitation issued; 2. Receipt of responses; 3. Opening and listing of all responses received; 4. Procurement staff will review each submission for compliance with the submission requirements of the solicitation, including verifying that each submission includes all documents required; 5. An Evaluation Committee ("Committee"), appointed by the City Manager, comprised of appropriate City of Miami personnel and members of the community, as deemed necessary, with the appropriate technical expertise and/or knowledge, shall meet to evaluate each response in accordance with the requirements of this solicitation and based upon the evaluation criteria as specified herein; 6. The Committee reserves the right, in its sole discretion, to request Proposers to make oral presentations before the Committee as part of the evaluation process. The presentation may be scheduled at the convenience of the Committee and shall be recorded; 7. The Committee reserves the right to rank the proposals and shall make its recommendation to the City Manager requesting the authorization to negotiate. No Proposer(s) shall have any rights against the City arising from such negotiations thereof; 8. The City Manager reserves the right to reject the Committee's recommendation to negotiate and instruct the Committee to re-evaluate and make another recommendation or reject all proposals. No Proposer(s) shall have any rights against the City arising from such termination thereof; 9. If the City Manager accepts the Committee's recommendation to negotiate, Procurement will negotiate a final contract with the Successful Proposer, and submit a recommendation to award a contract to the City Manager; 10. The City Manager shall then submit his or her award recommendation and negotiated contract to the City Commission for approval. Written notice shall be provided to all proposers; 11. If the City Manager accepts the award recommendation, the City Manager's recommendation for award of contract will be sent via email to all Proposers, which will initiate the protest period. Additionally, the award recommendation will also be posted in BidNet. 12. After reviewing the City Manager's recommendation, the City Commission may: • Approve the City Manager's award recommendation and negotiated contract; • Reject all proposals; or • Reject all proposals and instruct the City Manager to reissue a solicitation; The decision of the City Commission shall be final. Written notice of the award shall be given to the Successful Proposer. 2.26 FAILURE TO PERFORM Should it not be possible to reach the Successful Proposer or its Project Manager, and/or should remedial action not be taken within 48 hours of any failure to perform according to specifications, the City reserves the right to declare Successful Proposer in default of the agreement. 2.27 RECORDS During the contract period, and for at least three (3) subsequent years thereafter, Successful Proposer shall provide the City access to all files and records maintained on the City's behalf. 2.28 TRUTH IN NEGOTIATIONS Execution of the resulting agreement by the Successful Proposer shall act as the execution of truth -in -negotiation certificate stating that wage rates and other factual unit costs supporting the compensation of the resulting Agreement are accurate, complete, and current at the time of contracting. The original contract price and any additions thereto shall be adjusted to exclude any significant sums by which the City determines the contract price was increased due to inaccurate, incomplete, or non -current wage rates and other factual unit costs. All such contract adjustments shall be made within one (1) year following the end of the Agreement. 2.29 TRANSITION -OUT OBLIGATIONS For a period of three (3) months from the Termination Date of the contract, the Successful Proposer shall assist with the orderly transition of duties and shall be reasonably available to the succeeding contractor with regards to questions, inquiries and other details related to this contract, if applicable. 2.30 TERMINATION FOR DEFAULT If Successful Proposer defaults in its performance under this Agreement and does not cure the default within thirty (30) calendar days after written notice of the default, in addition to all remedies afforded to the City, the City Manager/Executive Director may terminate this contract in whole or in part, upon written notice without penalty to the City of Miami. The Successful Proposer shall be liable for all damages including the excess cost of procuring similar supplies and services. If it is determined for any reason the Successful Proposer is not in default or the Successful Proposer's failure to perform is without their or their subcontractor's control, fault, or negligence, the termination will be deemed for the convenience of the City. FOR CONVENIENCE The City Manager /Executive Director may terminate this Contract, in whole or in part, upon thirty (30) calendar days prior written notice when it is in the best interest of the City of Miami. If the contract is for supplies, products, equipment, or software, and so terminated for convenience by the City, the Successful Proposer will be compensated in accordance with an agreed upon adjustment of cost. If the contract is for services and so terminated, the City shall only be liable for payment in accordance with the payment provisions of the Contract for those services rendered prior to termination. 2.31 ADDITIONAL TERMS AND CONDITIONS No additional terms and conditions included as part of your solicitation response shall be evaluated or considered, and any and all such additional terms and conditions shall have no force or effect and are inapplicable to this solicitation. If submitted either purposely, through intent or design, or inadvertently, appearing separately in transmittal letters, specifications, literature, price lists or warranties, it is understood and agreed that the General Conditions and Special Conditions in this solicitation are the only conditions applicable to this solicitation and that the Proposer's authorized signature affixed to the Proposer's acknowledgment form attests to this. If a Professional Services Agreement (PSA) or other Agreement is provided by the City and is expressly included as part of this solicitation, no additional terms or conditions which materially or substantially vary, modify, or alter the terms or conditions of the PSA or Agreement, in the sole opinion and reasonable discretion of the City will be considered. Any and all such additional terms and conditions shall have no force or effect and are inapplicable to this PSA or Agreement. 2.32 COUNTERPARTS; ELECTRONIC SIGNATURES The resulting Agreement and any amendments hereto may be executed in counterparts and all such counterparts taken together shall be deemed to constitute one and the same instrument, each of which shall be an original as against either party whose signature appears thereon, but all of which taken together shall constitute but one and the same instrument. An executed facsimile or electronic scanned copy of the Agreement shall have the same force and effect as an original. The parties shall be entitled to sign and transmit an electronic signature on this Agreement (whether by facsimile, PDF, or other email transmission), which signature shall be binding on the party whose name is contained therein. Any party providing an electronic signature agrees to promptly execute and deliver to the other parties an original signed Agreement upon request. 2.33 ANTITRUST VIOLATOR VENDORS A person or an affiliate who has been placed on the Antitrust Violator Vendors List following a conviction or being held civilly liable for an antitrust violation may not submit a bid, proposal, or reply on any agreement to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on any agreement with a public entity for the construction or repair of a public building or public work; may not submit a bid, proposal, or reply on leases of real property to a public entity; may not be awarded or perform work as a grantee, supplier, subcontractor, or consultant under an agreement with a public entity; and may not transact new business with a public entity. 2.34 ANTI -HUMAN TRAFFICKING The Proposer confirms and certifies that it is not in violation of Section 787.06, Florida Statutes, and that it does not and shall not use "coercion" for labor or services as defined in Section 787.06, Florida Statutes. The Proposer shall execute and submit to the City an Affidavit, of even date herewith, in compliance with Section 787.06(13), Florida Statutes, attached an incorporated herein as "Anti -Human Trafficking Affidavit". If the Successful Bidder/Proposer fails to comply with the terms of this Section, the City may suspend or terminate this Agreement immediately, without prior notice, and in no event shall the City be liable to Successful Proposer for any additional compensation or for any consequential or incidental damages. See Attachment E, Anti -Human Trafficking Affidavit. Failure to complete, sign and upload the Anti -Human Trafficking Affidavit may render your bid non -responsive. 2.35 E-VERIFY EMPLOYMENT VERIFICATION Qualified Proposer(s) shall E-Verify the employment status of all employees and subcontractors to the extent required by federal, state, and local laws, rules, and regulations. The City shall consider employment by any Qualified Proposer(s) of unauthorized aliens a violation of Section 274A(e) of the Immigration and Nationality Act. If Qualified Proposer(s) knowingly employs unauthorized aliens, such violation shall be cause for termination of the Contract. Furthermore, Qualified Proposer(s) agrees to utilize the U.S. Agency of Homeland Security's E- Verify System, https://e-verify.uscis.gov/emp, to verify the employment eligibility of all employees during the term of the Contract. Qualified Proposer(s) shall also include a requirement in subcontracts that the subcontractor shall also utilize the E-Verify System to verify the employment eligibility of all employees of the subcontractor during the term of the Contract. 3.0 SPECIFICATIONS/SCOPE OF WORK I. INTRODUCTION PROPOSERS ARE NOT REQUIRED TO ENTER A UNIT PRICE IN THE LINE ITEM LISTED IN THE ACTUAL SOLICITATION. PROPOSERS SHALL COMPLETE ATTACHMENT C, PROPOSAL PRICE PACKET. II. RFP OVERVIEW This RFP establishes a contract for the design and installation of the Stormwater Pump Station Telemetry services which plans to add supervisory control and data acquisition ("SCADA") capabilities to twelve (12) existing pump stations, including cloud -based communications, allowing remote monitoring and control for the City of Miami's Department of Resilience and Public Works ("RPW"). The City has prepared design criteria to detail the requirements of the system, by way of detailed performance and prescriptive requirements. The removal of various existing physical features may be required in order to construct all components of the work as described in this design. The Proposer shall be responsible for the furnishing and installation of all systems, equipment, hardware, software, materials, supplies, and manufactured articles and furnishing all labor, transportation, and services, including fuel, power, water, and essential communications, or other operations including testing, commissioning, and final restoration work required for the functional and satisfactory delivery of the stormwater pump station SCADA system and all of its ancillary elements. The Proposer shall provide a complete installation, and all materials, trainings, system manuals, and services not expressly indicated or called for in this RFP which may be reasonably assumed as necessary for the complete and proper functionality of the system. III. STORM WATER PUMP STATION LOCATIONS ("Station" or "Pump Station") The system shall be provided for twelve (12) stations. A. Riverview —1301 NW 6th Street, Miami FL 33125 B. Lawrence — 342 SW 7th Avenue, Miami FL 33130 C. Orange Bowl —1775 NW 7th Street, Miami FL 33125 D. Belle Meade — 7747 NE 8th Avenue, Miami FL 33138 E. Brickell Avenue — SE 12th Street at Brickell Avenue Median, Miami FL 33130 F. Mary Brickell — 801 SW 1st Avenue, Miami, FL 33130 G. San Marco — 1383 South Venetian Way, Miami FL 33139 H. Antonio Maceo — 5105 NW 7th Street, Miami FL 33126 I. West End No. 1 — 6311 SW 6th Street — SW 63rd Court and SW 6th Street, Miami FL 33144 J. West End No. 2 — 6321 SW 2th Street — SW 63rd Court and SW 2nd Street, Miami FL 33144 K. West End No. 3 — 501 Tamiami Canal Road — NW 64th Court and NW 3rd Street, Miami FL 33126 L. West End No. 4 — 6250 Tamiami Canal Road — NW 62nd Court and NW 5th Street, Miami FL 33126 The City reserves the right to add new pump stations to the contract. Upon addition, a quote will be requested for the purchase, installation, and annual maintenance of all hardware/software necessary to bring the pump station on. IV. SCOPE OF WORK The Proposer shall provide all labor, equipment, materials, testing, and quality control for final acceptance by the City of the system components. In addition to furnishing and installation, the Proposer shall be responsible for the design, permitting, acceptance and testing, providing documentation (manuals) and warranties and training (as required). Additionally, the Proposer shall provide all the necessary investigations including site investigations, surveys, and utility locates if applicable. The Proposer shall be responsible for coordinating with utility agencies/owners for the required utility adjustments, removals, and/or relocations, if applicable. The scope encompasses, but is not limited to, all related site/civil/electrical/communications infrastructure, investigation, and design on electrical interface to input/output signals and devices at each Station; design, installation, configuration, and programming of a SCADA controller at each Station; design, installation, and startup of a cloud -based telemetry system; and landscaping. Landscaping shall only include refurbishment of any existing disturbed areas during installation. The Proposer shall prepare all surveys; designs; construction documents including drawings, specifications, as -built documentation, and shop drawings; as well as obtain all permits including, but not limited to, environmental, MOT, ROW, and building permitting, if applicable. Additionally, the Proposer shall perform all necessary inspections, testing, and perform all supportive ancillary tasks to the primary scope of services to successfully complete all phases of the Project. The Proposer shall be responsible for security, protection from vandalism and theft of their own means of work and equipment at each of the Stations. The Proposer shall furnish a telemetry -based SCADA System, including permitting, networks, remote terminal units ("RTU"), programming, SCADA system software and ancillary software, factory and on -site testing, training, startup, maintenance, and miscellaneous and ancillary services as required. The Proposer will be required to interface with existing structures, mechanical equipment, wiring, cabling and conduit, controls and electrical facilities and piping which may be removed if unused. The Proposer is responsible for all associated electrical work, instrumentation and control systems work and all appurtenant work to ensure the system is complete, tested, and ready for operation, all in confonnance with the City's contract documents. The telemetry system manufacturer selected shall provide a system that is fully compatible with the City's Stormwater Pump Station SCADA System, integrating the new system with the existing system and leveraging similar functionality, hardware/spares, programming skills, and support. Throughout the duration of this project, the Proposer shall involve and inform the public through a public involvement program for any impacts that may affect the public. The following sections provide an introductory scope at a high level. More detailed requirements are specified within other sections and attachments of this solicitation. A. GENERAL REQUIREMENTS Telemetry Implementation Fully implement and integrate the cloud -based telemetry system with the City's existing Stormwater Pump Station SCADA System. Enable access to Pump Station SCADA graphics from any authorized PC, tablet, smart phone, or other device with Wi-Fi connectivity. Coordinate with the City to install and activate required software on these devices for remote access. Provide two -factor authentication ("2FA") for access to the SCADA system to secure against unauthorized access to the system. The means of 2FA shall be compatible with any existing City 2FA. Station Controller The new RTUs are to provide monitoring and control functions at each station, and interface to a cloud -based telemetry system. The system is to be fully compatible with what the City has currently installed at all pump stations. Pump Stations contain a variety of existing control and monitoring devices, such as Flygt pump controllers, SmartStix I/O devices, control relays and timers. These devices may be retained and interfaced with or may be replaced with new RTUs. It is the Proposer's responsibility to investigate each station, and design the electrical interface required to provide the I/O indicated to the new RTU and SCADA System. Provide cellular modems for communications compatible with South Bayshore Lane Pump Station. Provide uninterruptible power supplies ("UPS") to each controller and telemetry system. Include environmental protection for the controller system as recommended by the system manufacturer. Enclosures shall be rated NEMA-4X (316L SS). Network Devices Local Ethernet -compatible network devices such as switches, routers, and media -converters. Minimum requirements: Copper ports - RJ-45, 10/100Mbps, qty. to be determined; 24 vDC powered; DIN -rail mounted; unmanaged. Client Application Local device application ("App") resident on smart phone or touchpad. Camera New 360-degree cameras at each Pump Station. Minimum requirements: 360-degrees of view; 4K resolution; 100% coverage; 60 days local recording; aluminum pole with internal chase for cabling. Raceways Comply with the Florida Building Code and the City's construction standards for the installation of below grade and exposed conduit. Minimum requirements: 3/4" minimum; rigid non-metallic below grade; rigid aluminum above grade and exposed. Conductors Comply with the Florida Building Code and the City's construction standards for the installation of conductors. Splices are not allowed. Minimum requirements: Type MTW inside control panels; Type XHHW-2 for power (#14 AWG minimum); 2-conductor, #16 AWG, twisted, shielded pairs for controls; CAT-6 for Ethernet. Rain Sensor Comply with the City's existing requirements. Minimum requirements: sensing pad size: 5cm x 4cm with a nickel plate on one face; analog and discrete outputs; anti -conductivity & oxidation with long- time use; sensitivity adjustable by a potentiometer Water Quality Analyzer Turbidity sensor and transmitter that measures suspended particles in a liquid sample. Minimum requirements: infrared/scattered light; +/- 0.001 NTU accuracy; 0.001 NTU detection limit; 120 vAC powered; LCD transmitter display. Fuel -Oil Level Gauge Level gauge installed in existing fuel -oil (diesel) tanks to measure fuel -oil level. Existing above -grade and subbase tanks supply fuel -oil to generators. Proposer shall examine each fuel -oil tank and provide a level gauge that applies to each specific application. Minimum requirements: local analog indication, 4-20 mA output to RTU. Elapse Time Meter Minimum requirements: Heavy duty with digital readout in hours, 4-20 mA output to RTU. Additional System Components Proposer shall submit solutions to the City for approval. Additional system components include (but are not limited to) discrete devices, door/gate switches, relays, and other control panel components. PUMP STATION DETAILS The twelve (12) existing pump stations include three (3) locations with building structures and nine (9) that are outdoor/fenced-in locations. Each station has common or similar equipment and devices that shall be connected to the telemetry system. This includes equipment such as stormwater pumps, transfer switches, starters, generator, control panels, etc. A list of existing features respective to each station can be found beginning in Section 1.3.3. Location, quantity, and applicability of each equipment and devices for individual pump station site shall be inspected, checked, and verified. Outdated devices and equipment, that are not compatible with the current SCADA & telemetry system, shall be modified/installed with the compatible sensor/signal, or if necessary, shall be replaced. If equipment, devices, or system listed in this pump station details does not reflect the actual existing equipment in the site, maybe due to outdated as-builts, out of services equipment, or under any circumstances, the scope of work shall adapt the current existing conditions and shall be provided with newly installed equipment, devices, or system. Install new equipment and enclosures on existing support structures as practical. Space exists at most stations for new enclosures. If adequate space is not available, design and install a supplemental support structure. Riverview Pump Station Riverview Pump Station consists of a building that houses a coarse screen, electrical panels, control panels, controls, soft starters, an auto -transfer switch for two (2) pumps, four (4) submersible stormwater pumps, which are two (2) 400HP and two (2) 500HP. The main electric power from the utility is supplied to the main switch board. The station has an emergency stand-by generator outside the building, which is only capable of supplying back-up power for one (1) of the submersible stormwater pumps and control panels. Riverview Pump Station contains the following devices/equipment which shall have remote monitoring and/or control: 1. Main Electric Power 2. Emergency Diesel Generator 3. Auto -Transfer Switches 4. Pumps 5. Pumps' Monitoring System 6. Pump Control Panel 7. Wet Well Level Indicator 8. Front Door 9. Spare I/O, Discrete and Analog Other devices/equipment that need to be provided/installed and monitored: 1. Generator monitoring system for total harmonic distortion (THD). 2. Generator Fuel Guage 3. Electronic Elapse Time Meters (ETM) for pump operation hours per day Optional devices/equipment that can be provided/installed and monitored: 1. Bar Screen 2. 360 cameras, covering the interior and exterior that needs to be monitored/secured 3. Fire System 4. CO2 Retardant System 5. Rain Sensor 6. Water Quality Analyzer Riverview Pump Station has existing SmartStix I/O interfaces and a panel -mounted OIT. Determine specific I/O currently monitored by the SmartStix I/O units. Based on requirements shown in Table 1, design the electrical interfaces required to provide control and monitoring functions with the new RTU and cloud -based SCADA System. The SmartStix T/O units may be incorporated into the upgraded system or replaced with a new RTU. Retain existing OIT functionality. Provide the followine SCADA control points: Table 1. Riverview Pump Station Scope Signal Quantity jimequired Wo Main Electric Power Failure on/off 1 Furnish and install conduit & conductors from existing ATS to RTU Main Automatic Transfer Switch (ATS) 1 Furnish and install conduit & conductors from existing failure on/off ATS to RTU Generator on/off. 1 Furnish and install conduit & conductors from the existing generator to RTU Diesel Tank Level 1 Furnish and install new fuel level gauge and provide conduit & conductors from the existing generator to RTU Pump(s) Status (running, stop, fault) 4 Furnish and install conductors from existing soft starters to RTU Pump station water levels high/low 1 Furnish and install conductors from the existing control panel controller to RTU Pumps hours of operation per day. 4 Furnish ETM function in RTU Monitoring system on/off. 1 Program the system to detect the monitoring status from cloud service to apps. Front door open/closed. 1 Furnish and install new door's sensor and provide conduit & conductors from existing front door to RTU ATS position (Normal/Emergency) 1 Furnish and install conduit & conductors from existing ATS to RTU Pump HOA Status (Not in Auto) 4 Furnish and install conductors from existing soft starters to RTU Generator Current, Voltage, Battery charger status, total harmonic distortion. Furnish and install new generator monitoring system for total harmonic distortion (THD) and provide conduit & conductors from the existing generator to RTU. Generator controller position (Not in 1 auto). Furnish and install Conduit & conductors from the existing generator to RTU 25% spare I/O, discrete and 1 analog. Program the system to monitor available spares. Additional bid items: ump Station Optional Quantity Water Quality (Turbid >29 NTU) on/off. 1 Furnish and install new analyzer element/transmitter, and provide conduit & conductors from element to transmitter and conductors from transmitter to RTU Bar Screen on/off 1 Furnish and install conductors from the existing bar screen to RTU CO2 Retardant System 2 building structures on/off Furnish and install conductors from existing bar CO2 Retardant system to RTU Fire System on/off. 1 Furnish and install conduit & conductors from the existing fire system to RTU Rain sensor at each station. 1 Furnish and install new rain sensor and provide conduit & conductors from the new rain sensor to RTU CCTV Surveillance (360° camera) 'Off/On/Signal Lost). 2 Furnish and install new cameras covering the exterior and interior of the building and provide conduit & conductors from their location to RTU Lawrence Pump Station The Lawrence Pump Station consists of a building that houses a coarse screen, auto -transfer switches, panels, controls, soft starters, two (2) stormwater pumps which are 100HP and 200 HP, and a conveyor system. The main electric power is split up into two (2) 600 Amp service rated disconnects, one serving the initial building design, including the main 100 HP pump, and the second serving the recent addition of the 200 HP pump. The station has an emergency stand-by generator outdoor supplying everything in the building except the 200 HP motor. Lawrence Pump Station contains the following devices/equipment that shall have monitoring and/or control: 1. Main Electric Power 2. Generator 3. Auto -Transfer Switches 4. Pumps 5. Pump's Monitoring System 6. Wet Well Level Indicator 7. Front Door 8. Spare I/O, discrete and analog Other devices/equipment that needs to be provided/installed and monitored: 1. Generator monitoring system for total harmonic distortion (THD). 2. Generator Fuel Guage 3. Electronic Elapse Time Meters (ETM) for pump operation hours per day Optional devices/equipment that can be provided/installed and monitored: 1. Conveyor System & Bar Screen 2. 360 cameras, covering the interior and exterior that needs to be monitored/secured 3. Fire System 4. CO2 Retardant System 5. Rain Sensor 6. Water Quality Analyzer Lawrence Pump Station contains existing SmartStix I/O interfaces and a panel -mounted OIT. Determine specific I/O currently monitored by the SmartStix I/O units. Based on requirements shown in Table 2, design the electrical interfaces required to provide control and monitoring functions with the new RTU and cloud -based SCADA System. The SmartStix I/O units may be incorporated into the upgraded system, or their functionality replaced with the new RTU. Retain existing OIT functionality. Provide the following SCADA control points: Table 2. Lawrence Pump Station Scope Signal Quantity Required Wo didill Main Electric Power Failure on/off 1 Furnish and install conduit & conductors from existing ATS to RTU Main Automatic Transfer Switch (ATS) 1 failure on/off Furnish and install conduit & conductors from existing ATS to RTU Generator on/off. 1 Furnish and install conduit & conductors from the existing generator to RTU Diesel Tank Level 1 Furnish and install new fuel level gauge and provide conduit & conductors from the existing generator to RTU Pumps on/off. 3 Furnish and install conductors from existing soft starters to RTU Pump station water levels high/low 1 Furnish and install conductors from the existing control panel controller to RTU Pumps hours of operation per day. 3 Furnish ETM function in RTU Monitoring system on/off. 1 Program the system to detect the monitoring status from cloud service to apps. Front door open/closed. 1 Furnish and install new door's sensor and provide conduit & conductors from existing front door to RTU ATS position (Normal/Emergency) 1 Furnish and install conduit & conductors from existing ATS to RTU Pump HOA Status (Not in Auto) 3 Furnish and install conductors from existing soft starters to RTU Generator Current, Voltage, Battery 1 charger status, total harmonic distortion. Furnish and install new generator monitoring system for total harmonic distortion (THD) and provide conduit & conductors from the existing generator to RTU. Generator controller position (Not in auto). 1 Furnish and install Conduit & conductors from the existing generator to RTU 25% spare I/O, discrete and analog. 1 Program the system to monitor available spares. Additional bid items: I able 2a. Lawrence Pump Station Optional11111111 Signal Quantity or Water Quality (Turbid >29 NTU) on/off. 1 Furnish and install new analyzer element/transmitter, and provide conduit & conductors from element to transmitter and conductors from transmitter to RTU onveyor & Bar Screen on/off 1 Furnish and install conductors from the existing bar screen to RTU CO2 Retardant System 2 building structures on/off 1 Furnish and install conductors from existing bar CO2 Retardant system to RTU Fire System on/off. 1 Furnish and install conduit & conductors from the existing fire system to RTU Rain sensor at each station. 1 Furnish and install new rain sensor and provide conduit & conductors from the new rain sensor to RTU CCTV Surveillance (360° camera) (Off/On/Signal Lost). 2 Furnish and install new cameras covering the exterior and interior of the building and provide conduit & conductors from their location to RTU Orange Bowl Pump Station The Orange Bowl Pump Station consists of a building that houses a coarse screen, panels, controls, soft starters, transfer switches, three (3) stormwater pumps, which are two (2) 100HP and one (1) 50 HP. The station has an emergency stand-by generator outside supplying the building. Orange Bowl contains the following devices/equipment requiring monitoring and/or control: 1. Main Electric Power 2. Generator 3. Auto -Transfer Switches 4. Pumps 5. Pump's Monitoring System 6. Wet Well Level Indicator 7. Bar Screen 8. Front Door 9. Spare I/O, discrete and analog Other devices/equipment that need to be provided/installed and monitored: 1. Generator monitoring system for total harmonic distortion (THD). 2. Generator Fuel Gauge 3. Electronic Elapse Time Meters (ETM) for pump operation hours per day Optional devices/equipment that can be provided/installed and monitored: 1. Bar Screen 2. 360 cameras, covering the interior and exterior that needs to be monitored/secured 3. Fire System 4. CO2 Retardant System 5. Rain Sensor 6. Water Quality Analyzer This Pump Station is controlled by hardware relays and alternator. Determine specific I/O currently monitored by the existing devices. Based on requirements shown in Table 3, design the electrical interfaces required to provide control and monitoring functions with the new RTU and cloud -based SCADA System. The device I/O units may be incorporated into the upgraded system or replaced with a new RTU. Retain existing OIT functionality. Provide the following SCADA control points: Table 3. Orange Bowl Pump Station Scope W Signal Quantity Required Wor Main Electric Power Failure on/off 1 Furnish and install conduit & conductors from existing ATS to RTU Main Automatic Transfer Switch (ATS) 1 Furnish and install conduit & conductors from failure on/off existing ATS to RTU Generator on/off. 1 Furnish and install conduit & conductors from the existing generator to RTU Diesel Tank Level 1 Furnish and install new fuel level gauge and provide conduit & conductors from the existing generator to RTU Pumps on/off. 3 Furnish and install conductors from existing soft starters to RTU Pump station water levels high/low 1 Furnish and install conductors from the existing control panel controller to RTU Me 3. Orange Bowl Pump Station Scope a1 Quantity Pumps hours of operation per day. 3 Required W. Furnish ETM function in RTU Monitoring system on/off. 1 Program the system to detect the monitoring status from cloud service to apps. Front door open/closed. 1 Furnish and install new door's sensor and provide conduit & conductors from existing front door to RTU ATS position (Normal/Emergency) 1 Furnish and install conduit & conductors from existing ATS to RTU Pump HOA Status (Not in Auto) 3 Furnish and install conductors from existing soft starters to RTU Generator Current, Voltage, Battery charger 1 status, total harmonic distortion. Furnish and install new generator monitoring system for total harmonic distortion (THD) and provide conduit & conductors from the existing generator to RTU. Generator controller position (Not in auto). 1 Furnish and install Conduit & conductors from the existing generator to RTU 25% spare I/O, discrete and analog. 1 Program the system to monitor available spares. Additional bid items: Table 3a. Orange Bowl Pump Station Optional Signal Quantity Water Quality (Turbid >29 NTU) 1 on/off. Furnish and install new analyzer element/transmitter, and provide conduit & conductors from element to transmitter and conductors from transmitter to RTU Bar Screen on/off 1 Furnish and install conductors from the existing ba screen to RTU CO2 Retardant System 2 building structures 1 on/off Furnish and install conductors from existing bar CO2 Retardant system to RTU Fire System on/off. 1 Furnish and install conduit & conductors from the existing fire system to RTU Rain sensor at each station. 1 Furnish and install new rain sensor and provide conduit & conductors from the new rain sensor to RTU CCTV Surveillance (360° camera) 2 (Off7On/Signal Lost). Furnish and install new cameras covering the exterior and interior of the building and provide conduit & conductors from their location to RTU Belle Meade Pump Station The Belle Meade Pump Station consists of a fenced area containing panels, controls, soft starters, transfer switches, three (3) 145HP stormwater pumps, a 40 HP duty pump and a 3/4 HP sump pump. The station has an emergency stand-by generator inside the fenced area. Belle Meade contains the following devices/equipment requiring monitoring and/or control: 1. Main Electric Power 2. Generator 3. Auto -Transfer Switches 4. Pumps 5. Pump Monitoring System 6. Wet Well Level Indicator 7. Fence Gate 8. Spare I/O, discrete and analog Other devices/equipment that need to be provided/installed and monitored: 1. Generator monitoring system for total harmonic distortion (THD). 2. Generator Fuel Guage 3. Elapse Time Meters (ETM) for pump operation hours per day Optional devices/equipment that can be provided/installed and monitored: 1. 360 cameras, covering the interior and exterior that needs to be monitored/secured 2. Rain Sensor 3. Water Quality Analyzer This station is currently equipped with an Allen-Bradley MicroLogix 1400 controller. A panel -mounted HMI, a Unitronics OIT, Gemalto modem, and Ethernet network switch are also existing. Determine specific I/O currently monitored and controlled by the existing Programmable Logic Controller ("PLC"). Based on requirements shown in Table 4, design the electrical interfaces required to provide control and monitoring functions with the new RTU and cloud -based SCADA System. The device I/O units may be incorporated into the upgraded system or replaced with a new RTU. Direct communication between the PLC and new RTU may be possible. Retain existing OIT functionality. Coordinate with the Owner on updating remote communication interface. Provide the following SCADA control points: Table 4. Belle Meade Pump Station Scope iiiiiM Quantityequired ,-,g •.. Main Electric Power Failure on/off 1 Furnish and install conductors from the existing ATS to RTU Main Automatic Transfer Switch (ATS) failure on/off 1 Furnish and install conduit & conductors from the existing ATS to RTU Generator on/off. 1 Furnish and install conductors from the existing generator to RTU Diesel Tank Level 1 Installation of fuel level gauge and conduit & conductors from the existing generator to RTU Pumps on/off. 3 Furnish and install conductors from the existing soft starters to RTU Pump station water levels high/low 1 Furnish and install conductors from the existing control panel controller to RTU Table 4. Belle Meade Pump Station Scope kignal Quantity Pumps hours of operation per day. 3 Required Work Furnish ETM function in RTU Bar Screen on/off. 0 Not applicable CO2 Retardant System 2 building structures 0 on/off Not applicable Fire System on/off. 0 Not applicable Monitoring system on/off. 1 Program the system to detect the monitoring status from cloud service to apps. Fenced gate open/closed. 1 Furnish and install new fence gate sensor and provide conduit & conductors from existing front door to RTU ATS position (Normal/Emergency) 1 Furnish and install conduit & conductors from existing ATS to RTU Pump HOA Status (Not in Auto) 3 Furnish and install conductors from existing soft starters to RTU Generator Current, Voltage, Battery charger 1 status, total harmonic distortion. Furnish and install new generator monitoring system for total harmonic distortion (THD) and provide conduit & conductors from the existing generator to RTU. Generator controller position (Not in auto). 1 Furnish and install Conduit & conductors from the existing generator to RTU 25% spare I/O, discrete and analog. 1 Program the system to monitor available spares. Additional bid items: Table 4a. Belle M Si_ .1 nal Quantity W Water Quality (Turbid >29 NTU) on/off. 1 Furnish and install new analyzer element/transmitter, and provide conduit & conductors from element to transmitter and conductors from transmitter to RTU Rain sensor at each station. 1 Furnish and install new rain sensor and provide conduit & conductors from the new rain sensor to RTU CCTV Surveillance (360° camera) (Off/On/Signal Lost). 1 Furnish and install new cameras covering the fenced area and provide conduit & conductors from their location to RTU Brickell Avenue Pump Station The Brickell Avenue Pump Station is in an open area that is composed of panels, controls, soft starters, transfer switches, two (2) 90 HP stormwater pumps. The station has an emergency stand-by generator. Brickell Avenue contains the following devices/equipment requiring monitoring and/or control: 1. Main Electric Power 2. Generator 3. Auto -Transfer Switches 4. Pumps 5. Pump Monitoring System 6. Wet Well Level Indicator 7. Fence Gate 8. Spare I/O, discrete and analog Other devices/equipment that need to be provided/installed and monitored: 1. Generator monitoring system for total harmonic distortion (THD) 2. Generator Fuel Guage 3. Electronic Elapse Time Meters (ETM) for pump operation hours per day. The station already has existing ETMs for pump 1, pump 2 and simultaneous pumps. Determine if the existing is compatible with the telemetry system and can be used to monitor the operation hours per day. Optional devices/equipment that can be provided/installed and monitored: 1. 360 cameras, covering the interior and exterior that needs to be monitored/secured 2. Rain Sensor 3. Water Quality Analyzer This station uses Flygt pump controllers and OITs. Determine specific I/O currently monitored by the existing Flygt I/O units. Based on the requirements shown in Table 5, design the electrical interfaces required to provide control and monitoring functions with the new RTU and cloud -based SCADA System. The Flygt I/O units may be incorporated into the upgraded system or replaced with a new RTU. Retain existing OIT functionality. Provide the followinE SCADA control points: al Quantity Required Work Main Electric Power Failure on/off 1 Furnish and install conductors from ATS to RTU Main Automatic Transfer Switch (ATS) failure on/off 1 Furnish and install conductors from ATS to RTU Generator on/off. 1 Furnish and install conductors from generator to RTU Diesel Tank Level 1 Installation of fuel level gauge and conduit & conductors from generator to RTU Pumps on/off. 2 Furnish and install conductors from existing soft starters to RTU Pump station water levels high/low l Furnish and install conductors from the existing control panel controller to RTU Pumps hours of operation per day. 2 Furnish ETM function in RTU Bar Screen on/off. 0 Not applicable Table 5. Brickell Signal Quantity Required Work CO2 Retardant System 2 building structures 0 on/off Not applicable Fire System on/off. 0 Not applicable Monitoring system on/off. 1 Program the system to detect the monitoring status from cloud service to apps. Fenced gate open/closed. 1 Furnish and install new fence gate sensor and provide conduit & conductors from existing front door to RTU ATS position (Normal/Emergency) 1 Furnish and install conduit & conductors from existing ATS to RTU Pump HOA Status (Not in Auto) 2 Furnish and install conductors from existing soft starters to RTU Generator Current, Voltage, Battery charger 1 status, total harmonic distortion. Furnish and install new generator monitoring system for total harmonic distortion (THD) and provide conduit & conductors from the existing generator to RTU. Generator controller position (Not in auto). 1 Furnish and install Conduit & conductors from the existing generator to RTU 25% spare I/O, discrete and analog. 1 Program the system to monitor available spares. Additional bid items: Avenue Pump Station Optional Quantity Water Quality (Turbid >29 NTU) on/off. 1 Furnish and install new analyzer element/transmitter, and provide conduit & conductors from element to transmitter and conductors from transmitter to RTU Rain sensor at each station. 1 Furnish and install new rain sensor and provide conduit & conductors from the new rain sensor to RTU CCTV Surveillance (360° camera) (Off/On/Signal Lost). Furnish and install new camera/s covering the fenced area and provide conduit & conductors from their location to RTU Mary Brickell Village Pump Station The Mary Brickell Village Pump Station consists of fenced area containing panels, controls, soft starters, transfer switches, two (2) 130 HP stormwater pumps. The station has an emergency stand-by generator inside the fenced area. Mary Brickell Village Pump Station contains the following devices/equipment requiring monitoring and/or control: 1. Main Electric Power 2. Generator 3. Auto -Transfer Switches 4. Pumps 5. Pump's Monitoring System 6. Wet Well Level Indicator 7. Fence Gate 8. Spare I/O, discrete and analog Other devices/equipment that need to be provided/installed and monitored: 1. Generator monitoring system for total harmonic distortion (THD). 2. Generator Fuel Gaue 3. Electronic Elapse Time Meters (ETM) for pump operation hours per day. The station already has existing ETMs for pump 1, pump 2. Determine if the existing is compatible with the telemetry system and can be used to monitor the operation hours per day. Optional devices/equipment that can be provided/installed and monitored: 1. 360 cameras, covering the interior and exterior that needs to be monitored/secured 2. Rain Sensor 3. Water Quality Analyzer This station uses Flygt pump controllers and OITs. Determine specific I/O currently monitored by the existing Flygt I/O units. Based on requirements shown in Table 6, design the electrical interfaces required to provide control and monitoring functions with the new RTU and cloud -based SCADA System. The Flygt I/O units may be incorporated into the upgraded system or replaced with a new RTU. Retain existing OIT functionality. Provide the following SCADA control points: aPe Quantity Required Work Main Electric Power Failure on/off 1 Furnish and install conduit & conductors from existing ATS to RTU Main Automatic Transfer Switch (ATS) failure on/off 1 Furnish and install conduit & conductors from existing ATS to RTU Generator on/off. 1 Furnish and install conduit & conductors from the existing generator to RTU Diesel Tank Level 1 Furnish and install new fuel level gauge and provide conduit & conductors from the existing generator to RTU Pumps on/off. 2 Furnish and install conductors from existing soft starters to RTU Pump station water levels high/low 1 Furnish and install conductors from the existing control panel controller to RTU Pumps hours of operation per day. 2 Furnish ETM function in RTU Bar Screen on/off ONLY for the 3 building structures. 0 Not applicable ,pe Quantit Required Work, CO2 Retardant System 2 building structures 0 on/off Not applicable Fire System on/off. 0 Not applicable Monitoring system on/off. 1 Program the system to detect the monitoring status from cloud service to apps. Fenced gate open/closed. 1 Furnish and install new fence gate sensor and provide conduit & conductors from existing front door to RTU ATS position (Normal/Emergency) 1 Furnish and install conduit & conductors from existing ATS to RTU Pump HOA Status (Not in Auto) 2 Furnish and install conductors from existing soft starters to RTU Generator Current, Voltage, Battery charger 1 status, total harmonic distortion. Furnish and install new generator monitoring system for total harmonic distortion (THD) and provide conduit & conductors from the existing generator to RTU. Generator controller position (Not in auto). l Furnish and install Conduit & conductors from the existing generator to RTU 25% spare I/O, discrete and analog. 1 Program the system to monitor available spares. Additional bid items: Table 6a. Mary Br Signal Quantity Water Quality (Turbid>29 NTU) on/off. 1 Rain sensor at each station. 1 Furnish and install new analyzer element/transmitter, and provide conduit & conductors from element to transmitter and conductors from transmitter to RTU Furnish and install new rain sensor and provide conduit & conductors from the new rain sensor to RTU CCTV Surveillance (360° camera) 1 (Off/On/Signal Lost). Furnish and install new cameras covering the fenced area and provide conduit & conductors from their location to RTU San Marco Pump Station The San Marco Pump Station consists of fenced area containing panels, controls, soft starters, transfer switches, and two (2) stormwater pumps. The station has an emergency stand-by generator inside the fenced area. San Marco contains the following devices/equipment requiring monitoring and/or control: 1. Main Electric Power 2. Generator 3. Auto -Transfer Switches 4. Pumps 5. Pump's Monitoring System 6. Wet Well Level Indicator 7. Fence Gate 8. Spare I/O, discrete and analog Other devices/equipment that need to be provided/installed and monitored: 1. Generator monitoring system for total harmonic distortion (THD). 2. Generator Fuel Guage 3. Electronic Elapse Time Meters (ETM) for pump operation hours per day. The station already has existing ETMs for pump 1 and pump 2. Determine if the existing is compatible with the telemetry system and can be used to monitor the operation hours per day. Optional devices/equipment that can be provided/installed and monitored: 1. 360 cameras, covering the interior and exterior that needs to be monitored/secured 2. Rain Sensor 3. Water Quality Analyzer This station uses hardware relays and timers for pump control. Determine specific I/O currently available. Based on requirements shown in Table 7, design the electrical interfaces required to provide control and monitoring functions with the new RTU and cloud -based SCADA System. The device control hardware may be incorporated into the upgraded system or replaced with a new RTU. Provide the following SCADA control points: Table 7. San Marco Pump Station Scope Signal Quantity equir-, , Main Electric Power Failure on/off 1 Furnish and install conduit & conductors from existing ATS to RTU Main Automatic Transfer Switch (ATS) failure on/off 1 Furnish and install conduit & conductors from existing ATS to RTU Generator on/off. 1 Furnish and install conduit & conductors from the existing generator to RTU Diesel Tank Level 1 Furnish and install new fuel level gauge and provide conduit & conductors from the existing generator to RTU Pumps on/off. 2 Furnish and install conductors from existing soft starters to RTU Pump station water levels high/low 1 Furnish and install conductors from the existing control panel controller to RTU Pumps hours of operation per day. 2 Furnish ETM function in RTU Bar Screen on/off. 0 Not applicable CO2 Retardant System 2 building structures on/off 0 Not applicable c1San Marco Pump Station Scope Quantity j.isted Work Fire System on/off. 0 Not applicable Monitoring system on/off. 1 Program the system to detect the monitoring status from cloud service to apps. Fenced gate open/closed. 1 Furnish and install new fence gate sensor and provide conduit & conductors from existing front door to RTU ATS position (Normal/Emergency) 1 Furnish and install conduit & conductors from existing ATS to RTU Pump HOA Status (Not in Auto) 2 Furnish and install conductors from existing soft starters to RTU Generator Current, Voltage, Battery charger 1 status, total harmonic distortion. Furnish and install new generator monitoring system for total harmonic distortion (THD) and provide conduit & conductors from the existing generator to RTU. Generator controller position (Not in auto) 1 Furnish and install Conduit & conductors from the existing generator to RTU 25% spare I/O, discrete and analog. 1 Program the system to monitor available spares. Additional bid items: Table 7a. San Marco Pump Station Optional Signal Quantity Wor Water Quality (Turbid >29 NTU) on/off. 1 Furnish and install new analyzer element/transmitter, and provide conduit & conductors from element to transmitter and conductors from transmitter to RTU Rain sensor at each station. 1 Furnish and install new rain sensor and provide conduit & conductors from the new rain sensor to RTU CCTV Surveillance (360° camera) (Off/On/Signal Lost). Furnish and install new camera/s covering the fenced area and provide conduit & conductors from their location to RTU Antonio Maceo Pump Station The Antonio Maceo Pump Station is in an open area that is composed of panels, controls, soft starters, transfer switches, stormwater pumps. The station has an emergency stand-by generator inside the fenced area. Antonio Maceo contains the following devices/equipment requiring monitoring and/or control: 1. Main Electric Power 2. Generator 3. Auto -Transfer Switches 4. Pumps 5. Pump's Monitoring System 6. Wet Well Level Indicator 7. Spare I/O, discrete and analog Other devices/equipment that need to be provided/installed and monitored: 1. Generator monitoring system for total harmonic distortion (THD). 2. Generator Fuel Guage 3. Electronic Elapse Time Meters (ETM) for pump operation hours per day. The station already has existing ETMs for pump 1, pump 2 and simultaneous pumps. Determine if the existing is compatible with the telemetry system and can be used to monitor the operation hours per day. Optional devices/equipment that can be provided/installed and monitored: 1. 360 cameras, covering the interior and exterior that needs to be monitored/secured 2. Rain Sensor 3. Water Quality Analyzer This station uses time delay relays and Flygt MiniCAS pump control/monitors. Determine specific I/O currently monitored by the existing hardware. Based on requirements shown in Table 8, design the electrical interfaces required to provide control and monitoring functions with the new RTU and cloud- based SCADA System. The device control/monitoring units may be incorporated into the upgraded system or have their functionality replaced with a new RTU. Retain existing OIT functionality. Provide the following SCADA control points: e :. Antonio Maceo Pump tation cope na1 Quantity ' equired Work Furnish and install conduit & conductors from existing ATS to RTU Main Electric Power Failure on/off 1 Main Automatic Transfer Switch (ATS) 1 failure on/off Furnish and install conduit & conductors from existing ATS to RTU Generator on/off. 1 Furnish and install conduit & conductors from the existing generator to RTU Diesel Tank Level 1 Furnish and install new fuel level gauge and provide conduit & conductors from the existing generator to RTU Pumps on/off. 2 Furnish and install conductors from existing soft starters to RTU Pump station water levels high/low 1 Furnish and install conductors from the existing control panel controller to RTU Pumps hours of operation per day. 2 Furnish ETM function in RTU Bar Screen on/off. 0 Not applicable CO2 Retardant System 2 building structures 0 on/off Not applicable Fire System on/off. 0 Not applicable ope Quantity Re uired Work Monitoring system on/off. Fenced gate open/closed. 1 1 Program the system to detect the monitoring status from cloud service to apps. Not applicable ATS position (Normal/Emergency) 1 Furnish and install conduit & conductors from existing ATS to RTU Pump HOA Status (Not in Auto) 2 Furnish and install conductors from existing soft starters to RTU Generator Current, Voltage, Battery charger status, total hainionic distortion. 1 Furnish and install new generator monitoring system for total harmonic distortion (THD) and provide conduit & conductors from the existing generator to RTU. Generator controller position (Not in auto). 1 Furnish and install Conduit & conductors from the existing generator to RTU 25% spare I/O, discrete and analog. 1 Program the system to monitor available spares. Additional bid items: ignal a. ' n'`anio Maceo Pump Station Optional Quantity Work Water Quality (Turbid>29 NTU) on/off. 1 Furnish and install new analyzer element/transmitter, and provide conduit & conductors from element to transmitter and conductors from transmitter to RTU Rain sensor at each station. 1 Furnish and install new rain sensor and provide conduit & conductors from the new rain sensor to RTU CCTV Surveillance (360° camera) 1 Furnish and install new cameras covering the (Off/On/Signal Lost). fenced area and provide conduit & conductors from their location to RTU Flagami West End No. 1 Pump Station The Flagami West End Pump Station No. 1 consists of a fenced area containing panels, controls, soft starters, transfer switches, and two (2) 85 HP stormwater pumps. The station has an emergency stand- by generator inside the fenced area. West End Pump Station No. 1 contains the following devices/equipment requiring monitoring and/or control: 1. Main Electric Power 2. Generator 3. Auto -Transfer Switches 4. Pumps 5. Pump Monitoring System 6. Wet Well Level Indicator 7. Fence Gate 8. Spare I/O, discrete and analog Other devices/equipment that need to be provided/installed and monitored: 1. Generator monitoring system for total harmonic distortion (THD). 2. Generator Fuel Guage 3. Electronic Elapse Time Meters (ETM) for pump operation hours per day. The station already has an existing ETM for pump 1 and pump 2. Determine if the existing is compatible with the telemetry system and can be used to monitor the operation hours per day. Optional devices/equipment that can be provided/installed and monitored: 1. 360 cameras, covering the interior and exterior that needs to be monitored/secured 2. Rain Sensor 3. Water Quality Analyzer The station is currently equipped with two Flygt pump controllers. Determine specific 1/0 currently monitored by the existing device I/O units. Based on requirements shown in Table 9, design the electrical interfaces required to provide control and monitoring functions with the new RTU and cloud- based SCADA System. The Flygt control units may be incorporated into the upgraded system or have their functionality replaced with a new RTU. Retain existing OIT functionality. Provide the following SCADA control points: Table 9. West End No. 1 Pump Station Scope Signal Quantity o Wiwi Wox_ Main Electric Power Failure on/off 1 Furnish and install conduit & conductors from existing ATS to RTU Main Automatic Transfer Switch (ATS) 1 failure on/off Furnish and install conduit & conductors from existing ATS to RTU Generator on/off. 1 Furnish and install conduit & conductors from the existing generator to RTU Diesel Tank Level 1 Furnish and install new fuel level gauge and provide conduit & conductors from the existing generator to RTU Pumps on/off. 2 Furnish and install conductors from existing soft starters to RTU Pump station water levels high/low 1 Furnish and install conductors from the existing control panel controller to RTU Pumps hours of operation per day. 2 Furnish ETM function in RTU Bar Screen on/off. 0 Not applicable CO2 Retardant System 2 building structures 0 Not applicable on/off Fire System on/off. 0 Not applicable iA e 9. West End No. 1 Pump Station Scope Quantityquired W Monitoring system on/off. 1 Program the system to detect the monitoring status from cloud service to apps. Fenced gate open/closed. 1 Furnish and install new fence gate sensor and provide conduit & conductors from existing front door to RTU ATS position (Normal/Emgency) 1 Furnish and install conduit & conductors from existing ATS to RTU Pump HOA Status (Not in Auto) 2 Furnish and install conductors from existing soft starters to RTU Generator Current, Voltage, Battery charger 1 status, total harmonic distortion. Furnish and install new generator monitoring system for total harmonic distortion (THD) and provide conduit & conductors from the existing generator to RTU. Generator controller position (Not in auto). 1 Furnish and install Conduit & conductors from the existing generator to RTU 25% spare I/O, discrete and analog. 1 Program the system to monitor available spares. Additional bid items: "oval Quantity Wor Water Quality (Turbid >29 NTU) on/off. 1 Furnish and install new analyzer element/transmitter, and provide conduit & conductors from element to transmitter and conductors from transmitter to RTU Rain sensor at each station. 1 Furnish and install new rain sensor and provide conduit & conductors from the new rain sensor to RTU CCTV Surveillance (360° camera) (Off/On/Signal Lost). Furnish and install new cameras covering the fenced area and provide conduit & conductors from their location to RTU Flagami West End No. 2 Pump Station The Flagami West End Pump Station No. 2 consists of a fenced area containing panels, controls, soft starters, transfer switches, and three (3) 90 HP stormwater pumps. The station has an emergency stand-by generator inside the fenced area. West End Pump Station No. 2 contains the following devices/equipment requiring monitoring and/or control: 1. Main Electric Power 2. Generator 3. Auto -Transfer Switches 4. Pumps 5. Pump Monitoring System 6. Wet Well Level Indicator 7. Fence Gate 8. Spare I/O, discrete and analog Other devices/equipment that need to be provided/installed and monitored: 1. Generator monitoring system for total harmonic distortion (THD). 2. Generator Fuel Guage 3. Electronic Elapse Time Meters (ETM) for pump operation hours per day. The station already has an existing ETM for pump 1, pump 2, and pump 3. Determine if the existing is compatible with the telemetry system and can be used to monitor the operation hours per day. Optional devices/equipment that can be provided/installed and monitored: 1. 360 cameras, covering the interior and exterior that needs to be monitored/secured 2. Rain Sensor 3. Water Quality Analyzer The station is currently equipped with three Flygt pump controllers. Determine specific I/O currently monitored by the existing device I/O units. Based on requirements shown in Table 10, design the electrical interfaces required to provide control and monitoring functions with the new RTU and cloud- based SCADA System. The Flygt control units may be incorporated into the upgraded system or have their functionality replaced with a new RTU. Retain existing OIT functionality. Provide the following SCADA control points: Table 10. West End No. 2 Pump Station Signal Scope Quantityquired Wo_A< Main Electric Power Failure on/off 1 Furnish and install conduit & conductors from existing ATS to RTU Main Automatic Transfer Switch (ATS) failure on/off 1 Furnish and install conduit & conductors from existing ATS to RTU Generator on/off. 1 Furnish and install conduit & conductors from the existing generator to RTU Diesel Tank Level 1 Furnish and install new fuel level gauge and provide conduit & conductors from the existing generator to RTU Pumps on/off. 3 Furnish and install conductors from existing soft starters to RTU Pump station water levels high/low 1 Furnish and install conductors from the existing control panel controller to RTU Pumps hours of operation per day. 3 Furnish ETM function in RTU Bar Screen on/off. 0 Not applicable CO2 Retardant System 2 building structures on/off 0 Not applicable Table 10. West End No. 2 Pump Station Scope Signal Quantity Required Work Fire System on/off. 0 Not applicable Monitoring system on/off. Fenced gate open/closed. 1 Program the system to detect the monitoring status from cloud service to apps. Furnish and install new fence gate sensor and provide conduit & conductors from existing front door to RTU ATS position (Normal/Emergency) 1 Furnish and install conduit & conductors from existing ATS to RTU Pump HOA Status (Not in Auto) 3 Furnish and install conductors from existing soft starters to RTU Generator Current, Voltage, Battery charger 1 status, total harmonic distortion. Furnish and install new generator monitoring system for total harmonic distortion (THD) and provide conduit & conductors from the existing generator to RTU. Generator controller position (Not in auto). 1 Furnish and install Conduit & conductors from the existing generator to RTU 25% spare I/O, discrete and analog. 1 Program the system to monitor available spares. Additional bid items: nd No. 2 Pump Station Optional Quantity Water Quality (Turbid >29 NTU) on/off. 1 Furnish and install new analyzer element/transmitter, and provide conduit & conductors from element to transmitter and conductors from transmitter to RTU Rain sensor at each station. 1 Furnish and install new rain sensor and provide conduit & conductors from the new rain sensor to RTU CCTV Surveillance (360° camera) 1 Furnish and install new cameras covering the fenced area and provide conduit & conductors from their location to RTU (Off/On/Signal Lost). Flagami West End No. 3 Pump Station The Flagami West End Pump Station No. 3 consists of fenced area containing panels, controls, soft starters, transfer switches, and three (3) 35 HP stormwater pumps. The station has an emergency stand-by generator inside the fenced area. West End Pump Station No. 3 contains the following devices/equipment requiring monitoring and/or control: 1. Main Electric Power 2. Generator 3. Auto -Transfer Switches 4. Pumps 5. Pump Monitoring System 6. Wet Well Level Indicator 7. Fence Gate 8. Spare I/O, discrete and analog Other devices/equipment that need to be provided/installed and monitored: 1. Generator monitoring system for total harmonic distortion (THD). 2. Generator Fuel Guage 3. Electronic Elapse Time Meters (ETM) for pump operation hours per day. The station already has existing ETMs for pump 1, pump 2, and pump 3. Determine if the existing is compatible with the telemetry system and can be used to monitor the operation hours per day. Optional devices/equipment that can be provided/installed and monitored: 1. 360 cameras, covering the interior and exterior that needs to be monitored/secured 2. Rain Sensor 3. Water Quality Analyzer This station uses time delay relays and Flygt MiniCAS pump control/monitors. Determine specific I/O currently monitored by the existing hardware. Based on requirements shown in Table 11, design the electrical interfaces required to provide control and monitoring functions with the new RTU and cloud- based SCADA System. The device control/monitoring units may be incorporated into the upgraded system or have their functionality replaced with a new RTU. Retain existing OIT functionality. Provide the following SCADA control points: ie it. west bna NO. 3 rump station scope tgn Quantity Main Electric Power Failure on/off 1 Furnish and install conduit & conductors from existing ATS to RTU Main Automatic Transfer Switch (ATS) failure on/off 1 Furnish and install conduit & conductors from existing ATS to RTU Generator on/off. 1 Furnish and install conduit & conductors from the existing generator to RTU Diesel Tank Level 1 Furnish and install new fuel level gauge and provide conduit & conductors from the existing generator to RTU Pumps on/off. 3 Furnish and install conductors from existing soft starters to RTU Pump station water levels high/low 1 Furnish and install conductors from the existing control panel controller to RTU Pumps hours of operation per day. 3 Furnish ETM function in RTU Bar Screen on/off. 0 Not applicable CO2 Retardant System 2 building structures 0 on/off Not applicable cope Quantity Required Work Fire System on/off. 0 Not applicable Monitoring system on/off. 1 Program the system to detect the monitoring status from cloud service to apps. Fenced gate open/closed. 1 Furnish and install new fence gate sensor and provide conduit & conductors from existing front door to RTU ATS position (Normal/Emergency) 1 Furnish and install conduit & conductors from existing ATS to RTU Pump HOA Status (Not in Auto) 3 Furnish and install conductors from existing soft starters to RTU Generator Current, Voltage, Battery charger 1 status, total harmonic distortion. Furnish and install new generator monitoring system for total harmonic distortion (THD) and provide conduit & conductors from the existing generator to RTU. Generator controller position (Not in auto). 1 Furnish and install Conduit & conductors from the existing generator to RTU 25% spare I/O, discrete and analog. 1 Program the system to monitor available spares. Tabl Optional Signal Quantity Wor Water Quality (Turbid >29 NTU) on/off. 1 Furnish and install new analyzer element/transmitter, and provide conduit & conductors from element to transmitter and conductors from transmitter to RTU Rain sensor at each station. 1 Furnish and install new rain sensor and provide conduit & conductors from the new rain sensor to RTU CCTV Surveillance (360° camera) (Off/On/Signal Lost). Furnish and install new cameras covering the fenced area and provide conduit & conductors from their location to RTU Flagami West End No. 4 Pump Station The Flagami West End No. 4 Pump Station consists of fenced area containing panels, controls, soft starters, transfer switches, and three (3) 60 HP stormwater pumps stormwater pumps. The station has an emergency stand-by generator inside the fenced area. West End No. 4 Pump Station contains the following devices/equipment requiring monitoring and/or control: 1. Main Electric Power 2. Generator 3. Auto -Transfer Switches 4. Pumps 5. Pump's Monitoring System 6. Wet Well Level Indicator 7. Fence Gate 8. Spare I/O, discrete and analog Other devices/equipment that need to be provided/installed and monitored: 1. Generator monitoring system for total harmonic distortion (THD). 2. Generator Fuel Guage 3. Electronic Elapse Time Meters (ETM) for pump operation hours per day. The station already has existing ETMs for pump 1, pump 2, and pump 3. Determine if the existing is compatible with the telemetry system and can be used to monitor the operation hours per day. Optional devices/equipment that can be provided/installed and monitored: 1. 360 cameras, covering the interior and exterior that needs to be monitored/secured 2. Rain Sensor 3. Water Quality Analyzer This station uses time delay relays and Flygt MiniCAS pump control/monitors. Determine specific I/O currently monitored by the existing hardware. Based on requirements shown in Table 12, design the electrical interfaces required to provide control and monitoring functions with the new RTU and cloud- based SCADA System. The device control/monitoring units may be incorporated into the upgraded system or have their functionality replaced with a new RTU. Retain existing OIT functionality. Provide the following SCADA control points: e 1 . West En o. Pump tation cope nal Quantity equired Wor . Main Electric Power Failure on/off 1 Furnish and install conduit & conductors from existing ATS to RTU Main Automatic Transfer Switch (ATS) failure on/off 1 Furnish and install conduit & conductors from existing ATS to RTU Generator on/off. 1 Furnish and install conduit & conductors from the existing generator to RTU Diesel Tank Level 1 Furnish and install new fuel level gauge and provide conduit & conductors from the existing generator to RTU Pumps on/off. 3 Furnish and install conductors from existing soft starters to RTU Pump station water levels high/low 1 Furnish and install conductors from the existing control panel controller to RTU Pumps hours of operation per day. 3 Furnish ETM function in RTU Bar Screen on/off. 0 Not applicable CO2 Retardant System 2 building structures 0 Not applicable on/off station Scope Quantity Re. uired Worl ire System on/off. 0 Not applicable onitoring system on/off. 1 Program the system to detect the monitoring status from cloud service to apps. enced gate open/closed. 1 Furnish and install new fence gate sensor and provide conduit & conductors from existing front door to RTU TS position (Normal/Emergency) 1 Furnish and install conduit & conductors from existing ATS to RTU 1'ump HOA Status (Not in Auto) 3 Furnish and install conductors from existing soft starters to RTU Generator Current, Voltage, Battery charger 1 status, total harmonic distortion. Furnish and install new generator monitoring system for total harmonic distortion (THD) and provide conduit & conductors from the existing generator to RTU. Generator controller position (Not in auto). 1 Furnish and install Conduit & conductors from the existing generator to RTU 25% spare I/O, discrete and analog. 1 Program the system to monitor available spares. Optional Quantity Water Quality (Turbid>29 NTU) 1 on/off. Furnish and install new analyzer element/transmitter, and provide conduit & conductors from element to transmitter and conductors from transmitter to RTU Rain sensor at each station. 1 Furnish and install new rain sensor and provide conduit & conductors from the new rain sensor to RTU CCTV Surveillance (360° camera) 1 Furnish and install new cameras covering the (Off/On/Signal Lost). fenced area and provide conduit & conductors from their location to RTU Governing Regulations and Standards It shall be the Proposer's responsibility to acquire and utilize the necessary manuals and guidelines that apply to the work required to complete the Project. Their services must include the preparation of all documents necessary to complete the Project. The Proposer shall promptly notify the City in writing of any conflict between this scope and governing regulations for clarification and resolution. Unless directed by the City, the Proposer shall abide by the more stringent requirement. The list below is not intended to be all inclusive, and it is the responsibility of the Proposer to comply with the latest local, state, and federal requirements, whether included in the list or not. The following is presented in no order of precedence: 1. Florida Building Code 2. City of Miami Department of Resilience and Public Works (RPW) Engineering standards 3. City of Miami RPW Design Submittal Requirements by Submittal Phase for City Capital Improvement Projects, see Attachment H, Phase Submittals for details. 4. City of Miami Stormwater Master Plan (2021), approved March 14, 2024 5. Miami Dade County Department of Regulatory and Economic Resources Permits and Inspections The Proposer is responsible for identifying and obtaining all permits necessary for the Project. The Proposer shall secure permits or permit modifications while acting as an authorized representative for the City for permitting purposes only. The Proposer's Project schedule shall include reasonable and ample time for the permitting process and obtaining permits. The Proposer shall be responsible for any necessary permit time extensions or re -permitting in order to keep the permits valid throughout the construction period. Preparation of complete permit application packages and responses to requests for additional information from the regulatory agencies shall be the responsibility of the Proposer. If any permitting agency rejects or denies the permit application, it is the Proposer's responsibility to notify the City immediately and to make whatever changes necessary at no additional cost to the City to ensure the permit is approved. Preparation of all documentation related to the acquisition of all applicable permits is the responsibility of the Proposer. The Proposer is responsible for the accuracy of all information included in permit application packages. Only approved plans shall be used in permit application packages. The Proposer shall provide the City with draft copies of any and all permit applications, including responses to agency requests for additional information, requests to modify the permits, and requests for permit time extensions, for review and approval by the City prior to submittal to the agencies. The City will have up to twenty-one (21) calendar days to review and comment on draft permit packages. Coordination and incorporation of the City review comments to obtain final approval for permit applications after the 21-day review period shall be the responsibility of the Proposer and will not be considered reason for a time extension or additional compensation. The Proposer shall address all comments by the City and obtain the City approval, prior to submitting the final permit package. The following governmental authorities that have or may have jurisdiction over the project have been identified. The list below is not intended to be all inclusive, and it is the responsibility of the Proposer to comply with all local, state, and federal requirements, whether included in the list or not. 1. City of Miami Department of Resilience and Public Works ("RPW") 2. City of Miami Building Department 3. Miami Dade County Department of Transportation and Public Works ("DTPW") 4. Florida Department of Environmental Protection 5. Florida Department of Transportation ("FDOT") 6. Miami Parking Authority ("MPA") Utility Coordination It is anticipated that during the installation period, the Proposer will encounter utilities that require adjustments, including relocation, removal, or decommissioning due to the Proposer's design and construction efforts, whether temporary or permanent. The Proposer shall ensure that utility adjustments that are necessary for the Project comply with RPW standards, Bulletins, policies, procedures, and design criteria, as well as with any applicable Utility Agency/Owner ("UA/O") standards, all applicable laws, any applicable utility agreements, all applicable governmental approvals and permits issued by authorities having jurisdiction for such work, and all other applicable requirements specified in the contract documents. Cost and fees associated with utility adjustments, relocation, removal, decommissioning, and installation of new utilities, whether temporary or permanent, shall be the sole responsibility of the Proposer. The Proposer is not entitled to any additional compensation or time for any utility adjustment or new utility located within the Project right-of-way or otherwise impacted by, or having an impact on, the Project or work activities. The Proposer is not entitled to additional compensation or time for inaccurate or omitted utility information provided in either the contract documents or the reference documents. Any utility enhancements or betterments performed as part of the utility adjustment, whether by Proposer or UA/O, shall be subject to the same standards and requirements as if it were a necessary utility adjustment. Any proposed utility enhancement shall be reviewed and approved by the City and shall obtain all required permits prior to commencing. The Proposer shall not be entitled to additional compensation or time as a result of any utility enhancement, whether performed by the Proposer or by the UA/O. The City has not carried out investigations for any utilities that might be potentially impacted by, or have an impact on, the Project or work activities. Accordingly, the City has not verified any of the utility information included in either the contract documents or the reference documents. Investigation and verification shall be the responsibility of the Proposer. It is the Proposer's sole responsibility to coordinate and resolve all utility impacts with each UA/O that has facilities within the Project right-of-way or that are otherwise potentially affected in any way by the Project, and to coordinate all utility adjustment work with a detailed working schedule. The Proposer is advised that utility facilities located outside of the Project right-of-way but within the construction limits may be impacted by construction work associated with the Project and therefore may require a utility adjustment. The Proposer shall be responsible for performing or arranging for the performance of all utility adjustment work and bearing the cost of the utility adjustment work not covered by the UA/O, whether located within or outside the Project right-of-way. The Proposer shall be responsible for obtaining the utility work schedules ("UWS") from the UA/O's and to include the UWS in the contract master schedule. Early communication with UA/O's is strongly encouraged to begin necessary coordination and scheduling of utility adjustments. Early communication with UA/O's is strongly encouraged to begin necessary coordination and scheduling of utility adjustments. Upon the Proposer's coordination with the UA/O, the design and construction for some utility adjustments may be performed by the UA/O with its own forces and/or contractors and consultants. The design and construction for all other utility adjustments shall be performed by the Proposer with its own forces and/or contractors and consultants (subject to any approval rights required by the UA/O for those working on its facilities). The Proposer is not entitled to additional compensation or time as a result of any utility work or failure to schedule in a timely manner any utility work, whether performed by the Proposer or by the UA/O. For each utility impacted by the Project, the Proposer shall determine, in cooperation with the UA/O, the utility adjustment work that is necessary. Subject to compliance with the applicable requirements of the contract documents, such work may include: 1. Design around if possible. 2. Protect in place. 3. Adjust. 4. Relocate. 5. Remove. The Proposer shall make every reasonable attempt to design around existing utilities, and to otherwise minimize impacts. The Proposer shall submit to the City a proposed utility design master plan for the Project, showing the approximate location of each existing utility, the existing utilities to remain in place, utilities with conflicts, the Proposer's Utility Adjustment proposals and proposed new utilities, and the relationship of the existing and proposed utilities to the Project. The Proposer shall coordinate with the affected UA/O as necessary to obtain their respective concurrence with the proposed utility design and submit the proposed master plan of utility design to the City for its review and approval. Within forty-eight (48) hours before excavating, the Proposer shall call the City for assistance with locating City owned utilities. Within forty-eight (48) hours before excavating, the Proposer should contact Sunshine State One Ca11 of Florida, Inc. (1-800-432-4770) for free locating service for utilities for contractors and excavators; subsequently, a locator will be dispatched to the location by Sunshine State One Call of Florida, Inc. The Proposer shall coordinate with the utility companies not included in the Sunshine State One Call of Florida, Inc. location service. Document Control Protocol The Proposer shall establish its Document Control Protocol. The Document Control Protocol shall be submitted to the City for review and approval no later than thirty (30) days from the Notice to Proceed ("NTP"). All documentation submitted by the Proposer for the City review shall be uploaded into the E-Builder system. The Proposer will be provided access to the electronic review system to review comments and input responses to comments. Submittals, Shop Drawings, Product Data and Samples Product data and samples of all materials and finishes to be supplied, furnished, and installed on this project shall be submitted by the Proposer to the City for review and approval. Product data and samples shall not be submitted before the approval of plans whereby using such items are shown on the plans. Component and package submittals must be accompanied by sufficient information for adjoining components/packages or areas of work to allow for proper evaluation of the component/package submitted for review. Each submittal shall be coordinated with the requirements of the work. The Proposer shall allow for the City review time of fifteen (15) calendar days for the procedural review of shop drawings unless approved by the City. The Proposer may request an expedited review of a particular submittal, subject to approval by the City. The review period commences upon the receipt of the valid submittal or re -submittal by the City or their representative and terminates upon the transmittal of the submittal back to the Proposer. Project Schedule The Proposer shall submit a master schedule for the City's review and approval within forty-five (45) days of NTP. It is the responsibility of the Proposer to develop a Work Breakdown Structure ("WBS") in coordination with the City. The City will review and approve the WBS. The Proposer's schedule shall allow for up to 15 calendar days review time for the City review of all submittals, including shop drawings. The Project schedule shall include activities for major components of the Project. The Proposer shall update the master schedule on a monthly basis and submit the updated schedule to the City. The minimum number of activities included in the schedule shall be those listed in the Schedule of Values and those listed below: 1. Award Date 2. Notice to Proceed ("NTP") 3. Initial Design Submittals 4. Final Design Submittals 5. Shop Drawing Submittals 6. Other Contractor -Initiated Submittals 7. Submittal Reviews by RPW 8. Design Review / Acceptance Milestones 9. Materials Quality Tracking 10. Start of Implementation 11. Mobilization 12. Installation/Implementation Phasing 13. Environmental and City Permits Acquisition 14. Utility Work Schedules 15. Landscape/Hardscape Plans 16. Holidays and Special Events (shown as non -workdays) 17. Additional Installation Milestones as determined by the Proposer. 18. Substantial Completion 19. Final Completion Date for All Work 20. Final Acceptance Meetings and Progress Reporting The Proposer shall anticipate and be responsible for periodic meetings with City personnel and other agencies as required for resolution of design and/or construction issues. Some of these meetings may be held simultaneously at the discretion of the City. These meetings may include, but are not limited to: 1. Post award kick-off meetings 2. Design progress meetings 3. Installation progress meetings 4. Maintenance of Traffic meetings 5. Permit agency coordination 6. Utility coordination meetings Computer Automation The Proposer shall utilize Autodesk AutoCAD 2022 to facilitate the development of the Contract Drawings. Drawings shall be produced in accordance with the City of Miami Department of Resilience and Public Works Standards. The Proposer is required to furnish the Project's CADD files after the plans have been released for installation. The Proposer is required to submit final documents and files which shall include complete CADD design. As part of the record drawings deliverables, field conditions shall be incorporated into AutoCAD design files. Field conditions shall be denoted on the plan sheets using the cloud revision utility as well as an "AB" revision triangle. The Proposer is required to furnish the updated Project's CADD files after Final Completion. Adjacent Construction Projects The Proposer shall be responsible for identifying and coordinating design and installation with other ongoing projects that are impacted by or impact the Project. Coordination is required to ensure facility maintenance, maintenance of traffic, and installation phasing compatibility. Any changes required by the Proposer due to coordination with said projects shall not be grounds for additional time or compensation. The Proposer shall receive no additional compensation or time for failure to properly coordinate in a timely manner. Use of City -Owned Right -of -Way All Project activities must be conducted within the City -owned right-of-way. Use of County- owned and State- owned right-of-way by the Proposer for the purpose of equipment or material storage, lay- down facilities, pre- cast material fabrication sites, or other related materials, shall require advance approval by DTPW and FDOT. In the circumstance that a temporary easement is required, the Proposer shall be responsible for obtaining said easements and all fees associated with the acquisition. Staging Areas/Right of Way Encroaching The Proposer will be solely responsible for securing from the City any temporary rights needed for installation operations, including but not limited to staging. Areas used for staging shall be returned to their original condition or better upon Project completion. The Proposer shall submit a complete staging plan, if applicable, within seven (7) days after the effective date of the NTP. Staging plans shall include a layout of the proposed staging areas including fences, roads, parking, buildings, storage areas, and equipment necessary for the timely prosecution of the Work. The staging plan shall be approved by the City. The Proposer shall protect from damage encroaching properties within the project limits. Whenever the Proposer's activities damage such existing property, it shall be immediately restored to a condition equal to or better than the condition existing at the time such damage occurred, at no expense to the City or the property owner. Maintenance During Construction The Proposer shall perform project maintenance activities for the locations of the Project. The maintenance start date shall be the date that the Proposer assumes full responsibility of Project maintenance, which will be 30 calendar days after NTP or when construction/mobilization begins, whichever occurs first. Project maintenance responsibilities will not end for the Proposer until Final Completion of the entire project by the City. Project maintenance responsibilities shall include, but are not limited to, litter removal, sweeping fence, and IT facilities. Any inventories required per RPW standards must be completed and submitted to the City for review and approval. Submittal shall be no later than 14 calendar days before the maintenance start date. The approved inventories must be handled in accordance with the requirements of RPW Standards. Failure to complete said inventories before the maintenance start date will result in the Proposer taking complete responsibility of all areas and systems with the assumption that areas are safe, hazard -free, in good condition, and are fully functional and operational. When permission has been granted by the City to close an existing roadway, the Proposer shall furnish and erect the proper signs, barricades, lights, flags, and other protective devices, which shall be subject to the approval of the jurisdictional agency, including but not limited to the City, Miami -Dade County, and/or Florida Department of Transportation. The Proposer shall furnish and maintain proper protective devices at such location for the entire time of closure as the jurisdictional agency may direct. Signage shall be in place one week before closure. Access for emergency and solid waste vehicles shall be maintained at all times to all private properties and businesses within or adjacent to the Project area. Fire hydrants on or adjacent to the work shall be kept accessible to fire apparatus at all times, and no material or obstruction shall be placed within twenty (20) feet, all directions, of any such hydrant. Materials and equipment shall be stored in a fenced or otherwise enclosed area during non -working hours. Proposer shall only store minimal amounts of materials on site within designated areas. Stockpiling of materials shall not create visual obstructions or impediments for local traffic. The Proposer shall limit the number of non -essential vehicles on the project area. The Proposer is responsible to provide public parking for its staff and sub -contractors offsite and arrange for group transportation to and from the project area in order to eliminate the need for personnel vehicles to be brought to the project area. The Proposer shall avoid staging/parking construction vehicles in private property or the swales in front of private properties. Design and Installation The Proposer shall be responsible for developing the set of final plans. The Proposer shall become familiar with all the documents presented in this solicitation. Attachment G, Technical Memorandum/Product Design and Installation Guideline shall serve as a general guideline of the design intent for the Project. The Proposer is to develop solutions in conformance with the guideline narratives. Furthermore, the Proposer specifically acknowledges and agrees that the Proposer is not entitled to rely on the Reference Documents or parts thereof except to the extent specifically permitted and noted in the guideline. The Proposer shall have Florida Licensed Professional Architects and Engineers sign and seal all plans, specifications, calculations, technical documents, and reports, and shall perform all professional requirements of the Proposer's engineer. Any modification to the component construction due to subsequent design changes as the result of design development shall be solely the Proposer risk. Upon review by the City, or their authorized representative, the plans will be stamped "Released for Construction" and returned to the Proposer. The review by the City is not meant to be a complete and detailed review. The Proposer is advised that approved plans only confirm the plans comply with the City requirements and criteria. The approval does not relieve the Proposer of any liability or responsibility for errors or omissions in the plans. The Proposer is advised that submittal reviews may require the review and approval of other agencies. Reviews by other agencies shall be the responsibility of the Proposer. All design and construction documents shall be prepared using the US Customary system of units (feet, pounds). Field Start-up and Testing Check and approve the installation of all components and all conductor connections between the various system components prior to placing the various processes and equipment into operation. Conduct a complete system checkout and adjustment, including calibration of all instruments, tuning of control loops, checking operation functions, and testing of final control actions. When there are future operational functions included in this work, they should be included in the system checkout. All problems encountered shall be documented and promptly corrected to prevent any delays in start-up of the various unit processes. Proposer shall provide all test equipment and software necessary to perform the testing during system checkout and start-up. Proposer shall transfer all test equipment and software to the City after all final testing and commissioning. Proposer shall be responsible for initial operation and shall make any required changes, adjustment or replacements for operation, monitoring and control of the various processes and equipment necessary to perform the functions intended. Proposer shall furnish to the City certified calibration reports for field instruments and devices specified above as soon as calibration is completed. Proposer shall furnish the City an installation inspection report certifying that all equipment has been installed correctly and is operating properly. The report shall be signed by authorized representatives of both Proposer and the Supplier. Proposer shall provide all software and licenses required to operate, troubleshoot, maintain and repair all systems provided under this contract. Note: Inspection and Test Reports shall be generated electronically and exported to Microsoft Excel and PDF formats for distribution. Training Proposer shall provide all labor, materials, equipment and incidentals required to perform and coordinate all required training at times acceptable to the City. No part of the training shall be construed as a substitution for complete and comprehensive Operations and Maintenance (O&M) manuals but should follow the same organizational structure as the O&M manuals. Provide one (1) eight -hour day course covering the structure and the functions of the system components and devices. The course shall familiarize the student with the procedures for applying the system to process control problems and use of the cloud -based system (client) application. At a minimum, the course shall cover the following topics: 1. Overview of systems functional capabilities. 2. Equipment overview including system component functions, operating principals and proper use. 3. Loading and start-up of the digital system hardware components. 4. Use of system commands and entering set points. 5. Installation of the client application. 6. Use of the client application. Final Acceptance The Proposer shall employ safe work practices as defined by the Occupational Safety and Health Administration (OSHA) and workmanship as defined by National Electrical Contractors Association (NECA), NECA 1-2013 "Good Workmanship in Electrical Contracting". Minimal workmanship requirements include: 1. All hardware has been installed correctly, in the correct locations, and tightened. 2. There are no sharp edges exposed on sheet metal, which may cause injury. 3. Cable ties are correctly installed, secured, and clipped. 4. Cable harness routing does not interfere with the insertion and removal of components and does not cause distortion or bending when the Vendstar-5 doors are closed. 5. Sockets and connectors are properly fastened and locked into position. 6. External labels are correctly installed, straight, in their respective recesses. Labels are firmly and uniformly installed, and no air bubbles are present. 7. Internal labels are correctly installed, straight, and in their respective locations. 8. The exterior does not have "burn marks" to detract from appearance. Exposed surfaces are finished and free from deep visible scratches. 9. The door closes easily and has no excessive gaps between the door and cabinet enclosure. 10. Painted surfaces are smooth and free of paint runs, chips, and scratches. 11. All internal and external locks are installed. Lock and cam mechanisms work smoothly without binding. Closeout Before obtaining Final Completion, the Proposer shall prepare and submit digital files and hard copies of the complete closeout package. At a minimum, the following items are to be included in the closeout packages: 1. Evidence of compliance with requirements of governing authorities and construction documents. 2. Final Record Documents: CADD files, submit hard copies and electronic format. 3. Warranties and bonds. 4. Evidence of payment and releases of liens. 5. Punch list. 6. As -Built plans. 7. Any additional items included in the General Conditions. 4.0 PROPOSAL SUBMISSION 4.1. SUBMISSION REQUIREMENTS Proposers shall carefully follow the format and instruction outlined below, observing format requirements where indicated. Proposals should contain the information itemized below and, in the order, indicated. This information should be provided for the Proposer utilized for the work contemplated by this Solicitation. Proposals submitted which do not include the following items may be deemed non -responsive and may not be considered for contract award. The proposal shall be written in sufficient detail to permit the City to conduct a meaningful evaluation of the proposed services. However, overly elaborate responses are not requested or desired. Proposals must be submitted through BidNet Electronic Bidding System ("BidNet") no later than the date and time indicated within the RFP, in order to be considered. Faxed documents are not acceptable. Emailed submissions are not acceptable. Hardcopy submissions are not acceptable. Proposals must be timely submitted through BidSync, or the Proposal will be disqualified. Untimely or misdelivered submittals will not be considered. NO EXCEPTIONS. The responses to this solicitation shall be presented in the following format. Failure to do so may deem your Proposal non -responsive. 4.2 FORMAT OF PROPOSALS SECTION 1: COVER PAGE The Cover Page should include the Proposer's name; Contact Person for the RFP; Company's Liaison for the Contract; Primary Office Location; Local Business Address, if applicable; Business Phone and Fax Numbers, if applicable Email addresses; Title of RFP; RFP Number; and Federal Employer Identification Number. SECTION 2: TABLE OF CONTENTS The table of contents should outline, in sequential order, the major sections of the Proposal, including all other relevant documents requested for submission. All pages of the Proposal, including the enclosures, should be clearly and consecutively numbered and correspond to the table of contents. SECTION 3. COVER LETTER AND EXECUTIVE SUMMARY A signed and dated summary of not more than two (2) pages containing Proposer's overall Qualifications, Experience and Technical Qualifications, as contained in the submittal. Proposer shall include the name of the organization, business phone, email address, contact person and a summary of the work to be performed. SECTION 4. MANDATORY SUBMITTALS The proposal document shall contain executed forms of all mandatory submittals for bond or surety, insurance, affidavits, and other required certificates or statements. 1. Include the signed RFP Certification Statement. 2. Include the Certifications form. 3. Completion and Submission of the Certification Statement Affirmation Affidavit Proposer shall complete, sign and have notarized Attachment F, Certification Statement Affirmation Affidavit attesting to Proposer's responsibility. 4. Completion and Submission of the Anti -Human Trafficking Affidavit: Proposer shall complete, sign and have notarized Attachment E, Anti -Human Trafficking Affidavit attesting to Proposer's responsibility and understanding of Florida State Statute Section 787.06. 5. Attachment C, Price Proposal Package. Failure to complete each price sheet for each location shall render the proposal non -responsive. Only one Proposal Package per proposal. Multiple pricing proposal packages shall render the proposal as non -responsive SECTION 5. PROPOSAL OF SERVICES The following Section of the proposal shall accurately represent the experience, qualifications and past performance of Proposer. The responses should include any and all information necessary for the City to evaluate the technical capabilities of the Proposer. A. MINIMUM QUALIFICATION REQUIREMENTS Include in detail, evidence that clearly demonstrates Proposer meets the Minimum Qualification Requirements, pursuant to Section 2.9, Minimum Qualifications Requirements. B. PROPOSER EXPERIENCE, QUALIFICATIONS AND DIVERSITY OF WORK PRODUCT 1. Describe the Proposer's organizational history and structure, provide a brief history of the firm, including years Proposer/firm has been in business providing a similar service(s), and indicate whether the City has previously awarded any contracts or permits to the Proposer/firm. 2. Provide the name of the Proposer's firm, corporation, joint venture, partnership, individual, or other legal entity's address, telephone/fax/email address, name of contact individual, date incorporated, principals and officers of Proposer, and Federal Employer Identification Number. Include location from where work will be performed. 3. Demonstrate that Proposer's firm is an active registered corporation with the State of Florida Department of State, Division of Corporations. 4. Demonstrate that Proposer's firm has been established for a minimum of five (5) years (as a business with the same Federal Employee Identification Number; not just individual employees). 5. Provide specific qualifications, project experience, and credentials that demonstrate Proposer's ability to perform the required scope of work. Proposer must clearly describe its qualifications and experience in the provision of similar work of a similar nature in the industrial automation and control systems or related industry. Include discussion of experience in specific fields or industries related to the proposed project. Include any and all licenses and certifications held. 6. Discuss Proposer's and/or Team's overall resources, including personnel, equipment, supervision and coordinating capacity, etc. 7. Provide a list of clients that have discontinued use of Proposer's services within the past two (2) years and indicate the reasons for the same. The City reserves the right to contact any reference as part of the evaluation process. 8. Provide a complete list of clients for which Proposer has provided a similar service(s) as required in this RFP. This list should detail Proposer's experience and include those services performed within the past five (5) years, as applicable. Include the name, address, phone number(s) and contact persons within each organization. The City reserves the right to contact references as part of the evaluation process. 9. Provide a list of no less than three (3) references within the past six (6) years, as applicable, for whom similar services were performed. Include the overall value of the contract, the term of the contract, and include the address, phone number(s) and contact persons within each organization. The City reserves the right to contact any reference as part of the evaluation process. 10. Describe any litigation or proceeding against Proposer, its partners, managers, sub- consultants/contractors and/or other key staff members, within the past five (5) years. Provide the circumstances and statuses of any disciplinary actions taken or pending against the Proposer, its partners, managers and/or other key staff members, by the state regulatory bodies or professional organizations or by any court or administrative agency which has ruled against its professional activities or performance. 11. Describe any current or pending litigation or proceeding involving Proposer, its partners, managers and/or other key staff members, and its professional activities or performance, if applicable. State the nature of the litigation, a brief description of each case, the outcome or projected outcome, and the monetary amounts involved. 12. Demonstrate that Proposer's firm has never filed for bankruptcy, is in sound financial condition, has no record of civil litigation or pending lawsuits involving criminal activities of a moral turpitude, and does not have conflicts of interest with the City. 13. Discuss any bankruptcies involving Proposer, its partners, manager, and/or other key staff members, if applicable. 14. Describe any firm accreditation or accolades by national organizations and disclose any conduct code violations recorded by such organizations. C. EXPERIENCE AND QUALIFICATIONS OF PROPOSED STAFF PROJECT TEAM OVERVIEW 1. Identify the proposed project manager and key personnel who will be assigned to this project. Include their roles, responsibilities, and the percentage of time they will dedicate. 2. Provide resumes or bios highlighting relevant certifications (e.g., ISA, PMP), technical skills, and prior SCADA/Telemetry experience. 3. Clearly identify which team members will perform the functions detailed in your proposal, including any subcontractors. SUBCONTRACTORS 1. If subcontractors are being used, list the firms, describe their roles, and outline their qualifications and prior collaboration with your team. Note: After proposal submission, but prior to the award of any contract issued as a result of this Solicitation, the Proposer has a continuing obligation to advise the City of any changes, intended or otherwise, to the Project Manager, key personnel, and subcontractors identified in its proposal. D. PROPOSED APPROACH TO PROVIDING THE SERVICES SCADA AND TELEMETRY DESIGN 1. Describe your proposed technical approach for delivering SCADA and telemetry services for stormwater pump stations, including: a. Overall SCADA system architecture (centralized, distributed, cloud -based, hybrid) b. Proposed SCADA software platform, version, and rationale for selection c. Communications methodology (e.g., cellular, radio, fiber, or hybrid), including data polling intervals and failover protocols d. User interface and alarm management features relevant to storm event monitoring and emergency response e. Data logging, trending, and historical reporting capabilities EXISTING SYSTEM INTEGRATION OR REPLACEMENT 1. Some pump station sites already have SCADA/telemetry systems installed. Please explain your approach for evaluating these existing systems and how you propose to either: a. Incorporate or interface with the current hardware/software, including any necessary upgrades to ensure compatibility with your proposed system architecture, OR b. Decommission and replace the existing system, explaining the justification, risks, and expected benefits of full replacement. 2. Describe your strategy for minimizing service disruptions during any replacement, upgrade, or integration efforts. 3. Indicate whether your system supports migration paths for partial upgrades or phased transitions. ELECTRICAL AND EQUIPMENT INTEGRATION 1. Detail how your system will integrate with key components of the stormwater pump stations, including: a. Existing or new programmable logic controllers ("PLC") b. Wet well level sensors, float switches, and flow meters c. Backup generators or automatic transfer switch ("ATS") systems d. Variable frequency drives (VFDs), motor controls, and pump status inputs 2. Confirm your system's compatibility with multiple equipment vendors and its ability to standardize data collection across varied assets. FLEXIBILITY AND SCALABILITY 1. Describe how your proposed SCADA system will accommodate: a. The addition of new pump station sites in the future b. New sensor types or remote monitoring features c. Integration with GIS, CMMS, or storm event dashboards IMPLEMENTATION, TESTING, AND TRAINING 1. Installation and Startup a. Describe your approach to SCADA and telemetry installation with minimal disruption to pump station operations. b. How will you validate full connectivity and functionality across all remote sites before system acceptance? 2. Testing & Commissioning a. What system acceptance testing ("SAT"), factory acceptance testing ("FAT"), or site -specific commissioning processes will you use? b. Describe your calibration and verification procedures for flow, level, and pump runtime data. 3. Training and Documentation a. Provide an outline of proposed training for City personnel, including content, duration, format (hands- on, virtual, manuals), and refresher opportunities. SUPPORT, MAINTENANCE & CYBERSECURITY 1. Ongoing Support a. Describe the warranty, remote support, and preventative maintenance services included. b. Detail your typical response times for SCADA failures, telemetry outages, or storm -related incidents. 2. Cybersecurity a. How will your system protect storm pump station controls and data from cyber threats? Include infoiiiiation on: i. Network segmentation ii. Password and user management iii. Encryption of data in transit and at rest SCHEDULE AND RISK MITIGATION 1. Provide a proposed project timeline from kickoff through final acceptance, including all key milestones. 2. Describe your approach to risk management for this project, particularly related to: a. Weather impacts b. Equipment lead times c. Integration with existing infrastructure SECTION 6: FINANCIAL INFORMATION AND FEE PROPOSAL FORM A. FINANCIAL CAPABILITIES 1. Provide documentation proving Proposer's financial strength and ability to provide start-up operations and reasonable working capital to handle this project. B. SUBMISSION OF PROPSAL FEE FORMS 1. ATTACHMENT C - SCADA AND TELEMETRY SERVICES FEE PROPOSAL 5.0 PROPOSAL EVALUATION EVALUATION CRITERIA Proposals will be evaluated and ranked by an Evaluation Committee ("Committee"). The Committee will be comprised of appropriate City of Miami personnel and members of the community, as deemed necessary, with appropriate experience and/or knowledge. The criteria are itemized with their respective weights for a maximum total of one hundred (100) points per Committee member. Technical and Price Criteria and Points Proposer's (firm) experience, qualifications. Proposer's staff experience, qualifications, and past performance in providing the type of services described in the solicitation, including relevant experience and qualifications of key personnel, including qualifications of subcontractors, that will be assigned to this project. 25 Points Proposer's approach and plan to providing the design, installation, and integration of the services requested. 25 Points Proposer's approach and plan to train, provide support, maintenance and cybersecurity of the services requested 10 Points Proposer's proposed schedule/timeline to complete all services requested. 10 Points Proposer's financial capabilities and price proposal. 30 Points Upon completion of the technical criteria evaluation indicated above, the Committee may choose to conduct oral presentations with the Proposers which the Committee deems to warrant further consideration. Upon completion of the oral presentations, the Committee will re-evaluate, re -rate, and re -rank the proposals remaining in consideration, based upon the written documents combined with the oral presentation. The price proposal will be evaluated subjectively in combination with the technical proposal, including an evaluation of how well it matches Proposer's understanding of the City's needs. The pricing evaluation is used as part of the evaluation process to determine the highest ranked proposer. The City reserves the right to negotiate the terms, conditions, and pricing as may be in the best interest of the City. Contract No. 2046386 EXHIBIT B CONTRACTOR'S PROPOSAL THIS PAGE INTENTIONALLY LEFT BLANK 19 Telemetry/SCADA Services /-NP4 STARCONTROLS Response to RFP No. 2046386 Storm Pump Station Telemetry and Supervisory Control and Data ("SCADA") System PROJECT Submitted: To: Proposing firm: January 9th, 2026 City of Miami Procurement Department Ms. Tahlia Gray 444 SW 2nd Ave, 6th Floor Miami, FL 33130 Star Controls Inc. 11555 Heron Bay Blvd, Suite 200 Coral Springs, FL 33076 Phone: (954) 604-6656 Fax: (954) 603-0492 Primary Contact: Tzvi Magril, President Cell Phone: (954) 288-7954 Email: tmagril@star-controls.com Federal EIN: 51-0533827 21.3 Ft Lawrence 206 Ft 3.0 Ft Antonio Mace.. 6.5 Ft 2.5 Ft Socket/Avenue zs West End No. 1 ts� 2.5 Ft west End No. 2 e1 19.7 Ft West End No. 2 mi 0.0 Ft West End No 4 3 I7.8 Ft 2.4 Ft 1.7 Ft 0.0 Ft STARCONTROLS City of Miami RFP No. 2046386 TABLE OF CONTENT SECTION 3 — COVER LETTER & EXECUTIVE SUMMARY 3 COVER LETTER 4 EXECUTIVE SUMMARY 5 SECTION 4 - MANDATORY SUBMITTALS 6 SECTION 5 - PROPOSAL OF SERVICES 14 A. MINIMUM QUALIFICATION REQUIREMENTS 15 B. PROPOSER EXPERIENCE, QUALIFICATIONS AND DIVERSITY OF WORK PRODUCT 16 1. Proposer's Organizational History and Structure 16 2. Proposer Firm Information 16 3. Active Registration with the State of Florida 16 4. Minimum Five (5) Years Business Establishment 16 5. Qualifications, Project Experience, and Credentials 18 6. Proposer's Overall Resources, Personnel, Equipment, Supervision, and Coordination Capacity 21 7. Client Service Continuity 22 8. Relevant Client List — Similar Services Provided 23 9. References — Similar Services 26 10. Litigation, Proceedings, and Disciplinary Actions (Past Five Years) 35 11. Current or Pending Litigation 35 12. Financial Condition, Bankruptcy, Litigation, and Conflicts of Interest 35 13. Bankruptcy History 35 14. Firm Accreditation, Accolades, and Conduct Code Violations 35 C. EXPERIENCE AND QUALIFICATIONS OF PROPOSED STAFF 38 Project Team Overview 38 1. Proposed Project Manager and Key Personnel 38 2. Resumes and Professional Bios of Key Personnel 39 Subcontractors 41 D. PROPOSED APPROACH TO PROVIDING THE SERVICES 42 SCADA AND TELEMETRY DESIGN 44 EXISTING SYSTEM INTEGRATION OR REPLACEMENT AND BUSINESS CONTINUITY 55 ELECTRICAL AND EQUIPMENT INTEGRATION 57 FLEXIBILITY AND SCALABILITY 59 IMPLEMENTATION, TESTING, AND TRAINING 61 SUPPORT, MAINTENANCE & CYBERSECURITY 64 SCHEDULE AND RISK MITIGATION 68 SECTION 6 - FINANCIAL INFORMATION AND FEE PROPOSAL FORM 74 A. FINANCIAL CAPABILITIES 75 B. SUBMISSION OF PROPSAL FEE FORMS 83 APPENDIX - ADDITIONAL DOCUMENTATION 86 2 STARCONTROLS City of Miami RFP No. 2046386 SECTION 3 - COVER LETTER & EXECUTIVE SUMMARY 3 STARCONTROLS City of Miami RFP No. 2046386 Cover Letter City of Miami Procurement Department Ms. Tahlia Gray 444 SW 2nd Ave, 6th Floor Miami, FL 33130 Dear Ms. Gray, Star Controls, Inc. is pleased to submit this proposal in response to the City of Miami's RFP No. 2046386, Storm Pump Station Telemetry and Supervisory Control and Data Acquisition ("SCADA") System project. Star Controls, Inc. is a South Florida based systems integrator specializing in SCADA, IloT, industrial communications, and cybersecurity solutions for Mission Critical infrastructure in the water, wastewater, and stormwater utilities. Our team brings decades of hands-on experience and a proven history of successfully delivering systems equal to or greater in scale and complexity than the system proposed for the City of Miami. Star Controls has extensive experience designing, implementing, and supporting Cloud SCADA systems for Mission Critical application, serving customers throughout South Florida, including the City of Weston and Plantation Acres. Our Cloud SCADA are securely hosted in high -availability, hardened data centers engineered for redundancy, cybersecurity, and disaster recovery. Our Cloud SCADA is actively used by satisfied customers who rely on its performance, resilience, and secure remote access for daily operations. The proposed solution is based on industry -proven, best -of -breed technologies, including VTScada by Trihedral and RTUs from Motorola Solutions, and is architected for usability, and long-term maintainability. Star Controls has successfully completed numerous SCADA Systems, new, expansion, and migration projects, while maintaining uninterrupted operations and minimizing risk to services. This proposal is complete and includes all required products, services, skills, and support as specified in the RFP and its addenda. We have carefully reviewed the City's requirements and are fully prepared to complete the project within the anticipated schedule and budget. Our strong local presence, with offices and technical resources in Coral Springs and throughout Florida, ensures responsive project execution and long-term post - implementation support. Star Controls is committed to delivering a future -ready SCADA system that meets, or exceeds, the City of Miami's operational objectives while ensuring continuous operation throughout the project lifecycle. We appreciate the opportunity to submit this proposal and look forward to partnering with the City of Miami on this important project. Tzvi Magri! President Star Controls, Inc. Cell: (954) 288-7954 Email: tmagril@star-controls.com Date: January 7th, 2026 4 STARCONTROLS City of Miami RFP No. 2046386 Executive Summary Star Controls, Inc. proposes a secure, high -availability Cloud SCADA solution purpose-built for Stormwater pump stations and telemetry sites, delivering modern monitoring, control, and cybersecurity while minimizing operational risk and lifecycle cost. Our pricing includes all required software, hardware, cellular communications, cybersecurity measures, and professional services as specified in the bid documents. Star Controls is a South Florida —based systems integrator with decades of experience delivering SCADA solutions for water, wastewater, and stormwater utilities. We bring deep expertise in Cloud SCADA architecture, cellular communications, and cybersecurity, with a proven track record supporting thousands of pump stations and stormwater sites across Florida. Our team has successfully led large-scale SCADA projects, from design to production, while maintaining uninterrupted operations. Cloud SCADA for Stormwater Operations Our proposed solution is built on StarCS Cloud SCADA, a flexible, non -binding Cloud SCADA platform specifically suited for mission -critical Stormwater applications. StarCS delivers the functionality, reliability, and performance traditionally associated with self -hosted SCADA systems, while providing the advantages of cloud deployment, including scalability, resilience, and simplified maintenance. StarCS is hosted in secure, high -availability data centers with redundant infrastructure and network paths, ensuring continuous operation during severe weather events. The platform supports remote and hard -to - reach Stormwater sites that other Cloud SCADA solutions cannot reliably serve. By leveraging off -the -shelf hardware and open architecture, the City retains long-term flexibility, avoiding vendor lock -in and preserving the ability to transition to self -hosted or alternate cloud environments in the future. Technology and Cybersecurity The solution integrates VTScada by Trihedral as the core SCADA software, delivering robust alarming, historical data, reporting, and intuitive HMI design optimized for Stormwater operations. All systems are designed in compliance with U.S. CISA cybersecurity guidelines, incorporating secure remote access, network segmentation, and hardened communications to protect critical infrastructure. Communications will utilize industrial -grade cellular routers and Verizon cellular service, engineered for reliability, redundancy, and wide coverage across the Stormwater sites. Project Delivery and Support Star Controls' approach emphasizes careful planning, parallel system operation with no downtime, early user engagement, and comprehensive training. Our methodology is based on proven best practices from successful Stormwater and utility SCADA deployments throughout Florida. We provide unmatched local support, proactive maintenance, and rapid response from our Florida -based engineering team. Our goal is to deliver a secure, reliable, and future -ready Stormwater Cloud SCADA system that supports current operational needs while enabling future expansion, including integration of smart devices such as VFDs, generators, and bypass pumping systems. 5 STARCONTROLS City of Miami RFP No. 2046386 SECTION 4 - MANDATORY SUBMITTALS 6 STARCONTROLS City of Miami RFP No. 2046386 Certiifl itien S totem ent Pleaft quote nn this form, ifuppticahle, net prices r r the iternfs) ILiIcd. Return signed original mid nthIn x €ap, farsuur fliz, Prices ibunld include oncosts.. includ-in k transportation t deztination. The Cit. rezertit�s the right toaccepaurreject nllurrnpart ufthlssalmib iun.PrlkeihauIdbe firm for 2a minimum arISO du 5 faltorning the time set fartluning or the muhmiasiun5. In the cent of;errors in cxterisiun f touiLs, the unit pries shall govern in deiterm milts the quoted prices. We (1) certify that we have read }o r salicitation, completed the necessary documents, and propose to furnish and deliver. F.GI.B. DEST[hf: TION, the items or services specified herein. The undersigned hereby certifies that neither the contractual party nor any of its principal ciwners or personnel have been convicted of any of the violations or debarred or suspended as set in section ! f - I 07 or Ordinance No. I22 7l _ By si Tong below_ the Proposer also cerli i ies pursuant to section 287.135(5 ), Florida Statutes. tbbat at the tine of submitting its Proposal it: (a) is nut on the "Scrutinized Companies with Activities in Sudan List" or the "Scrutinized Companies with Activities in Iran Terrorism .5 tors List`'; (b) does not ha' a business operations in Cuba or Sepia: and (c) is not participating in a bo cot1 of lsreel. The Proposer further acknowledges that a false certification may subject it to contract termination, civil penalties, and debarment as provided under section 287135. 135. All exceptions to this submission have been documented in the section below (refer to paragraph and section). EXCEPTIONS. We (1) certify that am: and all information contained in this submission is true; and we (1) further certify that this subirtii.sicn is trade without prior understanding. agreen>,ent, or C0111TlintiOn With aiy corporation. firm or person submitting a submission for the, an materials, supplies, equipment, or service, and is in all respects fair and without collusion or fraud. liVe (1) agree to abide by all tcrrns and cortditinns of this solicitation and certify that I am authorized to sign this submission for the stibtrtiittef_ Please print the following and sign your it name: PROPOSER NAM' L: Tzvi 1wvlsilrrif ADDRESS: 1 1555 Heron Ray Rl,d, S 20O C.'oraa] Spranits. FL 33076 PHONE. 954-604-6656 FAX: 954-603-0492 EMAIL: Tl iagril@Star-Controts.co , +CELL(Optiona]): SIGNED BY: TITLE: President DATE: GI/071202o FA! LURE. TO COMPLETE, SIGN, AND RETURN THIS FORM SiIALI. DISOL1.AUr( THUS RESPONSE 7 STARCONTROLS City of Miami RFP No. 2046386 Legal Name of Finn: Star -Controls Certifications Entity Type: Partnership. Sole Proprietorship, Corporation. etc. Corporation Year Established: 2005 Office Location: City of Miami, Miartru,Dade County, or Other Other. Coral Springs, FL- Broward County Business Tax Number/Occupational License Number: 327-10204 Busrncss Liecu_sc issuing Ancy/Oecupaticmal License 2ssuirg Agency: Broward Count - Business License Expiration DatcdOccupationai License Expiration Date: September 30, 2026 Federal Employee. Ident tkation:Numb(FEiN}_ 5I-0 33S27 Will Subcontractor(s) be used? (Yes or No) No Please list and acknowledge all addcndurnJaddcnda received. List the addendum/addenda number and date of receipt (i.e. Addendum No. 1, 11 t/2 ). If no a ddenduniladdcnda wasfwcrc issued_ please insert N/A. Acknowledged- Addendum No.1, 11/24/Z . Addendum No.2, 1211125. Addendum ,No.3. 12f23/25 If Proposer has a Local Office, as defined under Chapter 1HfArticle Ill, Section 1S-73 of the City Code, has Proposer filled out, notarized, and included with its RFP response the 'City of Miami Local Office Certification" form? YES OR NO! {The City of Miami Local Office Certification form is located in the BidNet Procurement Solutions Platform ("BidNet ).. under the Attachments Sextion of this solicitation.) No The Proposer has reviewed the attached Sample Proffssionai 5cr. ice Agreement ("Agreement"), Does Proposer acl rnov,ledge that the. attached Agreement is an example of the .standard Agreement used in conjunction with th the provisions of nc= services'? Yt s or No. Yes 8 STARCONTROLS City of Miami RFP No. 2046386 ATTACHIVIEN T C REQUEST FOR PROPOSALS ("RFP"] NO. 2046386 STORM PUMP STATION TELEMETRY AND SUPERVISORY CONTROL. AND DATA SYSTEM CERTIFICATION STATEMENT AFFIRMA11OFJ AFFIDAVIT TM Magi -II, AS PRESIDENT10EO OF Star -Contra' Inc, HEREBY DECLARE. AFFIRM, AND CERTIFY THE FOLLOWING STATEMENTS (1i THE PRINCIPALS} 01 _Star-ControISInc 15lARE Tzvi Magri'. President ;AND (2:1 NO PRINCIPAL HAS COMMITTED FRAUD OR THEFT, I.4AS NOT FILED FOR OR BEEN THE SUBJECT OF BANKRUPTCY, HAS SEEN SUMMONED TO RESPOND TO CRIMINAL CHANGES. OR BEEN CONVICTED UNDER FEDERAL OR STATE STATUTES OF EMBEZZLEMENT, THEFT, FORGERY, BRIBERY, FALSIFICATION OR DESTRUCTION OF RECORDS, RECEIVING STOLEN PROPERTY. OR ANY OTHER OFFENSE INDICATING A LACK OF BUSINESS INTEGRITY OR BUSINESS DISHONESTY, AND (3) NO COMPANY REPRESENTATIVE OR PERSONNEL HAS COMMITTED FRAUD OR THEFT; SUMMONED TO RESPOND TO CRIMINAL CHARGES OR BEEN CONVICTED UNDER FEDERAL OR STATE STATUTES OF EMBEZZLEMENT, THEFT, FOR 'ERY, BRIBERY, FALSIFICATION OR OESTRUCTi0N OF RECORDS, RECEIVING STOLEN PROPERTY OR ANY OTHER OFFENSEINDICATING A LACK OF BUSINESS INTEGRITY OR BUSINESS DISHONESTY. PURSUANT TO IFS GENERAL TERMS AND CONDITIONS SECTION 1.25 WHICH INCORPORATES SECTION 1B-11:17 OF THE PROCUREMENT CODE, ALL CONTRACTS FOR GOODS AND SERVICES, SALES, AND LEASES ISSUED BY THE CITY SHALL INCLUDE A CERTIFICATION THAT NEITHER THE CONTRACTUAL PARTY NOR ANY OF ITS PRINCIPAL OWNERS OR PERSONNEL HAVE BEEN CONVICTED OR COMMITTED ANY OF THE VIOLATIONS SET FORTH IN SECTION 1.25 GENERAL TERMS AND CONDITIONS. IN THE EVENT THAT THE BIDDER IS UNABLE TO PROVIDE SUCH CERTIFICATION, BUT STILL WISHES TO FIE CONSIDERED FOR AWARD OF THIS SOLICITATION, THE BIDDER SHALL FURNISH A WRITTEN EXPLANATION OF THE FACTS SUPPORTING ANY EXCEPTION TO THE REQUIREMENT FOR CERTIFICATION THAT IT CLAIMS THE BIDDER AGREES TO COOPERATE FULLY WITH THE CITY IN ANY INVESSTIGATIQN UNDERTAKEN BY THE CITY TO DETERMINE WHETHER THE CLAIMED EXCEPTION 13 APPLICABLE I SOLEMNLY DECLARE, AFFIRM, AND CERTIFY THAT THE CONTENTS OF THIS AFFIDAVIT ARE TRUE AND CORRECT TO THE BEST OF MY KNOWLEDGE INFORMATION. AND BELIEF. ;rear-GQIItrats_ Ini ME + ANYfFIRM) 453IGNATURE) Tzwi Magri!, PRESIDENT/GEO {PRINTED NAME] 11 f 0712026 DATE State of Florida County of Braward On this, the _ 111_ day of _January_, 2026_, before me personally appeared. _Tzvi Magri' the _PresfdontJCEO of Star - Controls Inc , known to me (or satisfactorily proven.' to be the person whose name is subscribed to vrrlhlri ttiis onstrumcnt. and atknowledged that they executed the Same fear tie purposes herein cuntarned In witness hereof, I hereunto se1 my bend and v3Eioial seal Natal). PuhllY (SEAL) TIKVA xaGRo. Commrssiran f NH 226I2I Mr C24r1m. Expires kir 10. N26 .. Sonmeq mrauth Nesonai No1a+y.xiln, rm. IWIMIIMEMIPEOP4, 9 /'1, STARCONTROLS City of Miami RFP No. 2046386 ANTI -HUMAN TRAFFIC KIN G AFAN'TT •l'Ite undersigned affirms. certifies. attests. and stipulates as follows: a The entity Is a non -governmental jental entity authorized. to transact tut -sinless In the State of -Florida and in good standing u•i[h the Ftnrida Departs nt of Shire, Division of Corporations. h. The nongovernmental ettt t, is eiilSer exeeutiob, renewing. cPT extending a contract (including, l±u[ not limited to, an). arriondmcnts, s applicable) math the fats 1 _ lIJnl] C Cit}'"J or one of its agencies, authorities, boards_ [rusts, or other C'inv ctttiili which constitutes a goverrnmenial entity as defined in Section 287.I3k(]i, Florida Statutes+2024j_ The nongovernmental entity is not in violrlticlrr of Section 787.O6, Florida Statutes (2021 _ titled "Human Trafficking." .1. T`hr rrrulgcivennrne'rttal enl ib doa:3 not use "c ourcioti - for labor or -services as defined in Section 7 X 7 (lf% Florida Statutes (2024). attached and incorp rat therein asExhibit A1fida Lt-1. tinder penalties ofperiurx, [ declare the fc}IIciv,in. t: a. l have road and understand the foregoing Artti-Human Trafficking Affidavit and that the facts, statements and. representations provided in Section, t ate tine and ernncct. h I tits an officer or a representative of the nongovernmental entity authorized to execute this Arai - 'Turman Trafficking Affidavit. Mingnrerranenlat Entity: _Star -Controls bac Name' T 1 M a Sri l siputure of Officer: Officer Title; President Offaee Ad s , 1.555 Heron Bay ki1v}d, Ste 20t1 Coral Springs. 1 [. 331076 [rnua] Ati.c1n : trnagn1: star-ontrols.com _ [Main Phone Number: 954-6O4—'6% Fls1N No_ 5]-0533827 STATE OF FLOR IJA COMITY or BROWARf3 The foregoing instrument was &Wain t,, slibuaribc41bcforc me by means of physical plre rtc a or "'i on lane It wart. I=I{]II. 1IIIX 7th dal, of 1a111ury, 2026� ti _I"tbi N[agril Its the authari; J driver nr representative for tile. mango.%enrrrtlattal .eattity'.. Hardie is personally lurnvai to rite ilailen5MORied as ideatirication NOT..RY PUJ3L[C SEA 1.4 Poly Commission F spires: C31 +G dV C of along OathSigiatura (Printed. Typed_ or Stumped Manta of7Vntar, t',ih'ic +F rif[vvs 1, • *tartti,bUe - State at ncedr CU►rnlrslan r HH 220820 My Ca1rm, Eires wr r0, 2Cti banded rirp4lriitwarNotary hue 10 STARCONTROLS City of Miami RFP No. 2046386 Price Proposal Package- Attachment C A - BASE FOR ALL STATIONS CITYWIDE TELEMETRY AND SCADA IMPROVEMENTS °' City of Miami BASE WORK, ITEMS TO BE IMPLEMENTED AT ALL 12 PUMP STATIONS Riverview_Lawrence_Orange Bowl_Belle Meade_Brickell Ave_Mary Brickell_San Marco_Antonio Maceo_West End 1_West End 2_West End 3_West End 4 Item # ITEM QTY UNIT PRICE PER STATION (12 STATIONS) UNIT COST TOTAL FOR ALL 12 STATIONS 1 Initial site visit and assessment 12 EACH $666.67 $8,000.00 2 Subscription Fee (annual, recurring, inclusive of all stations) 1 ANNUAL $12,000.00 $12,000.00 3 Design Fee (for all stations) 1 EACH $17,600.00 $17,600.00 4 Mobile app implementation (includes design and installation, inclusive of all stations) 1 EACH $24,000.00 $24,000.00 5 Platform Implementation (includes installation, inclusive of all stations) 1 EACH $7,000.00 $7,000.00 6 New updated RTU in N4X SS enclosure (includes equipment and installation) 12 EACH $22,691.49 $272,297.85 7 Cellular modems & UPS (includes equipment and installation) - ALREADY INCLUDED IN LINE ITEM 6 12 EACH $0.00 $0.00 8 Start-up, Testing & Training (inclusive of all stations) 1 DAYS $60,000.00 $60,000.00 9 Main Power: (includes equipment and installation) 12 LS $756.67 $9,080.00 A. Main Electric Power Failure B. Main ATS Failure C. ATS Position 10 Generator Monitoring System: (includes equipment and installation) 12 LS $2,485.00 $29,820.00 A. Generator on/off B. Generator Current/Voltage C. Generator Total Harmonic Distortion Sensor D. Generator Controller Position 11 Diesel gauge readings per generator (includes equipment and installation) 12 EACH $1,883.33 $22,600.00 12 Pumps: (includes equipment and installation) 12 EACH $2,323.33 $27,880.00 A. Pumps on/off B. Water Level C. Hours of Operation D. Pumps Position (Auto/Off/On/Manual/Trip/Fault) 11 STARCONTROLS City of Miami RFP No. 2046386 13 Door Sensor (includes equipment and installation) 12 EACH $376.67 $4,520.00 SUB -TOTAL SUBTOTAL 1 1 $494,798 14 MOBILIZATION/DEMOBILIZATION 12 EACH $5,996 $71,955.00 SUB -TOTAL SUBTOTAL 2 2 $71,955 TOTAL TOTAL COST COST $566,753 B - OPTIONAL WORK FOR 3 STATION CITYWIDE TELEMETRY CITY OF MIAMI OPTIONAL WORK, Riverview_Lawrence_Orange AND SCADA IMPROVEMENTS ITEMS TO BE IMPLEMENTED AT 3 PUMP Bowl STATIONS \� Item # ITEM QTY UNIT PER STATION (3 STATIONS) UNIT COST TOTAL FOR ALL 3 STATIONS 1 Cameras (includes equipment and installation) - 2 PER STATION 6 EACH $4,053.33 $24,320.00 2 Water Quality (turbidity) (includes equipment and installation) - 2 PER STATION 6 EACH $4,747.50 $28,485.00 3 Rain Gauge (includes equipment and installation) - 2 PER STATION 6 EACH $2,810.00 $16,860.00 4 Miscelleneous Building Equipment: (includes equipment and installation) - 2 PER STATION 6 LS $2,465.00 $14,790.00 A. Barscreen On/Off B. CO2 Retardant System C. Fire System On/Off SUB -TOTAL 1 $84,455 5 MOBILIZATION/DEMOBILIZATION 6 EACH $223 $1,340.00 SUB -TOTAL 2 $1,340 TOTAL COST $85,795 12 STARCONTROLS City of Miami RFP No. 2046386 C - OPTIONAL WORK FOR 9 STATION CITYWIDE TELEMETRY AND SCADA IMPROVEMENTS = CITY OF MIAMI 1 yj OPTIONAL WORK, ITEMS TO BE IMPLEMENTED AT 9 PUMP STATIONS Belle Meade_Brickell Ave_Mary Brickell_San Marco_Antonio Maceo_West End 1_West End 2_West End 3_West End 4 Item # ITEM QTY UNIT PER STATION (9 STATIONS) UNIT COST TOTAL FOR 9 STATIONS 1 Cameras (1 per station) 9 EACH $4,523.33 $40,710.00 2 Water Quality (turbidity) (1 per station) 9 EACH $4,211.94 $37,907.50 3 Rain Gauge (1 per station) 9 EACH $1,527.78 $13,750.00 SUB -TOTAL 1 $92,368 4 MOBILIZATION/DEMOBILIZATION 9 EACH $162 $1,455.00 SUB -TOTAL 2 ' $1,455 TOTAL COST $93,823 13 STARCONTROLS City of Miami RFP No. 2046386 SECTION 5 - PROPOSAL OF SERVICES 14 STARCONTROLS City of Miami RFP No. 2046386 A. MINIMUM QUALIFICATION REQUIREMENTS Star Controls, Inc. meets and exceeds all Minimum Qualification Requirements outlined in Section 2.9(5) of RFP No. 2046386- Storm Pump Station Telemetry and Supervisory Control and Data ("SCADA") System. A- Experience Star Controls, Inc. has over twenty (20) years of experience delivering SCADA, telemetry, industrial automation, and communications solutions to large municipal water, wastewater, and stormwater utilities comparable to the City of Miami. B- Business Continuity / Federal Employee Identification Number Incorporated in Florida in 2005, Star Controls, Inc. has operated continuously under the same FEIN for twenty (20) years and remains in good standing with the Florida Department of State. C- Litigation, Financial Standing, and Ethics Star Controls, Inc. has no past, current, or pending litigation, claims, bankruptcy, criminal matters involving moral turpitude, or conflicts of interest with the City of Miami. D- City Obligations and Contract Performance No principal, officer, owner, or stockholder of Star Controls, Inc. is in default on any City -related debt or contract, and the firm has faithfully performed on all prior contracts. E- Debarment and Public Entity Crimes Star Controls, Inc. is not a debarred vendor and has not been convicted of a public entity crime under § 287.133, Florida Statutes. 15 STARCONTROLS City of Miami RFP No. 2046386 B. PROPOSER EXPERIENCE, QUALIFICATIONS AND DIVERSITY OF WORK PRODUCT 1. Proposer's Organizational History and Structure Star Controls, Inc. is a Florida -based corporation with over twenty (20) years of experience providing SCADA, telemetry, industrial automation, communications, and cybersecurity services and equipment to large municipal organizations. The firm has extensive experience supporting water, wastewater, and stormwater utilities of similar size and complexity to the City of Miami. The company was incorporated in the State of Florida in 2005 and has continuously operated under the same Federal Employer Identification Number (FEIN) for the past twenty (20) years. Star Controls remains an active corporation in good standing with the Florida Department of State, Division of Corporations. Star Controls is structured to support the full lifecycle of municipal SCADA and automation projects. The organizational structure includes executive leadership, project management, engineering and programming teams, field service technicians, and administrative support. This structure enables effective coordination, efficient project execution, and responsive service delivery. 2. Proposer Firm Information Legal Entity Name: Star Controls, Inc. Business Address: 11555 Heron Bay Blvd., Suite 200, Coral Springs, Florida 33076 Office: 954-604-6656 Fax: 954-603-0492 Email: sales@star-controls.com Contact: Tzvi Magril- President Location Where Work Will Be Performed: Coral Springs, FL (Head Office) Date Incorporated: 2005 Federal Employer Identification Number (FEIN): 51-0533827 3. Active Registration with the State of Florida Star Controls, Inc. is an active registered corporation in good standing with the State of Florida Department of State, Division of Corporations. 4. Minimum Five (5) Years Business Establishment Star Controls, Inc. has been continuously established and operating as a business for over twenty (20) years under the same Federal Employer Identification Number (FEIN 51-0533827). This exceeds the City's minimum requirement of five (5) years of continuous business operation with the same Federal Employer Identification Number. 16 STARCONTROLS City of Miami RFP No. 2046386 State of Florida Department of .State I certify from the records of this office that STAR CONTROLS_ INC. is a Delaware corporation authorized to transact business in the State of Florida, qualified on January 24, 2005. The docuir-iPn.t number of this corporation is F05000000398. I further certify that said corporation has paid all fees due this office through December 31, 2025_ that its most recent annual report.. uluforin business report was filed on January 18, 2025, and that its status is active. I further certify that said corporation has not filed a Certificate of Withdrawal. GhTli under my hand and the Great Seal of the Strife of Florida at Tallahassee, the Capital, this the Eighteenth day of Jarivam 2025. Secretary af tate Tracking Number: 8815060645CC To authenticate this certlficate,risit the followw ng site,eater this number, and then follow the instructions displayed. kttps:::services,sunbiz,orgThingsCertificae0fftaCUsC'ertificace_ usbenticario-nl 17 STARCONTROLS City of Miami RFP No. 2046386 5. Qualifications, Project Experience, and Credentials Star Controls possesses the qualifications, experience, and technical credentials necessary to successfully perform the required scope of work for industrial automation and control systems. The firm was founded by global experts in SCADA, Industrial loT (IIoT), and communications, bringing a combined experience of more than one hundred (100) years. The team includes recognized Subject Matter Experts (SMEs) with a complete understanding of complex municipal operational environments. Star Controls has successfully implemented projects nationwide and internationally across critical infrastructure sectors, including water utilities, wastewater utilities, stormwater and flood control. Many of these projects support Smart City and Smart Grid initiatives and are of similar scope and complexity to the City of Miami's systems. The firm provides a comprehensive range of services, including trusted advisory services, system design, implementation, system integration, knowledge transfer, ongoing support, and managed services. Star Controls utilizes established project management methodologies and frequently partners with large engineering firms as part of integrated solution teams. Representative Experience and Clients Star Controls has provided services to numerous municipal and utility clients, including but not limited to: • Pinellas County, FL — Water Utility • Martin County, FL — Water Utility • City of Orlando, FL — Water Utility • City of Tampa, FL— Water Utility • City of Weston, FL — Stormwater / Flood Control • St. Johns County, FL — Water Utility • Honolulu Board of Water, HI — Water Utility • Orange County, FL — Water Utility • South Florida Water Management District (SFWMD), FL — Flood/Storm Water • Palm Beach School District, FL — Public Safety (300 sites) • NYPD / NYCT, NY — Network Fault Management • Detroit Edison, MI — Electric Utility • International water and electric utilities in Jamaica, the Bahamas, Grenada, and South Carolina * All clients are referenceable. 18 STARCONTROLS City of Miami RFP No. 2046386 Technical Capabilities and Design Approach Star Controls is a trusted provider of SCADA, IIoT (Industrial Internet of Things), and Communication solutions for Water, Wastewater and Stormwater applications. Over the years, we have successfully delivered SCADA projects and provided Electrical, Instrumentation, and Control System Services to Floridian Water Utilities. Star Controls offers different activities and services, from discovery and design, implementation, knowledge transfer, support, and managed services. The company utilizes project management methods, which empower the team to deal with substantial projects. The system's longevity, ease of use and predictable performance are among our highest professional objectives: • Needs Analysis and Advisory/Consultation • Design and implement SCADA systems • Cloud SCADA • Ongoing improvements and modifications, to reflect changes on customer's infrastructure and operations • Training and Knowledge Transfer • Analytics • Ongoing Support — Annual and On -demand Here is an overview of our activities: • Discovery and Design o Complete system discovery and analysis o Detailed design of the new system o Submittals and approvals • SCADA Software o We have 40 years of combined experience in SCADA design, programming, and maintenance. o Star Controls is HIGHEST QUALIFIED VTScada Integrator in South Florida, and actually among the nationwide best VTScada integrators (i.e. you can contact Trihedral). o VTScada refers to high -complexity projects to Star Controls due to our unmatched expertise. o VTScada frequently published our successful implementations in their case studies. o We have collaborated with Trihedral's development team to test beta versions and enhance their product before formal release. o Star Controls' Cloud SCADA services is based on VTScada • PLCs, RTUs, and IloT Devices o Our team is certified and experienced in a wide range of products. o Star Controls use the best products and technologies that meet the specific requirements and needs of each customer. • Communications and Networks o Our experts for communications networks for SCADA systems, gained the prestige of GLOBAL Subject Matter Experts in enhancing SCADA availability and resiliency. o We design and implement wireless networks that utilize different technologies and products, including data radios, cellular and other technologies. o Star Controls pioneered the use of SECURED cellular networks for SCADA. o Our experience with advanced network technologies, including LoRa, cover current and future needs. 19 STARCONTROLS City of Miami RFP No. 2046386 • SCADA Cybersecurity o We provide end -to -end protection for SCADA systems, including software, RTUs/PLCs, and networks. o Our services include Cyber Security vulnerability assessments and ongoing improvements. • Instrumentation o Our experts have extensive experience with both legacy and modern instrumentation technologies, introducing customers to smart instrumentation advancements. • Educational and Training o We believe in transferring our knowledge in the field so that you can be more self-reliant, and make the best decisions in regards to adapting, changing, or adding new technologies to your system. Our dedicated team of professionals has been implementing and supporting customers with RTUs and SCADA software systems for many years. Our team includes engineers and trainers with unparalleled knowledge and expertise. • Comprehensive Support o To increase its availability and extend the Life Cycle of the SCADA system, the system must constantly be maintained, optimized, and enhanced. o Star Controls offers a large portfolio of Support and Maintenance to fit the needs of your SCADA System. From remote sites, through communications and networks, all the way to the Control/Data Centers. Our skills and experience guarantee a holistic and detailed understanding of your operations and the SCADA system. o We offer scheduled and unscheduled support, ongoing optimization, and training for knowledge transfer. The support services can be scheduled or unscheduled to address immediate need. Urgent Support is available, including during non -office hours, to address faults that impact critical operations. o Star Controls also offers proactive maintenance, where we continuously monitor the performance of the system and detect degradation in performance before it interrupts operations. o We utilize powerful troubleshooting tools that are used for proactive maintenance, as well as fast reaction/fix of faults. Certifications and Vendor Qualifications Star Controls is certified on a wide range of industry -standard platforms, including: • Motorola Solutions • Trihedral VTScada • Rockwell Automation • Wonderware / AVEVA • Schneider Electric • Emerson • GE The firm maintains direct access to vendor product engineering teams and is qualified to test beta versions of new products prior to formal release. Due to its high level of expertise, Star Controls is frequently dispatched by vendors to remediate systems where other integrators have been unsuccessful. 20 STARCONTROLS City of Miami RFP No. 2046386 6. Proposer's Overall Resources, Personnel, Equipment, Supervision, and Coordination Capacity Star Controls maintains the organizational capacity, personnel resources, equipment, supervision, and coordination necessary to successfully execute projects of this size and complexity. The firm operates local offices throughout the State of Florida with dedicated technical staff capable of providing both on -site and remote support throughout all phases of the project lifecycle, including design, implementation, testing, commissioning, and ongoing support. All project activities are centrally managed and coordinated through Star Controls' Head Office, which serves as the primary point of supervision, communication, and quality control. Star Controls Head Office 11555 Heron Bay Blvd., Suite 200 Coral Springs, FL 33076 The Head Office is equipped with comprehensive maintenance instrumentation, testing tools, and technical resources required to support SCADA systems, field instrumentation, communications infrastructure, and industrial control systems. These resources enable efficient system configuration, testing, validation, troubleshooting, and commissioning. In addition, Star Controls maintains a separate secure storage facility for spare parts, replacement components, and other large or long -lead-time materials. This inventory capability supports rapid deployment, minimizes supply chain delays, and reduces operational downtime. Resources Summary • Personnel o Dedicated technical staff based in Florida o Ability to provide on -site and remote support throughout all project phases • Supervision and Coordination o Centralized management and oversight through the Head Office o Coordinated scheduling, staffing, logistics, and quality control • Equipment and Technical Resources o Comprehensive maintenance instrumentation and testing tools o In-house resources for SCADA, instrumentation, communications, and control systems o Capability to perform testing, commissioning, troubleshooting, and maintenance • Facilities and Inventory o Fully equipped Head Office supporting technical and administrative functions o Secure storage facility for spare parts and replacement components o Inventory of large or long -lead-time items to support rapid deployment 21 STARCONTROLS City of Miami RFP No. 2046386 Star Controls' combination of skilled personnel, centralized supervision, technical facilities, and inventory resources ensures efficient project execution, reliable system performance, and minimal operational downtime. 7. Client Service Continuity Star Controls has maintained strong, long-term relationships with all of its clients. There have been no cancellations or discontinuations of services in the past two (2) years. Many engagements with clients that began as individual projects have evolved into annual support contracts, reflecting the trust and confidence clients place in Star Controls' expertise. Numerous clients who rely on ongoing support have also entrusted Star Controls with additional projects, demonstrating both the strength of these partnerships and the firm's commitment to delivering consistent, high -quality service. This record of continuity underscores Star Controls' reputation as a reliable and trusted partner in SCADA, industrial automation, and control systems. 22 /'1, STARCONTROLS City of Miami RFP No. 2046386 8. Relevant Client List — Similar Services Provided Star Controls has provided SCADA, industrial automation, telemetry, communications, and control system services to a broad range of municipal, utility, and public safety clients over the past five (5) years. The firm's work includes system design, integration, implementation, commissioning, support, and ongoing maintenance. The following list represents a subset of clients for which Star Controls has delivered services of a similar nature to what as required in this RFP. All clients are referenceable, and the City reserves the right to contact references. elected Florida Customers Name of System Size/Type Date of Installation Contact Name Phone Number E-mail Pinellas County, FL Lift Station Scada 320 Sites 2017 - ongoing upgrades Justin Manning 727-464-5882 jmanning@pinellas.gov City of Orlando, FL Lift Station Scada 190 Sites 2017 - ongoing upgrades Guy Mecabe 321-765-8021 Guy.Mecabe@cityoforlando.net City of Tampa, FL Waste/Storm Water 250 Sites 2015 - - ongoing upgrades Javier Moreno 813-247-3451 Javier.Moreno@tampagov.net City of Weston, FL Lift Station Storm Water 83 Sites 2022- 2024 Peter Johson 954-385-2600 PJohnson@westonfl.org City of North Lauderdale, FL Lift Station Scada 32 Sites 2024-2025 Neil Buckeridge 954-597-4757 nbuckeridge@nlauderdale.org City of Boynton Beach, FL Lift Station Scada 192 Sites 2022 - ongoing upgrades Terry Rowe 561-742-6431 rowet@bbfl.us Martin County, FL Lift Station Scada 370 Sites 2016 - ongoing upgrades Tim Harrison 772-260-0046 tharriso@martin.fl.us Plantation Acers District, FL Storm Water System 6 Sites 2022-2024 Jorge Santana 954-802-6006 jorge_santana@paidfl.org City of Wildwood, FL WTP/WWTP/Lifstations 53 Sites 2023 - ongoing upgrades Jason Martin 352-643-0943 jmartin@wildwood-fl.gov SFWMD, FL Storm Water System 600 Sites 2015- ongoing upgrades Louis Rodriguez 561-753-2400 Irodrigu@sfwmd.gov SJRWMD, FL Storm Water System 12 Sites 2014- ongoing upgrades Matt Forham 386-643-1974 MForhan@sjrwmd.com Seminole County Wastewater SCADA 308 Sites 2022 - ongoing upgrades Jeron Rader 407-665-2760 jrader@seminolecountyfl.gov Village of Islamorada Waste Water Collection system 8 Sites 2024 - ongoing upgrades Clay Boggess 305-509-1760 clay.boggess@islamorada.fl.us Honolulu Board of Water, HI Island wide water SCADA 350 Sites 2015 - ongoing upgrades Blaine Shimizu 808-228-9281 BSHIMIZU@hbws.org Bahamas Water Company Island wide water SCADA 12 Sites 2012 - ongoing upgrades Krishnoff Albury 242-454-0166 wckalbury@wsc.com.bs Charles County, MD Water Scada 70 Sites 2018- ongoing upgrades Jason Weisman 240-270-4745 WeismanJ@charlescountymd.gov Jamaica Water Company Island wide water SCADA 75 Sites 2018 - ongoing upgrades Jeremy Wilson 876-926-5825 jeremy.wilson@nwc.com.jm Palm Beach School District, FL Access/Security Monitoring 208 Sites 2016 - ongoing upgrades Erik Glosman 561-248-3326 erik.glosman@palmbeachschools.org 23 STARCONTROLS City of Miami RFP No. 2046386 Note: • Many of these engagements began as project -specific work and have transitioned into ongoing annual support contracts, reflecting the firm's sustained client relationships and trusted advisory role. • Star Controls can provide additional references and contact details upon request to support the evaluation process. Another way to looks into our references is through the technology we used: Customer SCADA Software RTU Comm Networks Pinellas County, FL V V Martin County, FL d d d City of Orlando, FL V d City of Tampa, FL V V V City of Weston, FL V V V City of North Lauderdale, FL V V V City of Boynton Beach, FL V V V City of Wildwood, FL V V Plantation Acers Drainage District, FL d V V Honolulu Board of Water, HI V V City of Ormond Beach, FL V V Jamaica Water Company (NWC) V V V Bahamas Water Company (BWSC) V V V Seminole County, FL V V V SJRWMD, FL V V V SFWMD, FL V V St. Johns County, FL V V V Orange County, FL V V Charles County, MD V V V Mount Pleasant Water, SC d V V City of Deerfield Beach, FL d V V City of Coconut Creeks, FL V V d Palm Beach School District, FL V V d Detroit Energy, MI d University of Michigan, MI V V V US Airforce, Army and Navy, different locations V V V NYPD/NYCT, NYC, NY V V Palm Beach School District, FL V V V 24 STARCONTROLS City of Miami RFP No. 2046386 SCADA Projects — Partial Reference Star Controls has many large and medium SCADA customers in Florida and beyond. Some of the Florida SCADA customers are shown below: 4IOOL,A z n H 64 -1 , BEACH COU/ rt CITY OF e;RN OR LAN DO Pinellas County 1S4 SEMINOLE COUNTY FLORIDA'S NATURAI. CI IOICC Forth 1 ouderdole 25 STARCONTROLS 9. References — Similar Services City of Miami RFP No. 2046386 Star Controls, Inc. has provided SCADA, PLC, instrumentation, cybersecurity, and system integration services to municipal water and wastewater utilities comparable in size and complexity to the City of Miami. The following references represent projects completed or ongoing within the past six (6) years, all of which were successfully delivered and, where applicable, continue under maintenance and support with no early terminations. Reference 1 Client: City of Tampa, Florida — Water Utility Address: 306 E. Jackson Street, Tampa, FL 33602 Contact Person: Javier Moreno Phone: (813) 247-3451 Email: Javier.Moreno@tampagov.net Description of Services: Design and implementation of a comprehensive SCADA system upgrade for water distribution operations. Services included Allen-Bradley PLC programming, VTScada configuration and integration, control panel design and fabrication, system testing and commissioning, and cybersecurity enhancements. The project improved system reliability, operational visibility, and resilience while maintaining uninterrupted service to critical water infrastructure. Performance Period: 2021— Present Contract Value: $550,000 Key Project Personnel: Tzvi Magri! (Project Manager), Ron Zetouni (Lead SCADA Engineer), Diego Pinto (SCADA / Network Engineer) Reference 2 Client: City of Boynton Beach, Florida — Water Utility Address: 124 E. Woolbright Road, Boynton Beach, FL 33435 Contact Person: Terry Rowe Phone: (531) 742-6431 Email: rowet@bbfl.us Description of Services: Migration of legacy systems to a VTScada platform for water treatment operations. Scope included PLC programming, SCADA system configuration, network resiliency improvements, cybersecurity vulnerability assessments, system hardening, and operator training. The project enhanced system security, reliability, and staff proficiency while supporting long-term operational sustainability. Performance Period: 2020 — 2024 Contract Value: $425,000 Key Project Personnel: Ron Zetouni (Project Manager / Lead SCADA Engineer), Diego Pinto (SCADA / Network Engineer) 26 STARCONTROLS City of Miami RFP No. 2046386 Reference 3 Client: City of Weston, Florida — Water Utility Address: 17200 Royal Palm Boulevard, Weston, FL 33326 Contact Person: Peter Johnson Phone: (954) 385-2600 Email: PJohnson@westonfl.org Description of Services: Ongoing SCADA system maintenance and upgrades for municipal water utility facilities. Services included instrumentation upgrades, IIoT device integration, system optimization, and field commissioning to improve availability, redundancy, and operational efficiency. The work ensured continued system performance and reliability across critical water infrastructure assets. Performance Period: 2020 — 2023 Contract Value: $300,000 Key Project Personnel: Tzvi Magril (Project Manager), Charles Mondale (Instrumentation / Integration Specialist) Reference 4 Client: City of North Lauderdale, Florida Address: 701 SW 71st Avenue, North Lauderdale, FL 33068 Contact Person: Neil Buckeridge, Utilities Superintendent Phone: (954) 597-4757 Email: nbuckeridge@nlauderdale.org Description of Services: Design, implementation, and support of a comprehensive SCADA system for 30 lift stations and 2 canal level monitoring sites. Services included SCADA system architecture, PLC programming, control panel replacement and refurbishment, instrumentation integration, redundant radio and cellular communications, cybersecurity hardening, operator training, and ongoing system maintenance. Performance Period: 2024 — 2025 Contract Value: $1.3 million Key Project Personnel: Tzvi Magril (Project Manager), Ron Zetouni (Lead SCADA Engineer), Diego Pinto (SCADA / Network Engineer) Note: All services completed successfully and continued into maintenance phases. No early terminations. Also, Star Controls, Inc. has no past, current, or pending litigation, claims, arbitration, or disciplinary actions involving the firm, its partners, managers, subcontractors, contractors, or key staff members related to professional activities or performance. The firm has never filed for bankruptcy, is in sound financial condition, has no record of civil or criminal litigation involving moral turpitude, and has no conflicts of interest with the City. 27 STARCONTROLS Representative Projects and Client References 411111Nt North Lauderdale Customer: City of North Lauderdale, FL City of Miami RFP No. 2046386 System Description The City of North Lauderdale implemented a comprehensive SCADA system to monitor and control its wastewater lift station infrastructure. The project included thirty (30) lift stations and two (2) canal level monitoring sites and focused on improving operational reliability, visibility, and cybersecurity. The system incorporates modern SCADA technology, advanced pump control logic, redundant communications, and a user-friendly HMI. As part of the City's long-term strategy, the SCADA system was designed for high availability and scalability, supporting ongoing operations and future expansion. The City has published a bid for a new Stormwater site (C-14) and designated Star Controls as the sole approved SCADA integrator. Services and Products Provided by Star Controls After Star Controls was awarded the project, the firm provided full lifecycle services including detailed design, installation, development, system integration, training, and ongoing support. Star Controls is responsible for maintaining the SCADA system for the years to come. The advanced and comprehensive SCADA system includes the following components and features: • Remote lift station sites with high availability and independent local control, including advanced pump control logic • Monitoring and control of all lift station equipment, alarms, and operational conditions • Best -of -breed products, including VTScada, Motorola MC -Edge RTUs, and secured, redundant cellular and licensed radio communications • Simple and intuitive local and remote HMI • Comprehensive cybersecurity protection across all system components • Reporting, training, and annual support services Testimonial "The City of North Lauderdale selected Star Controls to deliver a comprehensive SCADA solution for our lift station system. Throughout the project, Star Controls effectively managed the work from design and implementation through commissioning and operator training. Their team delivered a secure and dependable system that improved monitoring, control, and day-to-day operations across our lift stations. Star Controls has proven to be a reliable partner and continues to provide ongoing system support and maintenance." Neil Buckeridge- Utilities Superintendent- City of North Lauderdale 28 STARCONTROLS City of Miami RFP No. 2046386 Customer: City of Tampa System Description The city of Tampa (FL) has a SCADA system that monitors and controls hundreds of Water and Wastewater Treatment Plants and Lift Stations. The system uses different generations of RTUs. The original wireless network is based on Motorola narrowband radios. For many years, the County has kept using advanced technologies to increase the system's availability, resiliency, and usability. Services and products that Star Controls provided Since its inception Star Controls has provided the City of Tampa with different products and services. • Upgrade the SCADA system. • Improved software application for existing sites. • Ongoing sites rehabilitation and expansions. • Ongoing support Star Controls also acts as a trusted advisor, on improvements, introduction of new technologies, as well as design and implementation of these initiatives. Testimonial "Star Controls has gained our trust and confidence, through years of relationships. The team at Star Controls is always available for us." "Star Controls is our trusted SCADA advisor. Star Controls proactively recommend us to improve the performance, resiliency, availability, and maintainability of the SCADA system. Star Controls constantly helps us to improve the performance and resiliency of the SCADA system." Javier Moreno - Instrumentation and Control Specialist, Wastewater Department, 29 STARCONTROLS City of Miami RFP No. 2046386 %996 Customer: City of Weston, FL System Description The City of Weston has upgraded its Storm Water management system, by adding SCADA to monitor and control its Storm Water Pumping sites. The SCADA system consists of five pump stations and 8 solar powered lake level monitoring sites. The system uses most modern SCADA components including integration of RTUs with smart devices, Cyber Security, and user-friendly HMI. As part of the city strategy, the SCADA system is based on the Cloud, which takes the Burdon of maintaining it. The expanded the Cloud SCADA system to cover all its Lift Stations. Services and products that Star Controls provided After Star Controls was awarded the project it went through all steps from detailed design to installation, development, integration, training, and support. Star Controls is responsible for maintaining the SCADA system for the next years to come. The advanced and comprehensive Cloud Based SCADA system includes many components and features: • Remote sites with high availability, independent local control, including logic that is based on information from other sites. • Cover every aspect of the remote sites, including pumps, alarm system and monitor every part of the pump station • Integration to smart devices such as Diesel Pumps Controllers, and smart sensors. • Simple and easy to use local and remote HMI • Cyber Secured — Complete and cover every part • Comprehensive reports Testimonial "Star Controls provided the City of Weston with the most advanced and cyber secured Cloud Based SCADA system for the mission critical storm water sites. From Detailed Design, to development, installation, and integration the team at Star Controls attended to our needs and requests. Star Controls was open to changes throughout the project. Star Controls has gained our trust and confidence that it will serve the city and the SCADA system for the years to come." Peter Johnson— Assistant Director of Public Works, City of Weston Please refer to additional information in the Appendix: • Case Study by the customer and Motorola • Cloud SCADA Design & Build Success - Story City of Weston, Florida 30 STARCONTROLS City of Miami RFP No. 2046386 T. CITY OF (AORLANDO Customer: City of Orlando System Description The City of Orlando has a SCADA system that monitors and controls its 220+ Lift Stations, which are part of the City's Wastewater Collection system. The system uses different generations of the Motorola RTUs (MOSCAD and ACE3600), and wireless networks. The original wireless network is based on Motorola narrowband radios. The city introduced cellular networks to gain from higher speed and good coverage, while keeping the radio network as backup. For many years, the City of Orlando has kept using advanced technologies to increase the system's availability, resiliency, and usability. Services and products that Star Controls provided Since its inception Star Controls has provided the City of Orlando with different products and services. Star Controls was qualified by the city as the main provider of services and services for its SCADA. Here are the products and Services that Star Controls provided: • Software for the RTUs. o Star Controls' StaRTU simplifies the application software and improves its maintainability. It also provides powerful troubleshooting and diagnostics tools. • fast -paced migration of old RTUs to New Cyber Secured RTUs • Assist with the Migration to Cellular • Annual Support • Ongoing projects Star controls delivered multiple projects involving upgrading of existing SCADA and field hardware, as well as advanced programming, and RTU software upgrade, using different types of radio and LAN/WAN communications. Star Controls also acts as a trusted advisor, on improvements, introduction of new technologies, as well as design and implementation of these initiatives. Testimonial "Star Controls has gained our trust and confidence, through many years of strong relationships. Star Controls provided the City of Orlando with different software products as well as services, which help our team to accomplish High -Availability of our SCADA system, and constantly improve its performance and resiliency. Our team members know that Star Controls is available whenever they need it." Guy Mecabe - Industrial Automation Manager, IA Group, Water Reclamation Division 31 STARCONTROLS Pinellas (ounty� Customer: Pinellas County (FL) City of Miami RFP No. 2046386 System Description Pinellas County (FL) has a SCADA system that monitors and controls more than 320 Lift Stations, which are part of the County's Wastewater Collection system. The system is using different generations of the RTUs and wireless networks. The original wireless network is based on Motorola narrowband radios. They migrated their network cellular, to gain higher speed and good coverage. For many years, the County has kept using advanced technologies to increase the system's availability, resiliency, and usability. Services and products that Star Controls provided Since its inception Star Controls has provided Pinellas County with various products and services. Star Controls was qualified by the County as the main provider of services for its SCADA. Here are the products and Services that Star Controls provided: • Led the Migration to Cellular • Software for the RTUs. o Star Controls' StaRTU simplifies the application software and improves its maintainability. It also provides powerful troubleshooting and diagnostics tools. o Star Controls' WaterWorks for Pumps Control was adopted by the County. • Migration of old RTUs to New Cyber Secured RTUs • Ongoing projects Star controls delivered multiple projects involving upgrading of existing SCADA and field hardware, as well as advanced programming, and RTU software upgrade. Star Controls also acts as a trusted advisor, on improvements, introduction of new technologies, as well as design and implementation of these initiatives. Testimonial "Star Controls has gained our trust and confidence, through years of relationships. Star Controls provided the Pinellas County with different software products as well as services, which have helped to increase the Availability and Maintainability of our SCADA system. Star Controls constantly help us to improve the performance and resiliency of the SCADA system. The team at Star Controls is always available for us." Edward Atchison - SCADA and Security Systems Manager, Pinellas County Utilities 32 STARCONTROLS City of Miami RFP No. 2046386 Customer: Martin County Utilities System Description Martin County (FL) has a SCADA system that monitors and controls more than 350 Lift Stations for Wastewater collection. The system uses different generations of RTUs. The original wireless network is based on Motorola narrowband radios. The County migrated its wireless networks, which is used by the SCADA, to Cellular network. For many years, the County has kept using advanced technologies to increase the system's availability, resiliency, and usability. Services and products that Star Controls provided Since its inception Star Controls has provided Martin County with different products and services. Here are the products and Services that Star Controls provided: • Helped with the Migration to Cellular network. • Improved software application for existing sites. • Software for the RTUs. The County was an early adopter of StaRTU and WaterWorks software products • Next Generation of RTUs — the County was an early adopter of the Motorola MC -Edge RTU • Ongoing support Star Controls also acts as a trusted advisor, on improvements, introduction of new technologies, as well as design and implementation of these initiatives. Testimonial "Star Controls provided Saint John County's SCADA Department with different software products as well as services, which has helped us to increase the Availability and Maintainability of our SCADA system. Star Controls constantly helps us to improve the performance and resiliency of the SCADA system. The team at Star Controls is always available for us." Tim Harrison - SCADA Department Manager, Martin County Utilities 33 STARCONTROLS City of Miami RFP No. 2046386 Customer: Honolulu Board of Water Supply System Description The Honolulu Board of Water Supply (BWS) has a SCADA system that monitors and controls more than 200 Water Pumping sites. The system uses different generations of RTUs. The original wireless network is based on Leased Line Communications. Later HBWS introduced wireless broadband networks. Recently the HBWS started using the FirstNet Cellular Network that is allocated for the utilities. For many years, the HBWS has kept using advanced technologies to increase the system's availability, resiliency, and usability. Services and products that Star Controls provided Since its inception Star Controls has provided Honolulu BWS with different products and services. Star Controls was pre -qualified by the County as a provider of services for its SCADA. Here are the products and Services that Star Controls provided: • Migration of old RTUs to New Cyber Secured RTUs, including products and services. • Improved software application for existing sites. • Helped with the Migration to different networks and improve availability through redundant links. • Software for the RTUs. • Ongoing support Star Controls also acts as a trusted advisor, on improvements, introduction of new technologies, as well as design and implementation of these initiatives. Testimonial "Star Controls has gained our trust and confidence, through years of relationships. With the advisory services that I received from Star Controls the availability, resiliency, and maintainability of the SCADA system. Star Controls is available 24/7 and was next to us anytime we need the support". Blaine Shimizu — Acting Telecommunications Supervisor, Honolulu Board of Water Supply 34 STARCONTROLS City of Miami RFP No. 2046386 10. Litigation, Proceedings, and Disciplinary Actions (Past Five Years) Star Controls, Inc. has not been subject to any litigation, legal proceedings, disciplinary actions, or adverse rulings within the past five (5) years. This includes matters involving the firm, its partners, managers, sub - consultants, contractors, or other key staff members. There have been no actions taken or pending against Star Controls by any state regulatory body, professional organization, court, or administrative agency related to the firm's professional activities or performance. 11. Current or Pending Litigation Star Controls, Inc., has no current or pending litigation or legal proceedings involving the firm, its partners, managers, or other key staff members. Accordingly, there are no cases to disclose, no outcomes pending, and no monetary amounts associated with litigation related to the firm's professional activities or performance. 12. Financial Condition, Bankruptcy, Litigation, and Conflicts of Interest Star Controls, Inc. has never filed for bankruptcy and is in sound financial condition. The firm has no record of civil litigation or pending lawsuits involving criminal activities of moral turpitude and maintains a strong record of ethical and professional conduct. Star Controls further affirms that it does not have any conflicts of interest with the City of Miami. 13. Bankruptcy History There have been no bankruptcies involving Star Controls, Inc., its partners, managers, or other key staff members. 14. Firm Accreditation, Accolades, and Conduct Code Violations Star Controls, Inc., has no record of conduct code violations or disciplinary actions issued by any national organization, professional association, or accrediting body. There are no sanctions or findings against the firm related to professional conduct or performance. Star Controls, Inc. holds multiple industry and vendor certifications, demonstrating expertise in SCADA and RTU systems from leading providers, including Schneider Electric, Rockwell Automation, GE Digital, Motorola Solutions, and VTScada. Key certifications include VTScada Certified Advanced Integrator and completion of the U.S. Department of Homeland Security's Virtual Industrial Control Systems Cybersecurity (301V) Training 35 STARCONTROLS City of Miami RFP No. 2046386 List of software and Product Certifications Star Controls has several industry and vendors' certificates including proficiency in several SCADA and RTU products_ GE Digital hneid r , "Electric Rockwell Automation IMOTOROLA SOLUTIONS VTScada Certified Advanced Integrator Star Controls Fi.4.1asoff2 $O/7 'Ai Certificate of Training Cn.I�NIaEo,3 U.S.. Dapartni111t n# Horn Oland Sarakrily CybOlcQullity and inrra4411u5#LIr4 aaswIy 01l94Thry IGM +V bla Hal To CPA 6hor.:10 1 .1. CaAhr Wu J1 Matheus R. Mello {on:c4e{Ap. 9r lne InJulivl Cnmrai SyaEah} tyhi M.curlty if9llfl h ihrhd lk5 Shi2U37 La. .Fr 1 CISA 36 STARCONTROLS City of Miami RFP No. 2046386 ControILogix Certificate Presented to kkthe ss hMelo kl R®r.11 . tir, Ln?.isr11t N Unrte=44 to .,.IITIFTIIM ram. u:rr,RJ t. Control Logo; Certificate Presented to Dfto Fires wrwarhai d.xpoori mr rtmb ro mpam C) mecum la iethyrialign Rockwell Atdeakitm Prawor$ Itt@ C„rhfr yta h5 MILIEUS MELD *Or r +K.,RI OCP2aO:ACCELERATED L 7:5 PEdOGR.A Mk1ER CERTIFICATE LEVEL 1 EEPTET.IER 16 2824 • EEPTEMBEFR2t1.'..Q24 CHEEKTr NNGR.rrr iRSTRULTOR: RI •I POP.11COA R tkweI hulr rtdi[n Pretends ha Ceflilimle ice DIEGO PINTO CCP2511. ACCELERATED L0GI O PROGRAMMER 1MER CERTIFICATE LEVEL I EEPTEMEER 1ij, kl - EEPTEM9ER 211.2G.14 CHEEKTOWAG4 W 1Mu�rmManses I liil t1.151RIKTOFE RI Rpk1{jpA 37 STARCONTROLS C. EXPERIENCE AND QUALIFICATIONS OF PROPOSED STAFF City of Miami RFP No. 2046386 Project Team Overview Star Controls proposes an experienced project team with a proven record delivering SCADA and telemetry systems for municipal water and wastewater utilities comparable to the City of Miami, supported by: • A clearly identified Project Manager with single -point accountability • Dedicated technical leads for SCADA engineering, communications, instrumentation, electrical systems, and I&C design • Adequate staffing depth to support schedule adherence and long-term system reliability • A strong local and regional South Florida presence enabling rapid response and coordination 1. Proposed Project Manager and Key Personnel Team Member (Years; Location) Project Manager SCADA System Engineer Comms & Networking. Electrical Devices Design of I&C Systems including Panels Doc. & Drafting Time Commitment Tzvi Magril (35 years; Coral Springs, FL) 15% Diego Pinto (10 Years; Palm Beach) V d V 35% Ron Zetouni (35 Years; Palm Beach) V d 10% Charlie Mondale (31 Years; Lakeland) V V 20% James Mondale (7 Years; Lakeland) V V V 20% Matheus Melo (4 Years; Palm Beach) V V 20% Jarret Shuler (19 Years; Jacksonville) V V V 5% Antonio Liriano (16 Years; Miami -Dade) V V V V 20% Emma Light (18 Years; Coral Springs) V V 10% - Area Leader; Main Contact for the Project This team organization directly supports the City of Miami's evaluation criteria for technical competence, organizational capacity, and project delivery reliability. 38 STARCONTROLS 2. Resumes and Professional Bios of Key Personnel City of Miami RFP No. 2046386 Diego Pinto (Main Contact Person) As a SCADA Programmer, Mr. Pinto has developed his career in Real -Time Embedded computation. Mr. Pinto is a subject matter expert in SCADA systems including for Mission Critical applications. Mr. Pinto has already gained a reputation as a productive and creative professional, with attention to customer satisfaction. • Role — Programmer, Project Manager, Support, Training, Networks, Cyber Security • Experience —10 years • Education — BSc. in Computer Science and Computer Engineering • Programming Languages — Several including Python, C/C##, Java, and others • Certifications from vendors and institutes (partial list) - SCADA Software (VTScada, Wonderware); RTUs/PLCs (Motorola, Rockwell Automation, Schneider Electric, Emerson); Networking (Cisco); CISA (Cybersecurity and Infrastructure Security Agency); Wireless (GE, Motorola, CalAmp, 4RF, LoRa) Tzvi Magril Tzvi brings to Star more than 35 years of experience in Design, Development, Sales, Business and Channel Development in the Communications and SCADA/Telemetry markets. Tzvi was a lead designer of Motorola SCADA products and has immense knowledge of the product line, as well as SCADA Systems design. Mr. Magril has implemented and maintained major SCADA systems for large clients throughout the world. • Roles — Solution Architect, Project Management • Experience - 35 years • Education - BSc. in Electrical and Computer Engineering • Certifications from vendors and institutes (partial list) - Motorola System Integration Institute (SII); MTA Safety; SCADA Software (Wonderware, VTScada); RTUs/PLCs (Motorola, Ayyeka); IT (ITIL - Information Technology Infrastructure Library); Wireless (GE, Motorola, CalAmp, 4RF, LoRa) • Awards - Mr. Magril has several patents in the SCADA industry Ron Zetouni Mr. Zetouni brings more than 30 years of experience in SCADA business for Water/Wastewater and other disciplines, covering the SCADA and communication aspects of projects. Mr. Zetouni' s experience includes design, programming, and integration with SCADA software (G.E. iFIX, Wonderware InTouch, Trihedral VTScada and others). During 8 years as the SCADA leader at the SFWMD and 14 years of tenure at Motorola, Ron has programmed and integrated dozens of SCADA systems in different applications (Water Utilities, Oil & Gas, Electric Utilities and others) for customers worldwide. Mr. Zetouni is a Global Subject Matter Expert (SME) in the water markets and wireless networks for SCADA. Experts from all over the world seek his support and advisory, leveraging his impressive skills and vast knowledge. • Role — Lead Engineer, Solution Architect, programmer, Integration, Field Engineering, Training, Support, Networks, Cyber Security • Experience — 35 years • Education — BSc. and MSc. Computer Science • Programming Languages — Several including Ladder Logic, C/C##, Java, and others • Certifications from vendors and institutes (partial list) - SCADA Software (VTScada, Wonderware, iFix); RTUs/PLCs (Motorola, Rockwell Automation, Schneider Electric, Emerson; Siemens); Networking (Cisco); Wireless (GE, Motorola, CalAmp, 4RF, LoRa) 39 STARCONTROLS City of Miami RFP No. 2046386 Charles Mondale As a global Subject Matter Expert in Telemetry and Environmental Monitoring, Mr. Mondale brings more than 30 years of experience in the Telemetry and Instrumentation for Water/Storm/Wastewater and Environmental Monitoring, which. Mr. Mondale experience and skills covers all aspects of a solution, from the sensors, the Dataloggers, Communications (with focus on Wireless networks), Power and Integrity of the system. Mr. Mondale has served as a team leader at the SJRWMD, leading the design, installation and maintenance of the Hydrology monitoring system the SJRWMD is using to manage water resources. • Role — Field Engineer, Project Manager, Instrumentation, Integration, Support, Programmer • Experience — 31 years • Education - BSc. in Electrical and Computer Engineering • Programming Languages — Campbell Scientific programming • Certifications from vendors and institutes (partial list) - SCADA Software (VTScada); RTUs/PLCs (Motorola, Campbell Scientific); Instrumentation; Wireless (GE, Motorola, CalAmp, 4RF) James Mondale As a Field Technician, Mr. Mondale is a solutions -oriented IT & SCADA Systems Professional with proven success in designing, implementing, and integrating cost-effective, high-performance technical solutions to meet challenging business needs. • Role — Field Technician, Programmer, Project Manager, Support, Training, Support, Networks, Cyber Security • Experience — 7 years • Education — Attend school for degree in Computer Science • Programming Languages — Several including C/C##, Ladder Logic, Java, and others • Certifications from vendors and institutes (partial list) - SCADA Software (VTScada; Wonderware); RTUs/PLCs (Motorola, Rockwell Automation; Campbell Scientific); Instrumentation; Wireless (GE, Motorola, CalAmp, 4RF, LoRa) Matheus Melo As a young Computer Science professional Mr. Melo focused on the development of Star Controls software products for the IloT & SCADA Systems. • Role —Programmer, Training, Support, Networks, Cyber Security • Experience — 4 years • Education — BSc in EE with minor in Computer Science; MSc in Computer Engineering • Programming Languages — Several including Python, C/C##, Java, and others. • Certifications from vendors and institutes (partial list) - SCADA Software (VTScada, Wonderware); RTUs/PLCs (Motorola, Rockwell Automation, Schneider Electric, Emerson); Networking (Cisco); CISA (Cybersecurity and Infrastructure Security Agency); Wireless (GE, Motorola, CalAmp, 4RF, LoRa) Jarret Shuler Jarret's background includes technology, energy, manufacturing, finance, and entrepreneurship. He studied Chemical Engineering at the University of Florida and Finance at the University of North Florida. Jarret has expanded his background by serving different industries. • Role —I&C Design and CAD • Experience —19 years • Education — BSc in Chemical Engineering; Finance • Skills — l&C Design of Control Systems, including panels. 40 STARCONTROLS City of Miami RFP No. 2046386 • Certifications from vendors and institutes (partial list) - CAD, Medium Voltage Switch Gear, Medium Voltage Switch Gear Drawing Schematics, Fundamentals of Structural Analysis, Design of Steel Structures, Structural Loading: Forces and Types, Lean Six Sigma Master Black Belt Antonio Liriano Well-rounded professional, with vast experience in different aspects of water and wastewater industries. Antonio's skills and experience cover instrumentation & control systems, panels, and electrical circuits. • Role —Certified Electrician • Experience —16 years • Education — Certified Electrician • Skills — I&C Design, Installation and troubleshooting processes and control systems, including high voltage. • Certifications from vendors and institutes (partial list) — Certified Electrician Subcontractors 1. Functional Responsibilities and Subcontractors All functions described in this proposal, including project management, SCADA engineering, communications and networking, I&C system and panel design, and documentation will be performed by Star Controls' in- house personnel. 41 STARCONTROLS D. PROPOSED APPROACH TO PROVIDING THE SERVICES City of Miami RFP No. 2046386 General Our team has successfully completed projects such as this one MANY TIMES before. Our team has done similar projects in Florida, in other states, and even in other countries. The wealth of experience we have gathered from previous projects complements all our other skills and ensures that the solution we present is based on real -life, field and time tested and proven technologies and methodologies. Fast -Track User Experience and Participation. We emphasize early customer experience enhancement. Staff will experience many system enhancements very quickly. This approach affords these benefits, among others: • Staff "buy -in" into the new system, as they are exposed to its development and provide beneficial input to its usability in the early stages of the development. • Better Training results and self-sufficiency. The staff will have some experience with the new system before the official training. This ensures better training results and more educated and self -maintained operators and staff. Discovery, Design, Development, and Integration Services General The Star Team has vast experience in the design and installation of many varieties of SCADA systems and products. Each customer has unique requirements and circumstances. Through our numerous previous accomplishments with and experience with many other customers, we've come to deeply understand the customer's SCADA needs. The following is a list of services Star provided to past clients. These demonstrate our capabilities of supporting the requirements of this RFP. Discovery • Comprehensive review and survey infrastructure • Interview users and administrators regarding current and future operation of the system. • Examination of the current system, detailing all current operational schemes and aspects (procedures, limitations, problems, SOPs, screen design and navigation settings, etc.) • Getting user input from stakeholders, including current restrictions and lacking features of the current system and improvement requests and considerations • Getting IT input on the City's IT Policies and procedures, including for Cyber Security Complete System Design and Integration Our expertise in the SCADA field, with a special devotion to the Water Industry, allows us to provide complete turn -key solutions, as well as stand-alone design, studies, and software and hardware integration activities. SCADA is not just a technology, but rather a game changer in the organization. Our design is taking into consideration different aspects that are important to the integration of the SCADA system into the organization. It includes seamless fit into existing Operations, best -in -class User's Experience (i.e. simple to use, yet, comprehensive) while the entire system is fully Cyber Secured (i.e. using the most advanced hardware and software for Cyber Security). 42 STARCONTROLS City of Miami RFP No. 2046386 Our SCADA solutions leverage State -of -the -Art technologies, products and expertise to accomplish High Availability, Resiliency, Longevity and are Cyber Secured. All our SCADA systems are designed to be open to accommodate future technologies (e.g. Next Generation Wireless Networks, Smart Sensors and Smart Field Devices), so the system can be upgraded without major cost. Design Principles Open Architecture — the system is based on open architecture at the field and the control center. At the field, the system is open to accommodate new instrumentation and control technologies that will be introduced to infrastructure. Data Integrity and Maintainability — one of the main challenges of every SCADA system is the trust that the organization has in the system (i.e. reliability and integrity of the information), and the efforts to keep the system in production. Through years of experience, we have developed several software modules and applications, mainly at the RTU level, that will improve the data integrity and maintainability of the system. Following are a few examples: RTU Historical Event Logging— no lost data and excellent data audit capabilities. Contention Reporting — maximize efficiency of radio channel, increase availability, and improve reliability. The system will utilize efficient Contention messages to significantly increase the responsiveness and efficiency of the communication channel. Local automation — eliminate dependencies on communication system. Advanced diagnostics — We have developed diagnostics software that monitors operational and communications events at the RTU. The information allows personnel to troubleshoot the system and analyze the Root Cause in local process or communications in no time. This increases system availability, while reducing maintenance costs substantially. Business Continuity — Throughout the project, we will utilize project management techniques and system technology to make sure that the migration from the old to the new system will be smooth with limited down- time. This will be in close collaboration with the personnel. Scalability - The system can be expanded and scaled to support other infrastructure, such additional sites, without major changes to the system. Partnership — no, this is not a technical feature or capability, but our most important "secret asset". We enjoy doing business and partnering with our customers. We TRULY UNDERSTAND the customer's needs and are always open to addressing them. As part of our partnership with our customers we keep transferring knowledge to increase his/her self-sufficiency and confidence in the SCADA system. New RTUs, Wireless Networks and Instrumentation Installation Services This core service includes RTU outdoor and indoor installations. The complete installation covers all civil, mechanical, software, and electrical aspects. The team will also install, test and calibrate all required instrumentation. 43 STARCONTROLS SCADA AND TELEMETRY DESIGN City of Miami RFP No. 2046386 Technical Approach to SCADA and Telemetry for Stormwater Pump Station A. Overall SCADA system architecture (centralized, distributed, cloud -based, hybrid) Star Controls offers the City of Miami its StarCS, the Proven, Flexible and Non -Binding Cloud SCADA service. StarCS provides Cloud SCADA with features and flexibility that you cannot find in other Cloud SCADA services: • Best of Both Worlds — combines features and capabilities of "Traditional SCADA" with the affordability and simplicity of Cloud SCADA • Designed for Mission Critical such as Storm Water applications. • Complies with CISA (www.cisa.gov) requirements for Cyber Security. • Advanced Local and Site -to -Site Control • StarCS can be tailored to your specific needs. • Non -Binding — all components are based on Best of Breed Non -Proprietary Products • Open Architecture o Communications with Existing Smart Devices; PLCs, Soft Starters, VFDs, Smarts Sensors o Ready to integrate with third party applications, such as Planning, AI, CRM, GIS • Demonstrates Unparalleled High Availability • Support All Networks — Cellular, Radio, LoRa, Mesh, ... o Offers redundant schemes • Offers Video from Remote Sites 44 STARCONTROLS Cloud SCADA Solution Architecture StarEdge SCADA Remote Site Wireless Communication Device STARCONTROLS I R I R City of Miami RFP No. 2046386 Your Global IIoT, SCADA, & Cyber Security Partner To fulfill the current and FUTURE needs, our proposed SCADA system is based on the following main components: • SCADA Software — VTScada software o The most advanced and user-friendly product. More information below. • RTU (Remote Terminal Units) - Motorola RTUs o The Best and the ONLY Cyber Secured RTUs, with huge installed base o Over forty years of experience in SCADA and other data communications for mission critical o Over 500,000 RTUs worldwide, including the main utilities (e.g. Orlando, Tampa, Martin County, Pinellas County,...) and the South Florida Water Management District (SFWMD). All SFWMDS' structures, such as gates and pumps, are monitored and controlled with the Motorola RTUs. o Designed and built to withstand harsh environmental conditions ■ Unparalleled robustness and resiliency ■ Unparalleled longevity o Cyber Secured — the only RTU o Open platform ■ Can interface any SCADA SW ■ Integrate with any device in the field, including Smart Devices o High Availability and Accuracy on Data from the field ■ Support Redundant Communications o Any communication domain - support current and future communications technologies 45 STARCONTROLS City of Miami RFP No. 2046386 o Advance Remote Over -The -Air Maintenance and Upgrade, including application and firmware. ■ Reduce substantially the need for on -site visit. • Cellular Communications, with future options to add other wireless networks • Top quality instrumentation and material • RTU Software Application — Star Controls developed specific software for pump controls, which simplifies the operations and maintenance of the pump stations. • Maintainability— our system provides powerful tools, yet simple to use, to troubleshoot and modify the system RTU that will be used at each site by the proposed SCADA system The main building block of the RTU at the remote sites is the latest generation of Motorola RTU. With over 500,000 Motorola SCADA RTUs installed worldwide, and over three decades of accumulated experience, it's no wonder that Motorola RTUs are able to provide the best SCADA Solutions. Motorola has the largest installed base of RTUs in Florida. Among the Floridian customers you can find the SFWMD, City of Orlando, Martin County, Pinellas County, St. Johns County, City of Tampa, City of Weston, City of North Lauderdale, City of Coconut Creek, Seminole County, City of Boynton Beach, City of Lake Worth, City of Coco Beach, City of Hialeah and many more. Motorola RTUs - Main Features • The Motorola RTU is a hybrid between the most powerful PLC and a VERY powerful communication device. • The Motorola RTU can be programmed and execute any local process and logic, but also can communicate to an RTU in another site if the logic or process requires site -to -site communications. o The Motorola RTU performs as a full fledge Pump Controller, match, or exceeds, any other pump controller • Designed and built to withstand harsh environmental conditions o Unparalleled robustness and resiliency o Unparalleled longevity - The Motorola RTUs last in the field for decades. We are still serving RTUs that were installed more than 30 years ago and still working • Cyber Secured — the only RTU in the market that is fully comply with the CISA's guidelines. o That's the reason large utilities and agencies are using the Motorola as the sole source for the RTU. • Input/Outputs — the Motorola RTU offers any type of Input or Output modules. It can accept any signal from the field and control every device. o The Motorola RTU can communicate with Smart Devices that will be added in the future, such as VFD, Soft Starter, Smart Devices and sensors o The Motorola RTU can manage backup generators, VFDs and any other PLC that manage another sub -process. o The Motorola RTU can communicate with sensors and remote devices through LoRa communications • Open platform o Can interface any SCADA SW through MODBUS, DNP3 and MQTT o Integrate with any device in the field, including Smart Devices • The development tools are based on the industry standard programming (CODESYS and C), which many programmers in the industry are familiar with. 46 STARCONTROLS City of Miami RFP No. 2046386 • "Over the air" SCADA Protocol — By utilizing the most powerful and widely accepted OSI model, the Motorola RTU offers as the most reliable, diversified and secure form of communication over any SCADA system. Versatile network interoperability, powerful data management. o Support remote monitoring and controls. o Support site to site communications. o High Availability and Accuracy on Data from the field - Support Redundant schemes o Network technologies - support current and future communications technologies. Cellular, Data Radios, LoRa, Ethernet, Fiberoptics, Satellite, Mesh and any future network technologies and products • Advance Remote Maintenance and Upgrade — You DO NOT NEED to travel to the remote sites to hold diagnostics, troubleshooting or update the software. All can be done remotely and SECURED from any place. MC -Edge RTU — Features Overview The MC -EDGE features the following capabilities: • Options of several Built-in communications devices o LTE modem for communication with center via Cellular operator o APX4000 radio for communication with center via digital ASTRO P25 o LoRa RF module to communicate on LoRaWAN with far wireless end nodes • External device connectivity for communication with center via ETH, USB, Serial • MDLC and Non-MDLC user application protocols • Cyber Security Defense suite • Local management capabilities of wired end node devices via up to 5 Expansion I/Os modules • MODBUS protocol support, acting as a MODBUS Client (Master) or MODBUS Server (Slave): • DNP3 protocol support, acting as DNP Client (Master), DNP Server (Slave), DNP Client (Master) & Server (Slave) • Local management capabilities of wired end node devices via RS232/RS485, Eth protocol • Management of wireless end node devices via LoRaWAN protocol: MC -EDGE configured as LoRaWAN full termination or as LoRa GW • User application development ro run inside MC -EDGE using built-in 'C' SDK toolkit or IEC 61131-3 (Codesys) programming languages • Connection with external NTP server for clock sync • Connection with external DNS server for Name-IP resolution • Connection with external Syslog server to send real-time MC -EDGE log events • Connection with external Radius Active Directory to manage Linux SSH users • Internal built-in MQTT Broker for connection with external MQTT clients using commercial MQTT protocol • Internal built-in MQTT Bridge for connection with an external MQTT Broker using commercial MQTT protocol Please refer to additional information in the Appendix: • MC -Edge Datasheet 47 ti‘ STARCONTROLS City of Miami RFP No. 2046386 Following are photos of MC -Edge in the filed 48 /'1, STARCONTROLS City of Miami RFP No. 2046386 B. Proposed SCADA Software Platform, Version, and Rationale for Selection Star Controls' Cloud SCADA service is based on VTScada ( ) SCADA software by Trihedral. It is the Industry's Most Powerful SCADA Software with hundreds of installations in Florida water utilities as well as a large national and international installation base. VTScada is multi -award -winning software that has been powering some of the largest mission critical applications in the world for over three decades. It is installed in 166 countries worldwide and at hundreds of North Americans Water, Wastewater, and Stormwater customers. VTScada also natively includes components not commonly found in HMI or SCADA software platforms such as polling management, historian, trends viewer, report generation, application version control, alarm notification, and system backup. You install everything at once in just a few minutes. Star Controls is the Advanced Integrator for VTScada and ranked by Trihedral as one of the best nationwide. • Trihedral (VTScada) has published many case studies that are based on the successful implementation by Star Controls. • Star Controls assists the development team of VTScada to improve the products by testing the Beta versions of different software modules and new releases. • Trihedral refers to Star Controls opportunities that require highly skilled resources of VTScada. Star Controls keeps the VTScada SCADA software up-to-date to the latest version, making sure that end -users will benefit from latest features and capabilities of the products. VTScada @ Glance • Large Installed Base • Open Architecture • Unparalleled Support Trending Business System Connectivit Security Alarm Management VTScada Mobile Access STARCONTROLS Software for Monitoring & Control Monitoring and Control Internet Connectivity Reporting 11.3.1 1.06.1 Your Global IloT, SCADA, & Cyber Security Partner Please refer to additional information in the Appendix: • VTScada Presentation 49 STARCONTROLS City of Miami RFP No. 2046386 C. Communications Methodology (e.g., cellular, radio, fiber, or hybrid), Including Data Polling Intervals and Failover Protocols Star controls will propose a cellular first approach to communications. The communication backbone will use up-to-date cybersecurity standards in order to isolate the remote units from any possible unauthorized access or data tampering. All network connectivity will be sent via private APN on the cellular network with the MDLC protocol. The MDLC is "secret sauce" behind the high availability of the communications in our solution is the MDLC protocol. The MDLC Protocol supports all modes: Polling, Report by Exception and Unsolicited. Mode and intervals are defined and configured based on the data's importance. The MDLC supports different types of redundancy (failover) options: Switch over, Hot Switchover and Cluster The MDLC protocol allows each Motorola RTU to act as a master SCADA node, so it can communicate with another site. This provides an RTU-RTU communications, including in the event of loss of communications with the SCADA control center. Advanced SCADA systems require intelligent communication capabilities in order to assure the flexibility, expendability, reliability, and high performance of the system. In addition, they require software controlled managing and maintenance of their communication network. SCADA systems can only be justified if these provide cost benefits to the customers. This can be achieved by combining smart communications into the system, which results in faster, less costly, and safer operation and of the customers' facilities. Motorola provides a solution to this challenge with its Motorola RTU system and the MDLC (Motorola Data Link Communications) protocol. The MDLC communication protocol is based on the Open Systems Interconnection (OSI) 7 layers model published by ISO, which Motorola specifically adapted for SCADA and radio communications. This is the only available protocol for radio which comprises all the seven recommended layers. Here, every RTU may act as a Distributed Control Unit (DCU) and as a communications node serving other units. FUTURE OPTION (NOT INCLUDED IN CURRENT PRICING) - Star Controls can support the City with the design to use redundant wireless link, such Data Radios. If the city elects to utilize the radio, it will act as a backup to the cellular in the case of failure. The radio system will be on an automatic switchover based on the communication statistics for individual sites or system wide. Please refer to additional information in the Appendix: • Motorola MDLC Features • MDLC-Reliability 50 STARCONTROLS City of Miami RFP No. 2046386 D. User interface and alarm management features relevant to storm event monitoring and emergency response User Interface Typical VTScada display pages include: • A graphical representation of the process. • Real-time and summary process values. • Control elements e.g. buttons, switches, dials, textboxes. • Alarm lists help ensure timely responses to issues. • Reports and trends to reduce waste and avoid downtime. The VTScada can be tailored to the SPECIFIC needs of EACH customer! Alarm Notification and Management VTScada supports all types of Alarm Notification, and provides complete management and control of alarms, escalation policies and much more. The following documents elaborate all its capabilities. Please refer to additional information in the Appendix: • VTScada-Alarm Management • VTScada-Alarm Notification e. Data Logging, Trending, and Historical Reporting Capabilities VTScada provides a continuous view of both historical and real-time data in a single timeline that covers the entire lifespan of your application. See any number of analog or digital I/O values displayed together as a graph or table. The HDV displays min, max, and average values and supports logarithmic scaling. Easily export any range of data to a file or database. VTScada also has powerful reporting capabilities. Please refer to additional information in the Appendix: • VTScada Historian • VTScada Reports 51 STARCONTROLS Mockup of the SCADA for the City of Miami Stormwater Project City of Miami RFP No. 2046386 ZT Miami Scada Site Map Northwest 12th Street Dolphin Expressway Dolphin Expressway West End 4 LeVlI Northw¢st'Ith Streets 2.18 West End 3 Level 2.65 ne status upped 3.14 street West Flagler Street Pump Status Stopped Rol uscrukler. Nort we Dotphtn Expessway Dolpnln fxpfesswa�' Northwest 7th Street Northwest 7th Street Sour ^wet( 1 rut St r pen hketuTtset West Flagler Street ay Antonio Mace( Level 2.19 Pumo Status Running Northwest 7th Street Neorrreett ...Street thernereo nor. Noe ewer, ind sow, West Flegter Street Miami Scada Situ M;ap Orange Bowl Level 2.44 Pump Status Stopped lagler Street Southwest 1st Street southwest erth Street ra Southwest 7th Street n Southwest ath Street Riverview ever 1.69 anus, 41L11%....1 nos Pump Stator . Running NorthWest loth Street anu.AV 41Z1158M411ON West Flagler S Southwest 1.1 Southwest 6,h Street Southwest ]th Street Southwest ath Street o° Ne.tnwett1<mstr.et yQ �y tret*ttt1t11Stlwt i5_ NonhwestlOth street Northwest eth Street Nonhw.N Nth Street Northwest 6th Street Northwest 6th Street Northwest 5th Street Northwest Sth Street No.rryvw,iel Lawrence Level 2.39 et Street Pump Status .1 Street Running Southwest SO Street Southwest 7th Street Southwest ath Street Southwest ll;n Street Northeast I,th Street North...lath Street Northeast ash Street Northwest Sod Street Northeast Sol stout ss ° NOtthweFt sat Street Southwest 3M Street Mary BricltgL,, t,.r xe...t Level 2.72 Pump Status Stopped Brickell Ave level 1.56 Pump Status Running Southwest 13th Street• MacArthur Causeway 52 STARCONTROLS City of Miami RFP No. 2046386 Scada Stormwater Stations Summary ar` Riverview 35 22 21.3 Ft 16:00 0000 08:00 Jan 7 San Marco 3.0 Ft 3- 2- Lawrence 20-1 20 20.6 Ft Orange Bowl 18- 16- 16:00 00:00 08:00 Ian 7 Antonio Maceo 7.5 - 5 6.5 Ft 16:00 00:00 08:00 16:00 00:00 08:00 Jan 7 Jan 7 Belle Meade 4- 2- 2.5 Ft Brickell Avenue 241 2 2.5 Ft 16:00 00:00 08:00 16:00 00:00 0800 Jan 7 Jan 7 16:00 West End No. 1 24 18 00.00 u6:o5 Jan 7 17.8 Ft 2.4 Ft 1G00 00:00 08 0:. Tan 7 West End No. 2 1.7 Ft 20 18 16:00 West End No. 3 19.7 Ft West End No. 2 0.0 Ft West End No. 4 191 20 _ 0 l 16:00 00:00 08:00 Jan 7 16A0 00:00 08:00 Jan 7 16:00 00.00 08.00 Ian 7 0.0 Ft 00:00 Jan 7 08:00 0 Scada Miami Stormwater Rivervie Level 2.13 Local / Remote Remote Common Status Normal Pump Command Stop Global Status Active 41.0 Poll 0.0 Min 0 Str Global Status Active AC Status Normal AC Status Auto Pump Status Stop Pump Status Stopped Start<0 Start<Stop Level< 0.5 Pump Fault Stop=0 DiR<0.5 Not in REMOTE Cooldown Level 2.07 Loral / Remote Remote Common Stars Normal Pump Command Stop Global Status Active 28.6 Poll 28.6 Min 0 Str Global Status Active AC Status Normal AC Status Auto Pump Status Stopp Pump Status Stopped 5tart-0 Start<Stop Level < 0.5 Pump Fault Stop=0 DiN<0.5 Not in REMOTE Cooldown Level 2.05 Local/Remote Remote 24.1 Poll 0.0 Min Global Status Active 0 Str El Common Status Normal AC Status Normal Auto Auto Ea Pump Status Stopped Run Fail Normal Orange Bowl Level 1.70 Global Status Normal 0.0 Min 0 Str Common Status Normal Common Status Normal AC Status Auto Pump Status Stopped Start<0 Start<5top Level < 0.5 Pump Fault Start<0 Start<Stop Level < 0.5 Stop=0 Dift<0.5 Not in REMOTE Cooldown Stop=O Diff<0.5 Not in REMOTE Level 1.98 15:PoII 15.8 Poll 0 Str Gl Local/Remote obal Stars Common Remote I Active Auto Common Status Normal AC Status Normal Auto Auto Pump Command Stop Pump Status Stopped Run Fail Normal Level 1.96 Global Status Normal 7.1 Poll 0 Str Common Stars Normal Common status Normal AC Status Auto Pump Status Stopped 5tag=0 Start<Stop Level < 0.5 Pump Fault Start<0 StermSto Level < 0.5 Stop--0 Dim<0.5 Not in REMOTE Cooldown Stop=0 Difk0.5 Not in REMOTE V1 Historical Data Viewer 53 tik STARCONTROLS City of Miami RFP No. 2046386 Historical Data Viewer d 90 Da s S llc g4414LLlv"Li A CO Pan azocm x 26 26 30 38 2997 27 33 24.67 17 0 15.5 24 17 0 I20851 11385� 111.41� 1 153� Oct 11 Oct 15 Oct 19 Oct 23 Oct 27 Oct 31 Nov4 Nov 8 r.�r�aiw►t Nov 12 Nov 16 Nov 20 Nov 24 Nov 28 Dec 2 Dec Dec 10 Dec 14 Dec 18 Dec 22 Dec 26 Dec 30 Jan 3 • 0 _0 _0 •0 m 0 m ma m _0 3en Name ti SW\SW304\RTU\W W_Level SW\SW651\RTU\WW_Level ti SNASW650\RTU\W W_Level ''se SW\SW306\RMW W_Level ^v 5W\SW647\RTU\WW_Level ti SW\SW649 RTU\1MN_Level 1. SW\SW307\RTUNWW_Level SW\SW661\RMW W_Level ti SW\SW300\RTU\WW_Level Plot Grid Notes Description Wetwell Level Pond Level Pond Level Wetwell Level Level Pond Level Wetwell Level Wetwell Level Wetwell Level Value Minimum 19.8 Ft 19 Ft -471 Ft -426 Ft 0Ft -311 Ft 24.8 Ft 19.6 Ft -552 Ft Maximum 22.2 Ft 213 Ft 19.7 Ft 34.5Ft 2.02 Ft 22.8 Ft 25.3 Ft 213 Ft 441 Ft Avera 21.1 20.5 18.5 28.7 0.048 21.9 24.9 20A 2.57 54 STARCONTROLS City of Miami RFP No. 2046386 EXISTING SYSTEM INTEGRATION OR REPLACEMENT AND BUSINESS CONTINUITY General The processes will include the following main steps: • Kickoff meeting • Sites Survey • Detailed Design o Documentation o Presentation o Approval • On -going assessment during the project implementation Also, during the project's deployment Star Controls will constantly be in touch with the City's PM and staff to address any unexpected situation or request for modification of the design. 1. Evaluation of Existing SCADA / Telemetry Systems Our approach begins with a structured and risk -based assessment of all existing SCADA and telemetry systems at each pump station site. This evaluation is conducted prior to final design and includes: • Hardware assessment: PLCs/RTUs, I/O modules, communication equipment, power supplies, and field instrumentation. • Software assessment: SCADA platforms, firmware versions, licensing status, historian integration, and cybersecurity posture. • Communications review: Protocols (e.g., Modbus, DNP3, OPC, Ethernet/IP), bandwidth, redundancy, and reliability. • Operational performance: Current functionality, reliability history, maintainability, and operator familiarity. • Lifecycle and supportability: Vendor support status, obsolescence risks, and availability of spare parts. Based on this evaluation, we'll prepare the Detailed Design Document. In collaboration with the City we'll determine the most appropriate path forward on a site -by -site basis. A. Incorporation or Integration of Existing Systems Where existing hardware and software are technically sound, supported, and align with long-term operational goals, our preferred approach is to incorporate or interface with the current system. This may include: • Retaining existing PLCs/RTUs and integrating them into the proposed SCADA architecture using standard, open communication protocols. • Upgrading firmware, communications modules, or network infrastructure to ensure compatibility, performance, and cybersecurity compliance. • Integrating existing HMI or SCADA components into a centralized or unified supervisory system. • Implementing gateways or middleware where required to bridge legacy protocols to modern platforms. 55 STARCONTROLS City of Miami RFP No. 2046386 This approach reduces capital costs, minimizes operational change, and preserves operator familiarity while still delivering a modern, scalable system. B. Decommissioning and Full System Replacement If the evaluation identifies systems that are obsolete, unsupported, insecure, or incompatible with the proposed architecture, we recommend full decommissioning and replacement. Justification for replacement may include: • End -of -life hardware or unsupported software platforms. • Inability to meet current cybersecurity, reliability, or regulatory requirements. • Excessive maintenance burden or poor system performance. • Limited scalability or lack of integration capability. Risks associated with replacement (e.g., temporary service interruption, operator retraining) are identified early and mitigated through detailed planning and phased execution. Expected benefits include improved system reliability, enhanced cybersecurity, standardized architecture across sites, reduced maintenance costs, and long-term vendor support. 2. Minimizing Service Disruptions Minimizing operational disruption is a core principle of our implementation strategy. Measures include: • Detailed cutover planning with clearly defined roles, timelines, and rollback procedures. • Use of parallel systems where feasible, allowing the new system to be commissioned and tested before final switchover. • Off -site configuration, simulation, and factory acceptance testing (FAT) prior to on -site work. • On -site commissioning during low -demand periods where operationally feasible. • Close coordination with operations staff to ensure continuous monitoring and rapid response during transitions. These practices ensure that pump station operations remain safe and reliable throughout integration or replacement activities. 3. Support for Phased and Partial Upgrades Our proposed system fully supports migration paths for partial upgrades and phased transitions. This includes: • Ability to integrate legacy and new equipment concurrently within the same SCADA environment. • Modular architecture that allows individual sites, pump stations, or subsystems to be upgraded independently. • Support for mixed hardware generations and multiple communication protocols during transition periods. • Clear long-term roadmap that enables incremental modernization without requiring a single, large- scale system replacement. This phased approach provides flexibility, reduces risk, and allows capital investments to be spread over time while maintaining continuous system operation. 56 STARCONTROLS City of Miami RFP No. 2046386 ELECTRICAL AND EQUIPMENT INTEGRATION Our SCADA solution is built on an open architecture and consists of two primary components: the Motorola RTU and VTScada SCADA software. This open design ensures seamless integration with existing infrastructure as well as flexibility to accommodate future expansions and technology upgrades at the stormwater pump stations. It means that our SCADA system can accommodate any existing and future components in the pump station; Soft Starters, PLCs, VFDs, Smart Sensors, sites access management and more. 1. Integration with Pump Station Components A. Programmable Logic Controllers (PLCs) The system integrates with both existing and new PLCs from multiple vendors using standard industrial communication protocols. The Motorola RTU interfaces directly with PLCs to collect, normalize, and transmit operational data to the SCADA control center. B. Wet Well Level Sensors, Float Switches, and Flow Meters The Motorola RTU supports direct I/O connections as well as digital communications with smart sensors. Wet well level sensors, float switches, and flow meters can be integrated either directly into the RTU or via PLCs and other intelligent devices. C. Backup Generators and Automatic Transfer Switch (ATS) Systems Generator status, ATS position, alarms, and run conditions are monitored through discrete and analog inputs or via smart controller interfaces. All generator -related data is centrally visible within the SCADA system. D. Variable Frequency Drives (VFDs), Motor Controls, and Pump Status Inputs The system integrates with VFDs, soft starters, motor controllers, and pump status signals using both hardwired I/O and network -based communications. This allows for real-time monitoring of pump performance, alarms, and operating conditions. 2. Multi -Vendor Compatibility and Data Standardization The Motorola RTU functions as a site manager, integrating and orchestrating all field devices within the pump station and managing communications between the station and the central SCADA control center. The RTU also supports peer -to -peer communication between pump stations when operationally required. All data collected, whether directly through RTU I/O or from smart devices such as PLCs, VFDs, and Smart sensors, is standardized and normalized within the SCADA system. This ensures consistent data representation, alarming, trending, and reporting across all assets, regardless of equipment vendor or device type. This open, standards -based approach provides long-term flexibility, vendor independence, and a scalable platform capable of supporting current and future stormwater pump station requirements. 57 STARCONTROLS City of Miami RFP No. 2046386 Motorola RTU — Site Manager Any type of Communications Devices and Apps a STARCONTROLS Control Monitoring Your Global IIoT, SCADA, & Cyber Security Partner 58 STARCONTROLS City of Miami RFP No. 2046386 FLEXIBILITY AND SCALABILITY Our SCADA system set the highest standard for flexibility and scalability in the SCADA market. • VTScada SCADA software - the VTScada can accommodate thousands of sites, support different industry's protocols and ongoing updated library to support RTUs, PLCs and sensors. • Motorola RTU — as described above, in the Electrical and Equipment Integration, the Motorola RTU can interface and integrate local and remote sensors, via o The Motorola RTU supports peer —to -peer communications, that can be used to retrieved information from remote sensors or from other sites. ■ (Use Case) City of Weston Stormwater sites - the RTUs in the pump stations communicate with water level sensors that measure the ponds/lakes level in different locations throughout the city. The RTUs in the pump stations receive the water level in "upper stream" of the drainage path and implement an algorithm that PREDICT the inflow water and operates the pump accordingly. The algorithm improves the utilization of the pumping power, saves energy and reduces the potential of flooding. o Motorola MC -Edge RTU has the option to become a LoRa Gateway, which means that in the future the City will be able to add LoRa based sensors, such as water level, to either view the information in the SCADA, or implement an action based on the information from the additional source. • Integration with Enterprise Application — the proposed SCADA is almost the only Cloud SCADA that can be integrate with any Enterprise application, such as GIS, CMMS, CRM, Storm Event Dashboard, Hydrology Modeling, NRW, ERP and more. o Star Controls has vast and successful experience with the integration of SCADA systems to Enterprise Applications. Our proposed SCADA solution is designed to set a high standard for flexibility, scalability, and future readiness. The system combines VTScada SCADA software with Motorola RTUs, enabling seamless expansion, multi - vendor interoperability, and integration with enterprise -level applications. 1. Accommodation of Future Growth and Enhancements A. Addition of New Pump Station Sites VTScada is a highly scalable SCADA platform capable of supporting thousands of sites within a single, unified system. New pump stations can be added with minimal configuration, without impacting existing operations. The system supports a wide range of industrial communication protocols and provides an actively maintained device library for RTUs, PLCs, and intelligent field devices. B. New Sensor Types and Remote Monitoring Features The Motorola RTU serves as a flexible site controller capable of interfacing with both local and remote sensors using wired I/O, standard industrial protocols, and wireless communications. 59 STARCONTROLS City of Miami RFP No. 2046386 • Peer -to -Peer Communications: Motorola RTUs support peer -to -peer communications, enabling data sharing between remote sensors and multiple sites without reliance on a central polling architecture. o Use Case — City of Weston Stormwater System: In the City of Weston, RTUs installed at pump stations communicate with upstream water level sensors located in ponds and lakes throughout the drainage network. The RTUs receive upstream water level data and execute predictive algorithms to estimate inflow conditions and proactively adjust pump operation. This approach improves pump efficiency, reduces energy consumption, and lowers the risk of flooding during storm events. • LoRa-Based Sensor Expansion: The Motorola MC -Edge RTU can be configured as a LoRa gateway, allowing the future addition of low - power, long-range sensors such as water level, rainfall, or environmental monitors. Data from these sensors can be visualized in the SCADA system or used to trigger automated control actions. C. Integration with Enterprise Applications The proposed SCADA solution supports robust integration with enterprise and cloud -based applications. VTScada's open architecture and native APIs enable seamless connectivity with systems such as: • GIS • CMMS • CRM • Storm event dashboards • Hydrology and hydraulic modeling tools • Non -Revenue Water (NRW) platforms • ERP systems Star Controls has extensive and proven experience integrating SCADA systems with enterprise applications, enabling municipalities to leverage operational data for asset management, planning, analytics, and real-time decision support. 60 STARCONTROLS IMPLEMENTATION, TESTING, AND TRAINING City of Miami RFP No. 2046386 After careful review of the City of Miami's project requirements, Star Controls' professional engineering staff has developed a structured and proven approach for the implementation, testing, and training of the proposed SCADA and telemetry system. Our methodology is based on extensive experience delivering SCADA solutions for stormwater, water, and wastewater environments and emphasizes minimal operational disruption, system reliability, cybersecurity, and long-term maintainability. 1. Installation and Startup A. Installation Approach with Minimal Disruption Star Controls will implement the SCADA and telemetry system using a phased and carefully sequenced installation strategy designed to minimize disruption to ongoing pump station operations. Key elements of this approach include: • Close coordination with City operations, IT, and maintenance staff prior to field activities • Detailed discovery and design to fully understand existing infrastructure, operational procedures, and constraints • Parallel system operation where feasible, allowing new components to be installed, configured, and tested without interrupting existing control and monitoring functions • Off -site configuration and pre -testing of SCADA software, RTU applications, and communications prior to deployment • On -site work scheduled to avoid critical operational periods and storm -sensitive windows Installation activities include RTU and field device installation, panel refurbishment or replacement as required, communications setup, and SCADA deployment on City -provided servers and workstations. All work is performed under direct supervision of a dedicated Project Manager to ensure adherence to safety, quality, and schedule requirements. B. Validation of Connectivity and Functionality Prior to system acceptance, Star Controls will validate full connectivity and functionality across all remote sites through a structured verification process that includes: • Confirmation of secure communications between each RTU and the central SCADA system • Verification of data polling, alarm reporting, and site -to -site communications • End -to -end testing of monitoring and control functions for pumps, sensors, generators, and associated equipment • Review of data accuracy, responsiveness, and redundancy mechanisms This validation process ensures that all sites are fully operational, securely connected, and performing as designed before acceptance testing. 2. Testing and Commissioning A. Factory Acceptance Testing (FAT), System Acceptance Testing (SAT), and Commissioning 61 /'1, STARCONTROLS City of Miami RFP No. 2046386 Star Controls utilizes a comprehensive testing and commissioning methodology to ensure system performance and reliability. This includes: • Factory Acceptance Testing (FAT): A witnessed "dry -run" lab test where the City can observe and evaluate system functionality prior to field installation. During FAT, simulated field conditions are used to validate logic, communications, alarms, displays, and reporting. • System Acceptance Testing (SAT): Following installation, Star Controls conducts a formal Site Acceptance Test jointly with City representatives. The SAT is performed in accordance with an approved Acceptance Test Plan (ATP) and verifies that all hardware, software, and communications components are installed correctly and operating as intended. • Commissioning: Final commissioning includes burn -in testing, operational validation under real conditions, and confirmation that all acceptance criteria have been met. B. Calibration and Data Verification Calibration and verification procedures are applied to ensure the accuracy and reliability of operational data, including: • Verification and calibration of wet well level sensors, flow meters, and pump runtime data • Validation of analog and digital I/O scaling within the RTUs and SCADA system • Cross-checking of field readings against SCADA values • Documentation of calibration results as part of final acceptance records This process ensures that all reported data is accurate, consistent, and suitable for operational decision - making and reporting. 3. Training and Documentation A. Training Program for City Personnel Star Controls provides comprehensive training tailored to City of Miami personnel, with content designed to support both daily operations and long-term system maintenance. Training includes: • SCADA System Overview: Architecture, system components, communications, and cybersecurity concepts • Operator Training: Hands-on instruction covering navigation, monitoring, alarms, trends, reports, and storm event response • Maintenance and Administrative Training: System configuration, troubleshooting, diagnostics, backups, and system updates Training is delivered through a combination of on -site, hands-on sessions, virtual instruction, and written manuals. Refresher training and follow-up sessions are available as needed to reinforce knowledge and support staff turnover or system expansion. 62 STARCONTROLS City of Miami RFP No. 2046386 Documentation Final documentation provided to the City includes: • System and owner's manuals • As -built drawings and configuration records • Completed and signed SAT and quality control checklists • Equipment inventory with asset identifiers and serial numbers • Warranty documentation and manufacturer manuals Project Management and Coordination A dedicated Project Manager will oversee the project from Notice to Proceed through final acceptance. The Project Manager will ensure transparent communication, coordinated scheduling, stakeholder alignment, and timely delivery of all milestones. Star Controls' project management methodology emphasizes risk mitigation, quality control, and adherence to City requirements and standards. 63 STARCONTROLS SUPPORT, MAINTENANCE & CYBERSECURITY 1. Ongoing Support City of Miami RFP No. 2046386 A. Warranty, Remote Support, and Preventative Maintenance Star Controls Maintenance and Support Program Star Controls provides comprehensive warranty, maintenance, and support services designed to ensure long- term reliability, availability, and performance of the City's SCADA system. Services are scalable and tailored to the City of Miami's operational requirements and budget. With regional offices in Coral Springs, West Palm Beach, and Lakeland, Florida, Star Controls offers rapid response, local expertise, and sustained lifecycle support for SCADA systems. Our staff includes highly qualified, certified engineers and technicians, and in many cases, original equipment manufacturers rely on Star Controls to support their installed systems. Star Controls has decades of experience supporting stormwater, flood control, and mission -critical municipal infrastructure, including storm -related and emergency response scenarios. Key support features include: • Remote monitoring and diagnostics • Preventative maintenance and system health checks • Firmware and software support • Lifecycle extension and system optimization • Optional annual or on -demand support agreements Our Cloud SCADA environment operates from three geographically diverse data centers with triple redundancy, ensuring continuous availability during storms or major events. Motorola RTUs used in the system are purpose-built for mission -critical applications and provide: • High availability and resiliency • Redundant and peer -to -peer communications between sites • Remote diagnostics and over -the -air programming • Embedded diagnostic tools for proactive and predictive maintenance B. Typical Response Times and Incident Handling Tiered Support and Escalation Model Star Controls utilizes a structured three-tier support model to minimize Mean Time to Repair (MTTR) and maximize system availability. Tier 1— Detection and Initial Response • Incident detection via: o City staff reporting through Star Controls' support center and ticketing system o Automated system diagnostics identifying failures or performance degradation • Initial troubleshooting performed remotely Tier 2 — Maintenance and Engineering Specialists • Escalation occurs if Tier 1 resolution is unsuccessful • Engineers and technicians trained specifically on the City's SCADA system • Secure remote access enables rapid diagnosis and corrective action • Focus on restoring operational functionality as quickly as possible Tier 3 — Core SCADA Engineering Team • Escalation for complex or systemic issues • Senior SCADA architects and software engineers with extensive design and lifecycle experience • World -class expertise in mission -critical SCADA systems 64 /'1, STARCONTROLS City of Miami RFP No. 2046386 Secure remote access for Tier 2 and Tier 3 teams significantly reduces downtime and improves response efficiency. Response Times • Urgent / Unscheduled Support (Critical Operations Impacted): o Typical response time: 2-5 hours, depending on contract terms and resource availability o Examples: telemetry outages, RTU failures, storm -related incidents 0 • Scheduled / Non -Urgent Support: o Minimum one -week notice o Used for system improvements, tuning, or planned maintenance Preventative and Proactive Support Star Controls provides scheduled remote "health -check" sessions to identify early signs of degradation and reduce the likelihood of unplanned outages. Findings are documented and shared with the City. Support Request Procedures • Email: support@star-controls.com • Phone: 1-954-604-6656 ext. 3 • Urgent incidents are escalated immediately, with temporary mitigation implemented, if necessary, before transitioning to permanent resolution. Training and Educational Services Star Controls provides comprehensive training and educational services delivered by experienced engineers and instructors with deep SCADA and telecommunications expertise. Training ensures City personnel are fully prepared to operate, maintain, and troubleshoot the system throughout its lifecycle. Please refer to additional information in the Appendix: • StarSupport 65 /'1, STARCONTROLS 2. Cybersecurity Star Controls is a recognized leader in SCADA cybersecurity and applies a holistic, defense -in-depth approach to protect storm pump station controls and data. Every component of the proposed system —from field devices to backend infrastructure —is designed with cybersecurity as a core requirement. City of Miami RFP No. 2046386 Holistic Approach for Cyber Security SCADA Remote Site Wireless Communication Device STARCONTROLS Cloud Server R Your Global IIoT, SCADA, & Cyber Security Partner a. Protection of Storm Pump Station Controls and Data Motorola RTU Cybersecurity The Motorola RTU is uniquely designed with built-in cybersecurity features that comply with guidance published by the Cybersecurity and Infrastructure Security Agency (CISA). Unlike many PLCs and RTUs commonly identified in ICS vulnerability advisories, Motorola RTUs incorporate security controls at the field - device level, significantly reducing system exposure. A. Network Segmentation The system architecture enforces strict segmentation between user interfaces, control functions, and field communications: 1. Front -End / Backend Separation o Cloud platform is used only for visualization and user interaction o All command, control, and device communications are handled by backend services in a secure datacenter o Pump station controls are never directly exposed to the public internet 2. Private Network Connectivity (Private APN) o All RTUs and field devices operate on a private carrier network o Devices are not publicly routable or internet-accessible 66 STARCONTROLS City of Miami RFP No. 2046386 o Prevents external scanning, probing, and unauthorized access attempts 3. Controlled Access Path o User actions flow through backend command/control services o Security policies and validation checks are enforced before any command is issued 4. Attack Surface Reduction o Segmentation prevents lateral movement o A compromise of the user interface does not grant direct access to control networks B. Password and User Management Star Controls enforces strong identity and access management controls: • Unique username and password per user • Mandatory multi -factor authentication (MFA) using Time -Based One -Time Passwords (TOTP) • Centralized authentication and authorization through backend services • Full accountability and traceability of user actions These controls significantly reduce risks associated with: • Credential theft • Phishing attacks • Password reuse • Brute -force attempts C. Encryption of Data in Transit and at Rest Data in Transit • RTU communications use AES-256-bit encryption with managed encryption keys • Private APN further protects communications by keeping traffic off public networks • Encrypted communications ensure confidentiality and integrity even if traffic is intercepted Data at Rest • Operational and control data is stored in the secure backend datacenter environment • Critical data is isolated from public -facing systems • Backend storage supports restricted access, auditing, and protected data handling Summary Through layered security architecture, strict network segmentation, strong identity controls, and robust encryption, Star Controls delivers a secure, resilient SCADA system designed to protect the City of Miami's storm pump station infrastructure against evolving cyber threats while maintaining operational reliability during normal and emergency conditions. Please refer to additional information in the Appendix: • Star Controls Cyber Security Brochure 67 STARCONTROLS SCHEDULE AND RISK MITIGATION City of Miami RFP No. 2046386 1. Proposed Project Timeline Star Controls proposes the following timeline to ensure a successful project delivery from kickoff through final acceptance. This schedule reflects our experience in SCADA and instrumentation projects and incorporates all key milestones, tasks, and dependencies. Duration of Implementation: • Base for All Stations (A) — 7-8 months • Optional Work for 3 Indoor Stations (B) —1 month • Optional Work for 9 Outdoor Stations (C) - 1 month The following table includes the main tasks. Task Description NTP Notice to Proceed Discovery and Design Kickoff Meeting During the initial project meeting the following objectives and procedures will be discussed and set: • Stakeholders and tasks owners' identification • Administration and logistics • Project schedule and milestones Detailed Discovery • Comprehensive review and survey infrastructure • Interview users and administrators regarding current and future operation of the system. • Examination of the current system, detailing all current operational schemes and aspects (procedures, limitations, problems, SOPs, screen design and navigation settings, etc.) • Getting user input from stakeholders, including current restrictions and lacking features of the current system and improvement requests and considerations • Getting IT input on the City's IT Policies and procedures, including for Cyber Security Detailed Design Document Star Controls staff will publish a detailed design document based on the information gathered in the discovery, combined with all the capabilities of SCADA and RTUs. The document highlights are following: • SCADA's development priorities • Required system hardware and network configuration. • Schedule, Database, tag naming conventions, • Screens, logic, etc. • Interface between VTScada and the RTUs with respect to connectivity, addressing, and alike. 68 STARCONTROLS City of Miami RFP No. 2046386 Task Description • System Security aspects • Alarm management and escalation policy. • Acceptance test plan and procedures (ATP) Detailed Design Presentation Following the submittal of the Detailed Design document, Star controls staff will present and discuss onsite the document details. During this meeting, all questions and concerns will be addressed. Design and ATP Submittals Official Detailed Design and Acceptance Document Submittals Approved Detailed Design Owner will approve the submittals New Hardware and Network setup Star Controls will purchase, and setup all new electrical, computation and network hardware as described in the detailed design document Install RTUs and Field Devices Install RTUs, refurbish or replace pump control panels at the Pump Station and Measurement sites Factory Acceptance Test (FAT) Test procedure where the customer has the opportunity to provide feedback, so changes and improvements will be implemented. Sites Acceptance Tests Individual Site Acceptance Tests System Acceptance Test (SAT) System Acceptance Test Training Training will include instruction on the following subjects: • SCADA system overview and general features • SCADA system operator training • SCADA system maintenance training Final Documentation Final Documentation will include system and owner's manual Commissioning System handover to the Owner 69 /'1, STARCONTROLS City of Miami RFP No. 2046386 Process Flow Diagrams The sample diagram illustrates tasks typically and generally involved in the system integration process, and a graphical work schedule — one of the tools used by Star Controls for project task/time management. Customer Requirements Site Survey Program Design Engineering and SOW Implementation Engineering Order Processing Project Documentation As built drawings Installation Books Manufacturing And Product Sourcing Customer System Center Field Support Installation and System Test Planning System Test Inspection Consolidation Shipping Installation Optimization Acceptance Warranty Training Maintenance System Design Implementation of System To Contract Specifications Customer Support 70 Name 1 DTP 2 @Discovery and Design 3 Detailed Discovery of Existing System 4 Detailed Design 5 Progress Presentation 6 Design Submittals 7 Approved Detailed Design 8 Order NEW SCADA Equipment 9 ElDevelopment (SCADA / Network) 10 Develop Srada 11 Develop PLC programs 12 Lab Testing 13 @Installation / lmpelementatlon 14 Riverview 15 Lawrence 16 Orange Dotal 17 Belle Meade 18 Brlckell Avenue Duration Start 0 days 2/2/26, 8:00AM 57 days 2/2/26, 8:00AM 20 days 2/2/26, 8:00 AM 20 days 3/2/26, 8:00 AM 1 day 3/30/26, 8:00 AM 1 day 3/31/26, 8:00AM 15 days 4/1/26, 8:00AM 40 days 4/22/26, 8:00AM 35 days 4/22/26, 8:00 AM 21 days 4/22/26, 8:00 AM 21 days 4/22/26, 8:00AM 14 days 5/21/26, 8:00 AM 511 Any, 6/17/26, 8:00 AM 4 days 6/17/26, 8:00 AM 4 days 6/23/26, 8:00AM 4 days 6/29/26, 8:00AM 4 days 7/3/26, 8:OOAM 4 days 7/9/26, 8:00AM 19 Mary Brlckell 20 San Marco 21 Antonio Macao 22 West End No. 1 23 West End No. 2 24 West End No. 3 25 West End No. 4 26 ptonnal Testing 27 System Test 28 system Acceptant Test 29 @System Training 30 Training Session 1 31 Management 32 Training Session 11 4 days 7/ 15/26, 8:00AM 4 days 7/21/26, 8:00AM 4 days, 7/27/26, 8:00AM 4 days17/31/26, 8:00AM 4 days'8/6/26, 8:00AM 4 days 8/12/26, 8:00AM Finish 2/2/26, 8:00AM 4/21/26, 5:00PM 2/27/26, 5:00PM 3/27/26, 5:00PM 3/30/26, 5:OOPM 3/31/26, 5:00PM 4/21/26, 5:00PM 6/16/26, 5:00PM 6/9/26, 5:00 PM 5/20/26, 5:00PM 5/20/26, 5:00PM 6/9/26, 5:00PM 9/4/26, 5:00 PM 6/22/26, 5:OOPM 6/26/26, 5:00 PM 7/2/26, 5:OOPM i7/8/26, 5:OOPM 17/14/26, 5:00PM 4 days 8/18/26, 8:00AM 10 days 8/24/ 26, 8:00 AM 5 days 8/24/26, 8.00 AM 5 days 8/31/26, 8:00 AM 25 days 9/7/26, 8:00AM 3 days 9/7/26, 8:00 AM 11 days 9/ 10/26, 8:00 AM 11 days 9/25/26, 8:00AM 7/20/26, 5:00PM 7/24/26, 5:OOPM 7/30/26, 5:00PM 8/5/26, 5:00PM 8/11/26, 5:00PM 8/17/26, 5:00PM 8/21/26, 5:00PM 9/4/26, 5:00 PM 8/28/26, 5.00PM 9/4/26, 5:00PM 10/9/26, 5:OOPM 9/9/26, 5:00PM 9/24/26, 5:00PM 10/9/26, 5:00PM 5 01 o J15 l72 o I15 Feb 2026 Ms. 2026 Project Timeline (FOR REFERENCE ONLY) 98£9170Z '0N d IH ! W P! W 40 Al! j STARCONTROLS City of Miami RFP No. 2046386 TASK Days Start End NTP 0 2/2/26 2/2/26 Discovery and Design 57 2/2/26 4/21/26 Detailed Discovery of Existing System 20 2/2/26 2/27/26 Detailed Design 20 3/2/26 3/27/26 Progress Presentation 1 3/30/26 3/30/26 Design Submittals 1 3/31/26 3/31/26 Approved Detailed Design 15 4/1/26 4/21/26 Order NEW SCADA Equipment 40 4/22/26 6/16/26 Development (SCADA / Network) 35 4/22/26 6/9/26 Develop SCADA 21 4/22/26 5/20/26 Develop PLC programs 21 4/22/26 5/20/26 Lab Testing 14 5/21/26 6/9/26 Installation / Implementation 58 6/17/26 9/4/26 Riverview 4 6/17/26 6/22/26 Lawrence 4 6/23/26 6/26/26 Orange Bowl 4 6/29/26 7/2/26 Belle Meade 4 7/3/26 7/8/26 Brickell Avenue 4 7/9/26 7/14/26 Mary Brickell 4 7/15/26 7/20/26 San Marco 4 7/21/26 7/24/26 Antonio Maceo 4 7/27/26 7/30/26 West End No. 1 4 7/31/26 8/5/26 West End No. 2 4 8/6/26 8/11/26 West End No. 3 4 8/12/26 8/17/26 West End No. 4 4 8/18/26 8/21/26 Formal Testing 10 8/24/26 9/4/26 System Test 5 8/24/26 8/28/26 System Acceptant Test 5 8/31/26 9/4/26 System Training 25 9/7/26 10/9/26 Training Session I 3 9/7/26 9/9/26 Management 11 9/10/26 9/24/26 Training Session II 11 9/25/26 10/9/26 72 STARCONTROLS City of Miami RFP No. 2046386 2. Risk Management Strategy for Weather, Equipment, and System Integration As experienced professionals in the SCADA and instrumentation industry, Star Controls has developed proven strategies and day-to-day practices focused on delivering successful projects and maintaining high customer satisfaction. We employ modern project management, quality assurance, and risk management methodologies to ensure on -time project completion while meeting, and often exceeding, system specifications. A dedicated Project Manager will be assigned to this project from kickoff through final acceptance. The Project Manager will coordinate closely with City staff and stakeholders on all aspects of the project, including planning, permitting, equipment procurement, installation, system commissioning, and operator training. Over the years, Star Controls has refined project management procedures specifically designed to identify, mitigate, and manage risks that could impact project schedules, including key risk areas and mitigation strategies, include the following: A. Weather Impacts Many of our projects are executed in regions subject to challenging weather conditions, including Florida's rainy season. As part of the detailed project schedule developed jointly with the City, Star Controls will incorporate schedule contingencies and buffer days to accommodate weather -related delays without impacting overall project completion. B. Equipment Lead Times Upon approval of the detailed design documentation, Star Controls will immediately initiate equipment procurement. Long -lead items will be identified early and, when appropriate, ordered in advance to minimize schedule risk. All equipment will be securely stored and staged to ensure readiness for installation. Notably, even during the post-COVID global electronics supply shortages, Star Controls successfully delivered all projects on time. C. Integration with Existing Infrastructure Star Controls has extensive experience integrating SCADA systems within existing stormwater infrastructure. During the detailed design phase, our engineers will thoroughly review, validate, and test integration points with all existing components to identify and resolve compatibility issues early, thereby minimizing risks during installation and commissioning. 73 STARCONTROLS City of Miami RFP No. 2046386 SECTION 6 - FINANCIAL INFORMATION AND FEE PROPOSAL FORM 74 /', STARCONTROLS A. FINANCIAL CAPABILITIES 1. Financial Capability Documentation City of Miami RFP No. 2046386 Since its inception, Star Controls has maintained a strong and stable financial position. The company possesses solid working capital, enabling us to build and sustain strong relationships with our vendors while fostering confidence in our financial stability among employees and customers. We are also fortunate to maintain long- standing relationships with customers who trust our performance and consistently remit payments on time. Star Controls' financial strength and working capital capacity are demonstrated by the enclosed balance sheets for fiscal years 2023, 2024, and 2025. These statements reflect sufficient liquidity and financial stability to support both project start-up and ongoing operations. Additionally, the company's 2023 and 2024 tax returns confirm consistent business activity and financial continuity. The included bond documentation further evidences Star Controls' financial responsibility and its ability to meet all contractual and bonding requirements for the City of Miami. Exhibit Document Name Coverage Period Purpose / What It Demonstrates Provided F-1 Company Balance Sheets FY 2023, 2024, 2025 Demonstrates financial stability, liquidity, and working capital available to support project start-up and execution ✓ F-2 Company Tax Returns (1st Page Only) Tax Years 2023, 2024 Confirms company revenue, legal entity status, and financial consistency ✓ F-3 Bond Current Demonstrates financial responsibility and capacity to support project obligations ✓ 75 STARCONTROLS City of Miami RFP No. 2046386 Exhibit F-1— Company Balance Sheet (FY 2023) 2:34 PM 01i05126 Accrual Basis STAR CONTROLS, INC. Balance Sheet As of December 31. 2023 ASSETS Current Assets Checking/Savings Citibank Regions Bank Total Checking/Savings Accounts Receivable Accounts Receivable Total Accounts Receivable Other Current Assets Inventory Asset Undeposited Funds Total Other Current Assets Total Current Assets TOTAL ASSETS LIABILITIES & EQUITY Liabilities Current Liabilities Other Current Liabilities LOAN SHAREHOLDERS LOAN Dec 31, 23 591,348.32 316,607.18 937,955.50 212,525.95 212,525.95 25,855.45 2,263.00 28,125.45 1,148,507.90 1,148,607.90 -324.52 -21,151.26 Total Other Current Liabilities-21,475.78 Total Current Liabilities -21,475.78 Long Term Liabilities SBA Loan 127,339.00 Total Long Term Liabilities 127,339.00 Total Liabilities 135,863.22 Equity Opening Bal Equity Retained Earnings Net income 15,003.00 1,069,668.53 -41,923.85 Total Equity 1,042,744.68 TOTAL LIABILITIES & EQUITY 1,148,607.90 Page 1 76 STARCONTROLS City of Miami RFP No. 2046386 Exhibit F-1— Company Balance Sheet (FY 2024) 2:34PM 01105t26 Accrual Basis STAR CONTROLS, INC. Balance Sheet As of December 31, 2Q24 ASSETS Current Assets Checking1Savings Citibank Regions Bank Total Checking/Savings Accounts Receivable Accounts Receivable Total Accounts Receivable Other Current Assets Inventory Asset Undeposited Funds Total Other Current Assets Total Current Assets TOTAL ASSETS LIABILITIES & EQUITY Liabilities Current Liabilities Other Current Liabilities LOAN SHAREHOLDERS LOAN Dec 31,24 523,060.21 405,013.36 928,073.57 901,794.10 501,794.10 25,865.45 2,263.00 28,126.45 1,757,994.12 1,757,994.12 -324.52 -21,151.26 Total Other Current Liabilities-21,475.78 Total Current Liabilities -21,475.78 Long Term Liabilities SBA Loan 118,567.00 Total Long Term Liabilities 118,567.00 Total Liabilities 97,091.22 Equity Opening Bal Equity Retained Earnings Net Income 15,003.00 1,027,744.68 518,155.22 Total Equity 1,560,902.90 TOTAL LIABILITIES 8 EQUITY 1,757,994.12 Page 1 77 STARCONTROLS City of Miami RFP No. 2046386 Exhibit F-1— Company Balance Sheet (FY 2025) 2:35 PM 91/05126 Accrual Basis STAR CONTROLS. INC. Balance Sheet As of December 31. 2025 Dec 31, 25 ASSETS Current Assets Checking/Savings Cash on Hand-7,000.00 Citibank 502,767.96 Regions Bank Total CheckingfSavings Accounts Receivable Accounts Receivable Total Accounts Receivable Other Current Assets Inventory Asset Undeposited Funds Total Other Current Assets Total Current Assets TOTAL ASSETS LIABILITIES & EQUITY Liabilities Current Liabilities Other Current Liabilities LOAN SHAREHOLDERS LOAN 449,948.88 945,716.84 391,349.85 391,349.85 64,286.45 16,839.70 81,126.15 1,418,192.84 1,418,192.84 -324.52 -21,151.26 Total Other Current Liabilities-21,475.78 Total Current Liabilities-21,475.78 Long Term Liabilities RAM Van 2021 Loan SBA Loan 30,983.61 109,795.00 Total Long Term Liabilities 140,77E1.61 Total Liabilities 119,302.83 Page 1 78 STARCONTROLS Exhibit F-2 — Company Tax Return (1st Page, 2023) =arrn 112O- apartment at the Tre3stry :rierrat Revenue SEnice Q.I.S. Income Tax Return for an S Corporation Do not fife 41ris form unless the corporation has filed or is attaching Form 2553 to elect to bean S corporation. Go to www.irs-g{w/Forrmf f2OS for instructions and the latest intomtatlort. City of Miami RFP No. 2046386 CMS No. 1545-0123 '7 For calendar year 2022 or tax ear r _ r€rr.in A S Eie tIm effective date 03/12/2005 B E+Jsneas activity code number {see Inslructlan5l C Check aSch. kl-3 a:ndlel ❑ , 2022, and in ■ . 20 TYPE OR PRINT Name STAR CONTROL, INC. ',P.:mbar. street End roan ar suite no. n a PA. tax. see nsiructIms- 11555 HERON BAY BLVD. #17 cry ar tarn, state cr province. aurrry, and ZJP or foreign postal code CORAL SPRINGS FL 3307E D Employer Idenntlllcatlon number E Date tkccorccraiec 03/12/2005 P Tatal assets (see trstruutams} 3 758,150. G Is the corporation electing to be an S corporation beginning with this tart year? See instructions. ❑ Yes [ l No H Check if: (1) ❑ Final return (2 ❑ Name change (3) ❑ Address change (4) ❑ Amended return (5) ❑ S election termination Enter the number of shareholders who were shareholders during any part of the tax year _ 2 J Check if corperatio n: (1} ❑ Aggregated actia'ities for section 465 al -risk purposes (22} ['Grouped activities for section 469 passiue actiuity purposes Cardiac: Include only trade cc busineas income and expenses on lines 1e through 22. See the instructions for more information. tb E 2 — i n Gross receipts or sales 2 ,132 , D4 8. h Less returns and allowano s c 2alance 1 c 2,132,048. 2 Cost of goods sold (attach Form 1125-A) 3 Gross profit. Subtract line 2 from line is 4 Net gain (loss) from Form 4797, line 17 (attach Form 4707) 5 Other income (loss) (sea instructions —attach statement) 6 Total income (loss). Add tides 3 through 5 2 1,123,051. 3 1,008,997. 4 5 6 1,008,997. Cl9tkittidaS (see instructionaforlimiteiiona) 7 Compensation of officers (sae instructions —attach Form 112E-E) 8 Salaries and wages Ijess employment credits) 9 Repairs and maintenance 10 Bad debts 11 Rents 12 Taxes and licenses 13 Interest (sea instructions) 14 Depreciation from Form 4562 not claimed on Fomi 1125-A or elsewhere on return (attach Form 4562) 15 Depletion (1)o not deduct oil and gas depletion ) 16 Advertising 17 Pension. profit haring- etc., plans 18 Employee benefit programs 10 Energy efficient commercial buildings deduction (attach Fame 7205) 20 Other deductions (attach staternent) see Statement: 21 Total deductions. Add lines 7 through 20 22 Ordinary busi Hess income POSS). Slbtract k1e 21 from line 8 7 211,200. 8 361, 6 B 7 - 9 10 11 11,210. 12 52,747. 13 5 , 551. 14 0 . 15 16 17 14,637, 18 19 20 347,690, 21 L, 004,922, 22 4,075. 411 e. cd x r- 23a Excess rat passive incline or LIFO recapture tax (see instructions) - . - 23a 23c b Tax from Sctledule D (Farm 1120-S) 230 c Add lines 23a and 23b (see instructions for additional taxes) 24a Current years estimated tax payments and preceding year's overpayment credited to the current year 24a 24x b Tax deposited with Form 7004 24b c Credit for federal tax paid on fuels ?attach Form 4136) 24c Elective payment election amount Iron Form 3800 24d z Add lines 24a through 24d 25 Estimated tax penalty (sae irrsbuctrons)- Check f Form 2220 is attached 0 26 Amount owed. If line 24z is smaller than the total of lines 23c and 25, enter amount owed . . 27 Overpayment, If line 24z is larger than the total of lines, 23c and 25, enter amount overpaid _ _ 28 Enter amount from lira 27: Created to 2024 estimated tax Refunded - 25 26 27 23 i{il1 Here ..rider penalties of perjury. 1 declare that I nave a arnlnso this return, lra5Jang eccunpanyxg sc ie,JIas aria staternents..ano to detest or my IQlomeow and oeief, It ts rue. tarrect, and complete. Deciareaon of prepar (other than taxpayer) la timed an oillntorrnarixl at which prepare -has any Kncwleoge. 1 PRTZR IDENT Hey the IPS discus fills rehrn Ynvr the preparer s11awn aelovr? .3lgnafJre oT amoer Dam litre see 1 030tiane. ® Yee ❑ rio Paid Peep lCr UseOnly PrInt.Ty.pe prepa'er's -ame Preparers Elgrahre arts 02/15/2024 check Tp aelrarnp rd PTIN :- litm'sECM Phase nu. - F�ITtEriairle Ftrn'n address For Paperwork Reduction Act Notice, see separate instructions. BAA REV @AIBIai can Farm 1120-3 ( 79 STARCONTROLS Exhibit F-2 — Company Tax Return (15t Page, 2024) Form 1 1 Depart/mid or the Treasury Werra! Revenue For Calendar }rear 2024 or A S electior pHerlivn r1;1:1 03/12/2005 B Butineas activiiy code nUrrib !sae rriatruclinnxl COiac— adiachad ❑ U.S. Income Tax Return for an 5 Corporation Do rSol.file this form unless the corpbrdtion has filed or is attaching Form 2553 to elect to be an S corpOratic+n, Go to www,irs.goa'1Fnwn1120$ for instructions and the latest information- City of Miami RFP No. 2046386 Orin P. 1:: Z124 arc ear bec}innin� TYPE PRINT Name STAR CONTROLS INC. 2024, ending ,20 0 Employer identification number Number, 13treat and faint Of suits no. if Af P,p. box, sae irstnac1Iorre, 11555 HERON D?LY BL'VU, k1 f E OMa incorp•ared U3/12.1200 {.ily' of town, s1a1a cr prawnae, Montt)._ and ZIP or foreign posliat code CORAL S PR.I r rL G l''L 3 3 C 7 6 F Traial assess gseo rnairucponel 929 23?- Q le the corporation electing to be an S corperettpn t 0 inning with this tax year? Sea Instructions © yes ® No 11 Check if: (1) in Final return (2). ❑ Name change (3} [] Address change (4) Q Amended return (5) fl 9 elec'ion toYmirretion I Enter the number of shareholders who were shareholders during arty part of ttre tax year .. . .. . 2 .1 Cheek If carporafiom (1} [1 Aggregated actin ties kir secticei 465 a riskswrpeses (2) ❑ Grouped ICY wi lco4159 passive a.ctlY:ty Imposes Caution: Include otaly !rade 04 busineaa lrk:onie and trgAngeS an I,nas la through 22. See the instructions for more Infwma4on, la Gross receipts orsales 3, 1 r 2, 69 13 , I: Less ratans wd allowances c Balance 10 3,162,688. m E — 2 Cost of goods sold (attach Form 1' 25-A) 3 Gross profit. Subtract line 2frortl line lc - - . , - 4 Ne1 gar (loss) iron- Form 4797,. Pan II, line 17 (attach Form 4797) 5 Other inoome,lossj (see instructions- ..attach sial.ement) 4 Tetaf income Pool• Add lines 3 tirotigh 5 . . , 2 1,873,311, 3 1, 285, 377, 4 5 6 1, 28 9, 37 7. 2 ° e .2 1} 2 k g ' -y C] 7 Compensation of officers (see instructions —attach Fi3rfn1125-E) 8 Salaries and wages (less employment credits) 9 Repairs and maintenance . 10 Clad debts 11 Rents 12 Taxes and licenses 13 Interest (sae irretruotion0,= , , , , , , , , , , , , , , , , , , , , , , , , 14 flepreciat:on `rorn Form. 4562 not claimed on Form 1125-A or elsewhere on return (alltadi Form 4562) 15 repletion (do not deduct oil and gas depletion) 18 A'J-'criising 17 Pension,profit-snaring, ntc., plens 18 Employee benefit programs 19 Energy offfoi int COrrirriarCial buildings cleoluottoi (atteoh Form 7206} S 20 Other - ee, S,La,LernenL, , , . .. , , , , 21 Total deductions, .Add I nos 7 1hroJgh 20 22 Ordinary business income {lo ]. Subtract line 21 from line 6 , . . , 7 ..:!0!), :,,.(11).. 5 409,765. 9 69. 10 11 42,174. 12 49,834. 13 3, 3.9. 14 ,. , 15 _ 16 17 i 6, 4 96. 18 19 20 r n7,022, 21 1, 2 35, a 5,8 _ 22 `::7, 11 i r4, 23e Excess not passive income c' LIFO recapture tax {see instructions} . . . 23a 2;3c b Tax from Schedule 0 (Form ` 120-S) 23b 4 c ,Add lines 23a and 23b (see instructions far additional taxes] 24a Current year's estimated at payments and preceding year's overpayment credited ;o the current year 24z Tax deposited w Lb Form Too4 , 1,o ha -b Credit for federal tax ,paid on fuels (attach Form 4135) c 2 d Elective payment election arrlonant fromForm3306 d x I z Add Ines 24a through 24d _ 25 Fstimated tax penally (sae instructions). Check i' Form 222G is attached . _ . . _ . _ , ❑ 26 Amount owed,. If I ne 24z is smaller than the total of I °nes 23c and 25, enter amount owed , , , 27 Overpayment. ff line 24z is larger than the total of line 23c and 25, ente+ amour!. overcall , . , 28 Enter arrrcunt from lire27: Credited to 2026 estimated tax Refunded , 25 28 27 29 sign Unrin, prnalrrrr; of prrp ry I crtdare ihet t have examined This ,eLirn, indudln2 accarnpeni'I°k1t'Scheduler w'i stetemente, end ro the beet of rrrr Iceco,03doe end tinier, it is in.e, cor'ncr, r. .. enrnplae@. Qeelerarrcvl 51 prepare/ roLL1er trrarn laa#ieye j 15 .. - _ 9 an all Inlormeilan of which p. epa rer has erg larawkidpe Here fi r # I. _ I 0 ..N T may Ilxi IRS disc,.1s thin alum xn'h rrn prnp,rcr 5hnr+n hdow? Sgraiure or'rrer Elate - € re i-,FrR,Glinres, ❑i y„, amp Paid 1 Prir,Typi pra°narnr'snomb PrEpanie99nalure Preparer• • 0ate ol / ' 3,'2. :222 3 Chrx:k • 1 Nni"^Rnyed Firrn's EIN - PTiv Use Only ' Phone ro. , _ For Paperwork Reductior Act Notice, see separate Instructions, BAA Cat, fro, 1 rtr10H r v aiaiaa5 Prep Forri 1120-512C2,1, 80 STARCONTROLS City of Miami RFP No. 2046386 Exhibit F-3 — Bond Documentation Document A310 TM — 2010 Conforms with The American Inatltute 01Ar0110ee% AIA Dacurneni 310. Bid Bond CONTRACTOR: SURETY: attar., ie hdimata vg'JoJeraittaY) r2ilrftv, i grade nn/s rargprhaelpdri place of FruPrre_c) StarCantro's, Enc. 14 555 'Heron Bays Boulevard, Suite 200 Coral Springs, FL 33076 OWNER: Vivre. & RI Vales wed rr, < fruss,t City of Miami 444 SW 2nd Ave, 6th Floor Miami, FL 33130 iOONDAMOUNT: S 5% The Ohio Casualty Insurance Company 175 Berkeley Street Boston, MA 4i2110 Flue Percent of Arrurit bid ThLS4fiOumanthos importan3. ragas camsaQutades. Ccnisuitn0417 with an attorney Is envoi raged w th rasnnct to its caeipletIon a r rrenlIftato i. Any syl;lo r relafasnee io Contractor. Smetr, O5r.B r ar Ohm!' party shall bn can Sld6a[i plu'al wtiarip atppt;ctblu, PROJECT: {a re , fort!tion* Ilrrdrwii'r rCtni#06.'►: ‘ritoat RFP Number 2046386, Storm Pump Station Telemetry and Supervisory Control. and Data ("SCAi7A") Syaiern Tlx: Con!rsc1o; add Sumty o:c heater! rn 1Ei ()mnt!.rin I1Lc anMt i i set fortis uboa , fori1La payment o$uliich the Coritcfcloeand SIttr�n�t bind !hear! ae1 gee., tlu r I',oi rs, egee.rrors, ail mirii srrs1ors, sitowssofs sited somas, }oindlystrtd as provided here iai. The ccridiilomi o. i11j4 Bond _sa .fil ch I I i I if the i .r ece epee the bid of lie Contractor wilirio ijlc time S ified in are hid dpati neiiL . r wj!11 izi Sach einux period 09 :i y be ;,Frccd 10 bF ilic Ut r.cr and Coo actor, altd [be Coti raotettiltrer (I) enters into a con[rr-el wi I!s the C In arcop ce will: IlleIerInsof5L:' Ibid. avidpiti'asSIN IiIxa=idorbondsitraw be.specified inthe biddieflafeontrr.et Documents, with osurety A pipcdta IIIc jurisdic1?on of no Projcst aed orhe.,s+ise seerplpbleto IIl4Owner for the lhilbful pe7forirranca e+fsuelr C'aal.ract aid for the prompt pLyr:iciI;UL10 nit.terial Ctizai5h{d orostotrion thereof-, or {2) pays to dcoOVIIINT thc di fre mime. aat ca esresed Item lee of i11i9 Irlorid, !NMI `li® hni,ur,t slice ifiici` 1t:.Aid t,id oud suck larger ammo too srllisti tlroO+ itsrtnoy ri go d falihcomma voltit rowdier Noy Hi perthrl:l Ll:ia work canted by raid b: il, Cirri Chi s nta i gua iw add Sac nun trod void.. ok lerirsise lu rv-ripen in fall rove and ellixt, Tbc :Arehe,cby+taiyes zinysisaikcetsfai>cgreen:e1II 1v iiFII:eOwnerem/JCaolraelostrte0tktlrltiro1in;e in which Llie Owner no*. accept the hid. *a:1.cr a f r:itLL% by sho fiurety shall not apply Ln ai;4' c%ree:¢nl1 mewling sixty () days ill Ibc aggregate bc) urad IRIe time far cceepLu Ilex tiL bills pacified In ihe bid drleulrhentit, And {I' c orgicr and Cusitiuebte SIffiII ellbtoiin Illo iuredy's consent Iur an escansli i 11 beyond ,isay I .DJ Jut:_ rthis liond is isxited in tonnttiion with a sub:lc:rlrsara', 's hits lg a Caulrpislct, t11ie tonic Com :Treeeor Lai Ihia<Bosud shall be decr•.icd to be SLbtonln CterOrld the sr an OwnerSIs]!I be decrard "a be Caritrscla;. R7i;.v i !six 1401111 ha% h -r ;si n':iSked Ln G un ply 1 ILn ' Li; OLII rr Ipkip1 reridoomoot in Ito Iricpti nii ri F' di 1'rr^js.L c i:y pLT>'vi i i in Lhis Ill:End cunllicling sa lh girl L.il:cuiar)' sir legs` nap:rein rot sho! i bC devised dekleo F ecelftnnl rtld nnI%'iai1Ln crank: n 1 i ni3 [n Noah KLaiu11iary or :}Lkar I14a1 requi;e:milt 5ba1=. be rice aced i:iearrttii:,Lrki lies hs. diet so furaishelb Umituanliu dm1. ibis Plural Asa l be construed am a a:IULc y hiwth andlxlL us a cIrI1n1,nw kw kind, Sig aid and scaled ibis 9th d.» of January. 2026 erlruaso Star Controls, Inc. rPolnerpoU By: The Ohio Ca -id ally insurance Company By, (Tide Jarrett Merlocci Att may-i r-FAct Surety Phone No. 617-357-9500 81 STARCONTROLS City of Miami RFP No. 2046386 Libe Mutual. SURETY POWER OF ATTORNEY Liberty Mutual Insurance Company The OI o Casuualty hristurante Camparry West American insurance Company Celt* fkI 421437111454011 KMQWN ALL PER$CN$ ev TI M PRt ENTS: Pad The <Oa Cwa.aety teadreiwce Comply I a raare5nn deny esseeteed alder de lass of the Stale of Nary Asses roe, trot Lteaty *Arai irarrarre Company is a corporation diek.rnigariaed ederthe law dthe %He of Almaden.", awl Vile51sew lemon Ciampefir a a mown* * ddy el mod [An the hews of the Stele et %Moe (Ners cot winery Mal the mil, pursue to a nJ a .e.he,Nir ail. KICK lam semi, ecelsftetiaed wan, SIR sees A tiurrnrl. Derrid R HeoYer. Ja wn Meriul:I:r, L7tprki. tP HrIsIxS, 41=1 l Nrdslara el cl the : ty c` Waal Lakes stele of FL cob ynllrl ieely J store fe male than [xmewned its trunve d rase hri altpneyrovraet Somas* [7iKJIE sea . edtr i I d'ge EM1-160, ix end 011411 WWI es suety iind se ie.screed and, say pedal w eentsernes, trues, more ram and alter Newly oblI5l no, In wawa cf ,hese p users and snail Ira ass kiafieg wan the Cagreperliee es d theybare hale wt13y Wei by he presidell seed awed by 'Iie tr::LLa•p of the C44154 res if' Nil oral VW persons IN WITHES& WHEREOF, ibis Paw& all Alienrey urea beer eutorrrred ay a3 out iargad Ace( ail uticaar at Ere Commies and file corporate seals, of the Competes base beim alizi O thereladls 74ata deya1 March _ S4atleofPERM LVAM is Ceara. of MONTG MER`r' SOS I4t day el h/arZh , Z S WOO Aheger3ortel ippsred NitieJ ZergMlawhr adcrvwIcdc ad hirrsell 10nedra.+4ssslam So:celeryalMalty lArYa91beware* t nyr tie 0No casualty Calawrvilirsiet Aroma loathers Company, and that he, as siu;1 l Id so l dos amide Ilse lc edanrq Wearied eml ke me wows t onerieeisd by skang Gal bwMalfd lbw owporaiea4 by Nolan a! ah etrfrigAlIciixei Gam#.. w WITNESS **REV, Phthetarowlosoltholmodiroynentand eliews try mime sell see P nn s Irh Urry. Ir5 341nli, sew tie day and year Aral mein Jr rYv The Pew of Aeons* es shade 144 salaried parw4Ve1 to and by arks* of the foams% Wawa and of The Ohio asuxlty ravor[o Ca-tpon talxrty Mutual ngyreircte Comma, we Wart tracker t eererceGoneonfrvrldch naalulwe we low in Yi form eel fillet ram es fall: MISCUE Ail- ORM& liana 12. Pulsar of Niamey. Any slim ail ei lie entail el t►s Oarptstaliall err[waezed ler tht purpose n waiI% by be Chaimwea El the lareeident, and sages In Bath antenna es To Uhlman or Ere Prera:Brrt nay' praemrLk eppornt a .8410149s41•14.0.re .haq be awl lG sick ell 1lf loll (if Mot Couwnel4n to weak wawa. WIC 110550454.Ed ': a ue OW NSW* may end et undedelungs, bomb, osougnizancee and eta. aunty eahiprliurec Sorb etgpmrfyeani ok Ritleor le die lialetiens ill lotto to Ikea ehlpeerke paAErs of atwmey ShM tone id pgeer Id hard the 0erpealbeby trei djaahne wild w eoatei d easy wend Its and to WW1 look. ttte seal of the CeryaraiW,. rAr _a so eeeoutet su tI Womb *el be 94 blaadrip m i aigi lid byt flee President end Legend le toy the Sicrel cy, Any pow er eirlaeily 9I Hided to my repiSweleav a cr nib r rey.in-4itl Mkt Rut pr 44110 tt d tors aids meyr bcritockedstwOrmbytalBoaNI,ite C.heirwrtenk tie Prew+Awrn el, by the acrl a cf utas '::7;ra sod pent eA eu!hLr~;. ARTICLE if ll - Eseeiadei et Corked* Sawn 5. Gunny Bonds end lJabrtd ietie. My Ads of Po Copan iartrnrttod rya fiat pnrppye it winee tar re demon Or #m irGddlait sad Mewl t0 era kmilahora Ee the ri4bn a7 cc RA prewen$ nary ,preswee, St MI Bp icui MA dtbevirrylbgact as ray be elem erri Is el N WO 01 be Cm wy to mere, esearile, swot eakeowasen. end 016ser as, admit' alp and 111 wieerksinvis, bends. reragrezenceo MO oiler m ely e4lgabwna, Such elloneris-Mesi wbSeri b the Weems ms 34 milts it N oir reapesbee poem e1 ewamer•, lie tilt porter b bled pa I_rxperr f by Ober *ewe and esanike Or ley sods'oadworks aid to Old iherstd Ire abe of the Carlini+. Usti so oirmih1,1 ilr I irate** steel ho es t as named ray to instant and *Peeled by Ooseersb . Certificate al DesiQnaUun - The President of the Company. acing purwucr5 tip 'tee Wins of Mae Company. aebistro Nathan J. 2arywte kietetanl Swan to awed welt ellornois-in-Pea me Islay be riressery 9r, xi on bead of the CseaoarrY o realm gavot soot, asknossoppo ail+ cam afs4 sr rev arty sne a1 uMrde14enage, berhls, ass an ! ctlaa sareeyaltievellan. nuthnrithitieal - I*UIW dos cowl' ei ire Coo~ Omelet MCI" Ure Doiaerry mnaenls whet leaaumlei r rredsannaly eepradated spieler! er! deny eesiennal secretary mitre Company. akrbe■eaar appearing upon a oirfirael for hny purger of seamy issued by toe Cxerrep ail see con n#cn rrfh g,rr5ty bendy, a hell he reed arid binding upon the Cf rtpany sit the same lerCe and Oriel ire ltiOelb Mew* armed. k Renee C. Wolin the undFreagreld +resltterst Smeary, The Obis Onsaity Mama Csonpewy, Lewly WAN Ingo/mot Company. end Was] kowcai ImriinoeF Connery do hereby califY the lee °tNgine pore( or eteliey of rAairdl Its lerssasgl is i kit he and tarred copotel the Pone* or &aim y &nailed t1y said Cam, he tie Ill Irma and diked end he# neth91wtrwaRled IN TESTIMONY w1rIER: C r I hawa heretrrtc eel ray hand end elided deg scaly ge said C.wripapiee Ode 91yr airy cif miry 026 . V1 17e7S LAIC (lf.' ? WAIt,J elk (2.14 Carrrvmye or Pe mimmli ift -Wirt rroasthaffEMA jA* +rm*tarnsr Uwe ht! rrn.nako0044 WO wain, Copft .1roamrlafMa By: IIPLUeJ .4-0.1.roakrode Ammo oonbir,awe Pastel, *bey Polat novae C L ow& r, +sactart Soactary 82 STARCONTROLS B. SUBMISSION OF PROPSAL FEE FORMS 1. ATTACHMENT C - SCADA AND TELEMETRY SERVICES FEE PROPOSAL A - BASE FOR ALL STATIONS City of Miami RFP No. 2046386 CITYWIDE TELEMETRY AND SCADA IMPROVEMENTS City of Miami BASE WORK, ITEMS TO BE IMPLEMENTED AT ALL 12 PUMP STATIONS Riverview_Lawrence_Orange Bowl_Belle Meade_Brickell Ave_Mary Brickell_San Marco_Antonio Maceo_West End 1_West End 2_West End 3_West End 4 Item # ITEM QTY UNIT PRICE PER STATION (12 STATIONS) UNIT COST TOTAL FOR ALL 12 STATIONS 1 Initial site visit and assessment 12 EACH $666.67 $8,000.00 2 Subscription Fee (annual, recurring, inclusive of all stations) 1 ANNUAL $12,000.00 $12,000.00 3 Design Fee (for all stations) 1 EACH $17,600.00 $17,600.00 4 Mobile app implementation (includes design and installation, inclusive of all stations) 1 EACH $24,000.00 $24,000.00 5 Platform Implementation (includes installation, inclusive of all stations) 1 EACH $7,000.00 $7,000.00 6 New updated RTU in N4X 5S enclosure (includes equipment and installation) 12 EACH $22,691.49 $272,297.85 7 Cellular modems & UPS (includes equipment and installation) - ALREADY INCLUDED IN LINE ITEM 6 12 EACH $0.00 $0.00 8 Start-up, Testing & Training (inclusive of all stations) 1 DAYS $60,000.00 $60,000.00 9 Main Power: (includes equipment and installation) 12 LS $756.67 $9,080.00 A. Main Electric Power Failure B. Main ATS Failure C. ATS Position 10 Generator Monitoring System: (includes equipment and installation) 12 LS $2,485.00 $29,820.00 A. Generator on/off B. Generator Current/Voltage C. Generator Total Harmonic Distortion Sensor D. Generator Controller Position 11 Diesel gauge readings per generator (includes equipment and installation) 12 EACH $1,883.33 $22,600.00 12 Pumps: (includes equipment and installation) 12 EACH $2,323.33 $27,880.00 A. Pumps on/off B. Water Level 83 STARCONTROLS City of Miami RFP No. 2046386 C. Hours of Operation D. Pumps Position (Auto/Off/On/Manual/Trip/Fault) 13 Door Sensor (includes equipment and installation) 12 EACH $376.67 $4,520.00 SUB TOTAL 1 SUBTOTAL 1 $494,798 14 MOBILIZATION/DEMOBILIZATION I 12 I EACH $5,996 $71,955.00 SUB -TOTAL SUBTOTAL 2 2 $71,955 TOTAL TOTAL COST COST $566,753 B - OPTIONAL WORK FOR 3 STATION CITYWIDE TELEMETRY AND SCADA IMPROVEMENTS CITY OF MIAMI OPTIONAL WORK, ITEMS TO BE IMPLEMENTED AT 3 PUMP STATIONS Riverview_ Lawrence_ Orange Bowl Item # ITEM QTY UNIT PER STATION (3 STATIONS) UNIT COST TOTAL FOR ALL 3 STATIONS 1 Cameras (includes equipment and installation) - 2 PER STATION 6 EACH $4,053.33 $24,320.00 2 Water Quality (turbidity) (includes equipment and installation) - 2 PER STATION 6 EACH $4,747.50 $28,485.00 3 Rain Gauge (includes equipment and installation) - 2 PER STATION 6 EACH $2,810.00 $16,860.00 4 Miscelleneous Building Equipment: (includes equipment and installation) - 2 PER STATION 6 LS $2,465.00 $14,790.00 A. Barscreen On/Off B. CO2 Retardant System C. Fire System On/Off SUB -TOTAL 1 $84,455 5 MOBILIZATION/DEMOBILIZATION 6 EACH $223 $1,340.00 SUB -TOTAL 2 $1,340 TOTAL COST $85,795 84 STARCONTROLS City of Miami RFP No. 2046386 C - OPTIONAL WORK FOR 9 STATION CITYWIDE CITY OF MIAMI OPTIONAL Belle Meade_Brickell 3_West TELEMETRY AND SCADA IMPROVEMENTS WORK, ITEMS TO BE IMPLEMENTED AT 9 PUMP STATIONS Ave_Mary Brickell_San Marco_Antonio Maceo_West End End 4 1_West End 2_West End z,-- 'Ii''"'''1 Item # L ITEM QTY • UNIT PER STATION (9 STATIONS) UNIT COST TOTAL FOR 9 STATIONS 1 Cameras (1 per station) 9 EACH $4,523.33 $40,710.00 2 Water Quality (turbidity) (1 per station) 9 EACH $4,211.94 $37,907.50 3 Rain Gauge (1 per station) 9 EACH $1,527.78 $13,750.00 SUB -TOTAL 1 $92,368 4 MOBILIZATION/DEMOBILIZATION 9 EACH $162 $1,455.00 SUB -TOTAL 2 1 $1,455 TOTAL COST $93,823 85 STARCONTROLS City of Miami RFP No. 2046386 APPENDIX - Additional Documentation • Case Study by the customer and Motorola • Cloud SCADA Design & Build Success - Story City of Weston, Florida • MC -Edge Datasheet • VTScada Presentation • Motorola-MDLC-Features • MDLC-Reliability • VTScada Alarm Management • VTScada Alarm Notification • VTScada Historian • VTScada Reports • StarSupport • Star Controls Cyber Security Brochure 86 el* THE CITY OF WESTON, FLORIDA STAYING A STEP AHEAD OF THE STORM WITH MOTOROLA SOLUTIONS AND STAR CONTROLS SCADA STORMWATER PUMPING SYSTEM The city of Weston is a master -planned community located in southwestern Broward County, Florida. The city boasts A -rated schools and outstanding public safety with the lowest crime rate per capita in the county. Encompassing 26 square miles and bordering the Everglades National Park, Weston's vibrant, culturally diverse residents and visitors enjoy a thriving outdoor -focused lifestyle. Yet, this area can be subject to extreme weather that can deluge the city with large amounts of water in a short period of time. In an average rainy season, the city can see up to 45 inches of rain, with individual storms capable of dropping 10-15 inches of rain or more over just a few days. To prevent flooding, the city uses an extensive stormwater management system, directing water runoff through a system of catch basins, culverts, retention ponds and pumping stations, which eventually flow to the Everglades. As a city with a population of approximately 70,000, Weston only employs a staff of five technicians to manage its stormwater system, so all operations need to be as efficient and reliable as possible. Yet, its stormwater pumping system was largely based on manual monitoring and operating functions, making it difficult for technicians to manage while also performing their other daily responsibilities. Weston sought a new way to control and automate the system. CUSTOMER PROFILE The City of Weston, Florida INDUSTRY Water Management SOLUTIONS Integrated SCADA IoT Stormwater Pumping System, including: • Motorola Solutions MC -Edge Intelligent IoT Gateway • Motorola Solutions ACE3600 Remote Terminal Unit (RTU) • Star Controls StarCS Cloud SCADA BENEFITS • System automation and remote - control capabilities mean Weston can spend more time on its core mission • Rich data is collected and shared with deep reporting capabilities through an easily accessible web - based portal • Cybersecurity and overall system health is bolstered to comply with CISA's (Cybersecurity and Infrastructure Security Agency) Cybersecurity Practices for Industrial Control Systems CASE STUDY I THE CITY OF WESTON, FLORIDA MOTOROLA SOLUTIONS CHALLENGES MANUAL PUMP MONITORING AND MAINTENANCE MADE SYSTEM OPERATIONS INEFFICIENT Like many cities in South Florida, Weston sits less than 10 feet above sea level, so any excess stormwater can quickly impact the community. That means that the public works department must closely track incoming storms as well as the daily functionality of the city's stormwater pump system. Historically, drainage technicians were assigned to manually check lake levels, clear any blocked drains, and ensure that all water could easily flow. During the rainy season, technicians would conduct these checks every morning and when on high alert, several times throughout the day. Anytime a decision was made to turn on the pumps, someone had to manually drive out to turn them on and then return to base. Then, they had to drive back every eight hours to monitor performance. When it came time to turn the pumps off, the same technicians would have to drive back to manually shut them down. If a moderate or major storm was predicted, monitoring and preparation was even more time consuming, threatening to slow response times when speed was needed most. "When a storm was coming, up to 50% of our technicians' time would be spent managing and monitoring these systems," said Peter Johnson, City of Weston Assistant Director of Public Works. "With the size of our department, that made it more difficult for staff to handle other duties and was simply an inefficient use of their time." A LACK OF QUALITY DATA COMPLICATED DECISION MAKING AND HINDERED DISPLAY OF REAL-TIME INFORMATION Weston's stormwater pump technicians and managers are tasked with making important system decisions daily, including when to start the pumps, how much water to pump, and how long to run the pumps. Yet, Weston would receive very limited actionable data from the system's mostly manual control processes, making it more difficult to make the best, most informed decisions possible. In addition, when the U.S. Army Corps of Engineers would look at the feasibility of new infrastructure projects in or around the city, they would often ask for historical data that was very difficult for Weston to produce. This lack of quality, actionable data was compounded by the fact that the city's ability to share information with residents, such as real-time lake levels was inefficient. "Data from our pumping system was very hard to gather," said Johnson. "And even when we had access to the right data, we didn't have the means to easily share it instantly with the community." CASE STUDY THE CITY OF WESTON, FLORIDA ow ,11111 III 11 IROI 1l■■i1 NMI 11 Inn[ JIIIIi III -1 III MI/■1 III ;IIP . , c !111111111111 inn i rrLcccct ---f." L LUL'UUUL CASE STUDY I THE CITY OF WESTON, FLORIDA WITH RISING REPORTS OF INFRASTRUCTURE BREACHES NATIONWIDE, WESTON WANTED TO DO MORE TO ENSURE CYBERSECURITY AND OVERALL SYSTEM HEALTH While Weston knew it needed to upgrade the control system for its stormwater pumps, it also wanted to ensure that any new system was monitored for overall health and especially protected against cyber breaches, for good reason. According to International City/County Management Association (ICMA) research', local governments are increasingly targeted by cyber criminals and bad actors for five main reasons: The sheer number of American local governments make them a large attractive target. 2. Local governments store considerable amounts of sensitive information, such as names, addresses, driver's license numbers, credit card numbers, social security numbers, and medical information. 3. In recent years, the availability of low cost but effective hacking tools that require little technical knowledge has made it relatively easy to get into the business of cybercrime, thus increasing the number and types of cybercriminals. 4. Local governments often operate under financial constraints that limit their ability to acquire and implement state of the art cybersecurity technology, policies, and practices. 5. As local governments connect infrastructure to the internet it can introduce new cyber risks and vulnerabilities. Knowing these risks, it was important that any solution Weston installed was tested and certified to comply with CISA's (Cybersecurity and Infrastructure Security Agency) Cybersecurity Practices for Industrial Control Systems. It was also important to have a partner that could monitor the system and alert the city to any suspicious activity or issues that could affect the system's overall health. ' https://icma.org/articles/pm-magazine/look-local-government-cybersecurity-2020 SOLUTION The City of Weston chose Star Controls, a Motorola Solutions partner, to design, build, and install a SCADA loT system that could automatically monitor city water levels and control pumping stations to redirect water as necessary. The city also made the decision to migrate its IT and associated applications to the cloud, so its SCADA system needed to be cloud -hosted as well. "The City has progressively moved many of our core software applications into the cloud to benefit from the reduced cybersecurity liabilities. In addition, the cloud provides us the ability to easily access applications from anywhere at any time," technology services director, Ryan Fernandes, stated. "It pained me to see people wasting time and efficiency," said Johnson. "We knew technology was there to save time and effort and we made the decision to move forward with it." The system utilizes the Motorola Solutions MC -Edge Intelligent IoT Gateways and ACE3600 Remote Terminal Units (RTUs) to monitor remote pumping and lake levels, collect data, and remotely control pumps and other equipment. Data collected from the system is forwarded to a cloud -based application which uses measured water levels and other inputs to direct stormwater as necessary. The use of Motorola MDLC protocol allows redundant schemes of communication between the remote sites and cloud -based control centers. In addition, the system includes site security, fire alarms, and intrusion detection. "The Motorola Solutions RTU is the only field controller that can easily act as the integrator for all these pieces," said Tzvi Magril, Star Controls Managing Partner and Co -Founder. "We can develop applications using a common programming language to remotely check on the health of each piece of the system, which is unique to the Motorola Solutions platform." Weston city staff worked closely with Star Controls on the design of its SCADA system using all off the shelf products, with cloud -hosted software. "We chose Star Controls and Motorola Solutions because they made the best suggestions on overall project design and could help us build and maintain a powerful, integrated, and secure system," said Johnson. "Plus, everyone knows Motorola Solutions is an established, trustworthy company" CASE STUDY THE CITY OF WESTON, FLORIDA BENEFITS SYSTEM AUTOMATION AND REMOTE -CONTROL CAPABILITIES MEAN WESTON CAN SPEND MORE TIME ON ITS CORE MISSION WHILE RESPONDING TO STORMS FASTER Today, Weston's entire stormwater pumping system can be remotely monitored and controlled, with the option to run in two modes, an automatic mode based on city water levels and a manual override mode, when needed. With all applications and data hosted in the cloud, it's easy for technicians to see each pump's status and control them remotely, even from a mobile phone or computer browser. "Recently, we had a fast moving, unexpected storm," said Johnson. "In the past, that would have meant a call to a technician in the middle of the night or waiting until morning. This time, we simply turned on two pumps with our mobile phones. When there's a problem or an issue, we can react immediately." During Hurricane Ian, Weston was spared a direct hit but still received 7 inches of rain in one day, further testing the new system. Based on data coming from the system, Weston lowered the lake levels in preparation. "We had a huge jump in confidence knowing we had full control of the system," explained Johnson. "We didn't have to worry if things were working, we could actually monitor everything in real time. Staff were elated that they didn't have to drive to each station to check on pumps since they could manage everything remotely. Technicians were now freed up to do other storm prep and related tasks. We were busy tracking the weather forecast and monitoring the performance of operating pumps. Everything just worked perfectly." Daily monitoring and maintenance is now vastly improved as well. For instance, the pumping system automatically monitors power coming from the local utility, so it knows if power is interrupted and can send alarm when running on backup generators. Fuel levels for diesel operated pumps are also automatically monitored. Remote lake level sensors also provide a clearer picture. Since lakes are connected underground by culverts, it's important to see all adjoining communities to monitor for blockages. When they occur, Weston sends in divers to clear them before the rainy season. Now, they can see the status of the lakes and culverts at all times using color -coded charts viewed remotely through any web browser or at the public works office on a 75-inch display. When there's an issue, automatic alerts are pushed to technicians' cell phones via voice, text and email. We had a huge jump in confidence knowing we had full control of the system... Everything just worked perfectly. - Peter Johnson, City of Weston Assistant Director of Public Works CASE STUDY I THE CITY OF WESTON, FLORIDA EASILY ACCESSIBLE RICH DATA WITH DYNAMIC REPORTING Weston now has access to both detailed, real-time data and rich historical data, whenever needed. For instance, they can see lake levels over time and gauge how the system performed under different scenarios. When the South Florida Water Management District requests specific data, it's easy for staff to quickly pull it using integrated and powerful reporting capabilities that all run in the cloud and can be accessed from any authorized device. "Data collection is a huge benefit to us," said Johnson. "We can respond faster and more comprehensively to specific requests, but just as important, we can learn from past historical data and get better with time." In addition, because all data and applications are hosted in the cloud, Weston can easily share information such as lake levels with the community, straight from their city website. BUILT WITH SECURITY IN MIND Weston's stormwater pumping system relies on the Motorola Solutions MC -Edge Gateway and ACE3600 RTU, each designed to comply with CISA's Cybersecurity Practices for Industrial Control Systems. The Motorola Solutions MC -Edge Gateway also allows integrators to easily develop their own software to monitor the health of the field computer and surrounding environment, making the system even more secure. "Motorola Solutions has been providing an open platform for customers to develop on for years," said Magril. "Others just don't offer the same level of flexibility or ease of use." In addition, with the StaRTU software residing on the Motorola products, Star Controls will help maintain the system, monitoring for breaches, looking to see how components are communicating with each other, and tracking general performance. If there's an issue, Weston can be much more proactive with maintenance or remediation. AN EXAMPLE FOR OTHER CITIES Today, Weston's Cloud -Based SCADA for stormwater pumping system is a reference point for other cities. "This is ahead of its time. Most cities strive to have a system of this type that is so comprehensive and advanced," said Johnson. Weston is also thrilled with their decision to host all system software and data in the cloud. "That's important because most cities with their limited resources don't have the ability to keep up with the management of a secured data center," explained Johnson. Overall, Johnson would highly recommend this type of system to others thinking of upgrading their stormwater pumping systems. "Most things come down to value," he said. "This investment is worth it. It's not inexpensive, but when you total the full amount it takes to maintain a manual system and the confidence and benefits you get from the automated system, it's worth it." And the best part? "Because the software is in the cloud, management and security is improved" said Johnson. For more information about intelligent loT and SCADA solutions, visit: motorolasolutions.com/iiot M MOTOROLA SOLUTIONS Motorola Solutions Inc., 500 W Monroe St, Chicago, IL 60661. U.S.A. motorolasolutions.com MOTOROLA, MOTOROLA SOLUTIONS and the Stylized M Logo are trademarks or registered trademarks of Motorola Trademark Holdings, LLC and are used under license. All other trademarks are the property of their respective owners. CO 2023 Motorola Solutions, Inc. All rights reserved. 03-2023 [LUOa] SCADA Design & Build Success Story City of Weston, Florida The City of Weston, Florida undertook a strategic initiative to modernize its water management infrastructure by implementing a new SCADA (Supervisory Control and Data Acquisition) system. The goal was to improve visibility, reliability, and operational control across the city's critical drainage assets. The project included five diesel -driven pump stations and eight remote canal monitoring sites, all integrated into a single, cohesive SCADA platform. The project followed a proven design -and -build delivery approach, progressing through clearly defined phases from kickoff to long-term support. 1. Kickoff Phase The project began with a formal kickoff meeting involving City of Weston stakeholders, operations personnel, and the project delivery team. Objectives, success criteria, communication protocols, and project milestones were established early to ensure alignment. Key outcomes of the kickoff phase included: • Confirmation of project scope covering 5 pump stations and 8 canal monitoring sites • Definition of roles and responsibilities • Agreement on schedule, reporting cadence, and risk management approach This phase set a collaborative tone and created a shared understanding of how the project would move from concept to commissioning. 2. Discovery Phase During the discovery phase, the project team conducted detailed field assessments and operational interviews to fully understand existing conditions and operational needs. At the pump stations, discovery focused on: • Diesel pump controls and status signals • Engine run, fault, and fuel -related monitoring points • Existing level sensors and local control logic At the canal monitoring sites, discovery addressed: • Canal level sensor types and accuracy requirements • Power and communications constraints at remote locations • Data reporting frequency and alarm thresholds This phase ensured that the SCADA solution would be tailored to real -world conditions rather than assumptions, reducing risk and rework later in the project. 3. Design Phase With discovery complete, the project moved into the design phase. The team developed a comprehensive SCADA architecture that unified pump station control and canal monitoring into a single system. Key design elements included: • PLC and RTU configurations for pump stations and monitoring -only sites • Communications architecture to reliably connect all 13 remote locations • Human -Machine Interface (HMI) graphics showing pump status, diesel engine health, and canal levels • Alarm management strategies for high/low canal levels, pump faults, and communications failures The design phase balanced operational clarity with scalability, ensuring the system could grow with the City's future needs. •44 kqt zssi zsu 33 2? H11 Rte Nam's Setpolnt Entry Wow Snake I Akan, Smoke 1 Atarrn Sranater Skarn-1).44mm Pump Starr Arieretael fuel Priodbus Carts Awl Laval Low eamamaaratala oar L==, laws k9. Au; 16 4.3. ace h ODA Gosh CRC h 00s h 903$ 0411h OA) h Oen h lug 24 sal sn, s 175 h Sit h S.02 h 492h S33 h lot 495h S42 Ss 471 h h h 131 h 4.97 h 4.92 S25 h to h 41$ h lide alt Door pump SPOOot Rom Current Ruronme 0 0 Mrs Last no,, (0,S) Acc. HOW, Ad, alS 1 Acc. Wartime Mr 410.3 Ogra *WNW 0 limn Current Raman. 00 We Ire Run (Days) $3 Aos. Hours Ad, 2000.0 At. 1.41•00oso Hr a 7 Hrs Current Runelm• 0.0100 Last Run ( garm) jj c• 2026 0, 0'• 20.6106 20.15-Z - S.; 9 St.* Water Lloral 4.60 Ft Unacked Current Shenno E.,ns Gant &mot trent Sep 13 SeD 17 On 14.11,03111.10411. Now Adding Note to Stotton 4. Implementation Phase During implementation, the approved design was brought to life through coordinated hardware, software, and field integration efforts. Activities included: • Panel fabrication and PLC/RTU programming • Installation and integration of diesel pump controls and canal level sensors • Configuration of the central SCADA server and historian • Development of intuitive HMI screens for operators and supervisors Close coordination with city operations minimized downtime and ensured that critical drainage infrastructure remained available throughout construction and cutover. imisammNIIMIMiMAMtic-.ViZto,Z%-grU4M 5. Acceptance Testing Phase Before final turnover, the system underwent a rigorous Acceptance Test to verify that all functional and performance requirements were met. Testing validated: • Remote monitoring and control of all five pump stations • Accurate real-time and historical data from all eight canal monitoring sites • Alarm annunciation, notification, and acknowledgment workflows • Communications reliability and failover behavior Any issues identified during testing were promptly resolved, resulting in a fully validated system ready for operational use. 6. Training Phase Operator and maintenance training was a key component of the project's success. Customized training sessions were conducted to ensure city staff could confidently operate and maintain the SCADA system. Training covered: • System navigation and HMI usage • Pump station control and alarm response • Canal level monitoring and trend analysis • Basic troubleshooting and support procedures Hands-on exercises using the live system helped reinforce learning and build operator confidence. 7. Support Phase Following system acceptance, the project transitioned into ongoing support. The support phase provided the City of Weston with peace of mind, knowing expert assistance was available as needed. Support services included: • Post -commissioning support during initial operations • Remote troubleshooting and system optimization • Documentation delivery and system backups This long-term partnership approach ensured that the SCADA system continued to deliver value well beyond project completion. Project Outcome The completed SCADA system gave the City of Weston a unified, real-time view of its pump stations and canal network. Operators gained improved situational awareness, faster response to changing canal conditions, and greater confidence in managing critical drainage infrastructure —especially during storm events. The successful design -and -build delivery demonstrated how a structured, phased approach can transform complex infrastructure into a reliable, operator -friendly SCADA solution. Data Sheet Your gateway to mission -critical loT Now, more than ever, systems operating in mission -critical environments require a new level of connectivity and security. Whether it's a natural disaster or a man-made emergency, IoTdevices are often on the first line of defense. MC -Edge® is an intelligent gateway designed for loT applications. MC -Edge's extensive security, ultra -reliable communication capabilities and reliability of transport across two-way radio, LTE, and analog radio modes make it easy for you to implement, support and grow your loT systems to fully support all your mission -critical operations. Built for versatility, MC -Edge has you covered today, and prepared for tomorrow. MC -Edge works with ThingPark, Actility's LoRaWAN Network and is fully configurable and manageable from the ThingPark Enterprise console. This addresses the need for the strictest requirements in security and operational continuity. M MOTOROLA SOLUTIONS ETH2 ETH3 RS232 RS485 SI2 11 11�\Z\\ . 1\\\\\11111111 \\\\1111111 1\\\\\\\111111 \\\\\\11111 1 1\\\ 11111 111111 11111 11111 11111 �1111111111 11\11'1111111 111\1'111 11 11111 11 i)1 11111 11 I 1 11111 111 11 11111 1111111 11111 1111111 11111 I1111111 01 1111111 011 1111111 1111 ♦11111;1111111 11111 Vertical operator solutions Network services Edge services (MC -Edge gateway) Sirens IDi Fire Stations Hazmat Utilities ((r) LTE LMR Mobile WAN (LMR, LTE) Edge processing (Filtering, aggregation, stream analytics, custom) Sensor connectivity (Wired, LoRa) Sensors and activators Vertical applications & services • Use cases with best -in -class reliability and security e.g.: Disasters, critical infrastructure Converged loT network • LMR • LTE • lot networks Edge gateways • Multi -network • Edge compute / analysis • Military grade hardware security Utilize MC -Edge to expand and grow your sensor networks The MC -Edge gateway enables exceptional remote monitoring and control capabilities. Expand reach with wireless built-in Expand your operations that currently have no power or communication coverage with MC -Edge, wireless LoRaWAN gateways and servers. MC -Edge is used as a data aggregator for LoRaWAN loT devices that can span wide areas with minimal power consumption. Utilize MC -Edge to backhaul LoRa data over two-way radio or wireless broadband to your loT applications. Enhance operations with edge computing With edge computing, activities such as decision -making, filtering, logging and analytics are handled on the edge, thus increasing network capabilities, responsiveness and efficiency. Enable control and P25 radio system remote management Integrated into Motorola Solutions' P25 dispatch or radio sites, MC -Edge can be used to control physical access, monitor environmental sensors and manage alarms. Ensure mission -critical system security MC -Edge will automatically look for malicious activity or violations of security policies and will only allow legitimate traffic to enter and block other activity. Unauthorized activity is logged and can be reported to a designated control center. AES 256 bit encryption protects sensitive data end -to -end, whether at rest or in transit. Embrace network agnostic connectivity and redundancy MC -Edge utilizes MDLC communication protocol to link distant sites for easy scaling and provide alternative communication links in case of fallback. Use of this standard functionality eliminates the need for costly custom programming or additional communications infrastructure. 2 System specifications GENERAL Operating temperature -30°C to 60°C (-22°F to 140°F) RTC Battery Charging 0°C to 45°C (32°F to 113°F) Dimensions (CPU) 2.95" x 6.3" x 4.4" (WxHxD) Dimensions (SPE I/O module) 1.4" x6 .5" x 4.4" (WxHxD) Dimensions (CAN bus I/O module) 2.95" x 6.3" x 4.4" (WxHxD) Backplane dimensions 6.2" x 1.2" x 3.1" (WxHxD) DIN rail option Yes Wall mount option Yes (using DIN rail) Construction Modular Input voltage 9-30V DC RTC backup Battery Type Rechargeable coin -cell battery, capable of maintaining the RTC for at least 30 days at +25N when the main power is disconnected SDIO card Yes Internal Transceiver Options P25 (North America), LTE, Private LTE, LoRa External Connections Analog MOTOTRBO TETRA P25 Null Modem Network Topologies Point-to-Point/Multipoint Store and Forward Star Tree Hierarchy Multi -Communication Backhaul Supported (dual/redundant link) CPU RTC Hardware clock with year, month, date, day, hour, minute, Yes and second supported Communication Ports RS232/RS485 Ethernet USB 1 port on the main board non -isolated and additional up to 2 ports on piggy Isolated (<115.2Kbps/<460.8Kbps) Up to 3 ports, 10/100Mbps (auto negotiation) Host port SOFTWARE Configuration and maintained tool PC Tool (STS) MDLC Networking Yes Direct Link Yes RTU to RTU communication Yes MDLC Store and Forward Yes Broadcast Yes Diagnostic (local, remote) Yes Error Logger (local, remote) Yes User programming C IEC61131-3 Security AES-256 end -to -end encryption User and machine authentication Central key management Central authentication server Access control Sensitive data in rest encryption IPsec SCEP PKI Secure hardware key storage (MAXIM) Protocols DNP 3.0, MDLC, Modbus, MQTT, SSH, SFTP Time Synchronization MDLC, NTP Set Date and Time Yes (w/ Time Zone and Daylight - Saving) Services DNS Yes DHCP Yes CSIF I/O PORTS I/O PERFORMANCES Main Board 3DI + 1 DO ML (Isolated) 2 kHz for all inputs SPE I/O modules Mixed I/O Module 16 DI 4D0 EE 4AI (+-20mA, 4-20mA) DI 1-8 Counter Input Frequency: 10 kHz DI 9-16 Counter Input Frequency: 1 kHz 3 DOs form A (two contacts), 1 D0 form C (3 contacts) Al Resolution 16 bit, 0.1 % @ 25C DI/DO Module 32 DI/DO FET 16 DI/DO FET 1 kHz for all inputs CAN bus I/O modules Mixed I/O Module 7 DI / 6 DO 4EE 2ML (Isolated) 4AI (+-20mA, 4-20mA) 1AO (Isolated) (AO: 0 -20mA, 4-20mA, 0-10V) Mixed Digital 8D0 EE 16DI 5-18 V /DRY 8D0 EE 16DI 18-60 V 2 kHz for all inputs 16 bit, 0.1% @ 25C 12 bit, 0.25% @ 25C - 2 kHz for all inputs - 2 kHz for all inputs 4G (LTE) / 3G SUPPORTING BANDS S North America Europe, Middle East, Africa Asia Pacific Latin America 4G Bands (LTE) Verizon B4 & B13 B8 (900MHz US), B48 (CBRS US) B3, B7, B20, CBRS EU: B42, B43 B3, B28 3G Bands (supporting bands) B2, B5 B1 for fallback B5 for fallback (3G Excluded in ANZ) B4, B7, B28 INTERNAL P25 RADIO SPECIFICATIONS (NORTH AMERICA) VHF 700/800 MHZ Frequency Range / Bandsplits2 TX: 136-174MHz RX: 136-174MHz TX: 763-776, 793-806/806-824, 851-870MHz RX: 763-776/ 851-870MHz Channel Spacing 30/25/12.5kHz 25/12.5KHz TX Output Power 1-5W 1-3W Receive Sensitivity (12dB SINAD) LORAWAN SPECIFICATIONS LoRaWAN Gateway Hardware Radio Chipset SX1301 and SX1257 Radio Frequency Plan AS923, AU915-928, EU863-870, US902-928 Frequency Ranges 863-870 MHz, 902-928MHz Receive Sensitivity Up to-140dBM Max TX Output +28dBM LoRaWAN Software 0.216pV 0 250uV LoRaWAN Server Yes 2Check with your local Motorola Solutions sales representative for frequencies available in your local area. LoRaWAN Gateway Basic station for general LoRaWAN network Actility base station for Actility LoRaWAN Network (ThingPark) 4 POWER MANAGEMENT Voltage Management Preconfigured thresholds based scenarios Power voltage that can be reduced or disabled 5 power consumption options available Power Consumption CPU module all radios off Max 300mA / Typical 150mA @ 12V (w/o SD card and USB) CPU module all radios on Max 450mA / Typical 250mA @ 12V (w/o SD card and USB) CPU module all radios on P25 TX 1.6 A / Typical @ 12V CPU module all radios on LoRA RX 8 channels 0.36A / Typical @ 12V CPU module all radios on LoRA TX 0.605A / Typical @ 12V CPU module all radios on LTE TX 0.45A / Typical @ 12V Mixed 10 module Max 194.4mA / Typical 64mA @12V Mixed digital 10 modules Max —357mA / Typical 21 mA @12V 32DID0 module Max 178mA / Typical 70 mA@12V 16DID0 module Max 145mA / Typical 50mA@12V Mixed 10 16 DI 4A0 4A1 module Max 165mA / Typical 80mA@12V REGULATIONS Safety US / Canada IEC62368-1 (cUL Listed) EU, Australia / New Zealand EN/ANZ 62368 Emission / EMC US / Canada CFR 47 FCC part 15, subpart B (class A) ICES003 EU, Australia / New Zealand EN301489-52, AS/CA SO42.1, Approved per RED To learn more, visit: www.motorolasolutions.com/mcedge SERVICE AND SUPPORT 1. Technical Support - Remote Technical Support from our Solutions Support Center 2. Software Updates - Safeguard your system from One year warranty vulnerabilities and improve network performance 3. Software Upgrades - Download the latest integrated system software releases with the latest features, functionalities and enhancements M MOTOROLA SOLUTIONS Motorola Solutions, Inc. 500 West Monroe Street, Chicago, IL 60661 U.S.A. motorolasolutions.com MOTOROLA, MOTO, MOTOROLA SOLUTIONS and the Stylized M Logo are trademarks or registered trademarks of Motorola Trademark Holdings, LLC and are used under license. All other trademarks are the property of their respective owners. ©2025 Motorola Solutions, Inc. All rights reserved. 06-2025 [BG15] VTScada® by Trihedral The industry's most powerful SCADA software for systems that simply can't fail. BralaG '® 2021 ENGINEERS' CHOICE AWARDS 1 WINNER Plait PRODUCT ea-YEAIT -)/0202� 1p 2020 111 Product aYear Agenda 9:00 - 11:30 — Presentation 12:00 — 16:00 — Product Demonstration VTScada by Trihedral One Install Provides All Core SCADA Components T SCada Under 200 MB Installer v Software for Monitoring 8 Control Monitoring & Control A l Date Time Tag Name 2 1-Dec-17 13:05:00 PlantDemc 3 1-Dec-17 13:05:00 PlantDemc 9 1-Dec-17 13:05:00 PlantDemc 5 1-Dec-17 13:05:00 PlantDemc 6 1-Dec-17 12:05:00 PlantDemc 7 1-Dec-17 13:05:00 Demo`TCP Reporting Communication Drivers Account Name I Mart Password Confirm Password Security Alarms & Notifications Historian Graphic Development Mobile Connectivity Mapping Trending Dmr APPI,rd 0109 11.102 I.14,11 20111510 35.460 0108 0. 5,snow Dotal. Dotal O 100 Sw.k.M1 TM wr.ro_ 20099 0106 933 O 105 rawae Sanwa Cru„9o, 111 C104 Mon 121.r 11. 201111.1519.100 0103 Mon 1.1.r 1120111114135. Version Control Enterprise Connectivity INTEGRATED ARCHITECTURE Standard & Optional Components • We develop and maintain every part of VTScada. • One license agreement for all SCADA components. • All features are automatically upgraded with every version. • Unique design vastly improves integration and scalability. .ia Open I/O Connectivity For All Your Devices MODOUS JSON DELTA DNP3 MATT DF1 DDE SPARKPLUG B MOTOROLA IP GATEWAY ROCKWELL MULTITRODE CAMPBELL SCIENTIFIC DMRON CALAMP GENERAL ELECTRIC BSAP GRUNDFDS BACnet DFS MDS ALLEN-BRADLEY KOYO CAT MDS FISHER BSAP CIP AND MANY MORE... DEVICE DRIVER LIBRARI Standard Out -of -the -box VTScada includes hundreds of industry standard and proprietary protocols. Since they are fully integrated, the are updated with every new version of VTScada. ■ Drivers included in the base price of VTScada. ■ Examples: Modbus (many variants) - DNP3 - DF1 - Rockwell Ethernet IP - Siemens - Omron - GE - MQTT - etc. ■ Advanced polling features can replace Master PLCs. ■ Direct drivers cost less than maintaining OPC servers. ■ Trihedral can develop custom drivers on request. Open I/O Connectivity For All Your Devices Advanced native polling tools. Protocol 1 Failover to redundant networks or devices. TELEMETRY TOOLS Standard • Remote Asset Polling Driver. • Telemetry protocols such as DNP3, IEC 60870, Motorola, DFS • Support protocols with store -and -forward, datahopping, digipeating. • Multiplexer support for redundant comm links. • Advanced polling tools for real-time poll rate adjustment and fast/slow switching. • Calculations and Deadband Control to support automated site to site interdependency. New Communication Drivers - OPC UA and MQTT DPCUA Address Select opctcpi :62541 Objects - Server 1�LCTT E Scalar Scalar_Inswctions Scalar Static [�. Simulation -0 Boolean -0 Byte ByteString -0 DateTime -0 Double - 0 Duration -0 Float - Guid -0 Int16 -0 Int32 Int64 - 0 Integer -0 Localeld - LocnlizedTe 1 Nodeld -0 Number - Ouali6edName SByte - 0 String -0 Time - Ulnt16 Attribute NodelD NodeClass BrowseName DisplayName Description WnteMask UserWreeMask Value ns_2;id-Scalar Simulation_Int32 2 ns-2id-Scalar Simulation_Int32 Int32 96 96 Value DataType Valuepank ArrayDimensioru AccessLevel UserAccessLevel MinimumSamplingI nterval Nirtorizing RolePermissions UserRolePermissions AccessRestnetions AccessLevelBx 2118112219 Int32 Scalar 3 0 False ✓S New MATT Client Driver Properties X ID r Camection I Credentials j Last Will Port 'Port --Missing-- ©® CI MQTT Client ID VTScada(XXXXXXXXXXX-XXXXXXXXXXXX-XXXXXXXXX-XXXXXXXXMQTT1 Keep Alive 120 QoS C QoS 0 - At most once O QoS 1 - At least once O Qo$ 2 - Exactly once ❑ Hold OK Cance OPC-UA CLIENT DRIVER Standard • Interface to OPC-UA servers running on local or remote computers. • An alternative protocol to OPC CLASSIC. No DCOM. • VTScada still supports the OPC CLASSIC. MQTT CLIENT DRIVER Standard • A gateway to the Industrial Internet of Things. • This subscribing client can read from an MQTT broker on your local network or the Internet. • You can then log, view, alarm, and report on values from devices connected to that host. Plug -And -Play Tag Creation 1 .` . Tag Browser. Showing 1 of 4,920 Running Tags 1 Using 22 of Unlimited Licensed Tags — ❑ X ❑o Show Children III I Names •• I ❑ Show Disabled All Areas .. pment Types s, I CIP/ENI X Y dd —,.j A 1 E \ Bemoulli_Lake Name Description Type Equipment Type Address AB-PLC1 Remote Site 1 PLC CIP/ENIP Device J1,0J Menus PubliicIncludes ServerStatus ' System Alarm DB System Event D8 ' SystemHistorian < > Import New Properties Draw Close Xi Importing Tags From Primo CIO 1 J SAP el S,1S9 Tags Selected 0 X CIP Port 1\CIP 1 AO testiO) AO_test(1) Aktest(10) AO.test(11) AO_test(12) AO_test(13) AQtest(14) AO_test(15) A test(2) L• Names •• Name AO AO test(1) AO_test(10) AO testil1) A0_test(12) Ao test(13) AO_test(14) A0 test(151 ['Shaw Chidren ❑Coe c oily (aT) 5 Analog (kU0u1J Analog (INOutJ Analog On/Out) Analog (INOut) Analog (WOutJ Analog (ln Outi Analog [WOut) Amato, lln%Outt Show Selected x • J; Show Unelected AO_test[Oj(AO_test(0J) AO test(1j(40 test[11) AO_test[101(AO test[10J) AO_test[11j1A0_test[n ]i AO_test(12j(AO test[12J) AO test[131:Ao test[13]i AO_test(148A0test[14]) AO tes11151.AO test11511 OK Cancel Easily filter and choose just the tags you need to import. TAG IMPORT FOR AB CIP DEVICES Standard Component • Import tags from AB CIP devices to your application with one button.* • Button enabled when a supported driver is selected. • Filter and select tags before importing. • Copy parent/child tag structures configured in the PLC. • More devices will be added in the future. Tag names in PLC must be legal tag names in VTScada. Built-in Historian - No Extra Cost or Configuration /111 Oraclee MS SQL Server HISTORIAN t MySQLc' vT VTScada SQLiter, THE VTScada HISTORIAh, Standard Component Every application includes an Enterprise historian capable of logging from two to two million I/O. • Add synchronized redundant historians in seconds.** • Configure 3rd-party databases as needed (sold separately). • Import history from other SCADA platforms in CSV format. SQL Server, Oracle, MySQL and SQLite are trademarks of their respective owners. ** Requires additional VTScada licenses. ':.FihersTurbidity Time O I B 1 6 Hours v 11 ..\Filter# 1 \Turbidity Filter#1 Turbidity Averages v Operator -Created Trending 15 Minutes v _VRIter#2\Turbidity Filter#2 Turbidity 05:15 05:30 05:45 06:00 06:15 06:30 06:45 0.0624622 0.0624571 0.0624539 0.0624580 0.0624617 0.0624631 0.0624614 0.053375 0,058367 0.058363 0058369 0.058374 0,058376 0.058373 Choose Plot or Grid view. HISTORICAL DATA VIEWER (HDV) Standard • No integrator required to add trend groups. • Click one or more screen values to plot, then save. • Add encrypted notes to the timeline. • Stacked and overlapping trend views. • Switch between Plot or Grid view. • Mobile trending from Thin Clients.* Add note to System Notes Feb 7, 2020 15:48A7 X PLC 3 malfunction caused these unexpected levels. Will replace this dayshiftl •pnsertaQuirckNotej OK Cancel Built-in Reporting Tools Scada ..u�..mn�.w.• �.. •5.5. — 134.493* 4 45.4 9419.4 94444.4.34 .1402.1 3 4 5 6 7 8 9 10 Report Page and Report Tag Standard • Ad -hoc or scheduled reports. • Simple built-in report generator. • Output to screen, txt, csv, Excel, database or email. ■ Export to custom Excel Report Templates. 934.3.4 fr Analog Summary Report from May A CI D 1 E 1 F G I F Analog ummary Report from May 2, 2019 06:55:00 to May 2, 2019 07:5 Station Tag Address Average Min Max Total Pump Flow gpm [40006] 3.64 0.6 18 218.34 Pump Flow gpm [40016] 3.45 0.6 16.5 206.96 Pump Flow gpm [40026[ 6.86 0.1 19.9 411.48 Pump Flow gpm [40036j 6.95 0.3 19.1 416.72 Pump Flow gpm [400461 5.39 0.4 19.1 323.63 Share Data With Enterprise Systems /RD-PARTY CONNErTT` TTV ADTTr Standard in Development Runtime Licenses VTScada makes it easy to share history across your organization. ■ ODBC Server - Query VTScada's Historian like an ODBC database. ■ OPC Client / Server - Connect to real-time process values. ■ SNMP Agent* - Real-time data and report -by -exception traps. ■ REST Interface - Retrieve large datasets in JSON format using SQL. ■ JSON - Import website and IOT information ■ Web Services - Use soap/XMI to access historical and real-time data. ■ VTScada - Connect different applications to one another. NEW IN 12.1 - The SQL View Tag allows third -party platforms to efficiently query vast amounts of data from the Historian. Standard in all licenses Work Directly With Process Data Outside VTScada Review View Add -ins Help VTScada 0 E Timestamp My Alarms\Analog 1:Value:Average 2019-06-01 03:00:00 2019-06-02 03:00:00 2019-06-03 03:00:00 2019-06-04 03:00:00 2019-06-05 03:00:00 2019-06-06 03:00:00 2019-06-07 03:00:00 2019-06-08 03:00:00 2019-06-09 03:00:00 2019-06-10 03:00:00 2019-06-1103:00:00 2019-06-12 03:00:00 2019-06-13 03:00:00 2019-06-14 03:00:00 2019-06-15 03:00:00 2019-06-16 03:00:00 2019-06-17 03:00:00 2019-06-18 03:00:00 2019-06-19 03:00:00 2019-06-20 03:00:00 2019-06-21 03:00:00 2019-06-22 03:00:00 2019-06-23 03:00:00 1.00 22.93 50.00 50.00 50.00 50.00 G Timestamp 2019-06-24 19: 2019-06-24 19: 2019-06-24 19: 2019-06-24 19: 2019-06-24 19: 2019-06-24 19: B Q Gk. (Body) 11 B ! u l 678 A 8 C 1 Timestamp My Alarms\Analog 1:Average 2 2019-08-15 00:00:00 1.00 3 2019-08-15014040 1.00 4 2019.08-15024040 1.00 5 2019-08-15034040 1.00 6 I 2019.08.15 04:00:00 1.00 7 2019-08-1505:0090 1.00 8 2019-08-15069090 1.00 9 2019-08-15 07:00:00 1.00 10 2019-08-15089090 1.00 11 2019-08-15 09:00:00 1.00 12 2019-08-15104090 1.00 13 2019-08-15 11:00:00 1.00 14 2019-08-1512:0090 1.00 15 2019-08-15 13:00:00 1.00 16 17 / 1 4 VTScada Excel Beporung Tag History Query Tag so..e.. + aaua. re.. nap Q Ole Ned r..rew '—".' � O + Query AnM.ss OO CAilholad a.e e Pee du )c.. reverser. /ee MICROSOFT EXCEL ADD -IN Standard in Development Runtime Licenses* Download the Excel° add -in, "VTScada - Data Retrieval" from the Microsoft Office Store° or App Source °. • Connect from a local or remote server. • Choose the VTScada Historian data source. • Select tags and build queries. • SSL/TLS is required to connect to VTScada. * Requires a Microsoft Excel license. Microsoft, Excel, Office Store, and App Source are trademarks of Microsoft. Active Enhanced Situational Awareness Scada Alarm Page All All System Alarm DB System Event DB 2016-01-26 11:26:41 Alarm Actions Analysis History Filter V.evr Unacked Current Shelved Disabled Event Area Event Application Startt 2016-01-26 11:26:41 3 2016-01-26 11:26.41 \3' •• Active Active System System 2016-01-26 11:26:41 2016-01-26 11:26:41 2016-01-26 11:26:41 2016-01-26 11:26:41 2016-01-26 11:26:41 2016-01-26 11:26:41 2016-01-26 11:26:41 Yt Add Note Commission Commission Disable Disable Disable Disable Commission System System Networklnformati LM Low Lift Pump St LM Low Lift Pump St LM Pre -Mix LM Pre -Mix ,Pre Mix 'stem WaterTreatmentPlantDemo\TCPIP Port\WaterTre4°ne1 Test Alarm (1) Eonel onel 2019-12-20 14:53.37 one) 'This was a test of the WTP levels. Recommend we increase the setpoints.j one3 one3 one3 one2 Configured Help Acknowledge Shelve Add Note Show Details le Plot Go to Page Go to Page (Popup) Properties Nan farm arm larm arm 1PrimaryAlmDi t\LowLiftPump t\LowLiftPump t\Pre-Mix\Raw t\Pre-Mix\Raw WaterTreatmentP) ant\Pre-Mix\Mixl WaterTreatmentP l a nt\Cl arifi ers\Set WaterDistributionSystem\Zone_1 \T WaterDistributionSystem\Zone_1 \T WaterDistributionSystem\Zone_1 \V WaterDistributionSystem\Zone_1 \V WaterDistributionistem\Zone- 31T- WaterDistributionS'st r \Zone WaterDistributionSysi • WaterDistribution sth• ALARM & ACTION LOGGING TOOLS Standard Alarm Page based on ISA's 18.2 Alarm Management Standard. • Alarm and Event databases in every application. • See current, active, unacknowledged, disabled, and shelved alarms. ■ Sort by date/time and filter by functional area or priority. • Use color, shapes, and symbols to help users with color vision deficiencies. • Shelve alarms to stop alerts during maintenance or alarm floods. ■ Add encrypted notes to alarm instances. Quickly Identify and Eliminate Nuisance Alarms All Database - O® ® -.o1-Y q-., FA=III 4: analysis - ter Bad Actors Alarm Flood History Distribution of Priorities Area Name Description 1 ❑2 Zone 1 Local TCP Port\PLCSim\Tank 1\Tank Level Monitor tank level HIGH 2 ♦ Zone 2 Local TCP Port\PLCSim\Tank 2\Tank Level Monitor tank level HIGH Q Zone 3 Local TCP Pori \PLCSim\Tank 3\Tank Level Monitor tank level HIGH P Count 14 2 Bad Actors Report - Summary of alarm occurrences within a specific period, sorted by the number of activations. Bad Actors Alarm Flood History Distribution of Priorities P 50 D Mar 20 r li ,rI Apr14 I.111 Apr9 Mar25 Mar30 x Alarm Flood Report - Count of alarms tripped within equal time slices. Click a bar to zoom into that period. ALARMS TUNING REPORTS Standard Bad Actors Alarm Flood History Distribution of Priorities fD Description Local TCP artwtCsa.va.k Mank Level Monitor tank level HIGH r TLmo.so 2016-04-07 Tn.5a.o5 Local rtan TCP k i,PLCsimvrn aak LATaLevel Monrto Local TCP .taok,PLCSinATank lATank Level Mon History Report- All active and trip alarm events in a specific period. Pad Actors Warm Hood History Distribution of Priorities pi Reported History Current Configuration ISA 182 Recommended Critical High 0 33% 67% 5% 15% dud High Criticai Hlc` • Priority Distribution Report - Compares priority of configured alarms and actual alarm occurrences against ISAs recommendations. Critical Alarms Find You Anywhere VTScada ALARM NOTIFICATION Optional Component Receive and ack alarms from anywhere via SMS text message, email, pager, and text -to -voice phone call. ■ Create contact rosters for areas, times and dates. ■ Tightly integrated for the life of your system. ■ Also supports voice and SMS using Twilio®. ■ OAuth 2.0 authorization for sending alarm notification emails. NEW IN 12.1 ■ VoIP-based alarm annunciation: no modem or Internet. ■ Enhanced Roster configuration. VTSLc]GU (AO text -to -speech alarm annunciation New in Version 12.1 VoIP-BASED ALARM ANNUNCIATION, NO MODEM OR INTERNET Part of Optional Alarm Notification System VTScada will always support voice modems for text -to -speech alarm annunciation. However, they are increasingly hard to source as telecoms phase out data over analog lines. Now, take advantage of the benefits of Voice over Internet Protocol (VoIP) without going through the internet. ■ No more discontinued third -party hardware. ■ No web -based third -party service required. ■ No need to expose your SCADA system to the Internet. Create Applications For the Global Market scads r' ® !l OEll I 1=1- 1 1 ii 3C fR 0419 2018-11-05 13:34:10 ift f i 2018-11-05 13:32:17 + • m 7 SecFAorAddR&le_abe.. AddServerLabel AddServerAboveLabel AddServerBelowLabel AddServerToListLa beI AddServiceListLabel EditPropsAddS itePropsTT AddSitePropsLabel EN - English " -_ Add Role Add Server Add Server Above Add Server Below Add Server to List Add Service -specific Lists Add Site Display Properties Add Site Properties CN - tgRtwS. TITAft _... i MULTI -LANGUAGE SUPPORT Standard Create translations for any number of languages.* • Users can set a preferred language or change on the fly. • Translate standard VTScada and application -specific terms. • Import translations all at once or term -by -term. * VTScada includes English by default. Translations to other languages are the responsibility of the end user. Site Mapping in Every Application New inV12 VTScada SLIPPY MAPS Standard * • No configuration required. • Tiles download automatically and cache indefinitely. • Select pins to see site data in standard or customized templates. 14 • Bulk Downloader- Import all tiles for designated areas and elevations. • Limit Area and Elevation - Focus users on their operational areas. • Carto® Map Tiles- High performance, high contrast, night view. • Overlapping Site Selector - Pop up lets you pick the site you want. * Mobile devices require VTScada Thin Client Licenses. Encrypted Electronic Notebooks Operator Notes F1A A °o Operator Notes Demo • 7I m nutes ago • Last updated 2 minutes ago Equipment ID: S17-PO4 Situation Summary: Pump flow significantly reduced Crew members: Darius Jones, Mike McInnis Details: Pump difficult to rotate. Removed and disassembled. Impeller damaged Actions Taken: New impeller ordered from stock. WO R15982 Suggested Acions to Mitigate Future Occurrence: Needs review of damage to identify cause. Comment • Whole ttveaa — Demo • _ nutes ago New impeller installed and pump reassembled. Back in service. Equipment ID: Maintenance Ticket Crew members: Actions Taken: [Insert a Quick Note] Pump 00S Problem with impeller Wive PC-13 a% I WteeiX22 ( 100 % Pump M-21 ON -AUTO Acknowledgeable'Sticky' Notes ti OPERATOR NOTEBOOKS Standard No more paper logbooks. • Make notebooks available system -wide. • Assign notebooks to specific equipment. • Alarm system notebook. • Add notes to alarms and trend points. • Export Notes for use in reports. Remote Access From Anywhere VTScada THIN CLIENTS Optional For HTML5 browsers on mobile devices and PCs. • Licensed by concurrently connected user. • No third -party server software required. • Supports SSL/TLS and VPN encryption. • Configure in minutes. ado Fen Iwnt Ion ▪ hIto. w«.uw. swlo� New in Version 12.1 BATCH & RECIPE MANAGEMENT Standard Component Batching is critical in industries like food & beverage and pharmaceuticals where repeatability and traceability are key. ■ Create any number of Ingredients, Recipes, and Recipe Books. ■ Automatically trigger batches to run multiple recipes in series. ■ Scale or modify batches to create revisions. ■ Changes are recorded and distributed across all servers. ■ Recipes can be imported and exported as spreadsheets ■ Utilities can even use Batching to prepare for bad weather. New in Version 12.1 Quick Start Version 12 video Tutorial EMBEDDED VIDEO WIDGET Adding live video feeds to HMI screens helps to protect operators and build their trust in their system. ■ RTSP video streaming protocol (used by Netflix®) supports a variety of cameras and decoding schemes. ■ The Video Widget is easily dragged -and -dropped from the VTScada Idea Studio - EMBEDDED BROWSERS Provide operators with just -in -time resources by adding browsers to your screens. Easily add weather maps, YouTube® training videos, pump maintenance PDFs, or even Thin Clients from other VTScada applications. Easily Manage Multiple Applications Vrx.a. A ph.bon M.n.gat - 0 X Scada Water Systems Master Overview o• i�tcrrK'.�p.n:ticr,• I O C. ► 'S Trace Viewer p ► a, WaterArdWastewaterDerno ✓ ► • a, lilt Station 14 ✓ • • a North Water Plant C. • tf Test Framework Ci ► 12.0 Powty Systems M.aste'f C..YYYI!'w • North Hydro Plant ,.. ■ Solar held 2 4 b. Solar held 1 !., ► • 0 Serial Mara 9 Dqr Used Sie Uwe.* Per,o6 End, So 16i 2020 Moray Wed 1,231 he VTScada APPLICATION MANAGER (VAM) Standard The VAM is the first thing you see when VTScada starts. This is where you create, import, and launch applications. You can access the VAM from the VTScada Internet Client (VIC) when running applications as a service or in the cloud. • Set up Thin Client servers and VPNs. • Access application configuration. • Create Application Lists for different job responsibilities. Fix Faulty Values and Insert Manual Data VT Historical Data Viewer Unnamed Group 44 u 10 Minutes ■ LU Raw Data ,rI 1 Seccn_I 0 Tag Selective: Export Time Span Data Mode &Time Per Record Note ._._�Tanld_evel System Notes ._..1TankIevel Time Tank Level System Notebook Tank Level 10:09:19.429 10:09:25.542 10:09:25.543 10:09:27.542 10:09:27.544 10:09:29.548 10:09:29.549 10:09:31.545 10:09:31.546 10:09:33.549 19:09:33.556 10:09:35.546 10:09:35.548 10:09:37.551 10:09:37.556 10:09:39.548 10:09:39.550 10:0941.549 10:09:41.551 100943.555 50.30 51.50 49.80 49.80 49.00 49.00 48.00 48.00 46.80 46.80 45.40 45.40 43,90 43.90 42.20 42.20 40.40 40.40 38.50 21.30 I.w VT-NastewaterPlantDemo TCPIP PortlWastew... X Lagged Ott • Cd30, 2018 IL1C823 • Nate added Oct 30, 201614%2119 Name: WastewaterPlantDemo\..\Tanks\Tank01TankLevel Description: Tank Level Event: Set to 51.5 Corrected value distorted by sensor interference. for e Close 6.10 6.10 HISTORICAL DATA EDITING Standard Override incorrect or missing values. Original values are retained. • Edit individual or ranges of values. • Edits require an explanatory note. • Edited values are marked in the Historical Data Viewer. Group Tags to Reflect Real -World Structures VT Tag Browser. Showing 27 of 4,926 Running Tags I Using 237 of Unlimited Licensed Tags {'� ] Bemoulli_Lake ► Site_Driver ► 1 ❑Show Children Names t' Show Disabled A Bernoulli_Lake GenerateLossReport --0 HP_Locatbon_Style �} LossReport ---c Site_Driver AutoAndLocked BrgVibeX {� BrgVibeZ BypassFlowRate �y BypassLossVolume --) BypassSwitchFeedbe - BypassValveSwitch DownstreamFlowRa - DownstreamFlowRa --0 Gate Position - GateSwitch GateSwitchFeedbacl IsPrimaryServerRunr —1 IsRaining LakeLevel - LakeLevelAlarmSet All Areas Equipment Types .. All Types x T Name Description Type UpstreamFlowRate • TurbineSpeed O OilPressnre O MainValveSwitc • MainValvePositi ✓ MainValveLockc MainSwitchFee( _akeLevelChanc ' . _akeLevelChanc _akelevelAlarm _akeLevel :Rain ing :sPrimaryServer +1 _1 GateSwitchFeec • GateSwitch O GatePosition O DowmtreamFlowRa S1 Down strea mFlo U BypassValveSwi Draw Plot View Alarms Upstream Flow Rate Analog (In] T--J'--- ^' Speed Analog Status Cut Copy Paste as Child New Child Delete Enabled Set Start Condition Create New Type Redefine Type Go to Page Go to Page (Popup) Properties e Analog Status h Selector Switch Analog (In] t Digital Status rick Digital Status Logger Logger age (Ft/hr] Rate of Change Analog Control tie site rlOnPrirnary Calculation rick Digital Status Selector Switch Analog Status Normalized NureircCakulatke [Guff e Analog (In] Selector Switch Analog [In] Digital Status HIERARCHICAL TAG BROWSER Standard A single interface to create and edit all your application tags. Only I/O addresses count towards your licensed tag limit. • Create reusable parent/child structures to model equipment or processes. • Save time and reduce errors when developing. • Draw multi -tag equipment in one step. • Easily export tags to a spreadsheet, edit, and re -import. Ion Instantly Intuitive Screen Development Cut A Text Colorize - [] Copy \ Line I ImageOpacity - j Brightness - E] Paste Z Pipe Jk Image Rotation - 40 Contrast - 1:71 Change Image E'0 Mirror r© Antiafias Reset Op city Rotation haat g$] }) D Welcome To VlScada - Start Nee L Water Treatment Plant Demo __ Fcc _', '.: _I Outlet Pumps 0Inlet Pumps 14] 285 v 90px le 1920 x 1014px Easily select and align graphical elements. VTScada IDEA STUDIO Standard in Development Runtime Licenses • A familiar drag -and -drop screen development interface. • Configure and commit changes without restarting. • Includes 200+ widgets, 4000+ graphics, and 3D pipes. Retur-i(Se1f); GU:Transfarm(296, 280, 395, 254, 1, 1, 1, 1, 1 ( Scaling ), 0, 0 ( Movement ), 1, 0 ( Visibility, Reserved ),. 0, 0, 0 ( Selectability ), Variable("FlowTotal Pump 3")\Number(0, 1, 1, GUITransform(184, 148, 212, 32, — 1, 1, 1, 1, 1 ( Scaling ), 0, 0 ( Movement ), 1, 0 ( Visibility, Reserved ), 0, 0, 0 ( Selectability ), Native scripting language provides unlimited customization. Help Operators Focus on What Matters Most Analog Bars P1 P51 1 ,P2 P4 P3 'Upstream Flaw 501 73 Sparklines Spider Graphs New inV12 + NEW HIGH PERFORMANCE WIDGETS Standard New drag -and -drop High Performance widgets add to the existing library of gray -scale objects. ■ Easily create high performance displays. • New Widgets optimized to work seamlessly with the new VTScada I/O & Calculations Tag. • Sparklines, analog bars, and spider graphs. Iona Deploy New Equipment in Seconds The Built-in Grundfos Pump Controller®Template PARAMETERIZED PAGES Standard* ■ Easily create reusable custom page templates. ■ Populated from parent/child tag structures. Pre -Built Pages ■ Grundfos Pump Controller® ■ Xylem MultiSmart® ■ MPE Pump Controller° ■ Generic Page Template _z * Configuration requires a Development Runtime License Instantly Recover From Configuration Mistakes '3( Edit Properties Edit Server Lists Edit Security ,t• Languages rk Create ChangeSet File +] Apply ChangeSet File Export/Sync Tags Manage Types Import Hie Changes E Maintain File Manifest f. Deploy Changes 0 Revert Changes Show Version Log * Ovenide Detection j Information cri,cr View the version status of workstations The current application version on each workstation is shown below. Local modifications are shown in blue. Deployed,. Selecting a workstation from the Worksta, Right -clicking on a Version log er' changes from that version in v The phrases shown in the created. Workstations Workstati' SERVER 2 SERVER 3 SERVER 4 SERVER 5 Version Log for Vers SERVER 1- SERVER 1- D SERVER 2-D1 SERVER 2 -D2 SERVER 2-D23 SERVER 2-D23 SERVER 2-D236 SERVER 2-D235 SERVER 2-D233 SERVER 2-D232 2022, 13:44:27.201 SERVER 2-D222 Thu 2022, 120037.684 SERVER 3-D3 Mon • 4, 2022, 09A5:39.9 SERVER 4-D165 Fri Apr 22, 2022, 14:1041.863 SERVER 5-D5 test are shown in red. The cc -rent deployed version is shown in black. 'bat workstation. tat of 107 records in log) ime Applied User ' S3:11.305 Logged Off Platform in 1040.985 Logged OR Platform in 02214:1^""' ,____..... _ 2 15 Show Version Details Thu Feb 2 Thu Feb 24, 2022 Thu Feb 24, 2022 12: Next 100 Show All Switch to This V gge `,out thaty eppli commit utoma commit itch to that version, reverse the translations used when the version was ng1Serwrl\ServerA arm °Monitor Monitaingkkrverl\ServerAkrm Reload APPLICATION VERSION CONTROL Standard Only VTScada offers advanced traceability and change management out -of -the -box with no configuration or third -party components. • Built into every application. • See who changed what and where. • Instantly reverse any change. • Switch to a known good version. No restart required. • Change log automatically saved across all app servers. Select the changes to apply Select the items you wish to change front the tree of changed items. pick the "Apply button to apply the displayed checkboses ind'cate conflicted files, carefully verify the proposed charges before selecting such records for applicati IV-[-] Source Files (1) Pages\Overview2SR M Tags M Images LI Properties [-] Text Files Binary Files Pages \Overview2.SRC 14 train l 15 Return (Self ); - 15 GUT_Transfosa(SE7, Ste, 595, 550, + 16 a 379, 17 1, 1, 1, 1, 1 Scaling ), 18 0, 0 ; Vvverrorc 4114 Easily Roll -out New and Updated Applications USER A USER A USER B USER A USER R ONLINE DEPLOYMENT Standard in Dev/RT Licenses Instantly deploy applications to networked servers and clients. Concurrent multi-user development. No configuration server required. Deploy validated changes via the network. Gigaratis sA0/! OFFLINE DEPLOYMENT Standard Manually deploy to offline computers with a single ChangeSet file. Easy to create, distribute, and import. Share with support teams. Clone applications. SERVER 2 SERVER 3 SERVER 1 SERVER 4 Meet the Challenge of a Changing Security Landscape Days to Patch 50 � Gd I " Based on da_a provided ay Trend Micro. Days to Patch Security Issues Following Notification by ICS-CERT. CYBERSECURITY VULNERABILITY MANAGEMENT Standard Implementations compliant with... • NERC/CIP (North American Electric Reliability Corporation) • DFARS 252 (Defense Federal Acquisition Regulations Supplement) • NIST 800 (National Institute of Standards and Technology) • Marine reliability standards ABS, Lloyds Bureau, DNV, BV High Reliability Systems • Multi -level fault tolerance Data Protection • Multi -level (and geo-separation) data backup methods Sale Easily Manage What Users Can Do and Where Users ® • General Usemame Alan Andrew Barry Blair Bryan E Dan Roles Chris Language English • Password Password Password never expires Advanced ©® • Privileges ® Confiqurer Logged Off Operator SuperUser Riles ❑Canfigurer Permits configuration of a VTS Confirm Password ❑ Force reset of password at nett Pdvdeges General Privileges Custom Privileges Administration Adrnmstrator ❑ Operator Permits operation of a VTS App s—J Permits complete control of all Additional Prlvi1eges © Internet Client Access Manager ❑� Administrator RI Remote Data Access p Application Stop Configure *CERTIFIED Trihedral Engineering Secure Development Lifecycle Process Account Control Manager Account Modify Account View Internet Client Access Remote Data Access Application Control Application Stop Application Manager Yew Version Control Advanced version Control Deploy Changes Revert Changes App!cation Configum - Edit Files Page Add ledge APPLICATION LEVEL USER ACCOUNTS Standard Centrally manage security from the standard operator interface. Deploy changes across the system without restart. NEW - VTScada's Dev Environment is now certified compliant with IEC 62443-4-1 Maturity Level 2 Security For Industrial Automation And Control Systems. • Windows Active Directory® support. • Industry -standard encryption. • Card -reader support. • OpenID Connect® allows single sign -in and 2 factor authentication when accessing Thin Clients. • OAuth 2.0 authorization for sending alarm notification emails. Instant Backup for History and Configuration it_Jo Configuration History Alarms Tags User Accounts INTERNET Automatic Bi-directional Synchronization PRIV' • Configuration History Alarms Tags User Accounts AUTOMATIC REAL-TIME SYSTEM BACKUP Requires Multiple Licenses Each networked server can be a complete up -to -the -second full - system backup. ■ Configure any number of sync'd servers in seconds. ■ Geographically isolated servers are offsite disaster backups. ■ Never forget another backup. A Smarter Approach to Hot Backup Failover VT L.Idd Site A LrI I AI DBB - DB A j INTERNET DB A DB B vineimmin Site B I 1:Wit SYSTEM -WIDE REDUNDANCY Requires Multiple Licenses Server Failover • Application Servers. • Thin Client Servers. • Load -share services. Synchronized Historians and Alarm Databases • Alarm and Event Databases. • Across LAN or WAN. Network Failover • Unique Driver Multiplexer. • Redundant Networks or Devices. An IT -Friendly Solution A custom IT dashboard. SYSTEM HEALTH MONITORING Standard ■ Optionally run VTScada as a service. ■ Windows° security integration. ■ PC and network health monitoring tags. ■ Built-in SNMP driver. ■ IANA registered TCP/IP port. ■ Tamper -proof configuration repository. Plant Operations Pionxa0✓emew • ♦♦ ♦♦•♦.♦•♦. 66666 CITY OF SACRAMENTO DEPARTMENT OF UTILITIES li : 2.w, —, �r,i�... A- �4 fir. -n ...:,4 . „ n„ n n _Ili .. 46/1- 1 ®I MEM I SACRAMENTO DEPARTMENT OF UTILITIES Sacramento, CA • 4 water treatment plants in a single 141,000 tag application. • 14 servers, 4 configuration workstations, 12 operator stations. • Comms to 80 Modicon PLCs. • Central security. • Enterprise access to Historian data. • Custom tag types and graphical widgets for standardization of colours, tags and graphics. GAINESVILLE REGIONAL UTILITIES Gainesville, FL • Rapid Wonderware and Dataflow I/O database conversions. • Centralized configuration of lift stations and plants. • Geographically separated primary and backup servers. Wastewater Collections mfDI w-a —! 4icare than Energv THE CITY OF CUSCO Peru • Wastewater treatment plant monitoring. • Integrators: Aquas Latinas Peru and Hydro Control Germany. • 7,500 Tags. • Synchronised alarms with Allen Bradley® PLCs and Panel Views • Remote access. • Redundant servers with hot backup. Wastewater Treatment Plant Monitoring OS .7 BOO :l F ,674 o ?fir'r 0.4/:! 113.11. •10:,�Yalt& * DIGESTION DE LORD Water Treatment 0 Li • t... +---•ram• .. Fi 1 - ' 'I I III r; i City of Ocala Ocala, FL • Driver library helped to transition from multiple systems to one standardized platform over several years. • Rapid DataFlow® and FIX® database conversions. • Distributed Historian databases. • Alarm Notification System integration. Fountain Hills Sanitary District Fountain Hills, AZ • Wastewater Treatment Facility (WTF). • Advanced Water Treatment Facility (AWTF). • 5 Aquifer Storage and Recovery (ASR) Wells. • Redundant Internet networks (DSL, Cable) for remote access. Seawater Treatment Plants Bahamas Water & Sewerage Company Island of New Providence • Blue Hill Water Reverse Osmosis Seawater Treatment Plant supplies 18,444 m3/day of water to 300,000 residents. • Centralized monitoring & control for plant and nearby tanks and pumping stations. • Interfaced to existing Motorola® MOSCAD RTUs. ■ Interfaced with Netbase® optimization software to help reduce millions of dollars in non -revenue -water (NRW) caused by widespread leaks in their aging pipe network. Or Islands a1/4 Turks and Caicos Water Company Providenciales Island • Single source water system upgraded without service interruption. • Designed and integrated by ProPump & Controls, Inc. • Monitoring and control of reverse osmosis desalinization plant with annual capacity of three -hundred million gallons. • Two new pre -fabricated pumping stations added. • Includes SCADAPack RTUs, Allen Bradley 503 and 505 controllers, and GE Versamax controllers. • Plant employs Modbus, DF1, and Ethernet communications. ran - P 450 M H I d d d d I I ump stations use z icense ra ios, customize scripts an ca cu ations. Water Distribution Warren County Water Warren County, OH ■ Distribution and water treatment. ■ Redundant servers and alarm notification. ■ Data extraction using ODBC Server. ■ XLReporter for Monthly Operating Reports (MOR). Hosted SCADA (Software as a Service) Benefits of Hosted Systems • Low upfront installation cost. • Predictable monthly expense. • Reduced maintenance. • Centralized data collection and storage. • Secure customer data access via Thin Client. • Distributed redundancy for disaster recovery. Kennedy Industries New Hudson, MI • Water and wastewater systems. • New customers online in days. • Supports 100 + PLCs and RTU manufacturers. • Variety of communication links (e.g., cellular, satellite). • Hybrid option allows local SCADA with hosted failover and backup. KISM SYSTEM MASTER KI STATION MASTER 45/1 mum. son 41 HamburgRd rum sP. sun lam room 301 201 ly R..F IS• 131 ST/1pN III Pay. Vrx. r CI R as ,:,' Hydrology vr • v• Site Map Gainesville • Ocala ✓ 27 • • P Coast 'Delia rlando • •• •• f LR I D A toff • • • • • • $ •• OpenStreetMap Contributors (www.openstreetmap • try Southwest Florida Water Management District Levee AlA 528 Palm la F of • I � !'t Ir r!I ei Neal.. � r . K. m t 14 I•� M S l 0 0 1 Im m MI Southwest Florida Water Management District Florida, USA • Over 300 dataloggers and PLCs. • Public Internet access to hydrologic data. • Logged data retrieval from field devices. • Dam and weir control (28 locations). • Oracle interface for hydrologic data modeling. Water Management and Flood Control John Richmond shows off his wirelessly operated VTScada Gate Control System St. Johns River Water Management District (SJRWMD) Florida, USA Serving over 5 million customers in Northeast and North Central FL. ■ Operates flood control structures. ■ Helps to protect water quality. ■ Redundant cellular -based SCADA system. ■ Includes 400 Campbell Scientific remote telemetry units (RTUs). ■ Direct control of flood water gates used during serious weather events. MDLC Features 1/4 STARCONTROLS FEATURES AND UNIQUE BENEFITS OF THE MDLC PROTOCOL Advanced SCADA systems require intelligent communication capabilities in order to assure the flexibility, expendability, reliability, and high performance of the system. In addition they require software controlled managing and maintenance of their communication network. SCADA systems can only be justified if these provide cost benefits to the customers. This can be achieved by combining smart communications into the system, which result in faster, less costly, and safer operation and of the customers' facilities. Motorola provides a solution to this challenge with its Motorola RTU system and the MDLC (Motorola Data Link Communications) protocol. These liberates the system engineering and the programmers from technical constraints and complexities of the communications and allows them to concentrate on their application and system operation. The MDLC communication protocol is based on the Open Systems Interconnection (OSI) 7 layers model published by ISO, which Motorola specifically adapted for SCADA and radio communications. This is the only available protocol for radio which comprises all the seven recommended layers. Here, every RTU may act as a Distributed Control Unit (DCU) and as a communications node serving other units. The following is a list of unique MDLC features and benefits: Application processes Variable length words File Transfer Short Messages The system engineers use the Motorola RTU STS in order to develop, maintain and modify their RTU application processes. They can then transfer the program via the MDLC protocol from -or -to all RTUs installed at the designated remote sites. The MDLC provides the Motorola RTU RTUs with very efficient communications methods, allowing to transmit variable length words (messages) between the RTUs and the RTUs and the SCADA centrals. The MDLC protocol allows to upload and download all types of data including free format files. This can be directly performed between all the sites, i.e. between the RTUs and between the RTUs and the SCADA central. The MDLC supports efficient transmission of short messages (bursts). This is done without actually creating a communications session (dialogue) between the transmitting and receiving sites (RTUs). MDLC Features 2/4 STARCONTROLS Remote Diagnostics The MDLC protocol provides the service technicians with an option to remotely perform diagnostics of the RTUs' hardware and software from any remote site (via an RTU) or from the central location. Remote Calibration The MDLC protocol also allows service technicians to perform calibration of the analog ports in all of the Motorola RTU RTUs in the network from any remote site, via any RTU, or from the central location. RTU to RTU links The MDLC protocol supports direct RTU to RTU links for sending databases, local statuses and analog values. This can be done directly (or via any number of RTUs) which act as a communications node. Process debugging The MDLC protocol allows to remotely monitor and debug the local application programs running in the RTUs. If required, the local process in a certain RTU may be updated without actually disturbing the system's operation. Error logging Error Correction Statistical data Mixture of media Store and Forward Unusual / occasional events are logged in a local error logger in the RTU without the need to wait and catch it in the real time. The logged historical events may be later retrieved via the network for post analysis. The MDLC protocol is equipped with a 32 Cyclic Redundancy Code (CRC) based acknowledge mechanism. Upon error detection, the receiving RTU asks the other side to resend only the damaged or missing frames, rather than the whole message frame. In order to save computer time for the process, the CRC's word calculation is performed by hardware. The MDLC allows remote access to each RTU (via the communications network) from any location, in order to obtain statistical data on the operation, events, parameters and processes at any of the designated sites. The MDLC protocol allows efficient combining (into the same data network) of several communication media such as cellular, radios, microwave, fiber optics while optimizing the overall performance of the system's operation. The MDLC protocol supports the use of the Motorola RTUs in the network as repeaters for data transmission. These RTUs may perform "store and forward" function (for range extension) by reusing the same channel. MDLC Features 3/4 STARCONTROLS Multiple centrals Data reliability Multiple physical ports Multiple logical links Multiple addressing Address recognition Multitasking operation Protocol emulation Use of radio media The MDLC protocol supports network communications with any number of Master Control Centers (MCC), and sub control centers in hierarchical scheme. These MCCs may be linked to the network at any RTU location. The MDLC protocol provides node -to -node as well as end -to -end data acknowledgement via any number of communication nodes (and media) between the RTUs and between the RTUs, and the SCADA central. The MDLC protocol supports multiple physical ports (Ethernet, Radio, RS-232, USB etc.) in a single RTU, enabling simultaneous communication via more than one port. The MDLC protocol allows simultaneous communications of multiple sessions via the same physical port (Central-to-RTU and RTU-to-RTU sessions). Sessions sent via the different logical links do not interrupt each other. The MDLC protocol supports: individual RTU addressing, system addressing for broadcasting the same message to a defined set of RTUs, a common address to all RTUs, and a spare address for future communication options. In order not to waste valuable process time spent on checking addresses of messages not intended for that site, the MDLC supports initial address screening in hardware. This increase the overall throughput over the network. The MDLC protocol support performance of several tasks (local processes and communications) without interrupting the normal operation of the RTU i.e. the local process and the control processes at other sites. The Motorola RTU allows emulation of other SCADA protocols. This will allow using the MDLC protocol a in combination with other SCADA systems by using of a Gateway or Bridge or Router connecting between various media. The MDLC protocol supports a wide variety of wireless and line media, including cellular, conventional, trunked, Data Radios, Fiber optics, Line, Satellite and Ethernet. Any combination of these and other physical channels may be integrated into a single data network. MDLC Features 4/4 STARCONTROLS Contention reporting Time tagging The MDLC protocol supports event reporting in both polling and contention modes. In the latter the RTU contends for the channel and will send its message only when the channel is available (free). This results in significant reduction of air time loading. The MDLC protocol is suitable for electric Distribution Automation systems, since these require support for system -wide time synchronization (RTUs, communications and central) with an accuracy of up to 1 milliseconds. For more information Contact Us: Tel: 1 + 954-604-6656 sales@star-controls.com www.STAR-CONTROLS.com 11555 Heron Bay Blvd, Suite #200, Coral Springs, Florida 33076 USA MDLC Reliability 1/2 STARCONTROLS Communications Reliability under MDLC This memo provides some highlights on the different mechanism for the reliable transmission of information as provided by the layered architecture of the MDLC protocol. The MDLC protocol was designed according to the guidelines provided by ISO regarding seven layer protocols, OSI (Open Systems Interconnection). The basic structure of the protocol is depicted in Figure 1. End -user application process I Application Layer Presentation Layer Session Layer Transport Layer Network Layer Link Layer Physical Layer i Data communication network File transfer,access and management, document and message interchange, job transfer and manipulation. Transfer syntax negotiation, data representation transformation. Dialogue and synchronization control for applications entities. End -to -end message transfer (connection management, error control, flow control) Network routing, addressing, call set-up and clearing. Data link control (framing,data transparency, error control), media access control. Mechanical and electrical network interface definitions. Figure 1. MDLC layered structure The usage of a seven layer structure in MDLC was especially designed to offer a grade of protection similar or superior to that encountered using line communications, but when operating mainly with radio communications which inherently are less reliable. The basic reliability of the protocol is given by the Link Layer protocol. When used in a radio environment, a powerful CRC-32 error detection code is appended to every transmitted frame. This error detection mechanism makes it virtually impossible for an errored frame to go undetected by the receiver. At the receiving end, every frame is checked for errors. If no errors are detected, the frame is passed to the upper layers of the protocol for further handling. A positive acknowledgment is then issued to the transmitter side to inform it of successful reception. If an error is detected, no acknowledgment is issued and the frame is discarded. The transmitting end, after a predetermined time-out, retransmits the unacknowledged frame. This is called a link retry. The number of retries is programmable and is set, by default, to four, i.e., the original transmission plus up to four retries. Let's assume that the probability of losing a frame in the channel is equal to 5%. It can be easily shown that the probability that a frame will not be received after four retries is on the order of 3.10-7. MDLC Reliability 2/2 STARCONTROLS A second level of end -to -end reliability is provided by the network and transport layers. The network layer is responsible for the routing of information through RTUs in the system that act also as communication nodes. In addition, it is the role of the network layer to identify an alternative path between end points in the case where a link is declared as unusable. An example is given in Figure 2. Normal Route Alternative Route Figure 2. Alternate routing In Figure 2, the communication from RTU A to RTU B is normally done using the upper path of RTUs. Assume that the first link in the upper path breaks. The Network layer automatically uses the alternate route in order to pass the information to RTU B, using now the lower path of RTUs. In a properly designed system, a link failure does not make the entire communication system unusable. Whenever a network is involved in communications, frames can get from origin to destination in the wrong order. For example, a frame transmitted between two nodes in the network may necessitate retransmission due to errors and may incur extra delays in that portion of the network. The transport layer at the destination site is responsible for providing the received frames in the correct order to the application. It will do that by delaying the out -of -order frames until the missing frame is received. An important task of the transport layer is its responsibility for the end -to -end integrity of the information. If the transport layer at the receiving end detects a 'gap' in the received frames, then, after a predetermined time-out, it requests from the originating RTU to resend the missing information. This process is known as a transport layer retry. This can occur when part of the information is lost due to a broken link somewhere in the network and information is rerouted through an alternate route. The retry mechanism at the transport layer offers this supplementary protection so as to guarantee end -to -end integrity of the transmitted information. An additional level of protection is offered at the session layer of the MDLC protocol. One of the tasks of the session layer is the synchronization of large transactions that may experience faults. The synchronization of lengthy information is especially important when unreliable media is used. It allows the application to continue from the point where the communication was interrupted without the need of starting all over again from the start of the application/communication. The MDLC protocol was designed as a seven layer protocol, not only to provide a flexible communication structure but also to enhance the reliability of the communications to levels similar to those obtained with reliable media. For more information Contact Us: Tel: 1 + 954.603.0491 Fax: 1 + 954.603.0492 sales@star-controls.com www.STAR-CONTROLS.com 11555 Heron Bay Blvd, Suite #200, Coral Springs, Florida 33076 USA VTScada by Trihedral Alarm and Event Management Standard Component 00 viScada Alarm Page em Awn, DB YY d O CI ® 0 ® D 11 1171 Y OR- F® 7. to =i alarm Actions reports &Analysis History Filter View Sounds History Active Unacked Current Sheered Disabled Configured Time Ack Status Area Name 21 2016-05-03 13:40:32 Ack • Alarm - Zonal ❑2 2016-06-03 13:36:39 Ack Ack Ack Ack Ack • Alarm LM Pre -Mix WaterDistributionSystem\Zone1W-`-- ""- r•-•-• 1 Flo Help WaterTreatmentPlant\Pre-Muc\InletBa Acknowledge Shelve Add Note Show Details ck Pre Out -of -the -Box Alarm and Event Management Thanks to VTScada's integrated design, every new application includes pre -configured databases that support an unlimited number of process alarms and events. Additionally, the standard VTScada Alarm Page provides an instantly intuitive alarm management interface. This approach reduces integration time and ensures that your mission -critical alarm features remain tightly integrated over the life of your system no matter how many times you expand your application or update VTScada. ISA 18.2 Compliant - The re -imagined alarm page and augmented tools help you enact the best practices outlined in the ISA 18.2-2009 Alarm Management Standard. VTScada Anywhere Client — This new Thin Client display option provides a consistent alarm interface across computers, phones, and tablets. Intuitive Operator Interface In the event of an alarm, simply click the blinking icon in the top right corner of every page to jump to the VTScada Alarm Page. • See current, active, unacknowledged, and disabled alarms. • Easily sort by date/time and filter by functional area or priority. • Acknowledge, silence, or mute alarms even while configuring. • Shelve alarms to stop alerts during maintenance and alarm floods. • Print any range of the alarm or event history. • Reduce eyestrain by choosing daytime and nighttime views. • Adjust text and row size for optimal viewing on different screens. • Access a time -stamped list of system events (e.g., logons or setpoint changes). Advanced Situational Awareness • Instantly identify the status and priority of each alarm in the list. • Plot the associated tag's data or open related displays. • Use a combination of text, symbols, color, and sound to best meet the visual needs of your team (e.g., color vision deficiency). • Provide context by adding encrypted operator notes to alarms. Require notes when acknowledging, shelving, or un-shelving alarms. • `Alarm Details' dialog provides an overview of each alarm's configuration, history, and notes. • Secure remote Thin Client access allows operators to manage alarms from anywhere using their own mobile devices. • New VTScada Anywhere Client provides access to all advanced alarm analysis tools. 1A5PM May3 � Logon of wear wiwiti*vinviailia 10.0uw..r..m.evw00.t 111 Pew!. u.ww.on*..un ... W_ VbMY+wi IN hwant nionnatrianAiini The New VTScada Anywhere Client Bad Actors Norm rbod History Dis8tiuson of Mantes P a Reported History Current Configuration ISA 18.2 Recommended 0 17% 83% 0 33% 67% 0 5% 15% 80 VT Alarm Details X WaterTreatmentPlant\Pre-Mix\RawWater\Turbidity Pre -Mix RawWater Turbidity Hi Warning Details Configuration Statistics Notes Selected record notes Logged Off acne: May 6, 201612:57:41 Removed buildup. Behaving normally now. Problem has returned. Perform another visual check on the day shift. [Insert a Quick Notel Comment I Add Note I I OK I ICancel OK Encrypted Alarm Notes VT Shelve Selected Shelve the selected alarrn Q for 5 minutes `1 0 until 31 2016-05-04 12:00 0 indefinitely OK 1 Cancel Alarm Shelving Expiration Triheciral A Delta Group Company vTscada by Trihedral Alarm Diagnostics and Nuisance Alarm Reduction Four new alarm reports help you to easily identify trouble spots in your physical system or the application's configuration. All Databsse 0 ®L' Analysis 3043 — ' Ir® AA -I I * Fifer View Bad Actors Alarm Flood History Distribution of Priorities Area ® Zone1 • Zone2 3 Q Zone 3 Name Local TCP Port\PLCSim\Tank 1'1Tank Level Local TCP Port\PLCSim\Tank 2'1Tank Level Local TCP Port1PLCSim\Tank 3't,Tank Level Description Monitor tank level HIGH Monitor tank level HIGH Monitor tank level HIGH Count 2 5 Percent 14 663 23.8 % 9.5 5''; Bad Actors Report —A 'bad actor' is an alarm that is tripped excessively indicating problems with equipment, processes, or alarm configuration. Easily spot bad actors by scanning alarm events within a specific period, sorted by the number of activations. Bad Actors Alarm Flood History Distribution of Priorities P 1 % 00 Mar 20 .1 I r 11 ..I II 1 Mar 25 Mar 30 Apr4 All Database 6 ® D u LU 10d - Y 71- 7E) PA —I I f1: Annl),is Filer Bad Actors Alarm Flood History Distribution of Prionties Date Event Area Time Name Description P User 16-04-07 12:03:29 • Active Zone Local TOP Port\PLCSim\Tank Wank Level Monitor tank level [UGH 2016-04-07 11:00:50 * active Zone 1 Local TCP Port\PLCSim\Tank 1\Tank Level Monitor tank level HIGH Active Zone 1 Local TCP Port\PLCSim\Tank 1\Tank Level Monitor tank level HIGH Bad Actors Alarm Flood History Distribution of Priorities .p Reported History Current Configuration ISA 18.2 Recommended 17% 83% C 33% 67% 5% 15% 80% Critical Hot, Critical F.c' Critical Filth ♦ ■ 0 • ■ © • ■ Alarm Flood Report — An 'alarm flood' occurs when there are more alarm events in a specific period than operators can reasonably handle. Quickly identify floods by moving your mouse over the blue bars to see the number of alarms tripped within periods of time. Click a bar to zoom into that period. History Report - This pre -filtered list shows only Active and Trip alarm events. Select an alarm then use the tools in the Analysis Toolbar to gather more information about it. E I • Alarm Details • Historical Data Viewer • Open Associated Pages • Alarm Properties Distribution of Priorities — Easily compare your application's alarm priority distribution with the ISA 18.2-2009 Alarms Management Standard. Compare the priority distribution for both your reported history and current configuration with the distribution recommended in the ISA 18.2-2009 standard. Trihedral A Delta Group Company vTscada by Trihedral Multi Plant Architecture - Centralized Management, Autonomous Operations Configure multiple alarm databases to separate operational alarms (e.g., plants and processes) for targeted alarm processing. System Alarm DB System Event DB epo7s.=.n, Unacked Current Shelved Disabled Configured Time Ack Status Area New VTScada applications include separate alarm and event databases. Existing applications are automatically converted. • The Alarm Database Tag allows you to add more databases as required and synchronize them across a network. • Filter the Alarm Page on any networked workstation to display lists from one or all of them. • Locally stored databases allow operators to manage and modify alarms even when disconnected from alarm servers. • Synchronized distributed databases keep your priceless alarm and event history safe and up-to-date. Areas of Responsibility Define what information users can see in large applications. For example, if an application monitors two plants, operators may see and respond to alarms from their respective plants, while the management team can see alarms from both plants. Efficient Alarm Configuration In seconds, authorized developers can create alarms in the Alarm Tag Properties Dialog in the VTScada Tag Browser. To simplify the process further, Alarm Tags are built right into the Analog Status and Digital Status Tags. Developers can also embed customized alarm lists into any custom display using the VTScada Idea Studio. Configure pop-up dialogs to ensure that operators are aware of high priority alarms. Uninterrupted Alarm Management VTScada's online configuration allows you to view and acknowledge alarms even while editing application tags, screens, and properties. SCADA Alarm Security Tightly control access to the Alarm Page and Alarm properties using application -level privileges assigned to specific user accounts in their areas of responsibility. Users must log in with their own credentials to access alarm information via workstations, Thin Clients, and alarm notifications. Alarm privileges can be revoked instantly across the whole system. Alarms/Events 2016-05-02 09A6:36 WaterDistribution5ystemk,\TankLow 2 Tank level too low - Tank 2 l- ----- •^- Application Application Started (0 min 19 sec) Ack All i Embedded Custom Alarm Lists VT Alarm(WaterDistributionSystem\Zone_2\Tank_24TankHigh_2) Properties x ID Triggered by Trigger Actions Display [TankLevel_2] Level of Tank 2 Q Constant Function 0 Expression EINJA ® Tag Greater Than > Setpoint [TankHiAtmSpFeedE_2] Tank2 high alarm setpointfeedback I X 0 Constant On Delay (s) C,. Expression Q Tag 0 Off Delay (s) 10 ® Constant 0 Expression 0 Tag Q Constant 0 Expression 0 Tag Deadband 4 0 Constant 0 Expression ?- Tag OK Cancel The Alarm Tag Configuration Dialog Triheclral A Delta Group Company TRY IT FOR YOURSELF Download the 90-day Trial VTScada.com/trial vTscada Mobile Alarm Management Optional Component VTScada Thin Clients allow authorized users to view and acknowledge alarms from anywhere. Authorized Thin Client users can easily select the display format that best suits their screen size and data plan. • The VTScada Anywhere Client — State-of-the-art Thin Client provides a consistent operator experience on any HTML5 device. Event -driven execution provides real- time data without overloading your data plan. Zero -footprint means nothing to download and install. No Java either. • VTScada Internet Client (VIC) - Windows PCs - Identical to a VTScada Thick Client operator workstation. • Mobile Internet Client (MIC) - HTML5 browsers on smartphones, tablets, PCs, and Macs - Text -based alarm interface optimized for smaller screens and data plans. Note: WAP is discontinued as of 11.2. Alarm Notification System Optional Component When alarms happen, your SCADA system needs to alert the right people as soon as possible no matter where they might be. • Automatic Alarm Callout - The VTScada Alarm Notification System (ANS) transmits alarm information anywhere via text -to -voice phone calls, SMS text messages, emails, and pagers. • Built -In is Better - VTScada's unique integrated approach vastly reduces integration time and ensures tight compatibility over the life of your system no matter what version you are running. The ANS shares the same tag and alarm databases as the VTScada application. • VoIP-Based Voice Alarms- In addition to physical modems, VTScada now supports three additional ways to send text -to -speech alarm notifications. • VolP to phone lines via analog telephone adapter (ATA). • VolP to PBX via internal digital phone service. • VolP to online VolP Service (Voice only). New in Version 12.1.35 - Use the above as well as Twilio Programmable Voice° and voice modems as redundant backups for voice alarm calls. VolP now allows encrypted call setup and encrypted audio. by Trihedral LUS? 3:26 PM 01, M. Scala Alarm Page ♦ - T: • ■ ®\ IIIm .e - • N• eA 4 A =t • E e n • Event Event Event Event Event Disable Disable Disable srvtem System :stem sretem System APaeat°m APPleaton APlakaton SetDdaula APPIea LM Pre-Mn WaterireatmentPlant,. - HiVhmmE NetwortInbrmation NetxorklnlwmamnAanmaryAYnDakr LM Io. LAt W.p Saw LSurteValveOPen I451 AP AP ro cn Re - E • • • J The New VTScada 'Anywhere' Client • Dial -in Phone Access - Dial into your application using your application security account to check levels, acknowledge alarms, change setpoints, or send commands to equipment. • Licensing - Add ANS to any VTScada Runtime or Development Runtime license by simply updating your software key. • Easily Configured Rosters (Updated in Version 12.1) - Rosters are lists of up to 39 users to contact in sequence until an alarm is acknowledged. ID Create any number of rosters for the whole application or functional Method """` e Start or roster aareas. Change rosters by events or on schedule (recorded in history). a Email Bob Easily reorder Roster Contacts via arrow buttons. a Email Sue Compact Email M. Set wait times for each contact or notify multiple contacts in one 'Iburst'I. X Delay for 1 minute • Repeat contacts without adding them multiple times. o Text Message Bob 902-555-0000 • Allow users to configure Rosters without the ability to modify tags. ' Delay for sm;"°tK sr` Voice Bob 902-555-0000 L Repeat 3 tunes unt 5 mnute O End of roster + Add contact + Add delay/repeat Phone Number / Erna, Address Usemane T Zara Enalied bob®mycompany.com sae®my<ompeny.<o- mavmy<omwny.<om bob sue bob Savers zone Sen.rr zone Saverhn.Zone Server Tom Zone Savable Zone OX Cancel Updated May 8, 2024 Intuitive Roster Configuration. VTScada.com info©trihedral.com 1.800.463.2783 (North Armin) 1.902.835.1575(Woddwida) +44 (0) 1224 25801 D (Europe) Trihedral A Delta Group Company Trihedral Engineering Limited 2024. VTScada and Tr' hedral are registered trademarks of Trihedral Engineering Limited. All other products are trademarks of their respective owners. vTscada The VTScada Alarm Notification System A fully integrated solution designed to work seamlessly for the life of your system. Optional Component Today's SCADA operators are too busy in the field to have time to sit looking at screens all day waiting for problems to occur. When alarms happen, the system needs to be able to get that information to the right person as soon as possible no matter where they might be. The VTScada® Alarm Notification System (ANS) transmits alarm information anywhere via text -to -voice phone calls, SMS text messages, emails, and pagers. Dial into your system using your application security account to check levels, acknowledge alarms, change setpoints, or send commands to equipment. Built-in is better VTScada's unique integrated approach to alarm notification vastly reduces integration time and ensures tight compatibility over the life of your SCADA system no matter what version you are running. Add ANS to any VTScada Runtime or Development Runtime license by simply updating your VTScada software key. The ANS shares the same tag and alarm databases as the VTScada application. Note: Alarm and event management is part of every VTScada application. The built-in SCADA alarm notification features described here are optional. by Trihedral A, VTscada VTScada • 11 New in VTScada 12.1 - Annunciate Voice Alerts over VolP, no modem or Internet VTScada will continue to support physical voice modems for text -to -speech alarm annunciation while they are available. However, it is increasingly difficult to find companies that produce them. Worse, telecom providers are phasing out support for data over analog lines. Version 12.1 lets you move beyond this hardware and take advantage of the benefits of VoIP without going through the internet. Leave no alarm unacknowledged - When an alarm goes unacknowledged for a user -defined period, VTScada won't stop until it finds an authorized person to acknowledge it. The system begins working its way through rosters of up to 30 contacts each. A contact is a combination of a staff member and a method of notification such as SMS text message, email, or over the phone via text -to -speech voice engine. This means you can create a contact for your cell phone and another for your landline. Configure any number of rosters for the whole application or specific functional areas. Roster activations are recorded as events in the alarm history. Dial -in phone access - Dial -in from anywhere to log in and use the auto -generated spoken menu's system to hear system values (e.g., well levels), perform control actions (e.g., start pump 1), and receive or acknowledge a list of alarms. Acknowledge by SMS, email, or text -to -voice - Once you are notified of an alarm via SMS text message, email, or text -to -voice phone call, you can easily acknowledge it the same way and stop VTScada from sending further notifications. ••.•. TELUS ? 4.23 PM Messages VTScada Contac: 04/29/2014, 04:12 PM. Zone 1 - Tank 1 level too low Code: 9MCZ Clk 04/29/2014, 04:12 PM. Alarm Acknowledged: Zone 1 - Tank 1 level too low O Crystal clear text -to -speech - VTScada uses the Microsoft® Speech API (SAPI). In addition to providing the latest in text -to -speech technology, SAPI simplifies our licensing and significantly reduces the size of the VTScada installer. Voice modem support - VTScada should work with any standard voice modem. Though we cannot guarantee the compatibility of third -party modems across all Windows operating systems our engineers have identified modems that they have used or have been used by our customers on our VTScada Support Forum. VTScada.com/modems Triheciral. A Delta Group Company \/TScada by Trihedral New in VTScada 12.1 - Alarm Notification/Roster Enhancements Version 12.1 makes it even easier to ensure your critical alarms find you anywhere. • Clearer and Easier Configuration - The Roster Properties dialog has been revamped to make it easier to organize the contacts. ■ Drag -and -drop Reordering — This includes the ability to easily reorder contacts in the roster via drag -and -drop. • Custom Callout Delays - Rather than a single delay between roster callouts, you can now set a custom wait time for each contact. ■ Notification Bursts — Custom delays allow multiple contacts to be notified in one "burst" by setting no delay between them. • Repeat Groups of Contacts - One or more contacts can be repeated in a roster without having to add them multiple times. Yi Roster (Rosters \Roster 2) Properties X ID Contacts Settings Method Name Phone Number / Email Address Username Time Zone Enabled Po Start of roster 0 Email Bob bob@mycompany.com bob Server Time Zone ..11 X 0 Email Sue sueamycompany.com sue Server Time Zone R X 0 Compact Email Max max@mycompany.com max Server Time Zone 0 X 11 Delay for 1 minute X 1 lJ Text Message Bob 902-555-0000 bob Server Time Zone M X 11 Delay for 5 minutes X r L Voice Bob 902-555-0000 Server Time Zone El X L Repeat 3 times with 5 minute delays X 0 End of roster + Add contact + Add delay/repeat OK Cancel Apply Advanced modem management - VTScada collects modems from all application servers into a single pool. VTScada searches this pool, rather than a specific server, for an appropriate data or voice modem to use when sending alarms. Twilio®, an alternative to physical modems - Problems with modem reliability? Unable to run phone lines to your server farm? Having difficulty sourcing voice modems? The VTScada Alarm Notification System can now support voice telephony and SMS alarm notifications using Twilio, a paid web -based communications platform. This requires SCADA access to the Internet and a Twilio account (www.twilio.com). Running VTScada as a service? — VTScada can optionally run in the background without an active user interface. Note that Microsoft does not permit Windows services to access SAPI, the built-in Windows text -to -speech engine. This means that if you're using the VTScada Alarm Notification System and you have configured your application to run as a service, the outgoing alarm calls will be silent. In this case, we recommend using Twilio (above) for alarm annunciation. This is not an issue for standard VTScada installations. Automatic failover - Server failover is an important factor in ensuring uptime and accessibility. This extends to alarm notification. Easily create lists of backup alarm notification servers that will automatically and seamlessly take over if the primary is unavailable. Responsibility will return to the primary server when it is restored. Application -level security - Secure access on incoming and outgoing calls is maintained using the standard VTScada Security Manager. To receive status or alarm information, users are prompted by VTScada for their password. Users who do not have the 'Alarm Acknowledge' security privilege will not be able to acknowledge alarms. Hardware requirements - Hardware requirements depend on how the notifications are sent. • For spoken alarms and pager notifications, the Alarm Notification System uses a modem to make outgoing calls. • For email notifications, configure an email server or provide access to a commercial server such as Gmail®. • For SMS-text notifications, you will need an SMS appliance. SMS hardware is not covered in this guide. Mobile alarm management - VTScada Thin Clients (licensed separately) allow you to securely view and acknowledge alarms anywhere using PCs, or HTML5 compliant mobile devices. DOWNLOAD THE 90-DAY TRIAL VTScada.com/trial Updated May 17, 2022 VTScada.com Infoatrihedral.com 1.800.463.2783 (North America) 1.902.835.1575 (Worldwide) +44 (0) 1224 258910 (Europe; Trihedral A Delta Group Company © Trihedral Engineering Limited 2022 VTScada and Trihedral are registered trademarks of Trihedral Engineering Limited. All other products are trademarks of their respective owners. VTscada by Trihedral Historical Data Management and Trending Standard Components Scciva A world -class historian that protects your data and puts it to use across your organization Available at no extra cost, the VTScada® Historian is an integrated component requiring no configuration or database management. Real-time synchronization ensures your history is safely distributed across all redundant servers. Developers can fold logged data into a variety of user interfaces while operators can create their own ad -hoc trends and reports. VTScada easily shares data with third -party business platforms. It can even import the history from your old legacy system. The VTScada Historian The only database specifically designed for SCADA Most SCADA platforms require a third -party database to store logged data. These products were designed to be generic tools used in almost any field such as accounting, academia, or sales management. Only VTScada includes an Enterprise historian designed specifically for SCADA applications. In addition to being fast and compact, this approach makes it possible to easily scale your application from a few hundred tags to a few million. There is no need to upgrade your simple "starter" database when your system starts to grow. This pre -configured historian vastly reduces integration time and eliminates the need to separately license and support third -party products. Best of all, each configured redundant server automatically contains an up -to -the -second backup of the whole database. 3R Party Databases via SQL Manual Data I/O Tags _a Calculations Totalizers Counters Alarms Electronic Operator Logbooks Log data from multiple sources based on triggers Data is stored directly to the Historian at the time of trigger occurrence, eliminating any need for separate real-time and historical databases. VTScada can log on change, on related event (can be used for disable/enable), on time/sample period, or on operator actions (e.g., manual data entry, setpoint change, or control action). A Delta Group Company Upon request, the Historian analyzes • Time -weighted average (analog) • Minimum (analog) • Maximum (analog) • Change in value (analog) vTscada by Trihedral Summary, on -demand data raw tag data and provides time -series summary divided into time slices. • Value at start (analog) • Time of Minimum (analog) • Time of Maximum (analog) • Totalizer (analog) Multiple Historian configuration ite vie N' ERNET� - 'p INT data, based on a user -definable duration • Interpolated (analog) • Diff between start and end (analog) • Zero to non -zero transitions (digital) • Non -zero time (digital) Historical Data Synchronization 1 r VTScada supports any number of historians for a single application. Each one can be configured to store data for a different geographical and functional area. Each tag may store data to one Historian. VTScada also allows you to configure redundant third - party relational databases such as Microsoft SQL, Oracle, and MySQL. These must each be separately purchased, installed, supported, and backed up as per their respective manufacturers' instructions. Redundant Historian configuration Thanks to VTScada's integrated design, every application server can host its own Historian. Each data point is stored identically on each one. Redundant Historians can also include third -party formats. For example, the primary and secondary could be the native VTScada Historian while the secondary backup could be Oracle. Redundant Historians may be co -located with the Primary or geographically separated provided an IP connection exists between them. Bi-directional synchronization Redundant Historians use the same schema. VTScada uses timestamps to ensure that each data -point is identical down to the millisecond. Should the primary database server fail, associated workstations and Thin Clients seamlessly switch to the next designated database. When restored, historical data automatically synchronizes across a local or wide area network at up to 160,000 values per second. This speed is automatically throttled to avoid interfering with real-time communications. If servers become isolated from one another, they will continue to log their own local I/O and automatically sync once their connections are restored. Long-term data storage. No more archiving. Data archiving was traditionally used in long-term historical data storage to mitigate limited drive space, and to provide a form of backup. VTScada makes this unnecessary. Its efficient storage format packs more data into every megabyte of hard drive space compared with other standard database formats. Using redundant Historians, as described above, is a far more robust backup methodology. Logged calculated values do not count against the licensed tag count. A Delta Group Company vTscada by Trihedral Secure historical data VTScada's Historian cannot be edited within VTScada or by third -party software. The proprietary log files are not human readable. VTScada uses a checksum to detect tampering or corruption. Note: If you are also logging to a redundant third -party database you will need to secure it as per the manufacturer's instructions. Historical data editing While the Historian cannot be altered, it is possible for authorized users to override individual or ranges of logged values. This is a helpful way to fix incorrect or missing values. Edited values are marked in the Historical Data Viewer along with a required explanatory note. Overwritten values are not lost. History data import from CSV files When replacing a SCADA application of a different software brand, VTScada helps you maintain a complete view of your process history, allowing you to import the historical data from your legacy system. Consult VTScada Help for information on formatting files for import. Simple Historian status monitoring The Historian Status Monitoring Widget provides instant status of write and storage rates. When write rates exceed storage rates, data is automatically buffered and written in burst mode when the Historian connection is available. VTScada write rates have been tested to 4,000 values per second for a single tag, thus buffering is usually the result of a slow network, underpowered CPU, or slow storage media. Historian Status Name Current Server Connection Status Queue Length Write Rate DB Store Rate Service Status - SystemNarmHistorian LAPTOP1 Connected 0 0 0 Ready SysternHistorian LAPTOP6 Connected 0 16 16 Ready Sharing Historian Data with Third -Party Platforms VTScada makes it easy to share real-time and/or historical data with third -party software platforms via these industry standard protocols and methods. • OPC Server - Allows OPC-compliant programs (including other VTScada applications with OPC clients) to exchange live data with standard VTScada applications. • OPC Client (DA & UA) - Allows VTScada applications to exchange live data with an OPC-compliant server (including VTScada applications with OPC servers). • ODBC Server - Allows you to use popular software like XLReporter®, Dream Report®, Crystal Reports®, Access®, or Excel° to extract VTScada system data. VTScada acts as a database where each logged tag represents a table of timestamps and values that reporting software can query to retrieve logged values. • REST & WEB Services - VTScada's REST and SOAP (XML) interfaces allow business systems to request real-time and historical data. They support time/date ranges, min, max, time of min, time of max, average, total, and SQL that include SELECT commands and WHERE clauses. • Third -Party Reporting - Third -party reporting products, such as e.RIS®, XLReporter®, and Dream Report®, have integrated VTScada interfaces. A Delta Group Company by Trihedral The VTScada Historical Data Viewer (HDV) A powerful trending tool that any operator can use. IIIstorical Uala Viewer '"HL 3 III k The HDV provides a continuous view of analog and digital data. • 11500 :MOO r21&10 Ik11f11 [5:It 0 1kM60 r5t1R50 1SSt00 152tl0 flit00 1]2i]0 IT13O0 112110 13:2A91i Ptn Hem anal rim O +fir .540psver.11rAeo Upebreem aawItIte O h. .11M,0.Fwew. MRn41.t0.104 9 . Pe.nwll}.te`.STmpie'*Rd imt:.e 2.411.2 Sped O ',pwwgrerrnfywP.. WpWe.m Ow. Rab • �.glpe.ns..�.rfmlb.et ®rP•re.5aen r.enere O System Hetes SdI R']ys }1% 457 RPM 506k^in clff snip[ 600 h"11s i% 19]R)H9 SW0^!n The VTScada Historical Data Viewer (HDV) is just one of the ways operators can This standard interface provides a continuous view of historical and real-time analog and digital I/O values. Move the Marker Line horizontally to see continuo at every selected timestamp. Icons in the Pen Legend below allow you to •1t wuhw.hrA.ntDme . TCAOM . W nee.0004ndi.. q.ny.. I0mp1 ,JSro.OJtren Shaw I NT/se weave Pum1Cvnrx PumeCuuem J Pumpibw 6enp Fbw J Pom0Reset Pact NMI J Pumg0PM Pump RPM J 904000 wp Pomp Parr J hrnoSpeedS, Ramp *p * A O PumpSyeelseCed Pump*. J w.vpee srro Pomp arm L J Po.wSpeedinpSP Peep Spa ilS J hmp0p..dT.S0C3I Pomp Spee o Purs00100 y't ^e"p X .12C12 100I6 112 RIe1 400I0 Vcw.r.m, I 10 Cut G% *oe 00 Gnu NreC1+d 00ele a.. 40014 40110 15 10015 10111 110 Plot tags right from the VTScada Tag Browser. Time Sep 25 02445 Sep 25 0230 Sep 25 02:15 Sep 25 0200 Sep 25 01:45 Sep 25 0130 Sep 25 01:15 Sep 25 0190 Sep 25 0045 Sep 25 0030 interact with their application's process history. data on a single timeline. It can include both usly updated values for each plotted analog tag hide pens (tags) or edit their appearance. ..\Filter#1\Turbidity ..\filterd2\Turbidity ..\fil[ct3\Turbidity .. Fillerd1 Turbidity Filler432 Turbidity Fitler#3 Turbidity 0.0648600 0.0E48600 0.0648600 0.0648600 0.0E48600 0.0E48600 0.0648600 0.0648600 0.0648600 0.0648600 0.061800 0.061800 0.061800 0.061800 0.061800 0.061800 0.061800 0.061800 0.061800 0.061800 1 �.0648600 0.0E48600 0.0648600 0.0648600 0.0648600 0.0E48600 0.0E48600 0.0E48600 0.0648600 0.0618600 See raw values in the Grid View tab of the HDV. Instantly intuitive trending designed for operators In addition to the standard page, you can also configure the HDV as a pop-up display or as an embedded trend group on custom pages. Best of all, operators can create and save their own ad -hoc trend groups with just a few clicks. They can also trend values right from the tag browser, or alarm page (image above left). HDV tabular view HDV data may also be shown in time -series tabular view (image above right), as raw data to the nearest millisecond, or as ave, min, or max values. Additionally, to facilitate time -sliced viewing, a total period may be selected, and then further time -sliced to display summary data for each period. For example, 24 hours of data may be shown as 24 separate rows of one -hour averages for a selected set of tags. Download the 90-day Trial VTScada.com/trial Updated March 11, 2022 VTScada.com info@trihedral.com nCi 1.800.463.2783 (North America) 1.902.835.1575 (Worldwide) +44 (3) 1224258910 (Europe1 A Delta Group Company © Trihedral Engineering Limited 2022. VTScada and Trihedral are registered trademarks of Trihedral Engineering Limited. All other products are trademarks of their respective owners. VT�ca�� by Trihedral Report Generation Standard Component Simple Scheduled or Ad -hoc SCADA Reporting Every VTScada software application includes two SCADA reporting components that allow users to create ad -hoc or recurring reports in seconds, the VTScada Reports Page and the VTScada Report Tag. The VTScada Reports Generating your own ad - Page hoc reports is as easy as selecting I/O tags, a time range, and an output format. 00 scada Reports Logon I✓I�®$*I507P 18 -1. Report Type Daily Snapshot Report 2. Tag List �d Group LSave Group Tags Available: (381) Types Analog Status Areas All NetworkInformation\ITDashboardiat NetworkInformation\I1Dashboardiat NetworkInformaeon\IFDashboardfar NetworkInformation ITD shboardar NetworkInformation\ITDashboard,at NetworkInformationV,Dashboerd1M Simulation \Simulated Waveforms (Ini Emulation\Simulated Waveforms Onl Simulation\ Simulated Waveforms (Inl Simulation \ Simulated Waveforms (Ini WastewaterUftStationSystemW orthS WastevaterLiftStationSystemWorthS WastewateriifStationSystem\NorthS WastewaaertifStationSystem NorthS Wastewa6edi9StationSystem\NorthS Wastewate UftS60tionSystem3orthS WastewaterUftStationSystemW orthS Wastewater(ifStetionSystemW orthS WastewatertifStationSystem NodhS WastewneertifStationSystemW orthS WastewetertiftStationSystem\NorthS WastsweterLiftStationSystemW orthS WastewatertiftStationSystem\NorthS Snwtooth Wave Freq 1 Period 60 (Input) Sine Wave Period 1 (Input) Step UpDown Steps 10 Freq 1 (Input) StepUp Steps 1000D Freq B Secs (AS) SCADA Remote Control Command Cancel Delay FB General Fault Code Out of Sequence Indication Reset Mode FB Elapsed Time Meter Elapsed Time Meter Alarm Reset Mode FB Lag Pump Delay FB Level Input Sensitivity FB Level from Analog Status SCADA Remote Control Command Cancel Delay FB General Fault Code Out of Sequence Indication Reset Mode FB Elapsed Time Meter Tags in Report(4) IiftSimulation\LiftStationSimulatedData\MPES liftSlmula0on\DflStationSimulatedData\MPES of imulation\Lift0tationSimutatedData\Pump UftSimulation\LiftStationSimulatedDMa\Pum0 (] SortAlphabeticNy 4 * Maximum Station Inflow (Rate) Feed badc(gpm) Minimum Station Inflow (Rate) Feedback (gpm) Pump 1 Capacity Feedback (gpm) Pump 2 Capacity Feedback (gp))) Ron Report 3. Reporting Pnnod Start Time 3t End 11 1 December2015 / N Su Mo Tu We Th Fr Sa 1 2 3 4 5 6 7 8 9 10 11 12 Pre 13 14 15 17 18 19 [ 20 21 22 25 26 27 28 29 30 1 4.N —5. Report Destination Output Type Default Printer ❑ Email Report ❑Email Report as Attachment Email Settings Printer Default Printer Browse 6. Report Options [L Use Excel to display screen reports L Use separate sheets/tables ET Rename sheets/tables ® 0E Reports Pre -defined SCADA Reports - VTScada provides a variety of pre -defined report types designed to analyze the performance of the equipment comprising your physical system. Most can be used across a wide variety of industries while others are intended specifically for water and wastewater. Any number of additional custom reports can be defined and saved. • Analog Summary Report - The average, minimum, maximum, and total values for selected analog tags within a configured period. • Daily Snapshot Report - A "snapshot" of each included tag's value, at a specified time and date. • Daily Total Report - The sum of values accumulated for each selected set of tags in a specified period. • Derived Flow Report - Displays the number of driver cydes, plus inflow, outflow, and total station flow. • Detail Report - Shows the values recorded for each selected tag, within the given time period. • Driver Communication Error Detail Report - Driver error activity, recorded over a specified period. • Driver Communication Summary Report - A history of driver activity for a specified time period. • Hourly Snapshot Report - A "snapshot" of selected tag's value, every 60 minutes in a specified time. • Hourly Total Report - The sum of the values accumulated hourly for selected tags in a specified time. • Rainfall Report - Per -tag summary of totals in a configured period showing the total rainfall for selected tags in a given period. • Pump Activity Report - Summarized values for Pump Status tags, showing overall pump activity. • Pump Discrepancy Report - Helps spot instances of pumps that should behave identically, but do not. • Standard Report - Shows all the values logged for a tag over a chosen time span. Triheclral A Delta Group Company VTScada The VTScada Report Tag Developers can configure VTScada Report Tags to run a particular report on schedule, automatically. Report Tags are time -zone aware and can be configured to run daily, weekly, monthly, manually, or when triggered by an event. Report Tag Widgets - Developers can add a variety of Report Tag Widgets to their display pages to allows operators to adjust the report setup, without requiring tag configuration privileges. Additionally, the Report Button Widget can be set to re -run the last scheduled report on demand. SCADA Reporting Output Formats • Output reports to the screen, a printer or to any of a number of formats including CSV, spreadsheet, and database. • Reports being saved to a file can also be emailed automatically if the VTScada workstation has access to an email server. • Create your own custom script reports and pre -formatted Excel by Trihedral New Report Properties ID Tag Period Trigger I Destination I Options Types Load Group Analogs Save Group Tags Available: (759) ILiftSimulation\Eift LihSimulation\Life LiftSim u lation\Life LALSimulation\Life LiftSimulation\Life LifSimulation\Life LiftSimulation\Lift LiftSimulation\Life LiftSimulation\Lif6 LiftSimulation\I.ife LiftSimulation\Life V Areas All Maximum Statii A Minimum Static Minimum Static Pump 1 Capacil Pump 1 Capacil Reset Elasped T Set Elasped Tim Pump 1 Elaspec Pump 2 Capacil Pump 2 Capac I Reset Elasped T Tags in Report (3) LiftSimulation\Life LiftSimulation\Life LiftSimulation\Life Call Pump 1 Call Pump 2 Maximum Station The VTScada Repol411,001a°'' + report templates (below). 26 27 28_ 29_ 30_ 31 Water - Wastewater -Technology Daily Report Charts: Energy Used, Efficiency, Hours Run, Total Faults 250.0 200.0 i 150.0 100.0 7 50.0 0.0 Llft5tation of Lift Station o2 liftstation 03 Energy Used Lift Station 04 Lift Statton05 LAE5tati05 oG Lift station07 • Pump 1 ■ Pump 2 • Pump 3 • Pump A Pre -formatted Excel® Report Template Third -Party SCADA Reporting VTScada was designed to keep your process history safe accessible. That includes making this data available to your third -party business systems and reporting packages to facilitate more complex needs, such as state -specific compliance reports. The following are Standard in Development/Runtime Licenses and Optional for Runtime Only Licenses: • VTScada Rest Interface (replaces WebServices) • VTScada OPC Server • VTScada ODBC Server • VTScada Excel Add -In Trihedral also works with reporting manufacturers such as XLReporter° and Dream Report° to create direct interfaces for sharing process data. TRY IT FOR YOURSELF VTScada.com/trial www.trihedral.com 1.800.483.2783 (North America) 1.902.835.1575 (Worldwide) I nfoetrihedral.com +44 (0) 1224 258910 (UK) 1.403.805.1972 (WesternCenada) 1 riheciiral A Delta Group Company © Trihedral Engineering Limited 2022. VTScada and Trihedral are registered trademarks of Trihedral Engineering Limited. All other products are trademarks of their respective owners. StarSupport Why use Star Controls Support for your SCADA System? To increase its availability and extend the Life Cycle of the SCADA system, the system must constantly be maintained, optimized, and enhanced. Star Controls offers a large portfolio of Support and Maintenance to fit the needs of your SCADA System. From remote sites, through communications and networks, all the way to the Control/Data Centers. Our skills and experience guarantee a holistic and detailed understanding of your operations and the SCADA system. Support services can be scheduled or unscheduled to address an immediate need. Urgent Support is available, including during non -office hours, to address faults that impact critical operations. Star Controls also offers proactive maintenance, where we continuously monitor the performance of the system and detect degradation in performance before it interrupts operations. StarAssured Star Controls offers StarAssured, a suite of support and maintenance services. Recognizing that each customer is unique, the StarAssured meets different needs and budget and can be tailored to specific needs. StarAssured includes: • Pre -Packaged (i.e., bundle) and Tailored Plans • Annual or On -Demand Remote and Onsite Proactive Maintenance — Remote Optimization Knowledge transfer Services: • Remote Support —Scheduled and Unscheduled • Onsite Support —Scheduled and Unscheduled All onsite services are coordinated with Star Controls, and in most cases will require Support Contract in place Onsite Educational and Optimization — Scheduled Monthly Remote Monitoring and Report Star/P%Support Annual Support Contract The Annual Support Contract provides customer peace of mind and allows Star Controls to plan the required engineering resources. The contract can be based on a Pre -Packaged or tailored around the specific needs. Star Controls strongly recommend customers sign up for the annual support plan. Naturally, customers that are under an annual support contract will benefit from faster response time. Our Pre -Packaged Annual Plans STARCONTROLS Remote Support — Scheduled Remote Support — Unscheduled Onsite Support — Scheduled Onsite Support — Unscheduled Onsite Support — Educational Monthly Remote Monitoring and Reporting 0 0 O 0 0 0 0 O O 0 O O 0 O 0 r"illir Contact one of our high -trained SCADA support representatives today for more information. STARCONTROLS Your Global SCADA & Telecommunications Partner © Star Controls, Inc. All rights reserved. v0620 Tel: 1 + 954.603.0491 Fax: 1 + 954.603.0492 sales@star-controls.com www.STAR-CONTROLS.com 11555 Heron Bay Blvd, Suite #200 Coral Springs, Florida 33076 USA ,004fre." STARCONTROLS YOUR GLOBAL 110T, SCADA & TELECOMMUNICATIONS PARTNER WE DELIVER SCADA CYBER SECURITY SOLUTIONS offering you end -to -end protection www.star-controls.com sales@star-controls.com 954.603.0491 1.1ri1. fa s ( G I `ate L 4r111=r 1 it l I 1111011 0101 01100111 HIE 1 001X10 0001 00101 oomoo 1 1C010l It IOU 1 '-inr11'CO 1 mom ono am tom tono cam omi ms " 8/114 41n - t , I 1:1)1* 1h 1Prinitirl) I 0 4 , ,011,ii f e1j 1u 4 • i I L - ` F lit "w ,- ,i, — I(r— s is (71I 1 ri rj a ,a. el, clip THREATS &VULNERABILITIES With numerous threats and vulnerabilities that could affect critical services, securing SCADA systems must be a top priority. • Lack of Network Segmentation • Lack of Encryption • Ransomware • Remote Access Policies • DDoS Attacks • Malware • Legacy Software • Default Configuration • Policies and Procedures • Command Injection and Parameters Manipulation damage. Attacks on SCADA systems are on the rise. The frightening truth is that many infiltrated systems have gone undetected. All too often, cyber criminals "infect" systems and silently monitor traffic, observe activity, and wait for months or even years before taking any action allowing them to strike when they can cause the most damage. GLOBAL ATTACKS Hackers' methods feel familiar in Ukraine power grid cyberattack Ukraine charges Russia with new cyber attacks on infrastructure REUTERS C -'brr Security Risks To 11e _iss.are T.SI In The- [Sit And adas Industries Largest DDoS attack ever delivered by botnet of hijacked IoT devices IFTWORIMIE xtta�ek pro.ree bx era.aeg tt• A,,u Aso is%eep t 3rt d Ukranian power outage: Are hackers testing tar worldwide SCADA cyber attacks? SCADA Attacks Double in 2014 bef%cl ys &viol? Wind' friXVi stays notarYye Vcrirkmstsiagull Oporwarnbircireigfickiaornti vOrcrliyste r.Lutindiwbt/ 510t Ya3ahnnpwl4, hr.rn trtMmIN*Vi T* % AUtfff12tionworI 1 'We recognize the enemy will use the Internet to recruit, to take down SCADA systems. In short, we expect a cyberattack as a prelude to war."- LTG Alan Lynn, DISA (Defense Information Systems Agency) Director IN THE PAST FEW YEARS WE HAVE SEEN: • February, 2021 - Cyber-attack in Oldsmar, Florida • July 2017 - "We never anticipated that our critical infrastructure control systems would be facing advanced levels of malware," Mr. Wellinghoff said. "Hackers Are Targeting Nuclear Plants, U.S. Says" New York Times • June 2017 - Greenberg, a senior reporter at Wired, reports that many cybersecurity experts believe Russia is using Ukraine as a cyber-war testing ground. • December 2016 - Incident occurred amid a flurry of 6,500 cyber attacks over two months, according to Ukraine's President Petro Poroshenko. Poroshenko said the attacks indicated Russian "cyberwar." • September 2016 - Largest DDoS attack ever delivered by botnet of hijacked loT devices, according to Network World. October 2015 - Chatham House, a UK think-tank, reported that the risk of a cyber attack on nuclear infrastructure is growing. The trend towards the digitization of SCADA systems is increasing the vulnerability of nuclear facilities, and many are inadequately prepared. Even where facilities are air -gapped, this safeguard can be breached with nothing more than a flash drive. • April 2015 - According to the 2015 Dell Security Annual Threat Report, SCADA attacks are on the rise. The report found that in 2014, the number of attacks on SCADA systems doubled compared to the previous year. Most of these attacks occurred in Finland, the United Kingdom, and the United States. • March 2015 - A report by the US Industrial Control Systems Cyber Emergency Response Team (ICS-CERT) found that it received 245 cyber incident reports from asset owners and industry partners in the fiscal year of 2014. • December 2014 - An unnamed German Steel Mill suffered extensive damage from a cyber-attack. The attackers were able to disrupt the control system and prevent a blast furnace from being shut down, resulting in 'massive' damage. Star Controls offers end -to -end, holistic approach, that integrate technologies, products and protocols that were designed for the ICS/SCADA security, and leverages technical Star Controls' know how. At a granular level, all products and solutions that Star Controls work with offer the highest level of security at every critical stage of operation. The solutions covers the OT (Operational Technology, the traditional ICS/SCADA), as well as the IT ( traditional IT security). Star Controls provides a complete Cyber Security solution for the ICS/SCADA systems, which detect and protect any potential entry point into the system. It's integrated and holistic approach stitches the Cyber Security for all components that are part of the SCADA system: Data Center - SCADA Servers and Front End Processors (or Gateways) Networks - Devices, such as Wireless Radios and Gateways Remote Sites - RTUs/PLCs and Smart Devices and Site Security Star Controls offers end -to -end, holistic approach, that integrate technologies, products and protocols that were designed for the ICS/SCADA security, and leverages technical Star Controls' know how. SCADA SOFTWARE For Cyber Security Star Controls offers different SCADA software products, while the VTScada is among the best fit for Cyber Security. VTSCADA SCADA SOFTWARE Each application includes its own security accounts and settings which control access to all parts of the application including workstations, thin clients, mobile clients, and alarm notifications. Deployed security changes are immediate and application wide. Accounts are easily copied, modified, and deleted. You can now even share accounts across multiple applications. Military -grade encryption Security protocols Password protection Group management Share security accounts applications FIREWALLS FOR ICS/SCADA Star Controls includes products from Check Point, the industry leader in IT Security, to provide a complete To -Down IT Security to the ICS/SCADA systems. r 114i di Mita Star Controls has partnered with the top vendors to include best of breed products in the SCADA Cyber Security Field Ank 1 AI aM R CHECK POINT GATEWAY AND ANALYTIC MANAGER Check Point offers the most advanced cyber security. Aligning Operational Technology (OT) with Information Technology (IT) security, Check Point provides an end -to -end multi -layer threat defense, allowing real-time protection and monitoring against threats with full visibility along with granular control of SCADA traffic. Paired with ruggedized appliance options and comprehensive protocol support, Check Point ensures critical assets are never compromised. With our best in class management platform all IT and OT environments are supported with a single, unified and robust management; the most advanced existing today. Check Point's SandBlast is a complete solution for IT security, including Firewall, Anti-Malware, Anti- Bot, Anti-Ransomware, Forensics and more. The following information on the SandBlast Zero Day Protection and Anti-Ransomware includes more details on its capabilities in these areas. SANDBLAST ZERO DAY PROTECTIONS All enterprises are at risk of targeted attacks such as spear phishing and Advanced Persistent Threats. Check Point SandBlast Zero -Day Protection, with its unique exploit -level detection and threat extraction, provides an additional layer of security from even the most sophisticated hackers and dangerous attacks. Unlike traditional sandboxing solutions that are subject to evasion techniques and either introduce unacceptable delays or let potential threats through while under evaluation, Check Point catches more malware, with minimal impact on delivery times. SandBlast is offered at the Network level, in the Cloud, and at the EndPoint. ANTI-RANSOMWARE Check Point SandBlast Agent with Anti-Ransomware and zero phishing technology, extends zero - day protections to web -browsers and end -user devices to defend against advanced attacks, keeping users safe no matter where they go. With continuous data collection and automated incident analysis, SandBlast Agent provides actionable forensics, which accelerates the process of understanding the complete attack lifecycle, damage & attack vectors, to maximize response team productivity and minimize resolution times. Anti-Ransomware keeps businesses one step ahead of attacks by automatically detecting, blocking and removing the most sophisticated ransomware infections and restoring any encrypted data as part of its automated remediation capability. WIRELESS GATEWAYS Star Controls offers a variety of wireless Gateways, such as cell modems or data radios, for private and public networks. Star Controls engineers will add all necessary authentication and encryption to the units, so secure this segment of the SCADA system. PRIVATE NETWORKS Star Controls offers products from leading vendors, such as CalAmp, 4RF and GE-MDS. PUBLIC NETWORK Star Controls offers products from leading vendors such as Sierra Wireless and Red -Lion. Our IT security experts will facilitate the dialogue with the cellular service provider, to define and implement all necessary IT security, e.g. VPN, while the data is going through the SP's networks. The AirLink Raven RV50 from Sierra Wireless is an example for Cellular Gateway that meets the OT and IT requirements. The Raven RV50 is loaded with features to secure critical data. It supports secure communications to multiple back -end systems by providing up to five concurrent VPN sessions. Remote authentication management allows enterprise -grade systems to manage access RTU, PLCS AND SMART DEVICES This area in the system is vulnerable and has been ignored by almost all vendors. Star Controls is addressing existing systems by adding layer of IT Security to sites with PLCs and Smart Devices that are used by the different vertical market. Star Controls is also promoting the Motorola ACE3600 RTU, which is the first RTU in the industry that provides a complete end - to -end IT Security to the remote monitor and controls. SECURED ACE3600 Secured ACE3600 RTUs, FEP (ACE IP Gateway or ACE3600 FIU) with enabled security features such as access/interface control, secured communication, secured files, and security -related logs. ACE3600 Security Policy is a set of configurable system -wide security parameters for enforcing the organization's security policy in the ACE3600 system management tools (STS), front-end units and field units. ACE SECURED SYSTEM - SECURITY LAYERS • Secure Access Control - User access control to all system parts - Roles and permissions - M2M access control - Central access management & control • Audit - Integrated security log - Logging security events - Sending security alerts • Stored Data Encryption - File encryption • Communications Security - Data payload encryption - Encryption key management - Integrated IP Firewall - Unused port disabling - Suppressing vulnerable protocols - Message Life Time • White listing - Run-file white listing in the RTUs - Management tools white listing & configuration change control • Secured programming - Implementing secured programming methodology - Avoiding "backdoors" - Using protocols / port scanners -.NET Code obfuscation STARTU SOFTWARE APPLICATION Star Controls' flagship software product, for the Motorola RTUs, is a game changer in the RTU/PLC market, providing the SCADA and the O&M team unparalleled capabilities and ease of use to configure, change and maintain every aspect of the RTU. The StaRTU has been upgraded to work on the Motorola Secured ACE600 RTU. Star Controls is also planning to incorporate logs from the StaRTU loggers (i.e. Communications and I/Os) into the Cyber Security Analytic at Check Point Manager. This will cover non-IP, legacy, SCADA systems. SITE SECURITY The site security is an important part of the overall security of the ICS/SCADA system. The integration of the two systems allows the correlation between alerts from IT security with the site security. The site security includes access management and advanced video surveillance, including video analytics. CYBER-SECURED SCADA SYSTEM CONCEPTUAL BLOCK DIAGRAM with Cyber Security Solution Partners FIU DMA CENTER V I-c...�cJcs CrvECKEO.'.- CHECK PCFINT GATEWAY d ICS ANALYTIC& 0 I)1 SCADA kF OTE SITE WIRELESS COMMUNICATION PEVIr<E MOTOROLA R TU Sta TUA Iirof CHECK POINT" • SCAPA LCH SITE VT L., v :.1 CwECK r.y'+" 1112111111 'mop/AIL (0s);) SCADA REMOTE SITE MOTOR f LA SOLUTIONS &CADA REMOTE SITE (0,4) SCADA REMOTE SITE (ON &CA6A REMOTE 51T 5CAOA RE MOTE SITE SIERRA►A v-i-scada WIRELESS" . arIwora eu k/rrorslg t xnral Solution Partner ST T 1 YOUR GLOBAL IIOT, SCADA & TELECOMMUNICATIONS PARTNER • 11555 Heron Bay Blvd, Suite #200 Coral Springs, FL 33076 +1-954-604-6656 sales@star-controls.com star-controls.com v0622 THE CITY OF WESTON, FLORIDA STAYING A STEP AHEAD OF THE STORM WITH MOTOROLA SOLUTIONS AND STAR CONTROLS SCADA STORMWATER PUMPING SYSTEM The city of Weston is a master -planned community located in southwestern Broward County, Florida. The city boasts A -rated schools and outstanding public safety with the lowest crime rate per capita in the county. Encompassing 26 square miles and bordering the Everglades National Park, Weston's vibrant, culturally diverse residents and visitors enjoy a thriving outdoor -focused lifestyle. Yet, this area can be subject to extreme weather that can deluge the city with large amounts of water in a short period of time. In an average rainy season, the city can see up to 45 inches of rain, with individual storms capable of dropping 10-15 inches of rain or more over just a few days. To prevent flooding, the city uses an extensive stormwater management system, directing water runoff through a system of catch basins, culverts, retention ponds and pumping stations, which eventually flow to the Everglades. As a city with a population of approximately 70,000, Weston only employs a staff of five technicians to manage its stormwater system, so all operations need to be as efficient and reliable as possible. Yet, its stormwater pumping system was largely based on manual monitoring and operating functions, making it difficult for technicians to manage while also performing their other daily responsibilities. Weston sought a new way to control and automate the system. CUSTOMER PROFILE The City of Weston, Florida INDUSTRY Water Management SOLUTIONS Integrated SCADA IoT Stormwater Pumping System, including: • Motorola Solutions MC -Edge Intelligent IoT Gateway • Motorola Solutions ACE3600 Remote Terminal Unit (RTU) • Star Controls StarCS Cloud SCADA BENEFITS • System automation and remote - control capabilities mean Weston can spend more time on its core mission • Rich data is collected and shared with deep reporting capabilities through an easily accessible web - based portal • Cybersecurity and overall system health is bolstered to comply with CISA's (Cybersecurity and Infrastructure Security Agency) Cybersecurity Practices for Industrial Control Systems CASE STUDY I THE CITY OF WESTON, FLORIDA MOTOROLA SOLUTIONS CHALLENGES MANUAL PUMP MONITORING AND MAINTENANCE MADE SYSTEM OPERATIONS INEFFICIENT Like many cities in South Florida, Weston sits less than 10 feet above sea level, so any excess stormwater can quickly impact the community. That means that the public works department must closely track incoming storms as well as the daily functionality of the city's stormwater pump system. Historically, drainage technicians were assigned to manually check lake levels, clear any blocked drains, and ensure that all water could easily flow. During the rainy season, technicians would conduct these checks every morning and when on high alert, several times throughout the day. Anytime a decision was made to turn on the pumps, someone had to manually drive out to turn them on and then return to base. Then, they had to drive back every eight hours to monitor performance. When it came time to turn the pumps off, the same technicians would have to drive back to manually shut them down. If a moderate or major storm was predicted, monitoring and preparation was even more time consuming, threatening to slow response times when speed was needed most. "When a storm was coming, up to 50% of our technicians' time would be spent managing and monitoring these systems," said Peter Johnson, City of Weston Assistant Director of Public Works. "With the size of our department, that made it more difficult for staff to handle other duties and was simply an inefficient use of their time." A LACK OF QUALITY DATA COMPLICATED DECISION MAKING AND HINDERED DISPLAY OF REAL-TIME INFORMATION Weston's stormwater pump technicians and managers are tasked with making important system decisions daily, including when to start the pumps, how much water to pump, and how long to run the pumps. Yet, Weston would receive very limited actionable data from the system's mostly manual control processes, making it more difficult to make the best, most informed decisions possible. In addition, when the U.S. Army Corps of Engineers would look at the feasibility of new infrastructure projects in or around the city, they would often ask for historical data that was very difficult for Weston to produce. This lack of quality, actionable data was compounded by the fact that the city's ability to share information with residents, such as real-time lake levels was inefficient. "Data from our pumping system was very hard to gather," said Johnson. "And even when we had access to the right data, we didn't have the means to easily share it instantly with the community." CASE STUDY THE CITY OF WESTON, FLORIDA ow ,11111 III 11 IROI 1l■■i1 NMI 11 Inn[ JIIIIi III -1 III MI/■1 III ;IIP . , c !111111111111 inn i rrLcccct ---f." L LUL'UUUL CASE STUDY I THE CITY OF WESTON, FLORIDA WITH RISING REPORTS OF INFRASTRUCTURE BREACHES NATIONWIDE, WESTON WANTED TO DO MORE TO ENSURE CYBERSECURITY AND OVERALL SYSTEM HEALTH While Weston knew it needed to upgrade the control system for its stormwater pumps, it also wanted to ensure that any new system was monitored for overall health and especially protected against cyber breaches, for good reason. According to International City/County Management Association (ICMA) research', local governments are increasingly targeted by cyber criminals and bad actors for five main reasons: The sheer number of American local governments make them a large attractive target. 2. Local governments store considerable amounts of sensitive information, such as names, addresses, driver's license numbers, credit card numbers, social security numbers, and medical information. 3. In recent years, the availability of low cost but effective hacking tools that require little technical knowledge has made it relatively easy to get into the business of cybercrime, thus increasing the number and types of cybercriminals. 4. Local governments often operate under financial constraints that limit their ability to acquire and implement state of the art cybersecurity technology, policies, and practices. 5. As local governments connect infrastructure to the internet it can introduce new cyber risks and vulnerabilities. Knowing these risks, it was important that any solution Weston installed was tested and certified to comply with CISA's (Cybersecurity and Infrastructure Security Agency) Cybersecurity Practices for Industrial Control Systems. It was also important to have a partner that could monitor the system and alert the city to any suspicious activity or issues that could affect the system's overall health. ' https://icma.org/articles/pm-magazine/look-local-government-cybersecurity-2020 SOLUTION The City of Weston chose Star Controls, a Motorola Solutions partner, to design, build, and install a SCADA loT system that could automatically monitor city water levels and control pumping stations to redirect water as necessary. The city also made the decision to migrate its IT and associated applications to the cloud, so its SCADA system needed to be cloud -hosted as well. "The City has progressively moved many of our core software applications into the cloud to benefit from the reduced cybersecurity liabilities. In addition, the cloud provides us the ability to easily access applications from anywhere at any time," technology services director, Ryan Fernandes, stated. "It pained me to see people wasting time and efficiency," said Johnson. "We knew technology was there to save time and effort and we made the decision to move forward with it." The system utilizes the Motorola Solutions MC -Edge Intelligent IoT Gateways and ACE3600 Remote Terminal Units (RTUs) to monitor remote pumping and lake levels, collect data, and remotely control pumps and other equipment. Data collected from the system is forwarded to a cloud -based application which uses measured water levels and other inputs to direct stormwater as necessary. The use of Motorola MDLC protocol allows redundant schemes of communication between the remote sites and cloud -based control centers. In addition, the system includes site security, fire alarms, and intrusion detection. "The Motorola Solutions RTU is the only field controller that can easily act as the integrator for all these pieces," said Tzvi Magril, Star Controls Managing Partner and Co -Founder. "We can develop applications using a common programming language to remotely check on the health of each piece of the system, which is unique to the Motorola Solutions platform." Weston city staff worked closely with Star Controls on the design of its SCADA system using all off the shelf products, with cloud -hosted software. "We chose Star Controls and Motorola Solutions because they made the best suggestions on overall project design and could help us build and maintain a powerful, integrated, and secure system," said Johnson. "Plus, everyone knows Motorola Solutions is an established, trustworthy company" CASE STUDY THE CITY OF WESTON, FLORIDA BENEFITS SYSTEM AUTOMATION AND REMOTE -CONTROL CAPABILITIES MEAN WESTON CAN SPEND MORE TIME ON ITS CORE MISSION WHILE RESPONDING TO STORMS FASTER Today, Weston's entire stormwater pumping system can be remotely monitored and controlled, with the option to run in two modes, an automatic mode based on city water levels and a manual override mode, when needed. With all applications and data hosted in the cloud, it's easy for technicians to see each pump's status and control them remotely, even from a mobile phone or computer browser. "Recently, we had a fast moving, unexpected storm," said Johnson. "In the past, that would have meant a call to a technician in the middle of the night or waiting until morning. This time, we simply turned on two pumps with our mobile phones. When there's a problem or an issue, we can react immediately." During Hurricane Ian, Weston was spared a direct hit but still received 7 inches of rain in one day, further testing the new system. Based on data coming from the system, Weston lowered the lake levels in preparation. "We had a huge jump in confidence knowing we had full control of the system," explained Johnson. "We didn't have to worry if things were working, we could actually monitor everything in real time. Staff were elated that they didn't have to drive to each station to check on pumps since they could manage everything remotely. Technicians were now freed up to do other storm prep and related tasks. We were busy tracking the weather forecast and monitoring the performance of operating pumps. Everything just worked perfectly." Daily monitoring and maintenance is now vastly improved as well. For instance, the pumping system automatically monitors power coming from the local utility, so it knows if power is interrupted and can send alarm when running on backup generators. Fuel levels for diesel operated pumps are also automatically monitored. Remote lake level sensors also provide a clearer picture. Since lakes are connected underground by culverts, it's important to see all adjoining communities to monitor for blockages. When they occur, Weston sends in divers to clear them before the rainy season. Now, they can see the status of the lakes and culverts at all times using color -coded charts viewed remotely through any web browser or at the public works office on a 75-inch display. When there's an issue, automatic alerts are pushed to technicians' cell phones via voice, text and email. We had a huge jump in confidence knowing we had full control of the system... Everything just worked perfectly. - Peter Johnson, City of Weston Assistant Director of Public Works CASE STUDY I THE CITY OF WESTON, FLORIDA EASILY ACCESSIBLE RICH DATA WITH DYNAMIC REPORTING Weston now has access to both detailed, real-time data and rich historical data, whenever needed. For instance, they can see lake levels over time and gauge how the system performed under different scenarios. When the South Florida Water Management District requests specific data, it's easy for staff to quickly pull it using integrated and powerful reporting capabilities that all run in the cloud and can be accessed from any authorized device. "Data collection is a huge benefit to us," said Johnson. "We can respond faster and more comprehensively to specific requests, but just as important, we can learn from past historical data and get better with time." In addition, because all data and applications are hosted in the cloud, Weston can easily share information such as lake levels with the community, straight from their city website. BUILT WITH SECURITY IN MIND Weston's stormwater pumping system relies on the Motorola Solutions MC -Edge Gateway and ACE3600 RTU, each designed to comply with CISA's Cybersecurity Practices for Industrial Control Systems. The Motorola Solutions MC -Edge Gateway also allows integrators to easily develop their own software to monitor the health of the field computer and surrounding environment, making the system even more secure. "Motorola Solutions has been providing an open platform for customers to develop on for years," said Magril. "Others just don't offer the same level of flexibility or ease of use." In addition, with the StaRTU software residing on the Motorola products, Star Controls will help maintain the system, monitoring for breaches, looking to see how components are communicating with each other, and tracking general performance. If there's an issue, Weston can be much more proactive with maintenance or remediation. AN EXAMPLE FOR OTHER CITIES Today, Weston's Cloud -Based SCADA for stormwater pumping system is a reference point for other cities. "This is ahead of its time. Most cities strive to have a system of this type that is so comprehensive and advanced," said Johnson. Weston is also thrilled with their decision to host all system software and data in the cloud. "That's important because most cities with their limited resources don't have the ability to keep up with the management of a secured data center," explained Johnson. Overall, Johnson would highly recommend this type of system to others thinking of upgrading their stormwater pumping systems. "Most things come down to value," he said. "This investment is worth it. It's not inexpensive, but when you total the full amount it takes to maintain a manual system and the confidence and benefits you get from the automated system, it's worth it." And the best part? "Because the software is in the cloud, management and security is improved" said Johnson. For more information about intelligent loT and SCADA solutions, visit: jlutions.com/iiot M MOTOROLA SOLUTIONS Motorola Solutions Inc., 500 W Monroe St, Chicago, IL 60661. U.S.A. motorolasolutions.com MOTOROLA, MOTOROLA SOLUTIONS and the Stylized M Logo are trademarks or registered trademarks of Motorola Trademark Holdings, LLC and are used under license. All other trademarks are the property of their respective owners. CO 2023 Motorola Solutions, Inc. All rights reserved. 03-2023 [COOL] SCADA Design & Build Success Story City of Weston, Florida The City of Weston, Florida undertook a strategic initiative to modernize its water management infrastructure by implementing a new SCADA (Supervisory Control and Data Acquisition) system. The goal was to improve visibility, reliability, and operational control across the city's critical drainage assets. The project included five diesel -driven pump stations and eight remote canal monitoring sites, all integrated into a single, cohesive SCADA platform. The project followed a proven design -and -build delivery approach, progressing through clearly defined phases from kickoff to long-term support. 1. Kickoff Phase The project began with a formal kickoff meeting involving City of Weston stakeholders, operations personnel, and the project delivery team. Objectives, success criteria, communication protocols, and project milestones were established early to ensure alignment. Key outcomes of the kickoff phase included: • Confirmation of project scope covering 5 pump stations and 8 canal monitoring sites • Definition of roles and responsibilities • Agreement on schedule, reporting cadence, and risk management approach This phase set a collaborative tone and created a shared understanding of how the project would move from concept to commissioning. 2. Discovery Phase During the discovery phase, the project team conducted detailed field assessments and operational interviews to fully understand existing conditions and operational needs. At the pump stations, discovery focused on: • Diesel pump controls and status signals • Engine run, fault, and fuel -related monitoring points • Existing level sensors and local control logic At the canal monitoring sites, discovery addressed: • Canal level sensor types and accuracy requirements • Power and communications constraints at remote locations • Data reporting frequency and alarm thresholds This phase ensured that the SCADA solution would be tailored to real -world conditions rather than assumptions, reducing risk and rework later in the project. 3. Design Phase With discovery complete, the project moved into the design phase. The team developed a comprehensive SCADA architecture that unified pump station control and canal monitoring into a single system. Key design elements included: • PLC and RTU configurations for pump stations and monitoring -only sites • Communications architecture to reliably connect all 13 remote locations • Human -Machine Interface (HMI) graphics showing pump status, diesel engine health, and canal levels • Alarm management strategies for high/low canal levels, pump faults, and communications failures The design phase balanced operational clarity with scalability, ensuring the system could grow with the City's future needs. •44 kqt zssi zsu 33 2? H11 Rte Nam's Setpolnt Entry Wow Snake I Akan, Smoke 1 Atarrn Sranater Skarn-1).44mm Pump Starr Arieretael fuel Priodbus Carts Awl Laval Low eamamaaratala oar L==, laws k9. Au; 16 4.3. ace h ODA Gosh CRC h 00s h 903$ 0411h OA) h Oen h lug 24 sal sn, s 175 h Sit h S.02 h 492h S33 h lot 495h S42 Ss 471 h h h 131 h 4.97 h 4.92 S25 h to h 41$ h lide alt Door pump SPOOot Rom Current Ruronme 0 0 Mrs Last no,, (0,S) Acc. HOW, Ad, alS 1 Acc. Wartime Mr 410.3 Ogra *WNW 0 limn Current Raman. 00 We Ire Run (Days) $3 Aos. Hours Ad, 2000.0 At. 1.41•00oso Hr a 7 Hrs Current Runelm• 0.0100 Last Run ( garm) jj c• 2026 0, 0'• 20.6106 20.15-Z - S.; 9 St.* Water Lloral 4.60 Ft Unacked Current Shenno E.,ns Gant &mot trent Sep 13 SeD 17 On 14.11,03111.10411. Now Adding Note to Stotton 4. Implementation Phase During implementation, the approved design was brought to life through coordinated hardware, software, and field integration efforts. Activities included: • Panel fabrication and PLC/RTU programming • Installation and integration of diesel pump controls and canal level sensors • Configuration of the central SCADA server and historian • Development of intuitive HMI screens for operators and supervisors Close coordination with city operations minimized downtime and ensured that critical drainage infrastructure remained available throughout construction and cutover. imisammNIIMIMiMAMtic-.ViZto,Z%-grU4M 5. Acceptance Testing Phase Before final turnover, the system underwent a rigorous Acceptance Test to verify that all functional and performance requirements were met. Testing validated: • Remote monitoring and control of all five pump stations • Accurate real-time and historical data from all eight canal monitoring sites • Alarm annunciation, notification, and acknowledgment workflows • Communications reliability and failover behavior Any issues identified during testing were promptly resolved, resulting in a fully validated system ready for operational use. 6. Training Phase Operator and maintenance training was a key component of the project's success. Customized training sessions were conducted to ensure city staff could confidently operate and maintain the SCADA system. Training covered: • System navigation and HMI usage • Pump station control and alarm response • Canal level monitoring and trend analysis • Basic troubleshooting and support procedures Hands-on exercises using the live system helped reinforce learning and build operator confidence. 7. Support Phase Following system acceptance, the project transitioned into ongoing support. The support phase provided the City of Weston with peace of mind, knowing expert assistance was available as needed. Support services included: • Post -commissioning support during initial operations • Remote troubleshooting and system optimization • Documentation delivery and system backups This long-term partnership approach ensured that the SCADA system continued to deliver value well beyond project completion. Project Outcome The completed SCADA system gave the City of Weston a unified, real-time view of its pump stations and canal network. Operators gained improved situational awareness, faster response to changing canal conditions, and greater confidence in managing critical drainage infrastructure —especially during storm events. The successful design -and -build delivery demonstrated how a structured, phased approach can transform complex infrastructure into a reliable, operator -friendly SCADA solution. Data Sheet Your gateway to mission -critical loT Now, more than ever, systems operating in mission -critical environments require a new level of connectivity and security. Whether it's a natural disaster or a man-made emergency, IoTdevices are often on the first line of defense. MC -Edge® is an intelligent gateway designed for loT applications. MC -Edge's extensive security, ultra -reliable communication capabilities and reliability of transport across two-way radio, LTE, and analog radio modes make it easy for you to implement, support and grow your loT systems to fully support all your mission -critical operations. Built for versatility, MC -Edge has you covered today, and prepared for tomorrow. MC -Edge works with ThingPark, Actility's LoRaWAN Network and is fully configurable and manageable from the ThingPark Enterprise console. This addresses the need for the strictest requirements in security and operational continuity. M MOTOROLA SOLUTIONS © MC -EDGE LTE�) (Main) ETH2 dd ETH3 RS232 RS485 Sit \\\11111111 111\�;111111� 11111\111111\1 1111 11111 11111111 111111111111 11111 11111111 11111 1111111 11111111 v11 1111111 1 1111111!�1 11111111 11 11111 1111111' ;‘‘1,‘11 1111111 111111 11111 �1`1,1111, Vertical operator solutions Network services Edge services (MC -Edge gateway) Sirens IDi Fire Stations Hazmat Utilities ((r) LTE LMR Mobile WAN (LMR, LTE) Edge processing (Filtering, aggregation, stream analytics, custom) Sensor connectivity (Wired, LoRa) Sensors and activators Vertical applications & services • Use cases with best -in -class reliability and security e.g.: Disasters, critical infrastructure Converged loT network • LMR • LTE • lot networks Edge gateways • Multi -network • Edge compute / analysis • Military grade hardware security Utilize MC -Edge to expand and grow your sensor networks The MC -Edge gateway enables exceptional remote monitoring and control capabilities. Expand reach with wireless built-in Expand your operations that currently have no power or communication coverage with MC -Edge, wireless LoRaWAN gateways and servers. MC -Edge is used as a data aggregator for LoRaWAN loT devices that can span wide areas with minimal power consumption. Utilize MC -Edge to backhaul LoRa data over two-way radio or wireless broadband to your loT applications. Enhance operations with edge computing With edge computing, activities such as decision -making, filtering, logging and analytics are handled on the edge, thus increasing network capabilities, responsiveness and efficiency. Enable control and P25 radio system remote management Integrated into Motorola Solutions' P25 dispatch or radio sites, MC -Edge can be used to control physical access, monitor environmental sensors and manage alarms. Ensure mission -critical system security MC -Edge will automatically look for malicious activity or violations of security policies and will only allow legitimate traffic to enter and block other activity. Unauthorized activity is logged and can be reported to a designated control center. AES 256 bit encryption protects sensitive data end -to -end, whether at rest or in transit. Embrace network agnostic connectivity and redundancy MC -Edge utilizes MDLC communication protocol to link distant sites for easy scaling and provide alternative communication links in case of fallback. Use of this standard functionality eliminates the need for costly custom programming or additional communications infrastructure. 2 System specifications GENERAL Operating temperature -30°C to 60°C (-22°F to 140°F) RTC Battery Charging 0°C to 45°C (32°F to 113°F) Dimensions (CPU) 2.95" x 6.3" x 4.4" (WxHxD) Dimensions (SPE I/O module) 1.4" x6 .5" x 4.4" (WxHxD) Dimensions (CAN bus I/O module) 2.95" x 6.3" x 4.4" (WxHxD) Backplane dimensions 6.2" x 1.2" x 3.1" (WxHxD) DIN rail option Yes Wall mount option Yes (using DIN rail) Construction Modular Input voltage 9-30V DC RTC backup Battery Type Rechargeable coin -cell battery, capable of maintaining the RTC for at least 30 days at +25N when the main power is disconnected SDIO card Yes Internal Transceiver Options P25 (North America), LTE, Private LTE, LoRa External Connections Analog MOTOTRBO TETRA P25 Null Modem Network Topologies Point-to-Point/Multipoint Store and Forward Star Tree Hierarchy Multi -Communication Backhaul Supported (dual/redundant link) CPU RTC Hardware clock with year, month, date, day, hour, minute, Yes and second supported Communication Ports RS232/RS485 Ethernet USB 1 port on the main board non -isolated and additional up to 2 ports on piggy Isolated (<115.2Kbps/<460.8Kbps) Up to 3 ports, 10/100Mbps (auto negotiation) Host port SOFTWARE Configuration and maintained tool PC Tool (STS) MDLC Networking Yes Direct Link Yes RTU to RTU communication Yes MDLC Store and Forward Yes Broadcast Yes Diagnostic (local, remote) Yes Error Logger (local, remote) Yes User programming C IEC61131-3 Security AES-256 end -to -end encryption User and machine authentication Central key management Central authentication server Access control Sensitive data in rest encryption IPsec SCEP PKI Secure hardware key storage (MAXIM) Protocols DNP 3.0, MDLC, Modbus, MQTT, SSH, SFTP Time Synchronization MDLC, NTP Set Date and Time Yes (w/ Time Zone and Daylight - Saving) Services DNS Yes DHCP Yes MEI I/O PORTS I/O PERFORMANCES Main Board 3DI + 1 DO ML (Isolated) 2 kHz for all inputs SPE I/O modules Mixed I/O Module 16 DI 4D0 EE 4AI (+-20mA, 4-20mA) DI 1-8 Counter Input Frequency: 10 kHz DI 9-16 Counter Input Frequency: 1 kHz 3 DOs form A (two contacts), 1 D0 form C (3 contacts) Al Resolution 16 bit, 0.1 % @ 25C DI/DO Module 32 DI/DO FET 16 DI/DO FET 1 kHz for all inputs CAN bus I/O modules Mixed I/O Module 7 DI / 6 DO 4EE 2ML (Isolated) 4AI (+-20mA, 4-20mA) 1AO (Isolated) (AO: 0 -20mA, 4-20mA, 0-10V) Mixed Digital 8D0 EE 16DI 5-18 V /DRY 8D0 EE 16DI 18-60 V 2 kHz for all inputs 16 bit, 0.1% @ 25C 12 bit, 0.25% @ 25C - 2 kHz for all inputs - 2 kHz for all inputs 4G (LTE) / 3G SUPPORTING BANDS S North America Europe, Middle East, Africa Asia Pacific Latin America 4G Bands (LTE) Verizon B4 & B13 B8 (900MHz US), B48 (CBRS US) B3, B7, B20, CBRS EU: B42, B43 B3, B28 3G Bands (supporting bands) B2, B5 B1 for fallback B5 for fallback (3G Excluded in ANZ) B4, B7, B28 INTERNAL P25 RADIO SPECIFICATIONS (NORTH AMERICA) VHF 700/800 MHZ Frequency Range / Bandsplits2 TX: 136-174MHz RX: 136-174MHz TX: 763-776, 793-806/806-824, 851-870MHz RX: 763-776/ 851-870MHz Channel Spacing 30/25/12.5kHz 25/12.5KHz TX Output Power 1-5W 1-3W Receive Sensitivity (12dB SINAD) LORAWAN SPECIFICATIONS LoRaWAN Gateway Hardware Radio Chipset SX1301 and SX1257 Radio Frequency Plan AS923, AU915-928, EU863-870, US902-928 Frequency Ranges 863-870 MHz, 902-928MHz Receive Sensitivity Up to-140dBM Max TX Output +28dBM LoRaWAN Software 0.216pV 0 250uV LoRaWAN Server Yes 2Check with your local Motorola Solutions sales representative for frequencies available in your local area. LoRaWAN Gateway Basic station for general LoRaWAN network Actility base station for Actility LoRaWAN Network (ThingPark) 4 POWER MANAGEMENT Voltage Management Preconfigured thresholds based scenarios Power voltage that can be reduced or disabled 5 power consumption options available Power Consumption CPU module all radios off Max 300mA / Typical 150mA @ 12V (w/o SD card and USB) CPU module all radios on Max 450mA / Typical 250mA @ 12V (w/o SD card and USB) CPU module all radios on P25 TX 1.6 A / Typical @ 12V CPU module all radios on LoRA RX 8 channels 0.36A / Typical @ 12V CPU module all radios on LoRA TX 0.605A / Typical @ 12V CPU module all radios on LTE TX 0.45A / Typical @ 12V Mixed 10 module Max 194.4mA / Typical 64mA @12V Mixed digital 10 modules Max —357mA / Typical 21 mA @12V 32DID0 module Max 178mA / Typical 70 mA@12V 16DID0 module Max 145mA / Typical 50mA@12V Mixed 10 16 DI 4A0 4A1 module Max 165mA / Typical 80mA@12V REGULATIONS Safety US / Canada IEC62368-1 (cUL Listed) EU, Australia / New Zealand EN/ANZ 62368 Emission / EMC US / Canada CFR 47 FCC part 15, subpart B (class A) ICES003 EU, Australia / New Zealand EN301489-52, AS/CA SO42.1, Approved per RED To learn more, visit: www.motorolasolutions.com/mcedge SERVICE AND SUPPORT 1. Technical Support - Remote Technical Support from our Solutions Support Center 2. Software Updates - Safeguard your system from One year warranty vulnerabilities and improve network performance 3. Software Upgrades - Download the latest integrated system software releases with the latest features, functionalities and enhancements M MOTOROLA SOLUTIONS Motorola Solutions, Inc. 500 West Monroe Street, Chicago, IL 60661 U.S.A. motorolasolutions.com MOTOROLA, MOTO, MOTOROLA SOLUTIONS and the Stylized M Logo are trademarks or registered trademarks of Motorola Trademark Holdings, LLC and are used under license. All other trademarks are the property of their respective owners. ©2025 Motorola Solutions, Inc. All rights reserved. 06-2025 [BG15] MDLC Reliability 1/2 STARCONTROLS Communications Reliability under MDLC This memo provides some highlights on the different mechanism for the reliable transmission of information as provided by the layered architecture of the MDLC protocol. The MDLC protocol was designed according to the guidelines provided by ISO regarding seven layer protocols, OSI (Open Systems Interconnection). The basic structure of the protocol is depicted in Figure 1. End -user application process I Application Layer Presentation Layer Session Layer Transport Layer Network Layer Link Layer Physical Layer i Data communication network File transfer,access and management, document and message interchange, job transfer and manipulation. Transfer syntax negotiation, data representation transformation. Dialogue and synchronization control for applications entities. End -to -end message transfer (connection management, error control, flow control) Network routing, addressing, call set-up and clearing. Data link control (framing,data transparency, error control), media access control. Mechanical and electrical network interface definitions. Figure 1. MDLC layered structure The usage of a seven layer structure in MDLC was especially designed to offer a grade of protection similar or superior to that encountered using line communications, but when operating mainly with radio communications which inherently are less reliable. The basic reliability of the protocol is given by the Link Layer protocol. When used in a radio environment, a powerful CRC-32 error detection code is appended to every transmitted frame. This error detection mechanism makes it virtually impossible for an errored frame to go undetected by the receiver. At the receiving end, every frame is checked for errors. If no errors are detected, the frame is passed to the upper layers of the protocol for further handling. A positive acknowledgment is then issued to the transmitter side to inform it of successful reception. If an error is detected, no acknowledgment is issued and the frame is discarded. The transmitting end, after a predetermined time-out, retransmits the unacknowledged frame. This is called a link retry. The number of retries is programmable and is set, by default, to four, i.e., the original transmission plus up to four retries. Let's assume that the probability of losing a frame in the channel is equal to 5%. It can be easily shown that the probability that a frame will not be received after four retries is on the order of 3.10-7. MDLC Reliability 2/2 STARCONTROLS A second level of end -to -end reliability is provided by the network and transport layers. The network layer is responsible for the routing of information through RTUs in the system that act also as communication nodes. In addition, it is the role of the network layer to identify an alternative path between end points in the case where a link is declared as unusable. An example is given in Figure 2. Normal Route Alternative Route Figure 2. Alternate routing In Figure 2, the communication from RTU A to RTU B is normally done using the upper path of RTUs. Assume that the first link in the upper path breaks. The Network layer automatically uses the alternate route in order to pass the information to RTU B, using now the lower path of RTUs. In a properly designed system, a link failure does not make the entire communication system unusable. Whenever a network is involved in communications, frames can get from origin to destination in the wrong order. For example, a frame transmitted between two nodes in the network may necessitate retransmission due to errors and may incur extra delays in that portion of the network. The transport layer at the destination site is responsible for providing the received frames in the correct order to the application. It will do that by delaying the out -of -order frames until the missing frame is received. An important task of the transport layer is its responsibility for the end -to -end integrity of the information. If the transport layer at the receiving end detects a 'gap' in the received frames, then, after a predetermined time-out, it requests from the originating RTU to resend the missing information. This process is known as a transport layer retry. This can occur when part of the information is lost due to a broken link somewhere in the network and information is rerouted through an alternate route. The retry mechanism at the transport layer offers this supplementary protection so as to guarantee end -to -end integrity of the transmitted information. An additional level of protection is offered at the session layer of the MDLC protocol. One of the tasks of the session layer is the synchronization of large transactions that may experience faults. The synchronization of lengthy information is especially important when unreliable media is used. It allows the application to continue from the point where the communication was interrupted without the need of starting all over again from the start of the application/communication. The MDLC protocol was designed as a seven layer protocol, not only to provide a flexible communication structure but also to enhance the reliability of the communications to levels similar to those obtained with reliable media. For more information Contact Us: Tel: 1 + 954.603.0491 Fax: 1 + 954.603.0492 sales@star-controls.com www.STAR-CONTROLS.com 11555 Heron Bay Blvd, Suite #200, Coral Springs, Florida 33076 USA MDLC Features 1/4 STARCONTROLS FEATURES AND UNIQUE BENEFITS OF THE MDLC PROTOCOL Advanced SCADA systems require intelligent communication capabilities in order to assure the flexibility, expendability, reliability, and high performance of the system. In addition they require software controlled managing and maintenance of their communication network. SCADA systems can only be justified if these provide cost benefits to the customers. This can be achieved by combining smart communications into the system, which result in faster, less costly, and safer operation and of the customers' facilities. Motorola provides a solution to this challenge with its Motorola RTU system and the MDLC (Motorola Data Link Communications) protocol. These liberates the system engineering and the programmers from technical constraints and complexities of the communications and allows them to concentrate on their application and system operation. The MDLC communication protocol is based on the Open Systems Interconnection (OSI) 7 layers model published by ISO, which Motorola specifically adapted for SCADA and radio communications. This is the only available protocol for radio which comprises all the seven recommended layers. Here, every RTU may act as a Distributed Control Unit (DCU) and as a communications node serving other units. The following is a list of unique MDLC features and benefits: Application processes Variable length words File Transfer Short Messages The system engineers use the Motorola RTU STS in order to develop, maintain and modify their RTU application processes. They can then transfer the program via the MDLC protocol from -or -to all RTUs installed at the designated remote sites. The MDLC provides the Motorola RTU RTUs with very efficient communications methods, allowing to transmit variable length words (messages) between the RTUs and the RTUs and the SCADA centrals. The MDLC protocol allows to upload and download all types of data including free format files. This can be directly performed between all the sites, i.e. between the RTUs and between the RTUs and the SCADA central. The MDLC supports efficient transmission of short messages (bursts). This is done without actually creating a communications session (dialogue) between the transmitting and receiving sites (RTUs). MDLC Features 2/4 STARCONTROLS Remote Diagnostics The MDLC protocol provides the service technicians with an option to remotely perform diagnostics of the RTUs' hardware and software from any remote site (via an RTU) or from the central location. Remote Calibration The MDLC protocol also allows service technicians to perform calibration of the analog ports in all of the Motorola RTU RTUs in the network from any remote site, via any RTU, or from the central location. RTU to RTU links The MDLC protocol supports direct RTU to RTU links for sending databases, local statuses and analog values. This can be done directly (or via any number of RTUs) which act as a communications node. Process debugging The MDLC protocol allows to remotely monitor and debug the local application programs running in the RTUs. If required, the local process in a certain RTU may be updated without actually disturbing the system's operation. Error logging Error Correction Statistical data Mixture of media Store and Forward Unusual / occasional events are logged in a local error logger in the RTU without the need to wait and catch it in the real time. The logged historical events may be later retrieved via the network for post analysis. The MDLC protocol is equipped with a 32 Cyclic Redundancy Code (CRC) based acknowledge mechanism. Upon error detection, the receiving RTU asks the other side to resend only the damaged or missing frames, rather than the whole message frame. In order to save computer time for the process, the CRC's word calculation is performed by hardware. The MDLC allows remote access to each RTU (via the communications network) from any location, in order to obtain statistical data on the operation, events, parameters and processes at any of the designated sites. The MDLC protocol allows efficient combining (into the same data network) of several communication media such as cellular, radios, microwave, fiber optics while optimizing the overall performance of the system's operation. The MDLC protocol supports the use of the Motorola RTUs in the network as repeaters for data transmission. These RTUs may perform "store and forward" function (for range extension) by reusing the same channel. MDLC Features 3/4 STARCONTROLS Multiple centrals Data reliability Multiple physical ports Multiple logical links Multiple addressing Address recognition Multitasking operation Protocol emulation Use of radio media The MDLC protocol supports network communications with any number of Master Control Centers (MCC), and sub control centers in hierarchical scheme. These MCCs may be linked to the network at any RTU location. The MDLC protocol provides node -to -node as well as end -to -end data acknowledgement via any number of communication nodes (and media) between the RTUs and between the RTUs, and the SCADA central. The MDLC protocol supports multiple physical ports (Ethernet, Radio, RS-232, USB etc.) in a single RTU, enabling simultaneous communication via more than one port. The MDLC protocol allows simultaneous communications of multiple sessions via the same physical port (Central-to-RTU and RTU-to-RTU sessions). Sessions sent via the different logical links do not interrupt each other. The MDLC protocol supports: individual RTU addressing, system addressing for broadcasting the same message to a defined set of RTUs, a common address to all RTUs, and a spare address for future communication options. In order not to waste valuable process time spent on checking addresses of messages not intended for that site, the MDLC supports initial address screening in hardware. This increase the overall throughput over the network. The MDLC protocol support performance of several tasks (local processes and communications) without interrupting the normal operation of the RTU i.e. the local process and the control processes at other sites. The Motorola RTU allows emulation of other SCADA protocols. This will allow using the MDLC protocol a in combination with other SCADA systems by using of a Gateway or Bridge or Router connecting between various media. The MDLC protocol supports a wide variety of wireless and line media, including cellular, conventional, trunked, Data Radios, Fiber optics, Line, Satellite and Ethernet. Any combination of these and other physical channels may be integrated into a single data network. MDLC Features 4/4 STARCONTROLS Contention reporting Time tagging The MDLC protocol supports event reporting in both polling and contention modes. In the latter the RTU contends for the channel and will send its message only when the channel is available (free). This results in significant reduction of air time loading. The MDLC protocol is suitable for electric Distribution Automation systems, since these require support for system -wide time synchronization (RTUs, communications and central) with an accuracy of up to 1 milliseconds. For more information Contact Us: Tel: 1 + 954-604-6656 sales@star-controls.com www.STAR-CONTROLS.com 11555 Heron Bay Blvd, Suite #200, Coral Springs, Florida 33076 USA ,004fre." STARCONTROLS YOUR GLOBAL 110T, SCADA & TELECOMMUNICATIONS PARTNER WE DELIVER SCADA CYBER SECURITY SOLUTIONS offering you end -to -end protection www.star-controls.com sales@star-controls.com 954.603.0491 1111011 0101 01100111 HIE 1 001X10 0001 00101 oomoo 1 1C010l It IOU 1 '-i1r1 1'CO 1 mom ono am tom tono cam omi ms " 81114 41°' - MI' f 4 • i Ir r 1 rt =► ,- r, — I(r— s is (71I ri rj a. if 1'6 el, clip THREATS &VULNERABILITIES With numerous threats and vulnerabilities that could affect critical services, securing SCADA systems must be a top priority. • Lack of Network Segmentation • Lack of Encryption • Ransomware • Remote Access Policies • DDoS Attacks • Malware • Legacy Software • Default Configuration • Policies and Procedures • Command Injection and Parameters Manipulation damage. Attacks on SCADA systems are on the rise. The frightening truth is that many infiltrated systems have gone undetected. All too often, cyber criminals "infect" systems and silently monitor traffic, observe activity, and wait for months or even years before taking any action allowing them to strike when they can cause the most damage. GLOBAL ATTACKS Hackers' methods lei ; : Y:. i 3r in Ukraine power grid tyberattack Ukraine charges Russia with new cyber attacks on infrastructure REUTERS Cyber Security Risks. To Ile AwareGrin The Oil And Gas Industries MEI Largest DDoS attack ever devered by botnet of hlacked loT devices tErNORKWIFILD Mack orNee.boo 6441i¢ 'hara4iokeep i adz't Ukranian power outage: Are halcicers testing for worldwide SCADA cyber attacks? • :.. SCADA Attacks Double in 2014 DorSKnwW swows?t rootrepx! Thous natawn a sir le Gv+wriwattdWAa aenidcmictcrrd s-kdidultoW 3CACA ryfgm}#1 wet M.1.+04 Y+tM1AWOOXWAyfop AitO:IationWoril 'We recognize the enemy will use the Internet to recruit, to take down SCADA systems. In short, we expect a cyberattack as a prelude to war."- LTG Alan Lynn, DISA (Defense Information Systems Agency) Director IN THE PAST FEW YEARS WE HAVE SEEN: • February, 2021 - Cyber-attack in Oldsmar, Florida • July 2017 - "We never anticipated that our critical infrastructure control systems would be facing advanced levels of malware," Mr. Wellinghoff said. "Hackers Are Targeting Nuclear Plants, U.S. Says" New York Times • June 2017 - Greenberg, a senior reporter at Wired, reports that many cybersecurity experts believe Russia is using Ukraine as a cyber-war testing ground. • December 2016 - Incident occurred amid a flurry of 6,500 cyber attacks over two months, according to Ukraine's President Petro Poroshenko. Poroshenko said the attacks indicated Russian "cyberwar." • September 2016 - Largest DDoS attack ever delivered by botnet of hijacked loT devices, according to Network World. October 2015 - Chatham House, a UK think-tank, reported that the risk of a cyber attack on nuclear infrastructure is growing. The trend towards the digitization of SCADA systems is increasing the vulnerability of nuclear facilities, and many are inadequately prepared. Even where facilities are air -gapped, this safeguard can be breached with nothing more than a flash drive. • April 2015 - According to the 2015 Dell Security Annual Threat Report, SCADA attacks are on the rise. The report found that in 2014, the number of attacks on SCADA systems doubled compared to the previous year. Most of these attacks occurred in Finland, the United Kingdom, and the United States. • March 2015 - A report by the US Industrial Control Systems Cyber Emergency Response Team (ICS-CERT) found that it received 245 cyber incident reports from asset owners and industry partners in the fiscal year of 2014. • December 2014 - An unnamed German Steel Mill suffered extensive damage from a cyber-attack. The attackers were able to disrupt the control system and prevent a blast furnace from being shut down, resulting in 'massive' damage. Star Controls offers end -to -end, holistic approach, that integrate technologies, products and protocols that were designed for the ICS/SCADA security, and leverages technical Star Controls' know how. At a granular level, all products and solutions that Star Controls work with offer the highest level of security at every critical stage of operation. The solutions covers the OT (Operational Technology, the traditional ICS/SCADA), as well as the IT ( traditional IT security). Star Controls provides a complete Cyber Security solution for the ICS/SCADA systems, which detect and protect any potential entry point into the system. It's integrated and holistic approach stitches the Cyber Security for all components that are part of the SCADA system: Data Center - SCADA Servers and Front End Processors (or Gateways) Networks - Devices, such as Wireless Radios and Gateways Remote Sites - RTUs/PLCs and Smart Devices and Site Security Star Controls offers end -to -end, holistic approach, that integrate technologies, products and protocols that were designed for the ICS/SCADA security, and leverages technical Star Controls' know how. SCADA SOFTWARE For Cyber Security Star Controls offers different SCADA software products, while the VTScada is among the best fit for Cyber Security. VTSCADA SCADA SOFTWARE Each application includes its own security accounts and settings which control access to all parts of the application including workstations, thin clients, mobile clients, and alarm notifications. Deployed security changes are immediate and application wide. Accounts are easily copied, modified, and deleted. You can now even share accounts across multiple applications. Military -grade encryption Security protocols Password protection Group management Share security accounts applications FIREWALLS FOR ICS/SCADA Star Controls includes products from Check Point, the industry leader in IT Security, to provide a complete To -Down IT Security to the ICS/SCADA systems. r 114i di Mita Star Controls has partnered with the top vendors to include best of breed products in the SCADA Cyber Security Field Ank 1 AI aM R CHECK POINT GATEWAY AND ANALYTIC MANAGER Check Point offers the most advanced cyber security. Aligning Operational Technology (OT) with Information Technology (IT) security, Check Point provides an end -to -end multi -layer threat defense, allowing real-time protection and monitoring against threats with full visibility along with granular control of SCADA traffic. Paired with ruggedized appliance options and comprehensive protocol support, Check Point ensures critical assets are never compromised. With our best in class management platform all IT and OT environments are supported with a single, unified and robust management; the most advanced existing today. Check Point's SandBlast is a complete solution for IT security, including Firewall, Anti-Malware, Anti- Bot, Anti-Ransomware, Forensics and more. The following information on the SandBlast Zero Day Protection and Anti-Ransomware includes more details on its capabilities in these areas. SANDBLAST ZERO DAY PROTECTIONS All enterprises are at risk of targeted attacks such as spear phishing and Advanced Persistent Threats. Check Point SandBlast Zero -Day Protection, with its unique exploit -level detection and threat extraction, provides an additional layer of security from even the most sophisticated hackers and dangerous attacks. Unlike traditional sandboxing solutions that are subject to evasion techniques and either introduce unacceptable delays or let potential threats through while under evaluation, Check Point catches more malware, with minimal impact on delivery times. SandBlast is offered at the Network level, in the Cloud, and at the EndPoint. ANTI-RANSOMWARE Check Point SandBlast Agent with Anti-Ransomware and zero phishing technology, extends zero - day protections to web -browsers and end -user devices to defend against advanced attacks, keeping users safe no matter where they go. With continuous data collection and automated incident analysis, SandBlast Agent provides actionable forensics, which accelerates the process of understanding the complete attack lifecycle, damage & attack vectors, to maximize response team productivity and minimize resolution times. Anti-Ransomware keeps businesses one step ahead of attacks by automatically detecting, blocking and removing the most sophisticated ransomware infections and restoring any encrypted data as part of its automated remediation capability. WIRELESS GATEWAYS Star Controls offers a variety of wireless Gateways, such as cell modems or data radios, for private and public networks. Star Controls engineers will add all necessary authentication and encryption to the units, so secure this segment of the SCADA system. PRIVATE NETWORKS Star Controls offers products from leading vendors, such as CalAmp, 4RF and GE-MDS. PUBLIC NETWORK Star Controls offers products from leading vendors such as Sierra Wireless and Red -Lion. Our IT security experts will facilitate the dialogue with the cellular service provider, to define and implement all necessary IT security, e.g. VPN, while the data is going through the SP's networks. The AirLink Raven RV50 from Sierra Wireless is an example for Cellular Gateway that meets the OT and IT requirements. The Raven RV50 is loaded with features to secure critical data. It supports secure communications to multiple back -end systems by providing up to five concurrent VPN sessions. Remote authentication management allows enterprise -grade systems to manage access RTU, PLCS AND SMART DEVICES This area in the system is vulnerable and has been ignored by almost all vendors. Star Controls is addressing existing systems by adding layer of IT Security to sites with PLCs and Smart Devices that are used by the different vertical market. Star Controls is also promoting the Motorola ACE3600 RTU, which is the first RTU in the industry that provides a complete end - to -end IT Security to the remote monitor and controls. SECURED ACE3600 Secured ACE3600 RTUs, FEP (ACE IP Gateway or ACE3600 FIU) with enabled security features such as access/interface control, secured communication, secured files, and security -related logs. ACE3600 Security Policy is a set of configurable system -wide security parameters for enforcing the organization's security policy in the ACE3600 system management tools (STS), front-end units and field units. ACE SECURED SYSTEM - SECURITY LAYERS • Secure Access Control - User access control to all system parts - Roles and permissions - M2M access control - Central access management & control • Audit - Integrated security log - Logging security events - Sending security alerts • Stored Data Encryption - File encryption • Communications Security - Data payload encryption - Encryption key management - Integrated IP Firewall - Unused port disabling - Suppressing vulnerable protocols - Message Life Time • White listing - Run-file white listing in the RTUs - Management tools white listing & configuration change control • Secured programming - Implementing secured programming methodology - Avoiding "backdoors" - Using protocols / port scanners -.NET Code obfuscation STARTU SOFTWARE APPLICATION Star Controls' flagship software product, for the Motorola RTUs, is a game changer in the RTU/PLC market, providing the SCADA and the O&M team unparalleled capabilities and ease of use to configure, change and maintain every aspect of the RTU. The StaRTU has been upgraded to work on the Motorola Secured ACE600 RTU. Star Controls is also planning to incorporate logs from the StaRTU loggers (i.e. Communications and I/Os) into the Cyber Security Analytic at Check Point Manager. This will cover non-IP, legacy, SCADA systems. SITE SECURITY The site security is an important part of the overall security of the ICS/SCADA system. The integration of the two systems allows the correlation between alerts from IT security with the site security. The site security includes access management and advanced video surveillance, including video analytics. CYBER-SECURED SCADA SYSTEM CONCEPTUAL BLOCK DIAGRAM with Cyber Security Solution Partners DMA CENTER CHECK POINT 6ATEWA.O' & ICS ANALVTiCS SCAM REMOTE SITE ismb WIRELESS COMMUNICATION DEVICE MOTOROLA TU a ► St TU SCAPA REMOTE SITE lico CHECK POINTCri) Wit) SCADA REMOTE SITE BOLA SOLUTIONS SCALA REMOTE SITE SCADA REMOTE SITF WARR REMLlrE SITE ;�y. SIERRA►��v-i-scada WIRELESS" s}Tlwof±euMr,rmraR Cxnral Solution Partner ST T 1 YOUR GLOBAL IIOT, SCADA & TELECOMMUNICATIONS PARTNER • 11555 Heron Bay Blvd, Suite #200 Coral Springs, FL 33076 +1-954-604-6656 sales@star-controls.com star-controls.com v0622 StarSupport Why use Star Controls Support for your SCADA System? To increase its availability and extend the Life Cycle of the SCADA system, the system must constantly be maintained, optimized, and enhanced. Star Controls offers a large portfolio of Support and Maintenance to fit the needs of your SCADA System. From remote sites, through communications and networks, all the way to the Control/Data Centers. Our skills and experience guarantee a holistic and detailed understanding of your operations and the SCADA system. Support services can be scheduled or unscheduled to address an immediate need. Urgent Support is available, including during non -office hours, to address faults that impact critical operations. Star Controls also offers proactive maintenance, where we continuously monitor the performance of the system and detect degradation in performance before it interrupts operations. StarAssured Star Controls offers StarAssured, a suite of support and maintenance services. Recognizing that each customer is unique, the StarAssured meets different needs and budget and can be tailored to specific needs. StarAssured includes: • Pre -Packaged (i.e., bundle) and Tailored Plans • Annual or On -Demand Remote and Onsite Proactive Maintenance — Remote Optimization Knowledge transfer Services: • Remote Support —Scheduled and Unscheduled • Onsite Support —Scheduled and Unscheduled • All onsite services are coordinated with Star Controls, and in most cases will require Support Contract in place Onsite Educational and Optimization — Scheduled Monthly Remote Monitoring and Report StarSupport Annual Support Contract The Annual Support Contract provides customer peace of mind and allows Star Controls to plan the required engineering resources. The contract can be based on a Pre -Packaged or tailored around the specific needs. Star Controls strongly recommend customers sign up for the annual support plan. Naturally, customers that are under an annual support contract will benefit from faster response time. Our Pre -Packaged Annual Plans STARCONTROLS Remote Support — Scheduled Remote Support — Unscheduled Onsite Support — Scheduled Onsite Support — Unscheduled Onsite Support — Educational Monthly Remote Monitoring and Reporting 0 0 O 0 0 0 0 O O 0 O O 0 O 0 rr"illr Contact one of our high -trained SCADA support representatives today for more information. ri‘ STARCONTROLS Your Global SCADA & Telecommunications Partner © Star Controls, Inc. All rights reserved. v0620 Tel: 1 + 954.603.0491 Fax: 1 + 954.603.0492 sales@star-controls.com www.STAR-CONTROLS.com 11555 Heron Bay Blvd, Suite #200 Coral Springs, Florida 33076 USA vTscada by Trihedral Alarm and Event Management Standard Component 00 vTScada Alarm Page SystemAlara DB Be, tf l®t ®O 111D % u n sod - Y °k 00'% IA -I ® * *❑ tease Alarm Actions Reports & Analysis Gist, Etter View Sounds History Active Unacked Current Shelved Disabled Configured Time Ack Status Area Name U 2016-05-03 13:40:32 Ack • Alarm Zone1 WaterDistributionSystem\Zone_1\V-`-- ""_''-- 1 ROI help Acknowledge Sheve Ack Ack Ack Ack ❑2 2016-05-03 13:36:39 Ack • Alarm LM Pre -Ma WaterTreatmentPlant\Pre-Mix\Inlettla Add Note Out -of -the -Box Alarm and Event Management Thanks to VTScada's integrated design, every new application includes pre -configured databases that support an unlimited number of process alarms and events. Additionally, the standard VTScada Alarm Page provides an instantly intuitive alarm management interface. This approach reduces integration time and ensures that your mission -critical alarm features remain tightly integrated over the life of your system no matter how many times you expand your application or update VTScada. ISA 18.2 Compliant - The re -imagined alarm page and augmented tools help you enact the best practices outlined in the ISA 18.2-2009 Alarm Management Standard. VTScada Anywhere Client — This new Thin Client display option provides a consistent alarm interface across computers, phones, and tablets. Intuitive Operator Interface In the event of an alarm, simply click the blinking icon in the top right corner of every page to jump to the VTScada Alarm Page. • See current, active, unacknowledged, and disabled alarms. • Easily sort by date/time and filter by functional area or priority. • Acknowledge, silence, or mute alarms even while configuring. • Shelve alarms to stop alerts during maintenance and alarm floods. • Print any range of the alarm or event history. • Reduce eyestrain by choosing daytime and nighttime views. • Adjust text and row size for optimal viewing on different screens. • Access a time -stamped list of system events (e.g., logons or setpoint changes). Advanced Situational Awareness • Instantly identify the status and priority of each alarm in the list. • Plot the associated tag's data or open related displays. • Use a combination of text, symbols, color, and sound to best meet the visual needs of your team (e.g., color vision deficiency). • Provide context by adding encrypted operator notes to alarms. Require notes when acknowledging, shelving, or un-shelving alarms. • 'Alarm Details' dialog provides an overview of each alarm's configuration, history, and notes. • Secure remote Thin Client access allows operators to manage alarms from anywhere using their own mobile devices. • New VTScada Anywhere Client provides access to all advanced alarm analysis tools. p3 $ v 1A5 PM May3 Log on • w�em ss Wes Sims Swee e. • v.� SOW �u„•N _l.t �.r„o,.. Mom"Sou K•, .�.,,, r.....,. em▪ ie O P* LIS went. Siv_liscsV*ii now The New VTScada Anywhere Client Bad Actors &arm Fk, d History Distribution or rrbrala P Reported History Current Configuration ISA 18.2 Recommended 0 0 17% 839' 0' 33% 67% 0''° 5% 15% 80% VT Alarm Details X WaterTreatmentPlant\Pre-Mix\RawWater\Turbidity Pre -Mix RawWater Turbidity Hi Warning Details Configuration Statistics Notes Selected record notes Logged Off • May 3, 201613:3339 • Note added May 6, 201612:57:41 Active Removed buildup. Behaving normally now. Problem has returned. Perform another visual check on the day shift. [Insert a Quick Cc mcm I Add Note I OK I ICancel I OK I Encrypted Alarm Notes VT Shelve Selected Shelve the selected alarm ® !°f: 0 until 31 2C16-05-04 0 indefinitely 5 minutes u 12:00 OK x Cancel Alarm Shelving Expiration Triheciral A Delta Group Company vTscada by Trihedral Alarm Diagnostics and Nuisance Alarm Reduction Four new alarm reports help you to easily identify trouble spots in your physical system or the application's configuration. All 3Od — ' ,I ICA -2 I .o. Database AnaI.isis Filter View Bad Actors Alarm Flood History Distribution of Priorities .Area Zone 1 Local TCP Port\PLCSim\Tank 1\Tank Level Monitor tank level HIGH 24111. Zone 2 Local TCP Port PLCSim\Tank 2\Tank Level Monitor tank level HIGH 3 0 Zone 3 Local TCP Port1PLCSim\Tank 3'1Tank Level Monitor tank level HIGH 2 Name Description Count 5 Percent 14 66.7 23.8% 9.5 % Bad Actors Report —A'bad actor' is an alarm that is tripped excessively indicating problems with equipment, processes, or alarm configuration. Easily spot bad actors by scanning alarm events within a specific period, sorted by the number of activations. Bad Actors Alarm Flood History Distribution of Priorities P 1 % 50 Mar 20 .1 .1 a I1 ..I Mar25 Mar30 li 1 Apr4 Ill_ Apr 14 All - 6 ®®°o Ui 10d °cE) FA -I 14. Database Analysis FIter V!err Bad Actors Alarm Flood History Distribution of Prionties P Date - Event Area Name Time Description 2016-04-07 a Active Zone 1 Local TCP Port\PLCSi ATank 1\Tank Level 12:03:29 Monitor tank level HIGH O 2016-04-07 A Active Zone 1 Local TCP Port\PLCSim\Tank 1\Tank Level 11:00:50 Monitor tank level HIGH User a 2016-04-07 , 10:54:05 Active Zonel Local TCP Port \PLCSim\Tank 1\Tank Level Monitor tank level HIGH Bad Actors Alarm Flood History Distribution of Priorities P 4011 Reported History Current Configuration ISA 18.2 Recommended 17' 83' 33' 67' Critical High Critical High 5' 15' 80°'° Critical High „arn rg Alarm Flood Report — An 'alarm flood' occurs when there are more alarm events in a specific period than operators can reasonably handle. Quickly identify floods by moving your mouse over the blue bars to see the number of alarms tripped within periods of time. Click a bar to zoom into that period. History Report - This pre -filtered list shows only Active and Trip alarm events. Select an alarm then use the tools in the Analysis Toolbar to gather more information about it. E I • Alarm Details • Historical Data Viewer • Open Associated Pages • Alarm Properties Distribution of Priorities — Easily compare your application's alarm priority distribution with the ISA 18.2-2009 Alarms Management Standard. Compare the priority distribution for both your reported history and current configuration with the distribution recommended in the ISA 18.2-2009 standard. Trihedral A Delta Group Company vTscada by Trihedral Multi Plant Architecture - Centralized Management, Autonomous Operations Configure multiple alarm databases to separate operational alarms (e.g., plants and processes) for targeted alarm processing. System Alarm DB System Event DB Scada VOEI 14101:1Dt. Unacked Current Shelved Disabled Configured Time Ack Status Area II New VTScada applications include separate alarm and event databases. Existing applications are automatically converted. • The Alarm Database Tag allows you to add more databases as required and synchronize them across a network. • Filter the Alarm Page on any networked workstation to display lists from one or all of them. • Locally stored databases allow operators to manage and modify alarms even when disconnected from alarm servers. • Synchronized distributed databases keep your priceless alarm and event history safe and up-to-date. Areas of Responsibility Define what information users can see in large applications. For example, if an application monitors two plants, operators may see and respond to alarms from their respective plants, while the management team can see alarms from both plants. Efficient Alarm Configuration In seconds, authorized developers can create alarms in the Alarm Tag Properties Dialog in the VTScada Tag Browser. To simplify the process further, Alarm Tags are built right into the Analog Status and Digital Status Tags. Developers can also embed customized alarm lists into any custom display using the VTScada Idea Studio. Configure pop-up dialogs to ensure that operators are aware of high priority alarms. Uninterrupted Alarm Management VTScada's online configuration allows you to view and acknowledge alarms even while editing application tags, screens, and properties. SCADA Alarm Security Tightly control access to the Alarm Page and Alarm properties using application -level privileges assigned to specific user accounts in their areas of responsibility. Users must log in with their own credentials to access alarm information via workstations, Thin Clients, and alarm notifications. Alarm privileges can be revoked instantly across the whole system. Alarms/Events i 2016-05-02 09:0636 WaterDistribution5ystem� \TankLow 2 Tank level too low - Tank 2 Ack All 2016-05-.. - - - --- Application Application Started (0 min 19 sec) s Embedded Custom Alarm Lists VT Alarm(WaterDistributionSystem\Zone_2\Tank_24TankHigh_2) Properties x ID Trigger Actions Display Triggered by [TankLevel_2] Level ofTank2 I/ .:. Constant 0 Expression 0 Tag Function Greater Than ) �^ Setpoint [TenkHiAlm5pFeedB_2] Tank 2 high alarm setpoint feedback nnn t s Constant 0 Expression 0 Tag On Delay (s) Off Delay (s) 0 0 Q Constant 0 Expression 0 Tag 0 Constant 0 Expression 0 Tag Deadband 0 !i Constant 0 Expression 0 Tag OK Cancel The Alarm Tag Configuration Dialog Triheclral A Delta Group Company vTscada Mobile Alarm Management Optional Component VTScada Thin Clients allow authorized users to view and acknowledge alarms from anywhere. Authorized Thin Client users can easily select the display format that best suits their screen size and data plan. • The VTScada Anywhere Client — State-of-the-art Thin Client provides a consistent operator experience on any HTML5 device. Event -driven execution provides real- time data without overloading your data plan. Zero -footprint means nothing to download and install. No Java either. • VTScada Internet Client (VIC) - Windows PCs - Identical to a VTScada Thick Client operator workstation. • Mobile Internet Client (MIC) - HTML5 browsers on smartphones, tablets, PCs, and Macs - Text -based alarm interface optimized for smaller screens and data plans. Note: WAP is discontinued as of 11.2. Alarm Notification System Optional Component When alarms happen, your SCADA system needs to alert the right people as soon as possible no matter where they might be. • Automatic Alarm Callout - The VTScada Alarm Notification System (ANS) transmits alarm information anywhere via text -to -voice phone calls, SMS text messages, emails, and pagers. • Built -In is Better - VTScada's unique integrated approach vastly reduces integration time and ensures tight compatibility over the life of your system no matter what version you are running. The ANS shares the same tag and alarm databases as the VTScada application. • VoIP-Based Voice Alarms- In addition to physical modems, VTScada now supports three additional ways to send text -to -speech alarm notifications. • VolP to phone lines via analog telephone adapter (ATA). • VolP to PBX via internal digital phone service. • VolP to online VolP Service (Voice only). New in Version 12.1.35 - Use the above as well as Twilio Programmable Voice° and voice modems as redundant backups for voice alarm calls. VolP now allows encrypted call setup and encrypted audio. by Trihedral 1ELUSF 3ZBPM scada AMMO 1,, •■ os■• •N•a1R A=t* Event Event Event Event Eon, Disame Double DiuWe Sy,am ApgA,nan SM.. Applh. Synem Applerzan System ....Its System Apoka LM Met.. WaterireatmenePhno. SR more nw nw ian Netr...m,om an\pn,ryAanDukr In La., W^o Sou SurxeKlreOpen 16SI AP A, i The New VTScada 'Anywhere' Client • Dial -in Phone Access - Dial into your application using your application security account to check levels, acknowledge alarms, change setpoints, or send commands to equipment. • Licensing - Add ANS to any VTScada Runtime or Development Runtime license by simply updating your software key. • Easily Configured Rosters (Updated in Version 12.1) - Rosters are lists of up to 39 users to contact in sequence until an alarm is acknowledged. Create any number of rosters for the whole application or functional areas. Change rosters by events or on schedule (recorded in history). • Easily reorder Roster Contacts via arrow buttons. • Set wait times for each contact or notify multiple contacts in one 'Iburst'I. • Repeat contacts without adding them multiple times. • Allow users to configure Rosters without the ability to modify tags. TRY IT FOR YOURSELF Download the 90-day Trial VTScada.com/trial Y1 Pctt, ID Contacts Wilted Name phone Number / Email Address a Start of roster Email Bob bob®mycompeny.com i Email Sue suetDmycomparycom Compact Email Mao mae6myconpany.com 11 Delay for 1 minute Q T. Message Bob 902-555-0000 1 Delay for 5 minutes Voice Bob 902-555-0000 L Repeat 3 times with 5 minute dela,s Q End of roster + Add contact + Add delay/repeat SXX9. Uunwrla T Zane Enabled bob ma, bob Sense Tote Zone Q X Saner Time Zene p x Sorer Tiro Zone © X x Saner rma zone El X x Sneers zone IA x x OK Cancel APPIY Updated May 8, 2024 Intuitive Roster Configuration. VTScada.com info©trihedral.com 1.800.463.2783(North Armin) 1.902.835.1575(Woddwida) +44 0) 1224 25801D (Europe) Trihedral A Delta Group Company Trihedral Engineering Limited 2024. VTScada and Tr' hedral are registered trademarks of Trihedral Engineering Limited. All other products are trademarks of their respective owners. VTScadao by Trihedral The VTScada Alarm Notification System A fully integrated solution designed to work seamlessly for the life of your system. Optional Component Today's SCADA operators are too busy in the field to have time to sit looking at screens all day waiting for problems to occur. When alarms happen, the system needs to be able to get that information to the right person as soon as possible no matter where they might be. The VTScada® Alarm Notification System (ANS) transmits alarm information anywhere via text -to -voice phone calls, SMS text messages, emails, and pagers. Dial into your system using your application security account to check levels, acknowledge alarms, change setpoints, or send commands to equipment. VTScada Built-in is better VTScada's unique integrated approach to alarm notification vastly reduces integration time and ensures tight compatibility over the life of your SCADA system no matter what version you are running. Add ANS to any VTScada Runtime or Development Runtime license by simply updating your VTScada software key. The ANS shares the same tag and alarm databases as the VTScada application. Note: Alarm and event management is part of every VTScada application. The built-in SCADA alarm notification features described here are optional. New in VTScada 12.1 - Annunciate Voice Alerts over VolP, no modem or Internet VTScada will continue to support physical voice modems for text -to -speech alarm annunciation while they are available. However, it is increasingly difficult to find companies that produce them. Worse, telecom providers are phasing out support for data over analog lines. Version 12.1 lets you move beyond this hardware and take advantage of the benefits of VoIP without going through the internet. Leave no alarm unacknowledged - When an alarm goes unacknowledged for a user -defined period, VTScada won't stop until it finds an authorized person to acknowledge it. The system begins working its way through rosters of up to 30 contacts each. A contact is a combination of a staff member and a method of notification such as SMS text message, email, or over the phone via text -to -speech voice engine. This means you can create a contact for your cell phone and another for your landline. Configure any number of rosters for the whole application or specific functional areas. Roster activations are recorded as events in the alarm history. Dial -in phone access - Dial -in from anywhere to log in and use the auto -generated spoken menu's system to hear system values (e.g., well levels), perform control actions (e.g., start pump 1), and receive or acknowledge a list of alarms. Acknowledge by SMS, email, or text -to -voice - Once you are notified of an alarm via SMS text message, email, or text -to -voice phone call, you can easily acknowledge it the same way and stop VTScada from sending further notifications. Messages VTScada Contac'. 04/29/2014, 04:12 PM. Zone 1 - Tank 1 level too low Code: 9MCZ 04/29/2014, 04:12 PM. Alarm Acknowledged: Zone 1 - Tank 1 level too low Crystal clear text -to -speech - VTScada uses the Microsoft® Speech API (SAPI). In addition to providing the latest in text -to -speech technology, SAPI simplifies our licensing and significantly reduces the size of the VTScada installer. Voice modem support - VTScada should work with any standard voice modem. Though we cannot guarantee the compatibility of third -party modems across all Windows operating systems our engineers have identified modems that they have used or have been used by our customers on our VTScada Support Forum. VTScada.com/modems Trihedrt A Delta Group Company vTscada by Trihedral New in VTScada 12.1 - Alarm Notification/Roster Enhancements Version 12.1 makes it even easier to ensure your critical alarms find you anywhere. • Clearer and Easier Configuration - The Roster Properties dialog has been revamped to make it easier to organize the contacts. ■ Drag -and -drop Reordering — This includes the ability to easily reorder contacts in the roster via drag -and -drop. • Custom Callout Delays - Rather than a single delay between roster callouts, you can now set a custom wait time for each contact. ■ Notification Bursts — Custom delays allow multiple contacts to be notified in one "burst" by setting no delay between them. • Repeat Groups of Contacts - One or more contacts can be repeated in a roster without having to add them multiple times. Roster (Rosters \Roster 2) Properties X ID Contacts Settings Method Name Phone Number / Email Address Usemame Time Zone Enabled iir Start of roster 0 Email Bob bob©mycompany.com bob Server Time Zone i0 X 0 Email Sue sueemycompany.com sue Server Time Zone 0 X 0 Compact Email Max max©mycompany.com max Server Time Zone l] X 11 Delay for 1 minute X 1 IJ Text Message Bob 902-555-0000 bob Server Time Zone © x 11 Delay for 5 minutes x r L Voice Bob 902-555-0000 Server Time Zone ❑d x IL Repeat 3 times with 5 minute delays X Q End of roster + Add contact + Add delay/repeat OK Cancel Apply I Advanced modem management - VTScada collects modems from all application servers into a single pool. VTScada searches this pool, rather than a specific server, for an appropriate data or voice modem to use when sending alarms. Twilio®, an alternative to physical modems - Problems with modem reliability? Unable to run phone lines to your server farm? Having difficulty sourcing voice modems? The VTScada Alarm Notification System can now support voice telephony and SMS alarm notifications using Twilio, a paid web -based communications platform. This requires SCADA access to the Internet and a Twilio account (www.twilio.com). Running VTScada as a service? — VTScada can optionally run in the background without an active user interface. Note that Microsoft does not permit Windows services to access SAPI, the built-in Windows text -to -speech engine. This means that if you're using the VTScada Alarm Notification System and you have configured your application to run as a service, the outgoing alarm calls will be silent. In this case, we recommend using Twilio (above) for alarm annunciation. This is not an issue for standard VTScada installations. Automatic failover - Server failover is an important factor in ensuring uptime and accessibility. This extends to alarm notification. Easily create lists of backup alarm notification servers that will automatically and seamlessly take over if the primary is unavailable. Responsibility will return to the primary server when it is restored. Application -level security - Secure access on incoming and outgoing calls is maintained using the standard VTScada Security Manager. To receive status or alarm information, users are prompted by VTScada for their password. Users who do not have the 'Alarm Acknowledge' security privilege will not be able to acknowledge alarms. Hardware requirements - Hardware requirements depend on how the notifications are sent. • For spoken alarms and pager notifications, the Alarm Notification System uses a modem to make outgoing calls. • For email notifications, configure an email server or provide access to a commercial server such as Gmail®. • For SMS-text notifications, you will need an SMS appliance. SMS hardware is not covered in this guide. Mobile alarm management - VTScada Thin Clients (licensed separately) allow you to securely view and acknowledge alarms anywhere using PCs, or HTML5 compliant mobile devices. DOWNLOAD THE 90-DAY TRIAL VTScada.com/trial Updated May 17, 2022 VTScada.com Infoatrihedral.com in O m7 sa f 1.800.463.2783 (North America) 1.902.835.1575 (Worldwide) +44 (0) 1224 258910 (Europe( Trihedral A Delta Group Company © Trihedral Engineering Limited 2022 VTScada and Trihedral are registered trademarks of Trihedral Engineering Limited. All other products are trademarks of their respective owners. VTscada by Trihedral Historical Data Management and Trending Standard Components A world -class historian that protects your data and puts it to use across your organization Available at no extra cost, the VTScada® Historian is an integrated component requiring no configuration or database management. Real-time synchronization ensures your history is safely distributed across all redundant servers. Developers can fold logged data into a variety of user interfaces while operators can create their own ad -hoc trends and reports. VTScada easily shares data with third -party business platforms. It can even import the history from your old legacy system. The VTScada Historian The only database specifically designed for SCADA Most SCADA platforms require a third -party database to store logged data. These products were designed to be generic tools used in almost any field such as accounting, academia, or sales management. Only VTScada includes an Enterprise historian designed specifically for SCADA applications. In addition to being fast and compact, this approach makes it possible to easily scale your application from a few hundred tags to a few million. There is no need to upgrade your simple "starter" database when your system starts to grow. This pre -configured historian vastly reduces integration time and eliminates the need to separately license and support third -party products. Best of all, each configured redundant server automatically contains an up -to -the -second backup of the whole database. 3'a Party Databases via SQL Manual Data I/O Tags da Calculations Totalizers Counters Alarms r Electronic Operator Logbooks Log data from multiple sources based on triggers Data is stored directly to the Historian at the time of trigger occurrence, eliminating any need for separate real-time and historical databases. VTScada can log on change, on related event (can be used for disable/enable), on time/sample period, or on operator actions (e.g., manual data entry, setpoint change, or control action). A Delta Group Company Upon request, the Historian analyzes • Time -weighted average (analog) • Minimum (analog) • Maximum (analog) • Change in value (analog) vTscada by Trihedral Summary, on -demand data raw tag data and provides time -series summary divided into time slices. • Value at start (analog) • Time of Minimum (analog) • Time of Maximum (analog) • Totalizer (analog) Multiple Historian configuration ite vie N' ERNET� - 'p INT data, based on a user -definable duration • Interpolated (analog) • Diff between start and end (analog) • Zero to non -zero transitions (digital) • Non -zero time (digital) Historical Data Synchronization 1 r VTScada supports any number of historians for a single application. Each one can be configured to store data for a different geographical and functional area. Each tag may store data to one Historian. VTScada also allows you to configure redundant third - party relational databases such as Microsoft SQL, Oracle, and MySQL. These must each be separately purchased, installed, supported, and backed up as per their respective manufacturers' instructions. Redundant Historian configuration Thanks to VTScada's integrated design, every application server can host its own Historian. Each data point is stored identically on each one. Redundant Historians can also include third -party formats. For example, the primary and secondary could be the native VTScada Historian while the secondary backup could be Oracle. Redundant Historians may be co -located with the Primary or geographically separated provided an IP connection exists between them. Bi-directional synchronization Redundant Historians use the same schema. VTScada uses timestamps to ensure that each data -point is identical down to the millisecond. Should the primary database server fail, associated workstations and Thin Clients seamlessly switch to the next designated database. When restored, historical data automatically synchronizes across a local or wide area network at up to 160,000 values per second. This speed is automatically throttled to avoid interfering with real-time communications. If servers become isolated from one another, they will continue to log their own local I/O and automatically sync once their connections are restored. Long-term data storage. No more archiving. Data archiving was traditionally used in long-term historical data storage to mitigate limited drive space, and to provide a form of backup. VTScada makes this unnecessary. Its efficient storage format packs more data into every megabyte of hard drive space compared with other standard database formats. Using redundant Historians, as described above, is a far more robust backup methodology. Logged calculated values do not count against the licensed tag count. A Delta Group Company vTscada by Trihedral Secure historical data VTScada's Historian cannot be edited within VTScada or by third -party software. The proprietary log files are not human readable. VTScada uses a checksum to detect tampering or corruption. Note: If you are also logging to a redundant third -party database you will need to secure it as per the manufacturer's instructions. Historical data editing While the Historian cannot be altered, it is possible for authorized users to override individual or ranges of logged values. This is a helpful way to fix incorrect or missing values. Edited values are marked in the Historical Data Viewer along with a required explanatory note. Overwritten values are not lost. History data import from CSV files When replacing a SCADA application of a different software brand, VTScada helps you maintain a complete view of your process history, allowing you to import the historical data from your legacy system. Consult VTScada Help for information on formatting files for import. Simple Historian status monitoring The Historian Status Monitoring Widget provides instant status of write and storage rates. When write rates exceed storage rates, data is automatically buffered and written in burst mode when the Historian connection is available. VTScada write rates have been tested to 4,000 values per second for a single tag, thus buffering is usually the result of a slow network, underpowered CPU, or slow storage media. Historian Status Name Current Server Connection Status Queue Length Write Rate DB Store Rate Service Status - SystemNarmHistorian LAPTOP1 Connected 0 0 0 Ready SysternHistorian LAPTOP6 Connected 0 16 16 Ready Sharing Historian Data with Third -Party Platforms VTScada makes it easy to share real-time and/or historical data with third -party software platforms via these industry standard protocols and methods. • OPC Server - Allows OPC-compliant programs (including other VTScada applications with OPC clients) to exchange live data with standard VTScada applications. • OPC Client (DA & UA) - Allows VTScada applications to exchange live data with an OPC-compliant server (including VTScada applications with OPC servers). • ODBC Server - Allows you to use popular software like XLReporter®, Dream Report®, Crystal Reports®, Access®, or Excel° to extract VTScada system data. VTScada acts as a database where each logged tag represents a table of timestamps and values that reporting software can query to retrieve logged values. • REST & WEB Services - VTScada's REST and SOAP (XML) interfaces allow business systems to request real-time and historical data. They support time/date ranges, min, max, time of min, time of max, average, total, and SQL that include SELECT commands and WHERE clauses. • Third -Party Reporting - Third -party reporting products, such as e.RIS®, XLReporter®, and Dream Report®, have integrated VTScada interfaces. A Delta Group Company by Trihedral The VTScada Historical Data Viewer (HDV) A powerful trending tool that any operator can use. Historical Data Viewer Re%led. DPwt r. Span Pan %Zoo m Men M6 no- d The HDV provides a continuous view of analog and digital data. 111500 13:1630 13:1600 161630 1311;60 111230 1619A0 13:1930 13:2000 132630 132190 132130 162240 133230 132320 112130 132600 I Pen Name Dascnphon Q N ..\UpsireamFlow100 Upstream Now Rate ti _ 6amValrePorition Main Valle Posdion 6 N Bernoulli rake*TUNineSpeed Turbine Rotational Speed _\Downstream FlowRate Upstream Flow Rate O • iL ArypassSwitchreedback Bypass Switch Feedback 6 in System Notes \600,4 G2d X Np64/ Value Minimum 444 ft•Ms S RPM 651036 Off Mamrmn 508 tt"3/s 74 % 457 RPM 506tt^36 Off AA R0s 450 RPM See nails Skirts OnTime 500000 The VTScada Historical Data Viewer (HDV) is just one of the ways operators can interact with their application's process history. This standard interface provides a continuous view of historical and real-time data on a single timeline. It can include both analog and digital I/O values. Move the Marker Line horizontally to see continuously updated values for each plotted analog tag at every selected timestamp. Icons in the Pen Legend below allow you to hide pens (tags) or edit their appearance. lA) WassewaterPlantDerno a TCPIP Port . WanereaterPlam1im r Pumps • Pump1 a Name w ❑Show CkMrm ❑ SRav Disabled .Istaeons nRe:oumes Menus Simulators System Alarm DB System Event DB WastewaterPlantDemo TCPIP Port WastPlanlSim 5M01555ntStyle 60 Pumps -0 noraun L� Pump0 3 PumpCurre t 3 PumpOhw 3 PumpRcsel 3 PumpRPM 3 Pumpl3unnirg 3 Pump0peedSP 3 PumpSpeerISPCM 3 PumpSpeedinp 3 PumpSpeedTrip5P All Types Pump Current Pump Flow Reset Puml Pump RPM Pump Runr Pump Spee �. Pump Spur Pump Rum Pump Spee 3 Pumpspeedi0pSPCM Pump Spee 3 Pumpsbrt Start Pump 10 3 rrmn rm, rM ��mn Analog Status 40012 Draw Plot View .arms Cut Copy Paste as Child New Child Delete Plot tags right from the VTScada Tag Browser. Time ..\Filter#l\Turbidity ..\filterd2\Turbidity ..\filtelt3\Turbidity . Fillerd1 Turbidity Fillerd32 Turbidity FitleA33 Turbidity Sep 25 02A5 Sep 25 0230 Sep 25 02:15 Sep 25 0200 Sep 25 01:45 Sep 25 01:30 Sep 25 01:15 Sep 25 0190 Sep 25 00A5 Sep 25 0030 0.0648600 0.0648600 0.0648600 0.0648600 0.0648600 0.0648600 0.0648600 0.0648600 0.0648600 0.0648600 0.061800 0.061800 0.061800 0.061800 0.061900 0.061800 0.061800 0.061800 0.061800 0.061800 See raw values in the Grid View tab of the HDV. 2.C648600 0.0648600 0.0648600 0.0648600 0.0648600 0.0E48600 0.0648600 0.0648600 0.0648600 0.0648600 Instantly intuitive trending designed for operators In addition to the standard page, you can also configure the HDV as a pop-up display or as an embedded trend group on custom pages. Best of all, operators can create and save their own ad -hoc trend groups with just a few clicks. They can also trend values right from the tag browser, or alarm page (image above left). HDV tabular view HDV data may also be shown in time -series tabular view (image above right), as raw data to the nearest millisecond, or as ave, min, or max values. Additionally, to facilitate time -sliced viewing, a total period may be selected, and then further time -sliced to display summary data for each period. For example, 24 hours of data may be shown as 24 separate rows of one -hour averages for a selected set of tags. Download the 90-day Trial VTScada.com/trial Updated March 11, 2022 VTScada.com info@trihedral.com n 0 I 1.800.463.2783 (Nod America) 1.902.835.1575 iworldwlde) +44 (3) 1224258910 (Europe) A Delta Group Company © Trihedral Engineering Limited 2022. VTScada and Trihedral are registered trademarks of Trihedral Engineering Limited. All other products are trademarks of their respective owners. VTada 0 by Trihedral The industry's most powerful SCADA software`' for systems that simply can't fail. align '® 2021 ENGINEERS' CHOICE AWARDS 1 WINNER Plait PRODUCT ea-YEAIT -)/0202� 2020 Product of Year Yesue., n.aro Agenda Agenda 9:00 - 11:30 — Presentation 12:00 — 16:00 — Product Demonstration VTScada® by Trihedral One Install Provides All Core SCADA Components v , r SCada Under 200 MB Installer Software for Monitoring 8 Control Monitoring & Control A l Date Time Tag Name 2 1-Dec-17 13:05:00 PlantDemc 3 1-Dec-17 13:05:00 PlantDemc 9 1-Dec-17 13:05:00 PlantDemc 5 1-Dec-17 13:05:00 PlantDemc 6 1-Dec-17 13:05:00 PlantDemc 7 1-Dec-17 13:05:00 Demo`TCP Reporting Communication Drivers Account Name I Sian Password Confirm Password Security Alarms & Notifications -�l 1 u ( Ne- t Iall f C1 Historian Graphic Development Mobile Connectivity Mapping Trending Ven,en Time Applied 0109 ( Mon Marla, 201115:10:35460 D108 show Vanlon Detail; 92310 Di" Switch to TNa Veralo "UD9 D106 Reverse Version Change 333 D105 Morse veision Changes .711 D104 l.len Mer 14. 201111:1S:d9780 D103 l.Ion Mar11,201111:16:335981 Version Control Enterprise Connectivity INTEGRATED ARCHITECTURE Standard & Optional Components • We develop and maintain every part of VTScada. • One license agreement for all SCADA components. • All features are automatically upgraded with every version. • Unique design vastly improves integration and scalability. Open I/O Connectivity For All Your Devices MODOUS JSON DELTA DNP3 MATT DF1 DDE SPARKPLUG B MOTOROLA IP GATEWAY ROCKWELL MULTITRODE CAMPBELL SCIENTIFIC DMRDN CALAMP GENERAL ELECTRIC BSAP GRUNDFDS BACnet DFS MDS ALLEN-BRADLEY KDYO CAT MDS EMI BSAP CIP EMI AND MANY MORE... DEVICE DRIVER LIBRARY Standard Out -of -the -box VTScada includes hundreds of industry standard and proprietary protocols. Since they are fully integrated, the are updated with every new version of VTScada. ■ Drivers included in the base price of VTScada. ■ Examples: Modbus (many variants) - DNP3 - DF1 - Rockwell Ethernet IP - Siemens - Omron - GE - MQTT - etc. ■ Advanced polling features can replace Master PLCs. ■ Direct drivers cost less than maintaining OPC servers. ■ Trihedral can develop custom drivers on request. amomm -i Open I/O Connectivity For All Your Devices Modbus Advanced native polling tools. Protocol 1 Protocol z Failover to redundant networks or devices. TELEMETRY TOOLS Standard ■ Remote Asset Polling Driver. ■ Telemetry protocols such as DNP3, IEC 60870, Motorola, DFS ■ Support protocols with store -and -forward, datahopping, digipeating. ■ Multiplexer support for redundant comm links. ■ Advanced polling tools for real-time poll rate adjustment and fast/slow switching. ■ Calculations and Deadband Control to support automated site to site interdependency. New Communication Drivers - OPC UA and MQTT DPCUA Address Select opctcpi :62541 Objects - Server 1�LCTT E Scalar Scalar_Inswctions Scalar Static [�. Simulation -0 Boolean -0 Byte ByteString -0 DateTime -0 Double - 0 Duration -0 Float - Guid -0 Int16 -0 Int32 Int64 - 0 Integer -0 Localeld - LocalizedTe 1 Nodeld -0 Number - OualiiedName SByte - 0 String -0 Time - Ulnt16 Attribute NodelD NodeClass BrowseName DisplayName Description WnteMask UserWreeMask Value ns_2;id-Scalar Simulation_Int32 2 ns-2id-Scalar Simulation_Int32 Int32 96 96 Value 2118112219 DataType Int32 ValueRank Scalar ArrayDimensiom AccessLevel 3 UserAccessLevel 3 MinimumSamplingI nterval 0 Hirtorizing false RolePermissions UserRolePermissions AccessRestnetions AccessLevelBx 12 New MATT Client Driver Properties X 10 I Connection Credentials j Lost ItAll Port *Port --Missing-- ©® CI MQTT Client 10 VracadaP00000XXXXX-XXXXXXXXXXXX-XXXXXXXXX-XXXXXXXXMQTT 1 Keep Alive 120 QoS 0 QoS 0 - At most once C QoS 1 - At least once Qo$ 2 - Exactly once ❑ Hold WOK J ` Cancel OPC-UA CLIENT DRIVER Standard • Interface to OPC-UA servers running on local or remote computers. • An alternative protocol to OPC CLASSIC. No DCOM. • VTScada still supports the OPC CLASSIC. MQTT CLIENT DRIVER Standard • A gateway to the Industrial Internet of Things. • This subscribing client can read from an MQTT broker on your local network or the Internet. • You can then log, view, alarm, and report on values from devices connected to that host. train 41, 011000 Plug -And -Play Tag Creation YC Tag Browser. Showing 1 of 4,920 Running Tags 1 Using 22 of Unlimited licensed Tags — 0 X ❑o Show Children IIIi I Names I ❑ Sltosv Disabled All Areas se pmem Types se I CIP/ENI ©a Y I 111 E \ • Bemoulli_Lake .,r Ii:::, u>uo T;: =q,: .� .. -,:. Addre,_ AB-PLC1 Remote Site 1 PLC CIP/ENIP Device (101 Menus Pubficlncludes ServerStatus • System Alarm DB System Event D8 ' SystemHistorian Import New Properties Draw Close Y1 Impeding Tags From OnVII:. CIP 1 I S.1S9 a 7t1S9 Tags Selected CIP Port 1\CIP 1 J :. •ett(0) •.est(10) 4 •est(11) _•est(12) • . •e•.t(13) • •est(14) •est(15) :se Nantes O Shaw Cladren OCenfctsOnty TYD� - 0 X X 7 4' Sttow Selected ',Shan, Unelected Name Type Add re, AO_test(0) Ao test(1) AO test(10) AO testf11) AO_test(12) AO test(13) AO test(14) AO testf1Sl Analog (In/Out) Analog (INout) Analog Bn/Outl Analog (INOut) Analog [INOutJ Analog pru'Ovtj Analog (INOutj Analog 1INOutl AQ_test[OJ(AO_test(Oj) 40 test[IJ(AO test[1]) AO_test[10)(AO test[101) AOtest(I11(Ao test(11] AO_test(121(AQ testf121) Aotest[13jiAo test[13] AO_test(14j(Ao_t estf 141) AO testll Sl/AO test f151 1 OK Cancel Easily filter and choose just the tags you need to import. TAG IMPORT FOR AB CIP DEVICES Standard Component • Import tags from AB CIP devices to your application with one button.* • Button enabled when a supported driver is selected. • Filter and select tags before importing. • Copy parent/child tag structures configured in the PLC. • More devices will be added in the future. Tag names in PLC must be legal tag names in VTScada. Oracle° Built-in Historian - No Extra Cost or Configuration HISTORIAN MS SQL Server VTScada SQLitee THE VTScada HISTORIAN Standard Component Every application includes an Enterprise historian capable of logging from two to two million I/O. • Add synchronized redundant historians in seconds.** • Configure 3rd-party databases as needed (sold separately). • Import history from other SCADA platforms in CSV format. SQL Server, Oracle, MySQL and SQLite are trademarks of their respective owners. ** Requires additional VTScada licenses. Operator -Created Trending sFihersTurbidity Time %OM Hours s,11 0 ..\F ilter#1 \Turbidity Filterxl Turbidity Averages so 15 Minutes so ..\Filter#2\Turbidity Filterxl Turbidity 05:15 05:30 05:45 06:00 06:15 06:30 06:45 0.0624622 0.0624571 0.6624539 0.0624580 0.0624617 0.0624631 0.0624614 0,058375 0,058367 0.058363 0.058369 0.058374 0,058376 0.058373 Choose Plot or Grid view. HISTORICAL DATA VIEWER (HDV) Standard • No integrator required to add trend groups. • Click one or more screen values to plot, then save. • Add encrypted notes to the timeline. • Stacked and overlapping trend views. • Switch between Plot or Grid view. • Mobile trending from Thin Clients.* Add note to System Notes Feb 7, 2020 15:4847 X PLC 3 malfunction caused these unexpected levels. Will replace this dayshiftl 0R Cancel Built-in Reporting Tools 00 vrscacla trail .non MI .22.201 2221.2 Analog Summary Report from May D I E 1 F G ummary Report from May 2, 2019 06:55:00 to May 2, 2019 07: Tag Address Average Min Max Total Pump Flow gpm [40006] 3.64 0.6 18 218.34 Pump Flow gpm [40016] 3.45 0.6 16.5 206.96 Pump Flow gpm [40026] 6.86 0.1 19.9 411.48 Pump Flow gpm [40036] 6.95 0.3 19.1 416.72 Pump Flow gpm [40046] 5.39 0.4 19.1 323.63 Report Page and Report Tag Standard • Ad -hoc or scheduled reports. • Simple built-in report generator. • Output to screen, txt, csv, Excel, database or email. • Export to custom Excel Report Templates. Share Data With Enterprise Systems IRD-DART! CONNErTTITTV fDTTANC Standard in Development Runtime Licenses VTScada makes it easy to share history across your organization. ■ ODBC Server - Query VTScada's Historian like an ODBC database. ■ OPC Client / Server - Connect to real-time process values. ■ SNMP Agent* - Real-time data and report -by -exception traps. ■ REST Interface - Retrieve large datasets in JSON format using SQL. ■ JSON - Import website and IOT information ■ Web Services - Use soap/XMI to access historical and real-time data. ■ VTScada - Connect different applications to one another. NEW IN 12.1 - The SQL View Tag allows third -party platforms to efficiently query vast amounts of data from the Historian. Standard in all licenses Work Directly With Process Data Outside VTScada ■ Review View Add -ins Help VTScada 0 E F G Timestamp My Alarms\Analog 1:Value:Average Timestamp 2019-06-24 19: 2019-06-01 03:00:00 2019-06-02 03:00:00 2019-06-03 03:00:00 2019-06-04 03:00:00 2019-06-05 03:00:00 2019-06-06 03:00:00 2019-06-07 03:00:00 2019-06-08 03:00:00 2019-06-09 03:00:00 2019-06-10 03:00:00 2019-06-1103:00:00 2019-06-12 03:00:00 2019-06-13 03:00:00 2019-06-14 03:00:00 2019-06-15 03:00:00 2019-06-16 03:00:00 2019-06-17 03:00:00 2019-06-18 03:00:00 2019-06-19 03:00:00 2019-06-20 03:00:00 2019-06-21 03:00:00 2019-06-22 03:00:00 2019-06-23 03:00:00 1.00 22.93 50.00 50.00 50.00 50.00 2019-06-24 19: 2019-06-24 19: 2019-06-24 19: 2019-06-24 19: 2019-06-24 19: < c Q Q Horne CtYbn(Body) It I. 678 A 8 C x 1 Timestamp My Alarms\Analog 1:Average 8 . c © i 1 :4 2 2019-08-15 00:00:00 3 2019-08-15014040 4 2019-08-15024040 5 2019-08-150390:00 2019-08-15 04:00:00 2019-08-15 05:00 00 2019-08-15 06:00:00 2019-08-15 07:00:00 10 2019-08-15 08:00:00 11 2019-08-15 09:00:00 12 2019-08-15 10:00:00 13 2019-08-15 11:00:00 14 2019-08-15 12:00:00 15 2019-08-15 13:00:00 16 7 6 7 9 1.00 1.00 1.00 1.00 1.00 1.00 1.00 1.00 1.00 1.00 1.00 1.00 1.00 1.00 vrscada Excel Reporting Q Tag History Query Wry+ ro s.xcea. + adds.ss u.. m8. Q watt...Inns Cunene day � a + 6.sr7w.ewss O crw4 a.. 6 Wass. Q Gat topie.as.aron. ..r r.•or MICROSOFT EXCEL ADD -IN Standard in Development Runtime Licenses* Download the Excel° add -in, "VTScada - Data Retrieval" from the Microsoft Office Store° or App Source °. • Connect from a local or remote server. • Choose the VTScada Historian data source. • Select tags and build queries. • SSL/TLS is required to connect to VTScada. * Requires a Microsoft Excel license. Microsoft, Excel, Office Store, and App Source are trademarks of Microsoft. Alarm Page * dOs 8 ® 00® • nod_ y 4C iA -t* 111 I�• Enhanced Situational Awareness Scada All All System Alarm DB System Event DB Time 2016-01-26 11:26:41 Alarm Actions Analysis History Filter Vev Sou Unacked Current Shelved Disabled Configured Event Area Application Startt 2016-01-26 11:26:41 .,3, a Active System 2016-01-26 11:26:41 \3' * Active System Help Aeknowledge Shelve 2016-01-26 11:26:41 \3 ., Commission System Add NoteN. 2016-01-26 11:26:41 0 '4 Commission System 2016-01-26 11:26:41 O Disable Networklnformatii 2016-01-26 11:26:41 O Disable LM Low Lift Pump St 2016-01-26 11:26:41 O Disable LM Low Lift Pump St 2016-01-26 11:26:41 O Disable LM Pre -Mix Properties 2016-01-26 11:26:41 N. Commission LM Pre -Mix t Add Note Pre Mix vstem Show Details lAt Plot Go to Page Go to Page (Popup) Nzr. farm arm farm arm \PrimaryAlmDi t\LowLiftPump t\LowLiftPump t\Pre-Mix\Raw t\Pre-Mix\Raw WaterTreatmentPl ant\Pre-Mix\Mix WaterTreatmentPl a nt\Clarifiers\Set WaterTreatmentPlantDemo\TCPIP Port\WaterTrearonel WaterDistributionSystem\Zone_1\T Test Alarm (1) .onel WaterDistributionSystem\Zone_1\T !one1 WaterDistributionSystem\Zone_1\V Active 2014-12-2014:53:37 one1 WaterDistributionSystem\Zone_1\ This was a test of the WTP levels. Recommend we increase the setpoints4 [one3 WaterDistribution4istem\Zone}\T !one3 WaterDistributionS'st r \Zone/'" one3 WaterDistributionSys _ one2 WaterDistnbution sty :1-• 1 13 ALARM & ACTION LOGGING TOOLS Standard Alarm Page based on ISA's 18.2 Alarm Management Standard. • Alarm and Event databases in every application. • See current, active, unacknowledged, disabled, and shelved alarms. ■ Sort by date/time and filter by functional area or priority. • Use color, shapes, and symbols to help users with color vision deficiencies. • Shelve alarms to stop alerts during maintenance or alarm floods. ■ Add encrypted notes to alarm instances. Quickly Identify and Eliminate Nuisance Alarms I All Database Anay;is - Y 1% 'A _t ® =• to Bad Actors Alarm Flood History Distribution of Priorities Area Name Description 0 Zone 1 Local TCP Port\PLCSim\Tank 1\Tank Level Monitor tank level HIGH ♦ Zone 2 Local TCP Port\PLCSim\Tank 2\Tank Level Monitor tank level HIGH Q Zone 3 Local TCP Pori \PLCSim\Tank 3\Tank Level Monitor tank level HIGH Count 14 2 Bad Actors Report - Summary of alarm occurrences within a specific period, sorted by the number of activations. Bad Actors Alarm Flood History Distribution of Priorities P 50 D 1 Mar 20 r ,rI li 1 .Ill Mar25 Var30 Apr4 Apr9 III_ Apr 14 x Alarm Flood Report - Count of alarms tripped within equal time slices. Click a bar to zoom into that period. ALARMS TUNING REPORTS Standard - 9 ® ® o m,-Y4-Pn , _: *- Bad Actors Alarm Flood History Distribution of Pnonties Date- a g1_ Zone I Description Local TCP ParttP26im1Tmh 1\Tank Level Monitor tank level HIGH 016-04-07 o 10.54.os LocalTCPPo°,PLCS m,Tank L,Tarrk Level Mom -tot -tank Local 1k°,PLCSiniTank L,Tank Level Monitor tank History Report- All active and trip alarm events in a specific period. Bad Actors Alarm Rood History Distribution of Priorities PI x Reported History Current Configuration ISA 18.2 Recommended 0 0 17% 83% 33% 67% 5% 15% 80' Critical High nticel High • 73' Priority Distribution Report - Compares priority of configured alarms and actual alarm occurrences against ISAs recommendations. Critical Alarms Find You Anywhere VTScada ALARM NOTIFICATION Optional Component Receive and ack alarms from anywhere via SMS text message, email, pager, and text -to -voice phone call. ■ Create contact rosters for areas, times and dates. ■ Tightly integrated for the life of your system. ■ Also supports voice and SMS using Twilio®. ■ OAuth 2.0 authorization for sending alarm notification emails. NEW IN 12.1 ■ VoIP-based alarm annunciation: no modem or Internet. ■ Enhanced Roster configuration. New in Version 12.1 text -to -speech alarm annunciation VoIP-BASED ALARM ANNUNCIATION, NO MODEM OR INTERNET Part of Optional Alarm Notification System VTScada will always support voice modems for text -to -speech alarm annunciation. However, they are increasingly hard to source as telecoms phase out data over analog lines. Now, take advantage of the benefits of Voice over Internet Protocol (VoIP) without going through the internet. ■ No more discontinued third -party hardware. ■ No web -based third -party service required. ■ No need to expose your SCADA system to the Internet. Create Applications For the Global Market Scala tirav V9: IV ®$E I 1bll ?c:T. Atk 1t 2018-11-05 13:34:10 a 2018-11-05 13:32:17 •e Sec FL k r Mc E SeckigrAoo .ole_abe_ EN - English A CN-Gp3 ,odd Role Ad dServerLe faeV Add Server AddServerAboveLabel AddServerBelowLabel Ad dServerToListLe bel AddServiceListLabel EditPropsAddSiteProp s . AddSitePropsLabel WEI Add Server Above Add Server Below Add Server to List Add Service -specific Lists Add Site Display Properties Add Site Properties ViTIMAE MULTI -LANGUAGE SUPPORT Standard Create translations for any number of languages.* • Users can set a preferred language or change on the fly. • Translate standard VTScada and application -specific terms. • Import translations all at once or term -by -term. * VTScada includes English by default. Translations to other languages are the responsibility of the end user. Site Mapping in Every Application VTScada SLIPPY MAPS Standard * • No configuration required. • Tiles download automatically and cache indefinitely. • Select pins to see site data in standard or customized templates. 14 • Bulk Downloader- Import all tiles for designated areas and elevations. • Limit Area and Elevation - Focus users on their operational areas. • Carto® Map Tiles- High performance, high contrast, night view. • Overlapping Site Selector - Pop up lets you pick the site you want. * Mobile devices require VTScada Thin Client Licenses. Encrypted Electronic Notebooks Operator Notes PI - Demo • 7, • Last updated 2 minutes ago Equipment ID: S17-PO4 Situation Summary: Pump flow significantly reduced Crew members: Darius Jones, Mike McInnis Details: Pump difficult to rotate. Removed and disassembled. Impeller damaged Actions Taken: New impeller ordered from stock. WO R15982 Suggested Acions to Mitigate Future Occurrence: Needs review of damage to identify cause. Comment • Whole thread Demo • -utes ago New impeller installed and pump reassembled. Back in service. !Equipment ID: Maintenance Ticket Crew members: Actions Taken: [Insert a Quick Note] Pump OOS Problem with impeller Valve iX-13 Quo / ,00 -22 % Pump iX-21 ON -AUTO ts' Acknowledgeable'Sticky' Notes OPERATOR NOTEBOOKS Standard No more paper logbooks. • Make notebooks available system -wide. • Assign notebooks to specific equipment. • Alarm system notebook. • Add notes to alarms and trend points. • Export Notes for use in reports. Remote Access From Anywhere VTScada THIN CLIENTS Optional For HTML5 browsers on mobile devices and PCs. ■ Licensed by concurrently connected user. ■ No third -party server software required. ■ Supports SSL/TLS and VPN encryption. ■ Configure in minutes. New in Version 12.1 BATCH & RECIPE MANAGEMENT Standard Component Batching is critical in industries like food & beverage and pharmaceuticals where repeatability and traceability are key. ■ Create any number of Ingredients, Recipes, and Recipe Books. ■ Automatically trigger batches to run multiple recipes in series. ■ Scale or modify batches to create revisions. ■ Changes are recorded and distributed across all servers. ■ Recipes can be imported and exported as spreadsheets ■ Utilities can even use Batching to prepare for bad weather. New in Version 12.1 Quick Start Version 12 video Tutorial EMBEDDED VIDEO WIDGET Adding live video feeds to HMI screens helps to protect operators and build their trust in their system. ■ RTSP video streaming protocol (used by Netflix®) supports a variety of cameras and decoding schemes. ■ The Video Widget is easily dragged -and -dropped from the VTScada Idea Studio' EMBEDDED BROWSERS Provide operators with just -in -time resources by adding browsers to your screens. Easily add weather maps, YouTube® training videos, pump maintenance PDFs, or even Thin Clients from other VTScada applications. Easily Manage Multiple Applications v-r':TSce Ja .:pp Manager - 0 X Scada Water Systems Internet Client Monitor 0 0 ► go Trace Viewer G ► a WaterAndWastewaterDemo ✓ ► • Lift Station 14 0 • • a North Wale/ Plant ✓ ■ IP Test Framework I. 12.0 Powtr Systems Matter C..ervutiv J ► • a North Hydro Plant a Solar Field 2 a Solar Freid 1 O ■ J ► J ► • O Salad Number 9 Lep Vito S9! V09reoe Pence, r>,a Sep 16.2020 l.kercry thee 1,231 ► e VTScada APPLICATION MANAGER (VAM) Standard The VAM is the first thing you see when VTScada starts. This is where you create, import, and launch applications. You can access the VAM from the VTScada Internet Client (VIC) when running applications as a service or in the cloud. • Set up Thin Client servers and VPNs. • Access application configuration. • Create Application Lists for different job responsibilities. Fix Faulty Values and Insert Manual Data VT Historical Data Viewer Unnamed Group d I 10 Minutes a ". n7 Raw Data 1 Second / 0 Tag Selection Dort lime Span Data Mode &lime Per Record Note ._._jTanl�evel System Notes ._..*sTankIevel Tank Level System Notebook Tank Level Time 10:09:19.429 10:09:25.542 10 09:25.543 C 10:09:27.542 10:09:27.544 10:09:29.548 10:09:29.549 10 09:31.545 48.00 10:09:31.546 4 _ 10 09:33.549 46.80 10:09:33.556 46.5u 10:09:35.546 45.40 10:09:35.548 45.40 10 09:37.551 43,90 10 09:37.556 43.90 10 09:39.548 42.20 10:09:39.550 42.20 10:09:41.549 40,40 10:0941.551 40.40 10-0943.555 38.50 50.30 51.50 ! 49.80 49.00 21.30 21.30 VT r;astewaterPlantDemotTCPIP Poi -Ma stew... X Logged Oft • Oct 3D,, 20081k0325 • Note added Cct30,, MC 816.2119 Name: WastewaterPlantDe+no\..\Tanks\TankO'\TankLevel Description: Tank Level Event: Set to 51.5 Corrected value distorted by sensor interference. Close J 6.10 6.10 HISTORICAL DATA EDITING Standard Override incorrect or missing values. Original values are retained. • Edit individual or ranges of values. • Edits require an explanatory note. • Edited values are marked in the Historical Data Viewer. Group Tags to Reflect Real -World Structures YE Tag Browser. Showing 27 of 4,926 Running Tags I Using 237 of Unlimited Licensed Tags (l Bemoulli_Lake ► Site_Driver ► 1 ['Show Children Names I ['Show Disabled A Bernoulli_Lake GenerateLossReport HP_Location_Style LossReport EF) Site_Driver AutoAndLocked BrgVibeX BrgVibeZ BypassFlowRate - BypassLossVolume - BypassSwitchFeedha - BypassValveSwitch DownstreamFlowRa —0 DownstreamFlowRa - Gate Position - GateSwitch GateSwitchFeedbacl IsPrimarySer erRunr - IsRaining LakeLevel LakeLevelAlarmSet All Areas Equipment Types .. All Types Name Description Type rJ UpstreamFlowRate TurbineSpeed OilPressure •..e MainValveSwitc MainVaIvePositi MainValveLockc MainSwitchFeec LakeLevelChanc LakeLevelChanc _akeLevelAlarm _aketevel Raining .PrimaryServer J J GateSwitchFeec • GateSwitch t GatePosition t DowrctreamllowBa O DownstreamFlo J BypassValveSwi Upstream Flow Rate Analog (In] Draw Plot View Alarms -' Speed Analog Status Cut Copy Paste as Child New Child Delete Enabled Set Start Condition Create New Type Redefine Type Go to Page Go to Page (Papup) Properties • Analog Status Selector Switch Analog [In] Digital Status eck Digital Status Logger Logger tinge [Ft/hr] Rate of Change Analog Control 1 Analog (In] ,'he site Digital Status ?OnPrimary Calculation eck Digital Status Selector Switch Analog Status Normalized NianencCakulafon[C4 e Analog (In] Selector Switch HIERARCHICAL TAG BROWSER Standard A single interface to create and edit all your application tags. Only I/O addresses count towards your licensed tag limit. • Create reusable parent/child structures to model equipment or processes. • Save time and reduce errors when developing. • Draw multi -tag equipment in one step. • Easily export tags to a spreadsheet, edit, and re -import. let Atuteted Instantly Intuitive Screen Development Cut Copy Paste A Text Line Z Pipe Colorize - PE Change Image Flu Mirror Image Opacity - . Brightness nk Image Rotation - Contrast r'0 Antialias Reset Op city Rotation Power rt }) [J Welcome To VTScada- Start Here 0 Wat,Treatment Plant Demo ❑ Holding Tank CI Outlet Pumps 0 Inlet Pumps 11 265 a 90px If] 1920 x 1014px Easily select and align graphical elements. VTScada IDEA STUDIO Standard in Development Runtime Licenses • A familiar drag -and -drop screen development interface. • Configure and commit changes without restarting. • Includes 200+ widgets, 4000+ graphics, and 3D pipes. Retur-i(Se1f); GU:Transfarm(296, 280, 395, 254, 1, 1, 1, 1, 1 ( Scaling ), 0, 0 ( Movement ), 1, 0 ( Visibility, Reserved ),. 0, 0, 0 ( Selectability ), Variable("F1owTotal Pump 3")\Number(0, 1, 1, GUITransform(184, 148, 212, 32, — 1, 1, 1, 1, 1 ( Scaling ), 0, 0 ( Movement ), 1, 0 ( Visibility, Reserved ), 0, 0, 0 ( Selectability ), Native scripting language provides unlimited customization. Help Operators Focus on What Matters Most Analog Bars Upstream Flow 501 'a 1 Sparklines / Spider Graphs P4 ----- f- P3 New inV12 + NEW HIGH PERFORMANCE WIDGETS Standard New drag -and -drop High Performance widgets add to the existing library of gray -scale objects. ■ Easily create high performance displays. ■ New Widgets optimized to work seamlessly with the new VTScada I/O & Calculations Tag. ■ Sparklines, analog bars, and spider graphs. The Built-in Grundfos Pump Controller®Template PARAMETERIZED PAGES Standard* ■ Easily create reusable custom page templates. ■ Populated from parent/child tag structures. Pre -Built Pages ■ Grundfos Pump Controller® ■ Xylem MultiSmart® ■ MPE Pump Controller° ■ Generic Page Template _z * Configuration requires a Development Runtime License Instantly Recover From Configuration Mistakes '( Edit Properties Edit Server Lists ,$ Edit Security 1 Languages F Create ChangeSet File a Apply ChangeSet File 4 Export/Sync Tags Manage Types ^, Import File Changes E6 Maintain File Manifest f. Deploy Changes 0 Revert Changes iE Show Version Log Ovenide Detection Information -onaor Ea ample View the version status of workstations The current application version on each workstation is shown below. Local modifications are shown in blue. Deployed Selectinga workstation from the Worksta• Right -clicking on a Version log er' changes from that version in v The phrases shown in the created. Workstations Workstatir SERVER 1 SERVER 2 4000.47o SERVER 3 I Thu SERVER 4 SERVER 5 Version Log for Ve SERVER 1- SERVER 1- D SERVER 2-D1 SERVER 2-D SERVER 2-D23 SERVER 2- ,SERVER 2-D236 SERVER 2-D235 SERVER 2-D233 SERVER 2-D232 2C22 13,44.27.201 SERVER 2-0222 2022, 12:00. 37.684 SERVER 3-03 Mon 14, 2022, 09:45:39.922 SERVER 4-D165 Fri Apr 20 2022, 14:1041.863 SERVER 5-D5 107 records in log) me Applied User 3:11.305 Logged Off Platform info 040.985 Logged Off Platform i - LI X est are shown in red. The cs trent deployed version is shown in black. `hat workstation. 202214:1"""" ____..... n._� 2 15 Show Version Details Thu Feb 2 Thu Feb 24, 2022 Thu Feb 24, 2022 12: Next 100 Show All Switch to This V commit oma • commit itch to that version, reverse the translations used when the version was ng\Serverl\ServerAlarm oManitoe Monitoring \Served\ServerAlarm Reload APPLICATION VERSION CONTROL Standard Only VTScada offers advanced traceability and change management out -of -the -box with no configuration or third -party components. • Built into every application. • See who changed what and where. • Instantly reverse any change. • Switch to a known good version. No restart required. • Change log automatically saved across all app servers. Select the changes to apply Select the items you wish to change from the tree of changed items. Click the 'Apply" button to apply the displayed checkboaes indicate conflicted files, carefully verify the proposed changes before selecting such records for applicati Cry Source files (1) Pages\Overview2SR LI Tags LI Images M Properties Text Files LI Binary Files Pages\Overview2.SRC 1 ? ® 14 Kalil I 15 Return (Self) ; 15 GLUM, ane£ccm IS67, S-18, 59S, 5E8, + 16 WII'z—.e....ourer ._..e ..... 17 1, 4, 1, 1, 1 { Scaling ), ir. 18 0, 0 { 6ovesore ), Easily Roll -out New and Updated Applications 41j14 ONLINE DEPLOYMENT OFFLINE DEPLOYMENT Standard in Dev/RT Licenses Standard Instantly deploy applications to networked Manually deploy to offline computers servers and clients. with a single ChangeSet file. Concurrent multi-user development. Easy to create, distribute, and import. No configuration server required. Share with support teams. Deploy validated changes via the network. Clone applications. Art SERVER 2 SERVER 3 SERVER 1 SERVER 4 Meet the Challenge of a Changing Security Landscape 200 50 Days to Patch ,fur .fir sec `vie 1" 55 1 4,,0 T?,'" 6ti Based on data provided ay Trend Mice` Days to Patch Security Issues Following Notification by ICS-CERT. CYBERSECURITY VULNERABILITY MANAGEMENT Standard Implementations compliant with... • NERC/CIP (North American Electric Reliability Corporation) • DFARS 252 (Defense Federal Acquisition Regulations Supplement) • NIST 800 (National Institute of Standards and Technology) • Marine reliability standards ABS, Lloyds Bureau, DNV, BV High Reliability Systems • Multi -level fault tolerance Data Protection • Multi -level (and geo-separation) data backup methods Easily Manage What Users Can Do and Where Users ® • General Usemame Alan Andrew Barry Blair Bryan Chris Dan Roles Chris Language English • Password Password Password never expires Advanced ❑* 0 ® • Privileges 0 Configurer Logged Off Operator SuperUser Confirm Password ❑ Force reset of password at next sign in Rohs ['Configure, Permits configuration of a VTS A ['Operator Pemlits operation of a VTS Appl SuperUser Permits complete control of all a Additional Privileges ['Internet Client Access ['Manager ['Administrator II Remote Data Access © Application Stop [' Configure O CERTIFIED Trihedral Engineering Secure Development Lifecycle Process Priloges General Privileges Administration Admmatrator Configure Account Control Manager Account Modify Account View Intemet Client Access Remote Data Access Application Control Application Stop Application Manager Y Version Control Advanced Version Control Deploy Changes Revert Changes Application Configuration Edit Files Page Add Seek APPLICATION LEVEL USER ACCOUNTS Standard Centrally manage security from the standard operator interface. Deploy changes across the system without restart. NEW - VTScada's Dev Environment is now certified compliant with IEC 62443-4-1 Maturity Level 2 Security For Industrial Automation And Control Systems. ■ Windows Active Directory® support. awe Afterk Industry -standard encryption. Card -reader support. OpenID Connect® allows single sign -in and 2 factor authentication when accessing Thin Clients. OAuth 2.0 authorization for sending alarm notification emails. Instant Backup for History and Configuration Configuration History Alarms Tags User Accounts INTERNET Automatic Bi-directional Synchronization tvir • Configuration History Alarms Tags User Accounts AUTOMATIC REAL-TIME SYSTEM BACKUP Requires Multiple Licenses Each networked server can be a complete up -to -the -second full - system backup. ■ Configure any number of sync'd servers in seconds. ■ Geographically isolated servers are offsite disaster backups. ■ Never forget another backup. MN. A Smarter Approach to Hot Backup Failover VT L.Idd Site A LrI I AI DBB - DB A j INTERNET DB A DB B vineimmin Site B I 1:Wit SYSTEM -WIDE REDUNDANCY Requires Multiple Licenses Server Failover • Application Servers. • Thin Client Servers. • Load -share services. Synchronized Historians and Alarm Databases • Alarm and Event Databases. • Across LAN or WAN. Network Failover • Unique Driver Multiplexer. • Redundant Networks or Devices. 4.4,24 An IT -Friendly Solution A custom IT dashboard. SYSTEM HEALTH MONITORING Standard ■ Optionally run VTScada as a service. ■ Windows° security integration. ■ PC and network health monitoring tags. ■ Built-in SNMP driver. ■ IANA registered TCP/IP port. ■ Tamper -proof configuration repository. Plant Operations ♦ ♦♦ •♦i♦i♦i♦i •4•�•�• CITV OF SACR AM ENTO • DEPARTMENT OF UTILITIES ECM SACRAMENTO DEPARTMENT OF UTILITIES Sacramento, CA • 4 water treatment plants in a single 141,000 tag application. • 14 servers, 4 configuration workstations, 12 operator stations. • Comms to 80 Modicon PLCs. • Central security. • Enterprise access to Historian data. • Custom tag types and graphical widgets for standardization of colours, tags and graphics. Wastewater Collections GAINESVILLE REGIONAL UTILITIES Gainesville, FL ■ Rapid Wonderware and Dataflow I/O database conversions. ■ Centralized configuration of lift stations and plants. ■ Geographically separated primary and backup servers. Wastewater Treatment Plant Monitoring ANS� n --- .. diri ‘""Valti;; "'`'. cm GHSOMETRO _ [7 11 13-20213 THE CITY OF CUSCO Peru • Wastewater treatment plant monitoring. • Integrators: Aquas Latinas Peru and Hydro Control Germany. • 7,500 Tags. • Synchronised alarms with Allen Bradley® PLCs and Panel Views • Remote access. • Redundant servers with hot backup. Water Treatment • • 1`7 •. ' • rI1 J-. _ City of Ocala Ocala, FL ■ Driver library helped to transition from multiple systems to one standardized platform over several years. ■ Rapid DataFlow® and FIX® database conversions. ■ Distributed Historian databases. ■ Alarm Notification System integration. Fountain Hills Sanitary District Fountain Hills, AZ ■ Wastewater Treatment Facility (WTF). ■ Advanced Water Treatment Facility (AWTF). ■ 5 Aquifer Storage and Recovery (ASR) Wells. ■ Redundant Internet networks (DSL, Cable) for remote access. Seawater Treatment Plants Bahamas Water & Sewerage Company Island of New Providence • Blue Hill Water Reverse Osmosis Seawater Treatment Plant supplies 18,444 m3/day of water to 300,000 residents. ■ Centralized monitoring & control for plant and nearby tanks and pumping stations. • Interfaced to existing Motorola® MOSCAD RTUs. ■ Interfaced with Netbase® optimization software to help reduce millions of dollars in non -revenue -water (NRW) caused by widespread leaks in their aging pipe network. Turks and Caicos Water Company Providenciales Island • Single source water system upgraded without service interruption. • Designed and integrated by ProPump & Controls, Inc. • Monitoring and control of reverse osmosis desalinization plant with annual capacity of three -hundred million gallons. • Two new pre -fabricated pumping stations added. • Includes SCADAPack RTUs, Allen Bradley 503 and 505 controllers, and GE Versamax controllers. ■ Plant employs Modbus, DF1, and Ethernet communications. Pump stations use 450 MHz licensed radios, customized scripts and calculations. Water Distribution Warren County Water Warren County, OH ■ Distribution and water treatment. ■ Redundant servers and alarm notification. ■ Data extraction using ODBC Server. ■ XLReporter for Monthly Operating Reports (MOR). Hosted SCADA (Software as a Service) Benefits of Hosted Systems • Low upfront installation cost. • Predictable monthly expense. • Reduced maintenance. • Centralized data collection and storage. • Secure customer data access via Thin Client. • Distributed redundancy for disaster recovery. Kennedy Industries New Hudson, MI • Water and wastewater systems. • New customers online in days. • Supports 100 + PLCs and RTU manufacturers. • Variety of communication links (e.g., cellular, satellite). • Hybrid option allows local SCADA with hosted failover and backup. KISM ,I SYSTEM MASTER KI STATION MASTER Mom S.P. Sun 11121on, son S 000 le to Alain. o., HamburgRd rum sP. sun typo.µ 1511 101 STATION TOTAL 333110, III321333,3.17. Idols 2333333, 101. uI1 tlt915) 61751800IY 1950pn 00P 0P off. I }ro 09 MENEM Pump 2 INFO 101. 316 t.19/17 PO 19Yopm nolmm Southwest Florida Water Management District Florida, USA • Over 300 dataloggers and PLCs. • Public Internet access to hydrologic data. • Logged data retrieval from field devices. • Dam and weir control (28 locations). • Oracle interface for hydrologic data modeling. Hydrology VP Site Map Gainesville P Coast r a�°+�; K mmaa •• g, • • •• ILRIDA • • • • • • • • °Same ::•; • • •• 1. �I ,•.••' •n OpenStreetMap Contributors (www.openstreebnap Southwest Florida o .,, Water Management District papilla Palm a F77 r o• moot • r• • •p1K • Water Management and Flood Control John Richmond shows off his wirelessly operated VTScada Gate Control System St. Johns River Water Management District (SJRWMD) Florida, USA Serving over 5 million customers in Northeast and North Central FL. ■ Operates flood control structures. ■ Helps to protect water quality. ■ Redundant cellular -based SCADA system. ■ Includes 400 Campbell Scientific remote telemetry units (RTUs). ■ Direct control of flood water gates used during serious weather events. VT�ca�� by Trihedral Report Generation Standard Component Simple Scheduled or Ad -hoc SCADA Reporting Every VTScada software application includes two SCADA reporting components that allow users to create ad -hoc or recurring reports in seconds, the VTScada Reports Page and the VTScada Report Tag. The VTScada Reports Page Generating your own ad -hoc reports is as easy as selecting I/O tags, a time range, and an output format. 0 O Scada Reports I✓S 10, cs®$ SW PM Aug 18i r1. Report Type DailySnapshot Report 2. Tag List ILoadGmup Types Analog Status Areas lave Grour� I All Tags Available: (381) NetworkInformation\fTDashboardTas NetworkInformation\ITDashboardTar NetworkIntormadon\ITDashboardTar Networklnformation\ITDeshboarc far, NetworkIntormation\ITDeshboardia( NetworkInformation fiDashboxrdTa( Simulation \Simulated Waveforms (Ins Simulation\Simulated Waveforms Ors Simulation\Simulated Waveforms an' Simulation\Simulated Waveforms (Ini WastewaterLif Station5ystemtNorthS WastesvaterUftStationSystem W orthS WastewatertiftStationSystemW orthS WastewatediftStetionSystemtNorthS Wastevaterti9StahonsystemworthS WastewatedifStationSystemW orthS WastewatcrURStationSystem\NorthS WastewatertiftStationSystemW orthS WastewaterUftStationSystem\NorthS WastewatertiftStationSystem\NorthS WastewatertiRStationSystem NorthS WastewaterLiftStationSystemblorthS WastewaterLiftStationSystem\NorthS Swtooth Wave Freq 1 Period 60 (Input) Sine Wave Period 1 (Input) Step UpDown Steps 10 Freq 1 (Input) StepUp Steps 10000 Freq 8 Secs (AS) SCADA Remote Control Command Cancel Delay FB General Fault Code Out of Sequence Indication Reset Mode FB Elapsed Time Meter Elapsed Time Meter Alarm Reset Mode FB Lag Pump Delay FB Level Input Sensitivity FB Level from Analog Status SCADA Remote Control Command Cancel Delay FB General Fault Code Out of Sequence Indication Reset Mode FB Elapsed Time Meter Tags in Report (4) Li6LSimulation\IiftStationSimuWtedData MPES LiflSimulation\LiftStationSimulatedData\MPES Liflsimu lotion\LiRStationSi mu lated Data\Pump Lif0Simulation\LiftStationSimulatedDMa\Pump QJ Sort Alphabetically 4 it Maximum Station Inflow (Rate) Feedback (gpm) Minimum Station Inflow (Rate) Feedback (gpm) Pump 1 Capacity Feedback (gpm) Pump 2 Capacity Feedback (gpm) Run Report - 3. Reporting Period Start Time tt End 11 4 December2015 / N Su Mo Tu We Th Fr S 1 2 3 4 5.. 6 7 8 9 10 11 12 7 Pre 13 14 15 17 15 225 26 20 21 22 `�'N�.J�a,. v� 27 28 29 30 t [4 N —5. Report Destination Outpot Type IDefault Printer ❑ Email Report ❑ Email Report as Attachment Email Settings Printer IDefault Printer Browse —6 Report Options O Use Excel to display screen reports ❑ Use separate sheets/tables E Rename sheets/tables ® PE Report Pre -defined SCADA Reports - VTScada provides a variety of pre -defined report types designed to analyze the performance of the equipment comprising your physical system. Most can be used across a wide variety of industries while others are intended specifically for water and wastewater. Any number of additional custom reports can be defined and saved. • Analog Summary Report - The average, minimum, maximum, and total values for selected analog tags within a configured period. • Daily Snapshot Report - A "snapshot" of each included tag's value, at a specified time and date. • Daily Total Report - The sum of values accumulated for each selected set of tags in a specified period. • Derived Flow Report - Displays the number of driver cydes, plus inflow, outflow, and total station flow. • Detail Report - Shows the values recorded for each selected tag, within the given time period. • Driver Communication Error Detail Report - Driver error activity, recorded over a specified period. • Driver Communication Summary Report - A history of driver activity for a specified time period. • Hourly Snapshot Report - A "snapshot" of selected tag's value, every 60 minutes in a specified time. • Hourly Total Report - The sum of the values accumulated hourly for selected tags in a specified time. • Rainfall Report - Per -tag summary of totals in a configured period showing the total rainfall for selected tags in a given period. • Pump Activity Report - Summarized values for Pump Status tags, showing overall pump activity. • Pump Discrepancy Report - Helps spot instances of pumps that should behave identically, but do not. • Standard Report - Shows all the values logged for a tag over a chosen time span. Triheclral A Delta Group Company vTscada The VTScada Report Tag Developers can configure VTScada Report Tags to run a particular report on schedule, automatically. Report Tags are time -zone aware and can be configured to run daily, weekly, monthly, manually, or when triggered by an event. Report Tag Widgets - Developers can add a variety of Report Tag Widgets to their display pages to allows operators to adjust the report setup, without requiring tag configuration privileges. Additionally, the Report Button Widget can be set to re -run the last scheduled report on demand. SCADA Reporting Output Formats • Output reports to the screen, a printer or to any of a number of formats including CSV, spreadsheet, and database. • Reports being saved to a file can also be emailed automatically if the VTScada workstation has access to an email server. • Create your own custom script reports and pre -formatted Excel by Trihedral New Report Properties D Tag Period I Trigger Load Group I Save Group I Tags Available: (759) Types Analogs Destination I Options Areas All LiftSin uIation\Lift Maximum Statil' LiftSimulation\Lift Minimum Static LiftSimulation\Lift Minimum Static LiftSimulation\Lift Pump 1 Capacil LiftSimulation\Life Pump 1 Capacil LiftSimulation\Life Reset Elasped T ❑ftSimulation\Lift Set Elasped Tim ❑ftSimulation\Life Pump 1 Elaspec IiftSimulation\Lift: Pump 2 Capacil LiftSimulation\Life Pump 2 Capacil LiftSimulation\Life Reset Elasped T Tags in Report (3) LiftSimulation\Lift LiftSimulation\Life LiftSimulation\Lift Call Pump 1 Call Pump 2 Maximum Station The VTScada RepoPeillgf alIY 1 r report templates (below). 2 3 4 5 8 s ater - Wastewater-Technoloo 10 Daly Report Charts: Energy Used,, Ett1ciency, Hours Run, Total Faults 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 250.0 200.0 150.0 100.0 50.0 28-Feb-14 To 01-Mar-14 Energy Used 0.0 Uftsluten01 UftStation02 LiftStation 03 lift Slaticn 04 Lift Station o5 Lift 3tatieno6 lift Station07 • FL1,1 • Pump 3 • Pump4 A Pre -formatted Excel® Report Template Third -Party SCADA Reporting VTScada was designed to keep your process history safe accessible. That includes making this data available to your third -party business systems and reporting packages to facilitate more complex needs, such as state -specific compliance reports. The following are Standard in Development/Runtime Licenses and Optional for Runtime Only Licenses: • VTScada Rest Interface (replaces WebServices) • VTScada OPC Server • VTScada ODBC Server • VTScada Excel Add -In Trihedral also works with reporting manufacturers such as XLReporter° and Dream Report° to create direct interfaces for sharing process data. TRY IT FOR YOURSELF VTScada.com/trial www.trihedral.com 1.800.483.2783 (North America) 1.902.835.1575 (Worldwide) I nfoetrihedral.com +44 (0) 1224 258910 (UK) 1.403.805.1972 (WestemCanada) 1 riheciiral A Delta Group Company © Trihedral Engineering Limited 2022. VTScada and Trihedral are registered trademarks of Trihedral Engineering Limited. All other products are trademarks of their respective owners. EXHIBIT C ADDENDUM TO SCOPE OF WORK AND FINAL PRICING A. Annual subscription fee: $1000 per station per year, including any new storm pump stations in the future. B. RTU cellular service to be provided by Verizon Wireless and managed by Star Controls. C. Annual support package for onsite/remote troubleshooting is included for Year 1 upon the implementation of the SCADA system. Year 2 and beyond, support is $37,000.00 per year. The support includes: 5 Days of Onsite Electrician Services @ $1000 per day 5 Days of Onsite SCADA Troubleshooting Services @ $1600 per day 120 Hours of Remote SCADATroubleshootingServices @ $200 per hour Additional hours or days needed to be billed at an amount no higher than the above - mentioned rates. D. Camera selected for the pump stations: IC Realtime P2025 (Model No. IPFX-P2025X- IRW1). The City will look to connect the cameras to the internet via a City managed contract with Verizon. If Star Controls manages cellular services for the cameras, the cost will be $1,500 per year per camera. The City and Star Controls will agree on the profile of use for data usage. Building Stations: $4938.33 each Submersible Stations: $5758.33 each E. Warranty period for RTU is one (1) year and starts upon the commissioning which may occur at 100% completion of all stations. With an extended warranty being offered 3 months prior to the expiration of the standard warranty. F. Data will not be lost during any downtimes. Data is stored on -site ready to upload to the cloud data management system when service/connectivity resumes. In the event of a breach, Star Controls shall automatically switch to a separate isolated path while inspecting and restoring the breached path. G. Star Controls will work to fulfill the City's need for MFA with login credentials/password access. H. City will grant access to Star Controls to the E-Builder system for the management of this project. I. Insurance requirements have been updated to include: Cyber/Professional Liability/Errors and Omissions — Combined aggregate limit $2,000,000.00 J. Additional documents attached to this Exhibit Camera Specifications for P2025 Updated Price Proposal Form P2025 CAMERA SPECIFICATIONS IPFX-P2025X-IRW1 2MP 25x Starlight IR PTZ Network Camera IGALTIME 4111 System Overview IC Realtime's IPFX-P2025X-IRW1 provides an all -in -one solution for capturing long distance video surveillance for outdoor applications. Together with infrared illumination up to 492ft with Starlight Technology, the camera is the perfect solution for dark, low light applications. The series combines a day/night mechanical IR cut filter for the highest image quality in variable lighting conditions during the day, and True WDR for applications with direct sunlight or glare. This PTZ also supports Intelligent Motion Detect 2.0 and Auto Tracking with IVS (Tripwire, Intrusion) It also includes other Al such as Abandoned/Missing support, Parking Detection as well as Face Detection. Other features include IP67 and IK10 protection and flexible AC 24V/ PoE+ power options. Functions Wide dynamic range (WDR) The camera achieves vivid images, even in the most intense contrast lighting conditions, using industry -leading wide dynamic range (WDR) technology. For applications with both bright and low lighting conditions that change quickly, true WDR (120 dB) optimizes both the bright and dark areas of a scene at the same time to provide usable video. Protection (IP67, IK10, wide voltage) Supporting ±25% input voltage tolerance, this camera suits even the most unstable conditions for outdoor applications. Its 6KV lightning rating provides effective protection for both the camera and its structure against lightning. IP67 is supported by the camera, which makes it suitable for both indoor and outdoor environments. IK10 compliance enables the camera to sustain the equivalent of 5kg (11.021bs) force. • 1/2.8" 2 Megapixel STARVISTM CMOS • Powerful 25x optical zoom • Max. 25/30fps@1080P • H.265 & H.264 triple -stream encoding • Auto tracking and IVS Support • Intelligent Motion Detect 2.0, Perimeter Protection • IR distance up to 492ft • 512GB mSD Support, IP67, IK10, PoE+ Auto -tracking This feature controls the pan/tilt/zoom actions of the camera to automatically track an object in motion and to keep it in the scene. The tracking action can be triggered manually or automatically by defined rules. Once a rule is triggered, the camera can zoom in and track the defined target automatically Smart H.265+ Smart H.265+ is the optimized implementation of the H.265 codec that uses a scene -adaptive encoding strategy, dynamic GOP, dynamic ROI, flexible multi -frame reference structure and intelligent noise reduction to deliver high -quality video without straining the network. Smart H.265+ technology reduces bit rate and storage requirements by up to 70% when compared to standard H.265 video compression Intelligent Video Analysis (IVS) With built-in intelligent video analytics, the camera has the ability to detect and analyze moving objects for improved video surveillance. The camera provides optional standard intelligence at the edge allowing detection of multiple object behaviors such as Tripwire analytics, allowing the camera to detect when a predetermined line has been crossed, ideal for business intelligence, workforce optimization, and actionable intelligence. Starlight For challenging low -light applications, Starlight Ultra -low Light Technology offers best -in -class light sensitivity, capturing color details in low light. The camera uses a set of optical features to balance light throughout the scene, resulting in clear images in dark environments. Interoperability The camera conforms to the ONVIF (Open Network Video Interface Forum) specifications, ensuring interoperability between network video products regardless of manufacturer. 1 I www.icrealtime.com FS-05112023-HV1-D1.00 IGALTIME IPFX-P2025X-IRW1 I[ ALTIME Technical Specification Camera Image Sensor Effective Pixels RAM/ROM Scanning System Electronic Shutter Speed Minimum Illumination S/N Ratio IR Distance IR On/Off Control IR LEDs Lens Lens Type Max. Aperture Angle of View Optical Zoom Focus Control Close Focus Distance DORI Distance PTZ Pan/Tilt Range Manual Control Speed Preset Speed Presets PTZ Mode Speed Setup Power up Action Idle Motion Protocol Video Compression Streaming Capability Resolution Frame Rate Bit Rate Control Bit Rate Day/Night Backlight Compensation White Balance Gain Control 1/2.8" STARVIST" CMOS 1920(H) x 1080(V), 2 Megapixels 1GB/4GB Progressive 1/1s-1/30,000s Color: 0.005 lux@F1.6 B/W: 0.0005 lux@F1.6 0 lux (IR light on) More than 55dB Distance up to 492ft (150m) Auto / Manual 4 4.8mm-120mm F1.6-F3.5 H: 58.5°-2.8°; V: 33.2°-1.5° 25x Auto/Manual 0.33 ft-4.92 ft (0.1 m-1.5 m) Detect Observe Recognize Identify 5,292 ft 2,119 ft 1,060 ft 528 ft Pan: 0° to 360° endless Tilt: -15° to +90°, auto flip 180° Pan: 0.1%s-300°/s; Tilt: 0.1%s-2003s Pan: 240° /s; Tilt: 200° /s 300 5 Pattern, 8 Tour, Auto Pan ,5 Scan Human -oriented focal Length/ speed adaptation Auto restore to previous PTZ and lens status after power failure Preset; Pattern; Tour; Scan ICR-SD, Pelco-P/D (Auto recognition) Smart H.265+; H.265; Smart H.264+; H.264; H.264B; H.264H; MJPEG (Sub Stream 1) 3 Streams 1080P(1920x 1080)/720P(1280x720)/D1(704x576/70 4x480)/CIF(352x288/352x240) Main stream: 1080p/1.3M/720p (1-25/30 fps) Sub streaml: D1/CIF (1-25/30 fps) Sub stream2: 1080p/1.3M/720p (1-25/30 fps) CBRNBR H.265/H.264: 448K - 8192Kbps Auto(ICR) / Color / B/W BLC / HLC / WDR(120dB) Auto, ATW, Indoor, Outdoor, Manual Auto / Manual Noise Reduction Motion Detection Region of Interest Electronic Image Stabilization (EIS) Defog Digital Zoom Flip Privacy Masking Audio Compression Network Ethernet Protocol Interoperability Streaming Method Max. User Access Edge Storage Web Viewer Management Software Smart Phone Certifications Certifications Interface Video Interface Audio Interface RS485 Alarm I/O Alarm Linkage Alarm Event Electrical Power Supply Power Consumption Environmental Operating Conditions Ingress Protection Vandal Resistance Lightning Protection Construction Casing Dimensions Net Weight Gross Weight 2D NR; 3D NR Supported Supported Supported Electronic; Supported 16x 180° Up to 24 areas PCM; G.711a; G.711Mu; G.726; MPEG2-Layer2; G722.1; G729; G723 RJ-45 (10Base-T/100Base-TX) HTTP; HTTPS; IPv4; RTSP; UDP; SMTP; NTP; DHCP; DNS; DDNS; IPv6; 802.1x; QoS; FTP; UPnP; ICMP; SNMP; SNMP v1/v2c/v3 (MIB-2); IGMP; ARP; RTCP; RTP; PPPoE; RTMP; TCP ONVIF (Profile S,G&T); CGI Unicast/ Multicast 20 (total bandwidth: 64 M) FTP; Micro SD card (512 GB): NAS IE, Chrome, Firefox, Safari SmartICRSS, DSS IOS, Android FCC: Part 15 subpart B, 1 port(BNC, 1.0V[p-p], 750) 1/1 channel In/Out 1 2/1 Capture; preset; tour; pattern; recording; triggering on -off value output; audio; sending email Motion/tampering detection; audio detection; network disconnection detection; IP conflict detection; memory card state detection; memory space detection; power exception detection 24 VDC, 2.5 A (± 25%); PoE +(802.3at) Basic: 13 W Max.: 22 W (illuminator + PTZ working) -40° C - +60° C (-40° F - +140° F) / Less than 95% RH IP67 IK10 TVS 6000 V lightning proof; surge protection; voltage transient protection MetaL 13.07" x 07.48" (332 mm x 1)190 mm) 10.36 lb(4.7 kg) 17.64 lb(8 kg) 2 I www.icrealtime.com FS-05112023-HV1-D1.00 I♦,ALTIME IPFX-P2025X-IRW1 IGALTIME Al Functions Ivs Basic IVS Tripwire; intrusion; fence climbing; loitering detection; abandoned/missing object; fast moving Advanced IVS Parking detection; people gathering; Auto Tracking Supported (Tripwire & Intrusion) Perimeter Protection Capabilities Tripwire; Intrusion (Supports target filtering of vehicle and human objects) Intelligent Motion Detect 2.0 Advanced secondary filtering for human and motor vehicle , reducing false alarms caused by Leaves, rain and lighting condition change. Supports Object Search with compatible NVRs. Capabilities Face Detection Capabilities Al Search Capabilities Face detection; track; snapshot; snapshot optimization; optimal face snapshot upload; face enhancement; face exposure; face attributes extraction including 6 attributes and 8 expressions; face snapshot set as face or one -inch photo; snapshot strategies (real-time snapshot, quality priority and optimization snapshot); face angle filter; optimization time setting Works together with Al enabled NVRs to perform refined intelligent search, event extraction and merging to event videos 3 I www.icrealtime.com FS-05112023-HV1-D1.00 I♦,ALTIME IPFX-P2025X-IRW1 I[ ALTIME Accessories Dimensions (mm/in) SR77.0 [SR3.03] 41 www.icreaLtime.com FS-05112023-HV1-D1.00 I( ALTIME REVISED PRICE PROPOSAL FORM CITYWIDE TELEMETRY AND SCADA IMPROVEMENTS City of Miamiry BASE WORK, ITEMS TO BE IMPLEMENTED AT ALL 12 PUMP STATIONS Riverview_Lawrence_0ra ge BowL6elle Meade_brickell Ave_Mary BrickelLSan Marco_Aotonio Maceo_West End 1_West End 2_West End 3_West End 4 Item # ITEM QTY UNIT PRICE PER STATION (12 STATIONS) UNIT COST TOTAL FOR ALL 12 STATIONS 1 Initial site visit and assessment 12 EACH $666.67 $8,000.04 2 Subscription Fee (annual, recurring, inclusive of all stations) 1 ANNUAL $12,000.00 $12,000.00 3 Design Fee (for all stations) 1 EACH $17,600.00 $17,600.00 4 Mobile app implementation (includes design and installation, inclusive of all stations) 1 EACH $24,000.00 $24,000.00 5 Platform Implementation (includes installation, inclusive of all Stations) 1 EACH $7,000.00 $7,000.00 6 New updated RTU in N4X SS enclosure (includes equipment and installation) 12 EACH $22 691.49 $272,297.88 7 Cellular modems & UPS (includes equipment and installation) 12 EACH $0.00 $0.00 8 Start-up, Testing &Training (inclusive of all stations) 1 DAYS $60,000.00 $60,000.00 9 MAC Power: (Includes equipment and installation) 12 LS $756.67 $9,080.04 A. Main Electric Power Failure B. Main ATS Failure C. ATS Position 10 Generator Monitoring System: (Includes equipment and installation) 12 LS $2,485.00 $29,820.00 A. Generator on/off B. Generator Current/Voltage C. Generator Total Harmonic Distortion Sensor D. Generator Controller Position 11 Diesel gauge readings per generator (includes equipment and installation) 12 EACH $1,883.33 $22,599.96 12 Pumps: (includes equipment and installation) 12 EACH $2,323.33 $27,879.96 A. Pumps on/off B. Water Level C. Hours of Operation D. Pumps Position (Auto/Off/On/Manual/Trip/Fault) 13 Door Sensor (includes equipment and installation) 12 EACH $376.67 $4,520.04 SUB -TOTAL 1 SUBTOTAL 1 $494,798 14 (MOBILIZATION/DEMOBILIZATION 1 12 1 EACH 5,996.00 71932 SUB -TOTAL 2 SUBTOTAL 2 71,952 RIVERVIEW TOTAL COST $566,750 CITYWIDE TELEMETRY AND SCADA IMPROVEMENTS CITY OF MIAMI OPTIONAL WORK, ITEMS TO BE IMPLEMENTED AT 3 PUMP STATIONS Riverview_Lawrence_Orange Bowl Item # ITEM QTY UNIT PER STATION (3 STATIONS) UNIT COST TOTAL FOR ALL 3 STATIONS 1 Cameras (includes equipment and installation) - 2 PER STATION 6 EACH $4,938.33 329,029 9R 2 Water Quality (turbidity) (includes equipment and installation) - 2 PER STATION 6 EACHq 747.50 S28,485.00 3 Rain Gauge (includes equipment and Installation) - 2 PER STATION 6 EACH $2 g10.00 516,860.00 4 Min eIIeneous Building Equipment: (Includes equipment and installation) - 2 PER STATION 6 LS $2 g65.00 S14,790.00 A. Barscreen On/Off B. CO2 Retardant System C. Fire System On/Off SUB -TOTAL 1 $89,764.98 6 MOBILIZATION/DEMOBILIZATION 6 EACH .223 $1,338.00 SUB -TOTAL 2 $1,338.00 TOTAL COST $91,102.98 CITYWIDE TELEMETRY AND SCADA IMPROVEMENTS CITY OF MIAMI OPTIONAL WORK, ITEMS TO BE IMPLEMENTED AT 9 PUMP STATIONS Belle Meade_Brickell Ave_Mary Brickell_San Marco_Antonio Maceo_West End 1_West End 2_West End 3_West End 4 Item # ITEM QTY UNIT PER STATION (9 STATIONS) UNIT COST TOTAL FOR 9 STATIONS 1 Cameras (1 per station) 9 EACH $5,758.33 551,824.17 2 Water Quality (turbidity) (1 per station) 9 EACH $4,211.94 $37,907.46 3 Rain Gauge (1 per station) 9 EACH $1,527.78 513,750.02 SUB -TOTAL 1 $103,482.45 4 MOBILIZATION/DEMOBILIZATION 9 EACH $162.00 $1.458.00 SUB -TOTAL 2 $1,458.00 TOTAL COST $104,940.45 Contract No 2049386 EXHIBIT D INSURANCE REQUIREMENTS & CERTIFICATE OF INSURANCE Commercial General Liability A. Limits of Liability Bodily Injury and Property Damage Liability Each Occurrence $1,000,000 General Aggregate Limit $2,000,000 Personal and Adv. Injury $1,000,000 Products/Completed Operations $1,000,000 B. Endorsements Required City of Miami listed as additional insured Contingent & Contractual Liability Premises and Operations Liability Primary Insurance Clause Endorsement II. Business Automobile Liability A. Limits of Liability Bodily Injury and Property Damage Liability Combined Single Limit Owned/Scheduled Autos Including Hired, Borrowed or Non -Owned Autos Any One Accident $1,000,000 B. Endorsements Required City of Miami listed as an additional insured III. Worker's Compensation Limits of Liability Statutory -State of Florida Waiver of Subrogation Employer's Liability A. Limits of Liability $100,000 for bodily injury caused by an accident, each accident $100,000 for bodily injury caused by disease, each employee $100,000 for bodily injury caused by disease, policy limit IV. Professional Liability /Cyber/Errors and Omissions Coverage Combined Single Limit Telemetry/SCADA Services 21 Contract No 2049386 Each Claim $1,000,000 General Aggregate Limit $2,000,000 Retroactive Date Included The above policies shall provide the City of Miami with written notice of cancellation or material change from the insurer in accordance with policy provisions. Companies authorized to do business in the State of Florida, with the following qualifications, shall issue all insurance policies required above: The company must be rated no less than "A-" as to management, and no less than "Class V" as to Financial Strength, by the latest edition of Best's Insurance Guide, published by A.M. Best Company, Oldwick, New Jersey, or its equivalent. All policies and /or certificates of insurance are subject to review and verification by Risk Management prior to insurance approval. 22 Telemetry/SCADA Services Contract No 2049386 EXHIBIT E CORPORATE RESOLUTIONS AND EVIDENCE OF QUALIFICATION TO DO BUSINESS IN FLORIDA (To be provided upon document execution) COMPANY RESOLUTION (This Resolution needs to authorize the signatory to sign) WHEREAS, Star Controls a Inc. (company type: Inc., LLC.), desires to enter into an Agreement with the City of Miami for the purpose of performing the work described in the contract to which this resolution is attached; and WHEREAS, the Board of Directors (board type; Board of Directors for Inc, Board of Managers for LLC.) at a duly held company meeting has considered the matter in accordance with the bylaws of the company; NOW, THEREFORE, BE IT RESOLVED BY THE BOARD of Star Controls (same as identified above) that this company is authorized to enter into the Agreement with the City, and the President (company officer title) and the Operations Manager (company officer title) are hereby authorized and directed to execute the Agreement in the name of this Company and to execute any other document and perform any acts in connection therewith as may be required to accomplish its purpose. IN WITNESS WHEREOF, this 13 day of July , 2026. Star Controls, Inc. ("Contractor") An Florida (State) Company By: Print Name: Tzvi Magril (sign) TITLE: President Print Name: Emma Light (sign) Telemetry/SCADA Services 23 Contract No 2049386 EXHIBIT F ANTI -HUMAN TRAFFICKING AFFIDAVIT 24 Telemetry/SCADA Services City of Miami RFP No. 2046386 ANTI -HUMAN TRAFFICKING AFAV+TT The undersigned affirms. certifies. attests. anti stipulates as follows: a The entity is a non -governmental entity authorized to transact kill -sinless In the State of -Florida and in good standing u•i[h the FLarida Department of Shire, Division of Corporations. h. The nongovernmental emit, is eitlser exeeutiob, r4Yle►ain ,. clr emending a contract (including, hot not limited to, an). arriertdmLmLs, as applicable) math the Cita 1 .lUJrlt] CCCiX}'"J or one of its agencies, authorities, boards_ [rusts, or other C'in• cIitilt which constitutes a goverrnmental entity as defined in Section 287.I3S(]y, Florida Statutes+2024j_ c The nongovernmental entity is not in violutiori of Section 787.06,, Florida Statutes {2024). titled "Human Trafficking." .1. The nonscivernrncrttal rcnl ib doa:3 not use "c t3rrcioti - for labor or -services as dcf'irled in Section 7X7 (lf% Florida Shuttles (2024), uttuehed and incur} ,rat ihereinl asLrdtrh]t1�41lrialsl 2. Under penalties of panic... [ declare the fr}Ilclu41r t: a. l have read and understand the foregoing Anti -Human Trafficking Aff1.1e5,4 and that the facts, statements and representations provided in Section, f are tsar- and eDirreet. h I am an officer or a representative of diff nongovernmental entity authorized to execute this Anti - Littman TraiTicking Atfidatit. Nungoverrancrilat Entity: _Star -Controls Inc Name' _T7r1 Mani siputure of Officer: Officer Title; President Offaee Adds , 1355 Heron Bay Lilv}d, Ste 20t1 Coral Springs. If. 33076 [rnua] Adclre : imalgn1: star-controls.com _ Main Phone Number: 954-6O4-665( [-N No_ 5]-0533827 STATE OF FLOP) COMITY or BR.OWARl The foregoing inatruineni was &Wain 1i:, and te TIbcd bcfvrc me by means of physical psesenco or `i online It ip1#r11Jb 7th dal, of _January, 2026_ by _I'tb-i Magril Has the authari;,ed driver or representative for tile. nango%erlerrtlatsul.emit}'.. fickle is personally luu ii to ri ilailen5MORied identification NOT..[tY PUJ3L[C SFx [.} My Commission F spires: C3) +G dV C of (,'Printed. Typed_ or Stumped Name ofNoEar• F',ih'ic • - ': Koury.Jsl,bDc-St te aLt ncedr Cd►rnlsslar, r HH f0820 My Cam'', Eires wr !0, 2Cti dander truovin riit a[ Notary hue, Mang tt Oath AGENDA ITEM SUMMARY FORM File ID: #19316 Date: 05/21/2026 Commission Meeting Date: 06/25/2026 Requesting Department: Department of Resilience and Public Works Sponsored By: District Impacted: All Type: Resolution Subject: Accept Proposal -Telemetry and Supervisory Control and Data System Purpose of Item: The nature of this item is to authorize a Resolution of the Miami City Commission with attachment(s), pursuant to Request for Proposals ("RFP") No. 2046386, from Star Controls, Inc., for the provision of a Telemetry and Supervisory Control and Data ("SCADA") System for the City's storm pump stations for the Department of Resilience and Public Works ("RPW"), for an initial term of one (1) year, with the option to renew for three (3) additional one (1) year periods; allocating funds from the 2023-2024 Statewide Flooding and Sea Level Rise Resilience Plan Grant and other various sources of funds from the General Fund; authorizing the City Manager to execute the negotiated Professional Services Agreement ("PSA") In a form acceptable to the City Attorney, and to negotiate and execute any and all documents, including any amendments, renewals, and extensions subject to all allocations, appropriations and budgetary approvals having been previously made, compliance with applicable provisions of the Code of the City of Miami, Florida, as amended, ("City Code"), including, the City of Miami's Procurement Ordinance, Anti -Deficiency Act, and Financial Integrity Principles, all as set forth in Chapter 18 of the City Code, in a form acceptable to the City Attorney, and in compliance with all applicable laws, rules and regulations, as may be deemed necessary for said purpose. Background of Item: On November 14, 2025, the Department of Procurement, on behalf of RPW, issued RFP No. 2046386 under full and open competition, to obtain proposals from experienced and qualified firms for the provision of a telemetry and SCADA system, in an effort to provide advanced storm pump monitoring services for the City's storm pump stations. Proposers were required to meet all of the minimum qualification requirements established within the RFP, in order to be deemed responsive. On January 9, 2026, three (3) proposals were received in response to the RFP, all of which were deemed responsive and responsible. The Evaluation Committee met on February 19, 2026, to discuss and evaluate the proposals. No oral presentations were held and the Evaluation Committee recommended that the City enter into negotiations with Star Controls, the highest -ranked Proposer. On March 31, 2026, Procurement and a designated negotiating team successfully completed negotiations with Star Controls and recommended to the City Manager the execution of a contract with Star Controls, who met all requirements and are the highest ranked responsive and responsible Proposer. The approximate cost of equipment and installation across all current storm pump stations is $762,793.43. Budget Impact Analysis Item is an Expenditure Item is NOT Related to Revenue Item is NOT funded by Bonds Total Fiscal Impact: Total Fiscal Impact: Approx. $762,793.43 General Account No: Various Reviewed By Department of Resilience and Public Works Review Completed 05/28/2026 5:54 PM Office of Management and Budget Office of Management and Budget Department of Procurement City Manager's Office City Manager's Office Legislative Division Office of the City Attorney Office of the City Attorney Office of the City Attorney City Commission Office of the City Clerk Luis Hernandez -Torres Marie Gouin Annie Perez Asael Marrero Natasha Colebrook -Williams Valentin J Alvarez Thomas M. Fossler Xavier Alban George K. Wysong III Maricarmen Lopez City Clerk's Office Juvenal Santana Department Head Budget Analyst Review Completed Budget Review Completed Procurement Review Completed Assistant City Manager Review Completed Approved on behalf of the City Manager Legislative Division Review Completed ACA Review Deputy Attorney Review Approved Form and Correctness Meeting Rendered Completed Completed Completed Completed Completed 06/02/2026 3:02 PM 06/02/2026 3:42 PM 06/09/2026 12:35 PM 06/12/2026 12:35 PM Completed 06/12/2026 4:49 PM 06/15/2026 4:38 PM 06/15/2026 8:28 PM 06/15/2026 8:34 PM 06/25/2026 9:00 AM 06/26/2026 4:25 PM City of Miami Legislation Resolution Enactment Number: R-26-0276 City Hall 3500 Pan American Drive Miami, FL 33133 www.miamigov.com File Number: 19316 Final Action Date:6/25/2026 A RESOLUTION OF THE MIAMI CITY COMMISSION, WITH ATTACHMENT(S), PURSUANT TO SECTION 18-86(C)(6)B OF THE CODE OF THE CITY OF MIAMI, FLORIDA, AS AMENDED ("CITY CODE"), APPROVING THE CITY MANAGER'S AWARD RECOMMENDATION FOR REQUEST FOR PROPOSALS NO. 2046386, ATTACHED AND INCORPORATED AS EXHIBIT "A," TO STAR CONTROLS, INC. ("CONTRACTOR"), FOR THE PROVISION OF A TELEMETRY AND SUPERVISORY CONTROL AND DATA ("SCADA") SYSTEM FOR THE CITY OF MIAMI'S ("CITY") STORM PUMP STATIONS FOR THE DEPARTMENT OF RESILIENCE AND PUBLIC WORKS (THE "SERVICES"), FOR AN INITIAL TERM OF ONE (1) YEAR, WITH THE OPTION TO RENEW FOR THREE (3) ADDITIONAL ONE (1) YEAR PERIODS IN AN ESTIMATED AMOUNT OF SEVEN HUNDRED SIXTY-TWO THOUSAND, SEVEN HUNDRED NINETY-THREE AND 43/100 DOLLARS ($762,793.43); ALLOCATING FUNDS FROM THE 2023-2024 STATEWIDE FLOODING AND SEA LEVEL RISE RESILIENCE PLAN GRANT AND OTHER LEGALLY AVAILABLE FUNDING SOURCES FROM THE GENERAL FUND; AUTHORIZING THE CITY MANAGER TO NEGOTIATE AND EXECUTE AN AGREEMENT, IN A FORM ACCEPTABLE TO THE CITY ATTORNEY, WITH CONTRACTOR FOR THE PROVISION OF THE SERVICES CONSISTENT WITH THE TERMS SET FORTH HEREIN; FURTHER AUTHORIZING THE CITY MANAGER TO NEGOTIATE AND EXECUTE ANY AND ALL OTHER DOCUMENTS, INCLUDING ANY AMENDMENTS, RENEWALS, AND EXTENSIONS, ALL IN FORMS ACCEPTABLE TO THE CITY ATTORNEY, SUBJECT TO ALL ALLOCATIONS, APPROPRIATIONS, PRIOR BUDGETARY APPROVALS, AND COMPLIANCE WITH APPLICABLE PROVISIONS OF THE CODE OF THE CITY OF MIAMI, FLORIDA, AS AMENDED, ("CITY CODE"), INCLUDING, THE CITY'S PROCUREMENT ORDINANCE, ANTI -DEFICIENCY ACT, AND FINANCIAL INTEGRITY PRINCIPLES, ALL AS SET FORTH IN CHAPTER 18 OF THE CITY CODE, AND IN COMPLIANCE WITH ALL APPLICABLE LAWS, RULES AND REGULATIONS, AS MAY BE DEEMED NECESSARY FOR SAID PURPOSE; AND PROVIDING FOR AN EFFECTIVE DATE. WHEREAS, the City of Miami ("City") requires a telemetry and supervisory control and data acquisition ("SCADA") system for its storm pump stations in order to provide centralized monitoring and control of the City's stormwater infrastructure for the Department of Resilience and Public Works ("RPW") (the "Services"); and WHEREAS, on November 14, 2025, the Department of Procurement, on behalf of RPW, issued Request for Proposals ("RFP") No. 2046386 under full and open competition, to establish a contract for the SCADA System; and WHEREAS, on January 9, 2026, three (3) proposals were received in response to the RFP, all of which were deemed responsive and responsible; and WHEREAS, on February 19, 2026, the Evaluation Committee ("Committee"), appointed by the City Manager, convened to discuss and evaluate the proposals consistent with the RFP requirements; and WHEREAS, no oral presentations were held, and the Committee scored the proposals and reached a consensus, pursuant to the guidelines established in the RFP, to recommend Star Controls, Inc. ("Contractor") as the highest -ranked, responsive, and responsible Proposer; and WHEREAS, thereafter, the City Manager concurred with the recommendation of the Committee and authorized Procurement to enter into negotiations with Star Controls for an agreement for the provision of the Services; and WHEREAS, on March 31, 2026, Procurement and a designated negotiating team completed negotiations with Contractor for an agreement for the provision of the Services; and WHEREAS, the City Manager recommended Contractor for award of an agreement for the provision of the SCADA System for an initial term of one (1) year, with the option to renew for three (3) additional one (1) year periods, in an estimated amount of Seven Hundred Sixty - Two Thousand, Seven Hundred Ninety -Three and 43/100 Dollars ($762,793.43), as further specified in the memorandum attached and incorporated as Exhibit "A" ("City Manager's Recommendation"); and WHEREAS, Section 18-86 of the Code of the City of Miami, Florida, as amended ("City Code") provides the procedures for use of competitive sealed proposals, including that awards in excess of $50,000.00 must be approved by the City Commission upon recommendation by the City Manager; and WHEREAS, the City Commission desires to approve the award to Contractor and to authorize the City Manager to negotiate and execute an agreement, and any necessary amendments, renewals, and extensions, all in forms acceptable to the City Attorney and consistent with the terms herein stated, for said purpose; NOW, THEREFORE, BE IT RESOLVED BY THE COMMISSION OF THE CITY OF MIAMI, FLORIDA: Section 1. The recitals and findings contained in the Preamble to this Resolution are adopted by reference and incorporated as if fully set forth in this Section. Section 2. Pursuant to Section 18-86(c)(6)b of the City Code, the award to Contractor for the provision of the telemetry and SCADA System for the City's storm pump stations for the RPW, for an initial term of one (1) year with the option to renew for three (3) additional one (1) year periods, in an amount not to exceed $762,793.43, as further specified in the City Manager's Recommendation, is hereby approved. Section 3. Funds for this purpose are allocated from the 2023-2024 Statewide Flooding and Sea Level Rise Resilience Plan Grant and other legally available funding sources from the General Fund, subject to the availability of funds and budgetary approval at the time of need. Section 4. The City Manager is authorized' to negotiate and execute an agreement, in a form acceptable to the City Attorney, with Contractor for the provision of the Services consistent with the terms set forth herein. Section 5. The City Manager is further authorized' to negotiate and execute any and all other documents, including any amendments, renewals, and extensions, all in forms acceptable to the City Attorney, subject to all allocations, appropriations and budgetary approvals having been previously made, compliance with applicable provisions of the City Code, including, the City's Procurement Ordinance, Anti -Deficiency Act, and Financial Integrity Principles, all as set forth in Chapter 18 of the City Code, and in compliance with applicable regulations, as may be necessary for said purpose. Section 6. This Resolution shall become effective immediately upon its adoption. APPROVED AS TO FORM AND CORRECTNESS: ge Wy j ng III, C ty ttor -y 6/15/2026 1 The herein authorization is further subject to compliance with all legal requirements that may be imposed, including but not limited to, those prescribed by applicable City Charter and City Code provisions. H L U K U CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) 07/13/2026 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Vermost & Associates, LLC 1200 Belcher Rd S Suite 1 Largo FL 33771 CONTACT Colleen Sparkman NAME: (A/CNoExt): FAX (727) 748-2886 FNo): (727) 577-4991 E-MAIL cs arkman vermost.com ADDRESS: p INSURER(S) AFFORDING COVERAGE NAIC # INSURERA: Hartford Fire Insurance Company 19682 INSURED Star Controls Inc 11555 Heron Bay Blvd Suite 200 Coral Springs FL 33076 INSURER B : Lloyd's Of London INSURER C : INSURER D : INSURER E INSURER F : COVERAGES CERTIFICATE NUMBER: Master REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. `LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. LIMITS SHOWN ARE INCLUSIVE OF AMOUNTS REQUESTED BY THE CERTIFICATE HOLDER AND MAY NOT REFLECT POLICY LIMIT AMOUNTS IN EXCESS OF THOSE REQUESTED. *Not Applicable in WY INSR LTR TYPE OF INSURANCE ADDL INSD SUBR WVD POLICY NUMBER POLICY EFF (MM/DD/YYYY) POLICY EXP (MM/DD/YYYY) LIMITS A X COMMERCIAL GENERAL LIABILITY Y 84SBMBW6797 03/25/2026 03/25/2027 EACH OCCURRENCE 2,000,000 $DAMAGE CLAIMS -MADE X OCCUR T PREMISESOr (Ea occurence) $ 300,000 MED EXP (Any one person) $ 10,000 PERSONAL & ADV INJURY $ 2,000,000 GEN'LAGGREGATE X POLICY OTHER: LIMIT APPLIES PRO JECT PER: LOC GENERAL AGGREGATE $ 4,000,000 PRODUCTS - COMP/OPAGG 4,000,000 $ $ A AUTOMOBILE X LIABILITY ANY AUTO OWNED AUTOS ONLY HIRED AUTOS ONLY X SCHEDULED AUTOS NON -OWNED AUTOS ONLY 84SBMBW6797 03/25/2026 03/25/2027 COMBINED SINGLE LIMIT (Ea accident) $ 2,000,000 BODILYINJURY(Perperson) $ BODILYINJURY(Peraccident) $ PROPERTY DAMAGE (Per accident) $ $ A X UMBRELLA LIAB EXCESS LIAB OCCUR CLAIMS -MADE 84WECBY9866 06/26/2026 06/26/2027 EACH OCCURRENCE $ 2,000,000 AGGREGATE $ 2,000,000 DED RETENTION $ $ A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below YIN N NIA 84WECBY9866 06/26/2026 06/26/2027 PER STATUTE OTH- ER E.L. EACH ACCIDENT 1,000,000 $ E.L. DISEASE- EA EMPLOYEE $ 1,000,000 E.L. DISEASE- POLICY LIMIT 1,000,000 $ B Professional Liability E&O and Cyber Liability ES00440451740 08/29/2025 08/29/2026 Limit of Liability $2,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) The City of Miami is named as additional insured. CERTIFICATE HOLDER CANCELLATION I City of Miami C/O Procurement Department 444 SW 2nd Avenue 6th Floor Miami FL 33130 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE / � \ J j�jj�y�p�(--,-e. (9,�"` _ •- ACORD 25 (2025/12) © 1988-2025 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD SPECTRUM POLICY DECLARATIONS (Continued) POLICY NUMBER: 84 SBM BW6797 Form Numbers of Forms and Endorsements that SS 00 01 03 14 SS 00 64 09 16 SS 04 38 09 09 SS 05 47 09 15 SS 09 67 09 14 SS 12 15 03 00 SS 51 33 12 23 IH 12 00 11 85 ADDITIONAL INSURED - PERSON -ORGANIZATION IH 12 00 11 85 30 DAY NOTICE OF CANCELLATION IH 12 00 11 85 WAIVER OF SUBROGATION IH 12 00 11 85 ADDITIONAL INSURED - OWNER, LESSEES OR CONTRACTOR ply: SS 00 05 12 06 SS 00 08 04 05 SS 01 58 09 24 SS 89 93 07 16 SS 40 58 03 16 SS 41 63 06 11 SS 51 10 03 17 IH 12 05 02 21 SS 09 70 12 14 SS 09 71 12 14 IH 99 40 04 09 SX 80 01 06 97 SS 51 34 09 24 SS 51 35 09 24 Form SS 00 02 12 06 Page 006 Process Date: 01/26/26 Policy Expiration Date: 03/25/27 SS 00 38 04 04 SS 00 60 09 15 SS 05 18 07 92 SS 09 01 12 14 SS 09 85 12 14 SS 25 80 09 24 SS 83 76 12 20 BUSINESS LIABILITY COVERAGE FORM (b) Rented to, in the care, custody or control of, or over which physical control is being exercised for any purpose by you, any of your "employees", "volunteer workers", any partner or member (if you are a partnership or joint venture), or any member (if you are a limited liability company). b. Real Estate Manager Any person (other than your "employee" or "volunteer worker"), or any organization while acting as your real estate manager. c. Temporary Custodians Of Your Property Any person or organization having proper temporary custody of your property if you die, but only: (1) With respect to liability arising out of the maintenance or use of that property; and (2) Until your legal representative has been appointed. d. Legal Representative If You Die Your legal representative if you die, but only with respect to duties as such. That representative will have all your rights and duties under this insurance. e. Unnamed Subsidiary Any subsidiary and subsidiary thereof, of yours which is a legally incorporated entity of which you own a financial interest of more than 50% of the voting stock on the effective date of this Coverage Part. The insurance afforded herein for any subsidiary not shown in the Declarations as a named insured does not apply to injury or damage with respect to which an insured under this insurance is also an insured under another policy or would be an insured under such policy but for its termination or upon the exhaustion of its limits of insurance. 3. Newly Acquired Or Formed Organization Any organization you newly acquire or form, other than a partnership, joint venture or limited liability company, and over which you maintain financial interest of more than 50% of the voting stock, will qualify as a Named Insured if there is no other similar insurance available to that organization. However: a. Coverage under this provision is afforded only until the 180th day after you acquire or form the organization or the end of the policy period, whichever is earlier; and b. Coverage under this provision does not apply to: (1) "Bodily injury" or "property damage" that occurred; or (2) "Personal and advertising injury" arising out of an offense committed before you acquired or formed the organization. 4. Operator Of Mobile Equipment With respect to "mobile equipment" registered in your name under any motor vehicle registration law, any person is an insured while driving such equipment along a public highway with your permission. Any other person or organization responsible for the conduct of such person is also an insured, but only with respect to liability arising out of the operation of the equipment, and only if no other insurance of any kind is available to that person or organization for this liability. However, no person or organization is an insured with respect to: a. "Bodily injury" to a co -"employee" of the person driving the equipment; or b. "Property damage" to property owned by, rented to, in the charge of or occupied by you or the employer of any person who is an insured under this provision. 5. Operator of Nonowned Watercraft With respect to watercraft you do not own that is less than 51 feet long and is not being used to carry persons for a charge, any person is an insured while operating such watercraft with your permission. Any other person or organization responsible for the conduct of such person is also an insured, but only with respect to liability arising out of the operation of the watercraft, and only if no other insurance of any kind is available to that person or organization for this liability. However, no person or organization is an insured with respect to: a. "Bodily injury" to a co -"employee" of the person operating the watercraft; or b. "Property damage" to property owned by, rented to, in the charge of or occupied by you or the employer of any person who is an insured under this provision. 6. '' Additional Insureds When Required By Written Contract, Written Agreement Or Permit The person(s) or organization(s) identified in Paragraphs a. through f. below are additional insureds when you have agreed, in a written Form SS 00 08 04 05 Page 11 of 24 BUSINESS LIABILITY COVERAGE FORM (6) When You Are Added As An Additional Insured To Other Insurance That is other insurance available to you covering liability for damages arising out of the premises or operations, or products and completed operations, for which you have been added as an additional insured by that insurance; or When You Add Others As An Additional Insured To This Insurance That is other insurance available to an additional insured. However, the following provisions apply to other insurance available to any person or organization who is an additional insured under this Coverage Part: (a) Primary Insurance When Required By Contract This insurance is primary if you have agreed in a written contract, written agreement or permit that this insurance be primary. If other insurance is also primary, we will share with all that other insurance by the method described in c. below. (b) Primary And Non -Contributory To Other Insurance When Required By Contract If you have agreed in a written contract, written agreement or permit that this insurance is primary and non-contributory with the additional insured's own insurance, this insurance is primary and we will not seek contribution from that other insurance. Paragraphs (a) and (b) do not apply to other insurance to which the additional insured has been added as an additional insured. When this insurance is excess, we will have no duty under this Coverage Part to defend the insured against any "suit" if any other insurer has a duty to defend the insured against that "suit". If no other insurer defends, we will undertake to do so, but we will be entitled to the insured's rights against all those other insurers. (7) When this insurance is excess over other insurance, we will pay only our share of the amount of the loss, if any, that exceeds the sum of: (1) The total amount that all such other insurance would pay for the loss in the absence of this insurance; and (2) The total of all deductible and self - insured amounts under all that other insurance. We will share the remaining loss, if any, with any other insurance that is not described in this Excess Insurance provision and was not bought specifically to apply in excess of the Limits of Insurance shown in the Declarations of this Coverage Part. c. Method Of Sharing If all the other insurance permits contribution by equal shares, we will follow this method also. Under this approach, each insurer contributes equal amounts until it has paid its applicable limit of insurance or none of the loss remains, whichever comes first. If any of the other insurance does not permit contribution by equal shares, we will contribute by limits. Under this method, each insurer's share is based on the ratio of its applicable limit of insurance to the total applicable limits of insurance of all insurers. 8. Transfer Of Rights Of Recovery Against Others To Us a. Transfer Of Rights Of Recovery If the insured has rights to recover all or part of any payment, including Supplementary Payments, we have made under this Coverage Part, those rights are transferred to us. The insured must do nothing after loss to impair them. At our request, the insured will bring "suit" or transfer those rights to us and help us enforce them. This condition does not apply to Medical Expenses Coverage. b. Waiver Of Rights Of Recovery (Waiver Of Subrogation) If the insured has waived any rights of recovery against any person or organization for all or part of any payment, including Supplementary Payments, we have made under this Coverage Part, we also waive that right, provided the insured waived their rights of recovery against such person or organization in a contract, agreement or permit that was executed prior to the injury or damage. Form SS 00 08 04 05 Page 17 of 24 From: Gomez Jr., Francisco (Frank) To: Gandarilla, Aimee Cc: Quevedo, Terry; Aviles, Yesenia Subject: RE: Contract No. 2046386 - Telemetry and SCADA Services (Matter 25-2910) Date: Wednesday, July 15, 2026 8:55:12 AM Attachments: image001.onq image002.pnq image003.onq image004.pnq Good morning Aimee, The COI is acceptable to Risk. Thanks, Frank Gomez, PIAM, CPI I Property & Casualty Manager City of Miami Risk Management 14 N.E. 1st Avenue 2nd Floor Miami, Florida 33132 (305) 416-174o Office (3o5) 416-176o Fax fgomez@miamigoy.com From: Gandarilla, Aimee <AGandarilla@miamigov.com> Sent: Wednesday, July 15, 2026 8:53 AM To: Gomez Jr., Francisco (Frank) <FGomez@miamigov.com> Cc: Quevedo, Terry <TQuevedo@miamigov.com>; Aviles, Yesenia <YAviles@miamigov.com> Subject: FW: Contract No. 2046386 - Telemetry and SCADA Services (Matter 25-2910) Good morning Frank, Please advise. Thank you. C Thank you, Aimee candmiltai Procurement Assistant City of Miami Procurement Department 444 SW 2nd Avenue, 6th floor, Miami, FL 33130 P (305) 416-1906 F (305) 400-5073 E agandarilla@miamigov.com "Serving, Enhancing, and Transforming our Community" From: Emma Light <elight@star-controls.con > Sent: Monday, July 13, 2026 2:09 PM To: Gandarilla, Aimee <AGandarilla@miamigov.com>; Tzvi Magril <tmagril@star-controls.com> Subject: RE: Contract No. 2046386 - Telemetry and SCADA Services (Matter 25-2910) CAUTION: This is an email from an external source. Do not click links or open attachments unless you recognize the sender and know the content is safe. Hi Aimee, Please see attached COI. Thank you, Emma Light elightPstar-controls.com Cell: +1-786-348-7617 Office: +1-954-604-6656 Support: +1-954-604-6656 Ext. 3 support(@star-controls.com STA RCONTROLS www.star-controls.com From: Gandarilla, Aimee <AGandarilla@miamigov.com> Sent: Monday, July 13, 2026 12:59 PM To: Tzvi Magril <tmagrik star-controls.com> Cc: Emma Light <elight(@star-controls.com> Subject: RE: Contract No. 2046386 - Telemetry and SCADA Services (Matter 25-2910) You don't often get email from agandarilla@miamigov.com. Learn why this is important Received. Thank you. Thank you, ftiAl et ca lld.GIJIA a/ Procurement Assistant City of Miami Procurement Department 444 SW 2 n d Avenue, 6th floor, Miami, FL 33130 P (305) 416-1906 F (305) 400-5073 E agandarilla@miamigov.com "Serving, Enhancing, and Transforming our Community" From: Tzvi Magril <tmagril(astar-controls.com> Sent: Monday, July 13, 2026 12:55 PM To: Gandarilla, Aimee <AGandarilla(Emiamigov.com> Cc: Emma Light <elight@star-controls.com> Subject: RE: Contract No. 2046386 - Telemetry and SCADA Services (Matter 25-2910) CAUTION: This is an email from an external source. Do not click links or open attachments unless you recognize the sender and know the content is safe. Good afternoon Aimee, I confirm receiving your message. Attached please find the signed Page #1 and Page #2. Emma, copied, will send you soon the required COI, in compliance with the requirements in the attached document. Thanks and Regards, Tzvi Magril tmagrilPstar-controls.com Cell: +1-954-288-7954 Office: +1-954-604-6656 Direct: +1-954-698-4998 Support: +1-954-604-6656 Ext. 3 supportPstar-controls.com STARCONTROLS www.star-controls.com From: Gandarilla, Aimee <AGandarilla(amiamigov.com> Sent: Monday, July 13, 2026 11:18 AM To: Tzvi Magril <tmagrilPstar-controls.com> Subject: Contract No. 2046386 - Telemetry and SCADA Services (Matter 25-2910) Importance: High Olivera, Rosemary From: Gandarilla, Aimee Sent: Thursday, August 6, 2026 4:36 PM To: Olivera, Rosemary Subject: PSA Star Controls, Inc RFP 2046386 (Matter 25-2910) PSA Star Controls, Inc RFP 2046386 (Matter 25-2910).pdf Good afternoon, Rosemary, Attached is a copy of the executed agreement. Thank you, Aimee qamd.cvti,U,ai Procurement Assistant City of Miami Procurement Department 444 SW 2nd Avenue, 6th floor, Miami, FL 33130 P (305) 416-1906 F (305) 400-5073 E agandarilla@miamigov.com "Serving, Enhancing, and Transforming our Community"