Loading...
HomeMy WebLinkAbout23817AGREEMENT INFORMATION AGREEMENT NUMBER 23817 NAME/TYPE OF AGREEMENT OMNI CRA & ST. JOHN COMMUNITY DEVELOPMENT CORPORATION, INC. DESCRIPTION GRANT AGREEMENT/FUNDING FOR REHABBING ST. JOHN VILLAGE APARTMENTS II/FILE ID: 8990/CRA-R-21- 0036/MATTER ID: 21-2778 EFFECTIVE DATE March 9, 2022 ATTESTED BY TODD B. HANNON ATTESTED DATE 3/18/2022 DATE RECEIVED FROM ISSUING DEPT. 3/23/2022 NOTE OMNI REDEVELOPMENT DISTRICT COMMUNITY REDEVELOPMENT AGENCY INTER -OFFICE MEMORANDUM City Clerk's Office (Todd Hannon) Date: March 22, 2022 From Humberto Executive Director CC: Jesly De Los Santos Legal Assistant Matter IC: 21-2778 Subject: Grant Agreement by and between the Omni CRA and St. John Community Development Corporation. Enclosures: Grant Agreement For your records, please find enclosed a copy of the Grant Agreement by and between the Omni CRA and St. John Community Development Corporation. Should you have any questions regarding the attached, please feel free to contact our office at 305-679-6870. Thank you. GRANT AGREEMENT BY AND BETWEEN THE OMNI REDEVELOPMENT DISTRICT COMMUNITY REDEVELOPMENT AGENCY AND ST. JOHN COMMUNITY DEVELOPMENT CORPORATION, INC. THIS GRANT AGREEMENT is entered into as of the. day of march 2022 by and between the OMNI REDEVELOPMENT DISTRICT COMMUNITY REDEVELOPMENT AGENCY, a public agency and body corporate created pursuant to Section 163.356, Florida Statutes, with a principal address at 1401 N. Miami Avenue, Miami, Florida 33136 ("CRA"), and ST. JOHN COMMUNITY DEVELOPMENT CORPORATION, INC. a Florida non-profit corporation with a principal address at 1311 N.W. 3rd Avenue, Miami, FL 33136 ("GRANTEE)). RECITALS WHEREAS, GRANTEE submitted a grant application and proposals directly to the CRA requesting Five Hundred Sixty Four Thousand and 00/100 Dollars ($564,000.00) as grant funds to assist GRANTEE with construction costs associated with the development of the St. John Village Apartments 1I, located at 1445 NW 1 ' Place, Miami, FL, (the "Project"); which is within the CRA's redevelopment area and WHEREAS, the Board of Commissioners, through Resolution NO, CRA-R-21-0036, adopted October 22, 2021, which is attached hereto as Exhibit "A," and incorporated herein by reference (the "Authorizing Resolution"), authorizes the issuance of a Grant in an amount not to exceed Five Hundred Sixty Four Thousand and 00/100 Dollars ($564,000.00), to GRANTEE for the purpose of assisting GRANTEE with construction costs associated with the construction of the Project ("Program"); and WHEREAS, pursuant to the Authorizing Resolution, the Executive Director of the CRA ("Executive Director") is authorized to disburse the funds for the Program, on a reimbursement basis or directly to vendors upon presentation of invoices and satisfactory documentation to qualifying businesses; and WHEREAS; GRANTEE and the CRA wish to enter into this Agreement to set forth the terms and conditions relating to the use by GRANTEE of a grant in the not to exceed amount of Five Hundred Sixty Four Thousand and 00/100 Dollars ($564,000.00) ("Grant") for the Project as defined below; and NOW, THEREFORE, in consideration of the promises and the mutual covenants contained herein, the parties agree to as follows: I. RECITALS. The recitals and all Statements contained therein are true and correct and are hereby incorporated into this Agreement 2. GRANT. Subject to the terms and conditions set forth herein and GRANTEE'S compliance with all of its obligations hereunder, including the Rent Regulatory Agreement, the CRA hereby agrees tO make available to the GRANTEE the Grant to be used for the Project, and as disbursed in the manner hereinafter provided. 3. USE OF GRANT. The Grant shall be used by GRANTEE as follows: to pay for costs associated with the rehabilitation of the existing apartment complex located at 1445 NW I m Place, Miami, Florida, which will result in the construction of ten (10) apartment units with a unit Mix of four (4) two -bedroom and six (6) one -bedroom units. Two of the units shall be set aside for residents earning 50% of the average median income ("AMI"), and eight units shall be set aside for residents earning 65% of ANIL The Project includes the following scope ofwork: new flooring, kitchens, bathrooms, hUrricane impact windows/doors, air conditioning, painting, laundry facility, rod, plumbing, electrical, paving, and onsite drainage, as more fully described in Composite Exhibit "B", which is attached hereto, and incorporated herein by this reference, which includes GRANTEE's Grant Application, 4. COMPLIANCE WITH POLICIES AND PROCEDURES. GRANTEE understands that the use of the Grant is subject to specific reporting, record keeping, administrative and contracting guidelines, audit, and other requirements affecting the activities funded by the Grant for the Project. GRANTEE covenants and agrees to comply with such requirements and represents and warrants to the CRA that the Grant shall bc used in accordance with all of the requirements, terms and conditions contained therein, as the same may be amended during the term hereof. Without limiting the forogciing, GRANTEE represents and warrants that it will comply with, and the Grant will be used in accordance with, all applicable federal, state, and local codes, laws; rules and regulations. 5. RECORDS, INSPECTIONS, REPORTS/AUDITS AND EVALUATION. To the extent required by law, the Inspection and Audit provisions set forth in Sections 18-101 and 18-102 of the Code Of the City of Miami, as amended ("City Code"), are deemed as being Page 2 of 21 incorporated by reference herein and additionally apply to this Agreement. GRANTEE understands, acknowledges, and agrees that: (a) The CRA must meet certain record keeping and reporting requirements with regard to the Grant and that in order to enable the CRA to comply with its record keeping and reporting requirements, GRANTEE shall maintain all records as required by the CRA; and (b) At the CRA's request, and no later than thirty (30) calendar days thereafter, GRANTEE shall deliver to the CRA such reports and written statements relating to the use of the Grant as the CRA may require from time to time; and (c) All costs and expenses of the Project shall be at actual cost with no markups; and (d) The CRA shall have the right to conduct audits of GRANTEE's records pertaining to the Grant and to visit and to inspect the Project, in order to conduct its monitoring and evaluation activities, and that GRANTEE shall cooperate with the CRA in the performance of these activities; and (e) GRANTEE's failure to comply with these requirements or the receipt or discovery (by monitoring, evaluation, or audit) by the CRA of any inconsistent, incomplete, or inadequate information shall be grounds for the immediate termination of this Agreement by the CRA. 6. REVERSION OF ASSETS. Upon the expiration, termination, or cancellation of the term of this Agreement, any unspent Grant funds shall immediately revert to the possession. and ownership of the CRA, and GRANTEE shall transfer to the CRA all unused Grant funds at the time of such expiration, termination, or cancellation. 7. INSURANCE REQUIREMENTS: Insurance Requirements for the Project are attached and incorporated herein as Exhibit "C." 8. DISBURSEMENT OF GRANT. Subject to the terms and conditions contained in this Agreement, and at the time of execution of this Agreement, the CRA shall make available to GRANTEE, on a reimbursement basis, an amount not to exceed Five Hundred Forty Six Thousand and 00/100 Dollars ($546,000.00) in Grant funds. Payments will be made only after GRANTEE has submitted to the CRA, and the CRA has received and approved in writing such Project specific invoices; (a) which shall be accompanied by sufficient supporting documentation and contain sufficient details, to constitute a "Proper Invoice" as defined by Florida Statutes Section 218.73 and 218.74, and (b) which are subject to verification by the CRA of acceptable work product for the Project, with ten percent (10%) of the requested reimbursement retained until completion of Page 3 of 21 the Project. Only one reimbursement request may be submitted during each thirty (30) day period. in no event shall payments to GRANTEE under this Grant Agreement exceed Five Hundred Sixty Four and 00/100 Dollars ($504,000.00), nor shall Grant funds be used in any form inconsistent with the terms, conditions, obligations, and requirements contained herein. 9. TERM. The tenor of this Agreement shall commence on the date first above written and shall terminate upon full disbursement of either (a) Five Hundred Sixty Four Thousand and 00/100 Dollars ($564,000.00) or (b) such lesser amount should the final completion of the Project not require the entire not to exceed amount of Five Hundred Sixty Four Thousand and 00/100 Dollars ($564,000.00) from the Grant; provided, however, that all rights of the CRA to audit or inspect, to require reversion of assets, to enforce representations, warranties and certifications, to default remedies, to limitation of liability and indemnification, and to recovery of fees, expenses, and costs shall survivethe expiration or .earlier .terrnination of this Agreement. 10. REMEDIES FOR NON-COMPLIANCE. if GRANTEE fails to perform. any of its obligations or covenants hereunder, or materially breaches any of the terms, conditions, obligations; or requirements contained herein, including the Rent Regulatory Agreement, then the CRA shall have the right to take one or more of the following actions, irrespective of any remedies available to it in law and/or equity: (a) Withhold cash payments, pending correction of the deficiency by GRANTEE; (b) Recover payments made to GRANTEE; (c) Disallow (that is, deny the use of the Grant for) all or any part of the cost for the activity or action for the Project notin compliance; (d) Withhold further awards for the Project; and (e) Take such other actions and/or remedies that may be legally permitted at law or equity, including the recovery of funds paid to GRANTEE. 11. NON-DISCRIMINATION. GRANTEE, for itself and on behalf of its contractors and sub -contractors, agrees that it shall not discriminate as to race, sex, color, religion, national origin, age, marital status, sexual orientation, or disability in connection with its performance under this Agreement. Furthermore, GRANTEE represents that no otherwise qualified individual shall, solely, by reason of his/her race, sex, color, religion, national origin, age, marital status, sexual Page 4 of 21 orientation, or disability be excluded from the participation in, be denied benefits of, or be subjected to discrimination under any program or activity receiving financial assistance pursuant to this Agreement. 12. CONFLICT OF INTEREST. GRANTEE has received copies of, or is familiar with, the following provisions regarding conflict of interest in the performance of this Agreement by GRANTEE. GRANTEE covenants, represents and warrants that it will comply with all applicable conflict of interest provisions including, but not limited to, the: (a) Code of the City of Miami, Florida, Chapter 2, Article V; and (b) Miami -Dade County Code, Section 2-11.1. 13. CONTINGENCY CLAUSE. Funding for this Agreement is contingent on the availability of funds and continued authorization for Project activities, and is subject to amendment or termination due to lack of funds or authorization, reduction of funds, and/or change in regulations. 14. CERTIFICATIONS RELATING TO THE GRANT: GRANTEE certifies that: (a) All expenditures of the Grant shall be made only for the Project and in accordance with the provisions of this Agreement. (b) Reasonable accounting records for the Project shall be maintained by GRANTEE. (c) The expenditures of the Grant shall be properly documented and such documentation shall be maintained on file at the Project site. (d) Periodic progress reports shall be provided to .the CRA as requested from time to time. (e)- No expenditure of Grant funds shall be used for political activities: (f) GRANTEE shall be liable to the CRA for any amount of the Grant expended in a manner inconsistent with this Agreement. 15. MARKETING, The GRANTEE shall comply with the following provisions related to the marketing of the Project: (a) GRANTEE shall consult with the CRA's Executive Director regarding all uses and displays of the recognition of the CRA. (b) GRANTEE shall prominently display signage acknowledging the CRA's Grant contribution to the Project at GRANTEE's primary place of business, and for a period of two (2) years after expiration of this Agreement. Page 5 of 21 (c) GRANTEE shall produce, publish, advertise, disclose, or exhibit the CRA's name and/or logo, in acknowledgement of the CRA's contribution to the Project, in all forms of media and communications created by GRANTEE in relation to this Agreement and/or the Project, for the purpose of publication, promotion, illustration, advertising, trade or any other lawful purposes, including but not limited to stationary, newspapers, periodicals, billboards, posters, email, direct mail, flyers, telephone, public events, and television, radio, or internet advertisements or postings, or interviews. (d) The CRA shall have the right toapprove the form and placement of all acknowledgements, which approval shall not be unreasonably withheld. (e) GRANTEE further agrees that the CRA's name and logo may not be otherwise used, copied, reproduced, altered in any manner, or sold to others for purposes other than those specified in this Agreement: Nothing in this Agreement, or in GRANTEE's use of the CRA's name and logo, confers or may be construed as conferring GRANTEE any right, title, or interest whatsoever in the CRA's name, identifying information, and logo beyond the limited right granted in this Agreement. 16. DEFAULT. If GRANTEE fails to comply with any term or condition of this Agreement, or fails to perform any of its obligations hereunder, including the Rent Regulatory Agreement, then GRANTEE shall be in default. Upon the occurrence of a default hereunder the CRA, in addition to all remedies available to it by law, may immediately, upon written notice to GRANTEE, terminate this Agreement whereupon all payments, advances, or other compensation paid by the CRA to GRANTEE while GRANTEE was in default shall be immediately returned to the CRA. GRANTEE understands and agrees that termination of this Agreement under this section shall not release GRANTEE from any obligations accruing prior to the effective date of termination. 17. NO LIABILITY OF THE CRA OR THE CITY. None of the respective officers, employees, agents, representatives, or principals, whether disclosed or undisclosed, of the CRA and of the City of Miami ("City") shall have any personal liability with respect to any of the provisions of this Agreement. Any liability of the CRA and of the City under this Agreement shall be subject to the limitations imposed by Section 768.28, Florida Statutes. 18. SPECIFIC PERFORMANCE. In the event of breach of the Grant Agreement by the CRA, the GRANTEE may only seek specific performance of the Grant Agreement and any recovery shall be limited to the actual amount of the Project costs not to exceed the amount of Grant funding authorized for the Project. In no event shall the CRA be liable to GRANTEE for any Page 6 of 21 additional compensation, other than that provided herein, or for any consequential or incidental damages. 19. INDEMNIFICATION OF THE CRA AND THE CITY. GRANTEE hereby agrees to indemnify, protect, defend, save, release, and hold harmless the CRA, the City, and their respective officers, employees, agents, representatives, and principals from and against any and all claims, actions, damages, liability and expense (including fees, costs, and expenses of attorneys, investigators and experts) in connection with loss of life, personal injury, or damage to property arising out of the performance or non-performance of this Agreement and the Project, except to the extent such loss, injury or damage was caused by the gross negligence of the CRA, the City, or their respective officers, employees, agents, representatives, and principals. 20. ' DISPUTES. In the. event of a dispute between the Executive Director of the CRA and GRANTEE as to the terms and conditions of this Agreement, the Executive Director of the CRA and GRANTEE shall notify each in writing of the dispute and proceed in good faith to resolve the dispute within thirty (30) calendar days of such written notice. If the dispute is not resolved within such thirty (30) calendar days, the dispute shall be submitted to the CRA's Board of Commissioners ("Board") for resolution within ninety (90) calendar days thereof, or such longer period.as may be agreed to by the parties to this Agreement. The Board's decision shall be deemed final and binding on the parties. 21. CAPTIONS. The captions in this Agreement are for convenience only and are not a part of this Agreement and do not in any way define, limit, describe, or amplify the terms and provisions of -this Agreement or the scope or intent thereof. 22; ENTIRE AGREEMENT. This instrument constitutes. the sole and only agreement of the parties hereto relating to the Grant, and correctly set forth the rights, duties, and obligations of the parties. There are no collateral or oral agreements or understandings between the CRA and GRANTEE relating to this Agreement or the Grant and/or Project. Any promises, negotiations, or representations not expressly set forth in this Agreement are of no force or effect. This Agreement shall not be modified in any manner except by an instrument in writing executed by the authorized representatives of the parties. The CRA's authorized representative is the Executive Director. GRANTEE's authorized representative is Eric Haynes in accordance with GRANTEE's corporate authorization, attached and incorporated as Composite Exhibit "D", which includes GRANTEE's Corporate Status Update. Page 7 of 21 23: CONSTRUCTION. Should the provisions of this Agreement require judicial or arbitral interpretation, it is agreed that the judicial or arbitral body interpreting or construing the same shall not apply the assumption that the terms hereof shall be more strictly construed against one party by reason of the rule of construction that an instrument is to be construed more strictly against the party which itself or through its agents prepared same, it being agreed that the agents of both parties have equally participated in the preparation of this Agreement. 24. COVENANTS. Each covenant, agreement, obligation, term, condition or other provision herein contained shall be deemed and construed as a separate and independent covenant of the party bound by, undertaking or making the same, not dependent on any other provision of this Agreement unless otherwise expressly provided. All of the terms and conditions set forth in this Agreement shall apply throughout the term of this Agreement unless otherwise expressly set forth herein. 25. CONFLICTING TERMS. In the event of conflict between the terms of this Agreement and any terms or conditions contained in any attached documents, the terms of this Agreement shall govern. 26. WAIVER. No waiver or breach of any provision of this Agreement shall constitute a waiver of any subsequent breach of the same or any other provision hereof, and no waiver shall be effective unless made in writing by the non -breaching party. 27. SEVERABILITY. Should any provision contained in this Agreement be determined by a court of competent jurisdiction to be invalid, illegal, or otherwise unenforceable under the laws of the State of Florida, then such provision shall be deemed modified to the extent necessary in order to conform with such laws, or if not modifiable to conform with such laws, that Same shall be deemed severable, and in either event, the remaining terms and provisions of this Agreement shall remain unmodified and in full force and effect. 28. NO THIRD -PARTY BENEFICIARY RIGHTS. No provision of this Agreement shall, in any way, inure to the benefit of any third parties so as to constitute any such third party a beneficiary of this Agreement, or of anyone or more of the terms hereof, or otherwise give rise to any cause of action in any party not a party hereto. 29. AMENDMENTS. No amendment to this Agreement shall be binding on either party, unless in writing and signed by the authorized representatives of both parties, 30. OWNERSHIP OF DOCUMENTS. Upon request by the CRA, all documents Page 8 of 21 developed by GRANTEE shall be delivered to the CRA upon completion of this Agreement, and may be used by the CRA, without restriction or limitation. GRANTEE agrees that all documents maintained and generated pursuant to this Agreement shall be subject to all provisions of the Public Records Law, Chapter 119, Florida Statutes. It is further understood by and between the parties that any document which is given by the CRA to GRANTEE pursuant to this Agreement shall at all times remain the property of the CRA, and shall not be used by GRANTEE for any other purposes whatsoever, without the written consent of the CRA. 31. AWARD OF AGREEMENT. GRANTEE warrants that it has not employed or retained any person employed by the CRA to solicit or secure this Agreement, and that it has not offered to pay, paid, or agreed to pay any person employed by the CRA any fee, commission percentage, brokerage fee, or gift of any kind contingent upon or resulting from :the award of the Grant: 32. NON-DELEGABILITY. The obligations of GRANTEE under this Agreement shall not be delegated or assigned to any other party without the CRA's prior written consent which may be withheld by the CRA, in its sole discretion. 33. CONSTRUCTION OF AGREEMENT, GOVERNING LAW, AND VENUE. This Agreement shall be construed and enforced in accordance with Florida law without regard to its conflicts of law provisions. In the event of litigation, controversies, or legal problems arising out of or as a result of this Agreement and/or the Project, shall be submitted to the jurisdiction of the State of Florida courts in the Eleventh Judicial Circuit in and for Miami -Dade County, Florida. The venue shall be Miami -Dade County, Florida. Each party shall be responsible for its own attorney's fees, costs, and expenses. Moreover,. GRANTEE acknowledges that it shall adhere to any and all state, local, and federal laws, rules and regulations in undertaking the Project and in complying with this Agreement, to:include the Code of the City of Miami, Florida, as amended. 34. WAIVER OF JURY TRIAL. GRANTEE and the CRA hereby knowingly, irrevocably, voluntarily, and intentionally waive any right either may have to a trial by jury in respect to any action, proceeding, claim, or counterclaim based on this Agreement and/or the Project, or arising out of, under, or in connection with this Agreement, the Project, any renewal(s) hereof, any amendment, extension, or modification of this Agreement, or any other agreement executed between the parties in connection with this Agreement, the Project, or any other course of conduct, course of dealing, statements (whether verbal or written), or any other actions of any Page 9 of 21 party hereto. This waiver is a material inducement for the CRA and the GRANTEE to enter into this Agreement. 35. TERMINATION OF CONTRACT FOR CONVENIENCE, The CRA retains the right to terminate this Agreement at any time for convenience, without penalty to the CRA. In that event, the CRA shall give five (5) days written notice of termination to GRANTEE: 36. NOTICE. All notices or other communications which shall or may be given pursuant to this Agreement shall be in writing and shall be delivered by personal service, or by registered mail, addressed to the party at the address indicated herein or as the same may be changed from time to time. Such notice shall be deemed given on the day on which personally served, or, if by mail, on the fifth (5th) day after being posted, or the date of actual receipt, whichever is earlier. To CRA: Omni Redevelopment District Community Redevelopment Agency 1401 North Miami Avenue Miami, FL 33136 Attn: Executive Director With a copy to: Office of the City Attorney 444 S.W. 2nd Avenue, 9`f' Floor Miami, FL 33130 Attn: Victoria Mendez, General Counsel To GRANTEE: St. John Community Development Corporation 1324 NW 3`d Avenue Miami, Florida 33136 Attn: Eric Haynes, Executive Director 37:' INDEPENDENT CONTRACTOR. GRANTEE, its contractors, subcontractors, employees, and agents shall be deemed to be independent contractors, and not agents or employees of the CRA, and shall not attain any rights or benefits under the civil service or pension programs of the CRA, or any rights generally afforded its employees; further, they shall not be deemed entitled to Florida Workers' Compensation benefits as employees of the CRA. 38. SUCCESSORS AND ASSIGNS. This Agreement shall be binding upon the parties hereto, and their respective heirs, executors, legal representatives, successors, and assigns. Page 10 of 21 39. AUTHORITY. Both the CRA and GRANTEE certify that each possesses the legal authority to enter into this Agreement. A resolution, motion or similar action has been duly adopted as an official act of each party as a governing body, authorizing the execution of this Agreement, and identifying the official representative of each to act in connection herewith and to provide such additional information as may be required by the terms of this Agreement. 40. PUBLIC RECORDS. GRANTEE understands that the public shall have access, at all reasonable times, to all documents and information pertaining to the CRA, subject to the provisions of Chapter 119, Florida Statutes, and any specific exemptions there from, and GRANTEE agrees to allow access by the CRA and the public to all documents subject to disclosure under applicable law unless there is a specific exemption from such access. GRANTEE's failure or refusal to comply with the provisions of this section shall result in immediate termination of the Agreement by the CRA. Pursuant to the provisions of Section 119.0701, Florida Statutes, GRANTEE must comply with the Florida Public Records Laws, specifically the GRANTEE must: A. Keep and maintain public. records that ordinarily and necessarily would be required by the public agency in order to perform the service. B. Provide the public with access to public records on thesame terms and conditions that the public agency would provide the records and at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. C. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law. D. Meet all requirements for retaining public records and transfer, at no cost, to the public agency all public records in possession of the GRANTEE upon termination of the contract and destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. E. All records stored electronically must be provided to the CRA in a format compatible with the information technology systems of the public agency. GRANTEE agrees that any of the obligations in this section will survive the term, termination and cancellation hereof. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC Page 11 of 21 RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: Telephone No.: 305-679-6870 E-Mail: IJONESMIAMIGOV.COM Address: 1401 NORTH MIAMI AVENUE, MIAMI, FLORIDA 33136. 41. SURVIVAL. All obligations (including but not limited to indemnity and obligations to defend, release, and hold harmless) and rights of any party arising during or attributable to the period prior to expiration or earlier termination of this Agreement shall survive such expiration or earlier temiination. 42. COUNTERPARTS; ELECTRONIC SIGNATURES. This Agreement may be executed in any number of counterparts, each of which shall be deemed an original, but all of which shall constitute one and the same instrument Facsimile, .pdf and other electronic signatures to this Agreement shall have the same effect as original signatures. [SIGNATURES APPEAR ON THE FOLLOWING PAGE] (Remainder of Page Intentionally Left Blank} Pagc 12 of 21 IN M'ITNESS WHEREOF. the parties hereto have caused this instrument to he executed by their respective officials thereunto duly authorized as of the day and year above written. ATTEST: By: - Name: ,54c ver 6 r a.7- k ATTEST: Todd B. no i ' erk of the hoard Date: 3] r g a c a'. APPROVED AS TO INSURANCE REQUIREMENTS: By: Ann -Marie Sharpe. Director. Risk Management Department St. John Community Development Corporation, a Florida not -for -profit corporation By: Eric 1... Hay cs, xecutive Director OMNI REDEVELOPMENT DISTRICT COMMUNITY REDEVELOPMENT AGENCY of the City of Miami. a public agency and body corporate created pursuant to Section 163.356, Florida Statutes ("C'RA") g .L,.7fir.iL ;e sen-W tlkdf. Executive Director Bamaby Min APPROVED AS TO FORA AND CORRECTNESS: By: Victoria Mendez, General Co nsel Matter ID: 21-2778 D.J.G. Page 13 0121 EXHIBIT "A" OMNI CRA-R-21-0036, adopted October 22, 2021 Page 14 of 21 Or - * 111111Iua' , • ot. 0k.o Miami FL OMNI CRA Resolution CRA-R-21-0036 A RESOLUTION OF THE BOARD OF COMMISSIONERS OF THE OMNI REDEVELOPMENT DISTRICT COMMUNITY REDEVELOPMENT AGENCY ("CRA"), BY A FOUR -FIFTHS (4/5THS) AFFIRMATIVE VOTE, AFTER AN ADVERTISED PUBLIC HEARING, RATIFYING, APPROVING, AND CONFIRMING THE EXECUTIVE DIRECTOR'S RECOMMENDATION AND FINDING THAT COMPETITIVE NEGOTIATION METHODS AND PROCEDURES ARE NOT PRACTICABLE OR ADVANTAGEOUS PURSUANT TO SECTIONS 18-85 AND 18-86 OF THE CODE OF THE CITY OF MIAMI, FLORIDA, AS AMENDED, AS ADOPTED BY THE CRA; WAIVING THE REQUIREMENTS FOR COMPETITIVE SEALED BIDDING AS NOT BEING PRACTICABLE OR ADVANTAGEOUS TO THE CRA; AUTHORIZING THE EXECUTIVE DIRECTOR TO NEGOTIATE AND EXECUTE ANY AND ALL DOCUMENTS NECESSARY, ALL IN FORMS ACCEPTABLE TO THE GENERAL COUNSEL, TO ALLOCATE GRANT FUNDS IN AN AMOUNT NOT TO EXCEED $564,000.00 FOR REHABILITATION OF THE PROPERTY LOCATED AT 1445 NW 1ST PLACE, MIAMI, FLORIDA LOCATED WITHIN THE CRA'S REDEVELOPMENT AREA; ALLOCATING FUNDS FROM THE CRA'S FISCAL YEAR 2020-2021 BUDGET. Information Department: Category: Attachments OMNI Community Redevelopment Agency Other Sponsors: Agenda Summary and Legislation 8990 Bid Waiver Memo 8990 Notice to the Public 8990 St. John CDC Funding Request 8990 1445 NW 1st Place_Property Search Application 8990 County Required Rent Regulatory Agreement 8990 St. John Villages Apt II Deed 8990 St. John Community Development Bid Waiver Memo 2021-06-03 8990 Notice to the Public 2021-06-03 8990 Notice to the Public 2021-05-06 8990 Fully Executed County Loan Agreement (OBSOLETE) 8990 Secured Promissory Note (OBSOLETE) Body/Legislation WHEREAS, the Omni Redevelopment District Community Redevelopment Agency ("CRA") is tasked with reducing slum and blight within its Redevelopment Area; and WHEREAS, on September 13, 2016, the Board of Commissioners of the CRA ("Board") adopted Resolution No. CRA-R-16-0042 adopting the City of Miami's procurement ordinance as the process in which any and all services and goods are procured by the CRA; and WHEREAS, page 41, Section D-2 of the CRA's 2010 Redevelopment Plan ("Plan") lists the objective of the CRA is to "[a]chieve rehabilitation of the maximum number of housing units" and to make "Improvements to the Public Realm" by "[enhancing] the areas' visual attractiveness to businesses and residents"; and WHEREAS, page 42, Sections A-1 and A-3 of the Plan also state as goals of the CRA to Provide incentives for redevelopment of blighted properties" and to Promote rehabilitation and maintenance of existing viable uses and structures"; and WHEREAS, St. John Community Development Corporation, Inc., a Florida Not For Profit Corporation ("Grantee"), submitted a proposal to the CRA to rehabilitate ten (10) affordable housing units at the property located at 1445 NW 1st Place, Miami, Florida ("Project"); and WHEREAS, the Grantee specifically requests grant funding for the Project in the not to exceed total amount of $564,000.00; and WHEREAS, the success of the Project will result in accomplishing the stated objectives and goals of the Plan; and WHEREAS, based on the recommendation and findings of the Executive Director, it is in the CRA's best interest to authorize, by an affirmative four -fifths (4/5ths) vote, a waiver of competitive sealed bidding procedures pursuant to Sections 18-85 and 18-86 of the Code of the City of Miami, Florida, as amended ("City Code"), as adopted by the CRA, and to authorize the Executive Director to negotiate and execute any and all agreements necessary, all in forms acceptable to the General Counsel, with the Grantee for the provision of grant funds for the Project in an amount not to exceed $564,000.00, subject to the availability of funds; NOW, THEREFORE, BE IT RESOLVED BY THE BOARD OF COMMISSIONERS OF THE OMNI REDEVELOPMENT DISTRICT COMMUNITY REDEVELOPMENT AGENCYOF THE CITY OF MIAMI, FLORIDA: Section 1. The recitals and findings contained in the Preamble of the Resolution are adopted by reference and incorporated as fully set forth in this Section. Section 2. By a four -fifths (4/5ths) affirmative vote, after an advertised public hearing, the Executive Director's recommendation and written findings pursuant to Sections 18-85 and 18-86 of the City Code, as adopted by the CRA, are ratified, approved, and confirmed and the requirements for competitive sealed bidding methods as not being practicable or advantageous to the CRA are waived. Section 3. Funding for a total amount not to exceed $564,000.00 for the Project is allocated from the CRA's Fiscal Year 2020-2021 budget line item 12. Section 4. The Executive Director is authorized to negotiate and execute any and all agreements necessary, all in forms acceptable to the General Counsel, with the Grantee for the purposes stated herein. Section 5. This Resolution shall become effective immediately upon its adoption. Meeting History OMNI Jun 3, 2021 11:00 AM Community Redevelopment Regular Meeting Agency Note for the Record: Item 6 was continued to the next scheduled OMNI Community Redevelopment Agency (CRA) Meeting. RESULT: CONTINUED [UNANIMOUS] AYES: Ken Russell, Joe Carollo, Jeffrey Watson ABSENT: Alex Diaz de la Portilla, Manolo Reyes Oct 22, 2021 10:00 AM OMNI Community Redevelopment Regular Meeting Agency RESULT: ADOPTED [UNANIMOUS] MOVER: Joe Carollo, Vice Chair, District Three SECONDER. Manolo Reyes, Board Member, District Four i,. Draft Next: 10/22/2021 10:00 AM 1 Draft COMPOSITE EXHIBIT "B"- PROJECT DESCRIPTION Page 15 of 21 REV. HENRY NEVIN — FOUNDER OFFICERS: BISHOP JAMES D. ADAMS CHAIRMAN OF THE BOARH WILL MILLER, Ed.D. 1ST VICE CHAIRMAN WALTER DENNIS 2ND VICE CHAIRMAN ALEXIS SNYDER SECRETARY EDWINA PACE ASSISTANT SECRETARY THEMA CAMPBELL TREASURER LEHONDRA SWAIN ASSISTANT TREASURER BOARD OF DIRECTORS: NELSON ADAMS, Ill, M.O. EDWARD BLAIR, IV BETTY BURKE-CLAY'I•UN COREY B. COLLINS, Esq. MARTHA DAY CECIL DUFFIE TROY DUFFLE JAMAAL FAIRLEY ERICK FERNANDEZ KERRY GRANT ROBERT HARRIS, Esq. HOMER HUMPHREY, RI'h. DONAVAN JACKSON GARFIELD MILLER, Esq. CHARLES SCOTT T'RAN STUDWELL, Ed.D. ERIC L. HAYNES EXECUTIVE DIRECTOR St. John Community Development, Corp. 1324 NW 3,dAve Miami FL 33136 30S•372-0682 Phone 305-381.9574 Fax www.stjohncdc.org ST OH COMMUNITY11I kEIor.;i..1 P A 1 I ,1 June 1, 2020 Mr. Jason Walker, Executive Director City of Miami Omni CRA 1401 North Miami Avenue Miami FL 33136 RE: Request for Funding: $564,000 St John Village Apartments II 1445 NW 1st Place Dear Mr. Walker: Following up on our discussion, regarding the Omni CRA's desire to finance projects within its boundaries, I'm writing to request $564,000 to fund a financing gap for our St John Village Apartments II, an existing 10-unit low income apartment building that we're currently rehabbing. ST JOHN VILLAGE APARTMENTS II, located at 1445 NW 1st Place, is an existing apartment complex which is undergoing a substantial rehabilitation. When completed, the deed restricted affordable housing project will contain ten (10) apartment units with a unit mix of four (4) two -bedroom and six (6) one - bedroom units. Two of the units have been set -aside for residents earning 50% AMI and eight units have been set -aside for residents earning 65% AMI. The scope of work for the rehabilitation includes new flooring, new kitchens, new bathrooms, new hurricane impact windows/ doors, central air- conditioning, interior and exterior painting, new laundry facility, garbage enclosure, new roof, major plumbing and electrical repairs/upgrades and site improvements to include an onsite drainage system. Current Status: As of the date of this communication, the roof is complete and many of the finish materials have been purchased and are stored in sealed containers on site and at the CDC's office parking lot. We anticipate the issuance of the master permit within the next two weeks and the remobilization of construction activity at the site by July 151, 2020. We are attaching the following documents to assist you in considering our request: • Sources & Uses of Funds • Operating Pro Forma for the initial year of operation (Note that while HOME funding allows rents affordable to up to 65% AMI for eight of the units, we're projecting 60% AMI rents less $40 per month to ensure the older rehabbed units can be competitive with newly constructed LIHTC units, including our own.) • Recorded Rent Regulatory Agreement with Miami -Dade County • Timeline (assuming master permit is approved in time to start July 1n) Our justification for the $564,000 contribution is based on the attached Sources & Uses. You will note that we are currently leveraging $812,117 in HOME funds from Miami -Dade County and about $667,000 in SJCDC equity value of the property. We look forward to your favorable consideration of our request. Please let us know if you need additional information. We are also available to conference with you to address any questions you may have. Sincerely, Eric L. Hay s Executive Director EXHIBIT "C"- INSURANCE REQUIREMENTS • INSURANCE REQUIREMENTS FOR A CERTIFICATE OF INSURANCE CONSTRUCTION REQUIREMENTS ST. JOHN COMMUNITY DEVELOPMENT CORPORATION, INC. I. Commercial General Liability A. Limits of Liability Bodily Injury and Property Damage Liability Each Occurrence $1,000,000 General Aggregate Limit •$ 2,000,000 Products/Completed Operations $ 1,000,000 Personal and Advertising Injury $1,000,000 B. Endorsements Required City of Miami listed as an Additional Insured OMNI CRA listed as an additional insured Contingent and Contractual Liability Premises and Operations Liability Explosion, Collapse and Underground Hazard Primary Insurance Clause Endorsement Completed Operations extended for (3) years after project completion 11. Business Automobile Liability A. Limits of Liability Bodily Injury and Property Damage Liability Combined Single Limit Any Auto Including Hired, Borrowed or Non -Owned Autos Any One Accident S 1,000,000 B. Endorsements Required City of Miami included as an Additional Insured OMNI CRA listed as an additional insured Page 16 of 21 III. Worker's Compensation Limits of Liability Statutory -State of Florida Waiver of subrogation Employer's Liability A. Limits of Liability $1,000,000 for bodily injury caused by an accident, each accident $1,000,000 for bodily injury caused by disease, each employee $1,000,000 for bodily injury caused by disease, policy limit IV. Umbrella Policy (Excess Follow Form) A. Limits of Liability Bodily Injury and Property Damage Liability Each Occurrence $ 2,000,000 Aggregate $ 2,000,000 City of Miami & OMNI CRA listed as an additional Insured. Coverage is excess follow form over all liability polices contained herein. V. Owners & Contractor's Protective Each Occurrence General Aggregate $1,000,000. $1-,000,000 City of Miami & OMNI CRA listed as the named insured Page 17 of 21 to:P- epc— VI. Payment and Performance Bond $TBD. City & OMNI CRA listed as obligees VIT. Builders' Risk Causes of Loss: All Risk -Specific Coverage Project Location Valuation: Replacement Cost Deductible: $25000 All other Perils 5% maximum on Wind/Hail and Flood City of Miami & OMNI CRA listed as loss payees A. Coverage Extensions: As provided by carrier The above policies shall provide the City of Miami with written notice of cancellation or material change from the insurer not less than (30) days prior to any such cancellation or material change, or in accordance to policy provisions. Companies authorized to do business in the State of Florida, with the following qualifications, shall issue all insurance policies required above: The company must be rated no less than "A-" as to management, and no less than "Class V" as to Financial Strength, by the latest edition of Best's Insurance Guide, published by A.M. Best Company, Oldwick, New Jersey, or its equivalent All policies and /or certificates of insurance are subject to review and verification by Risk Management prior to insurance approval. Page 18 021 eLZ- r 1 ACoad CERTIFICATE OF LIABILITY INSURANCE — DATE(MDD/YYYY) M/ r THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. OR ALTER THE COVERAGE AFFORDED BY THE THIS POUCIES AUTHORIZED A CONTRACT BETWEEN THE ISSUING INSURER(S), IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED, the policy(les) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder In Neu of such endorsement (s). PRODUCER South Florida Casualty, Inc. 415 North 4th Street Lantana, FL 33462 °HONNEF 561-533-6144 IF"" 561-533-6170 �p lArc_ Nol. E-MAIL Blaine@sfcins.net ADDRESS attltna an AFFORDING DOVERAos MACS INSURER A: Kinsale Insurance Company 38920 INSURED Bofam Construction Company Inc. 5823 Sandbirch Way Lake Worth, FL 33463 754-245-0102 INSURERS: Progressive (CA) 24260 IHsuRERC.Evanston Insurance Company 35378 INSURER D : JNSURFRE: INSURER F• COVERAGES CERTIFICATE • THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POUCIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. 1NSR LTR TYPE OF INSURANCE Audi. NOR susr( *WO PO ICYNUMBEH POLICY EFF /MM(PIYYYY',i POLICY EXP ,MM.'DDI' y y LIMITS A GENERAL X LMBLITY COMMERCIAL GENERAL LIABILITY 9 EACH OCCURRENCE $ 1,000,000 DIAGE10 HEWED PREMISES SES (Ea occurrence) $ 100,000 1 CLAIMS -WADE X OCCUR MED EXP Any temperson) $ Excluded PERSONAL &ADVINJURY $ 1,000,000 ..---- GENERAL AGGREGATE $ 2,000,000 GENT. AGGREGATE POLICY LIMITAPPLES PER rig PcR9 U] LOC PRODUCTS-COMP/OP AGG s 2,000,000 s B AUTOMOBILE _ X LIABILITY ANYAUTO AU - OWNED S HIRED AUTOS X 7{ AUTOS NON -OWNED AUTOS 01330986-8 2/1/20222/1/202: COMBINED SINGLE LIMIT :Eaecadenfl s 1 000 000 BODILY INJURY (Per person) $ BODILY NN1RY(Per occident) S PROPERTY DAMAGE (per accde iI $ UM $ 1,000,000 A X UMBRELLA LIAR Ex�ssLNs OCCUR CLAIMS -MADE EZXS3058648 9/4/20219/4/2022 EACH OCCURRENCE S 2,000,000 AGGREGATE $ 2,000,000 DED l 1 RETENTIONS s WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETORIPARTNER/EXECUTIVE OFF10ER/MEMBER EXCLUDED? (Mandatory In NH) I,as describe under DESCRIPIION OF OPERATIONS below NIA 1 nCC STATU.1 1OFR E.L. EACH ACCIDENT $ E.L. DISEASE -EA EMPLOYEE $ E L DISEASE - POLICY LIMIT S DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (Attach ACORD 101, Addict* Remarks Schedule, tt Is more spool required) Certificates holder is listed as additional insured with respects to the General and auto liability. This insurance is primary and noncontributory coverage afforded for contingent, contractual XCU exposures. Excess to follow form over the general liability policy. :I .. ■0 City of Miami 444 SW 2nd Ave 8th Floor Miami, FL 33130 1 aL SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WLL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIV ACORD 25 (2010/05) ©1988-2010 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD CERTIFICATE OF LIABILITY INSURANCE DATE(MMIDDJYrrY) 1/11/2022 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED, the policy(lea) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder In Ileu of such endorsement s PRODUCER South Florida Casualty, Inc. 415 North 4th Street Lantana, FL 33462 •N A NAME. PHONE., Frt561-533-6144 Cti ADDRESS I FAX 1 INC Nor" 61-533-6170 aine@sfcins.net IN$URMR(a) AFFORDING COVERAGE INSURER A: Kinsale Insurance Company INSURED Bofam Construction Company Inc. 5823 Sandbirch Way Lake Worth, FL 33463 754-245-0102 INSURER B•Progressive (CA) INSURER Evanston Insurance Company INSURER D INSURFRE• NAIC • 38920 24260 35378 COVERAGES • THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDrTIONS OF SUCH POLICIES. LIMBS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAMS. Wan TYPE OF INSURANCE ADM NMR WOW tNVD -• •. ICY NUMBER POLICY EFF (MM/DDJYYYY),MM/QDIYYYYI POLIfCCYY EXP LMrrS A GENERAL LIABILITY COMMERCIAL GENERAL 'CLAIMS -MADE LIABILITY X OCCUR 0100095299-2 9/4/20219/4/2022 EACH OCCURRENCE S 1,000,000 }( NIEID PREMISES EaEoccurrencel S 100,000, MEDEXP(Anyone pnrsunj s Excluded PERSONAL&ADVINJURY $ 1,000,000 $ 2,000,000 GENERAL AGGREGATE GENT AGGREGATE LMITAPPLIES 9 PER: PRODUCTS • COMP/OP AGO $ 2,000,000 DPOLICY n Pc LOC $ B rAUTOMOBILE LIABILITY ANYAUTO ALL OWNED AUTOS HIRED AUTOS SCHEDULED AUTOS NON•OWNED AUTOS 01330986-7 2/1/20212/1/2022 IEaacBI D)SINGLEUMTT S 1,000,000 BODILY INJURY (Per person) $ . BODILY INJURY (Per accident) S X X PROPERTY DAMAGE (ppr ecadcnl l $ $ 1,000,000 A UMBRELLA LIAR EXCESS LIAB OCCUR CLAIMS -MADE EZXS3058648 9/4/20219/4/2022 EACH OCCURRENCE $ 2,000,000 x I l AGGREGATE ♦$ 2,000,000 DED 1 "RETENTIONS S WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? (Mandatory In NH) M yes, describe under DESCRIPTION OF OPERATIONS Y N NIA l TWC STATrU- I 1DFR - E.L. EACH ACCIDENT below E.L. DISEASE - EA EMPLOYEE S � L OISFASE - POLICY LIMIT $ DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (Mach ACORD 10tAddional Remarks SchsdlM, a new space Is required) Certificates holder is listed as additional insured this insurance is primary and noncontributory coverage afforded for contingent, contractual XCU exposures 1 _ I ..a, a, : OMNI Community Redevelopment Agency 1401 N. Miami Avenue Miami FL 33136 •. SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. ACORD 25 (2010/05) 03:>1988-2010 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD SURETY COMPANY United States Fire Insurance Company 305 Madison Avenue Morristown, NJ 07960 (973)490-6600 AGENT NAME Security Bond Associates, Inc. 10131 SW 40th Street Miami, FL 33165 (305) 552-5414 BOND RIDER To be attached to and form a part of Bond No. 602-113575-6 dated July 20t, 2017, and issued on behalf of Bofam Construction Company, Inc. as Principal, to St. John Community Development Corporation, as Obligee. It is hereby understood and agreed that the bond is changed or revised in the particular manner as checked below: () Name or address or Principal changed to: (✓) Amount of bond changed from: $354,250.00 to: $632,887.50 () Other This rider shall become effective as of May 28, 2019. IN WITNESS WHEREOF United States Fire Insurance Company has caused its Corporate Seal to be hereunto affixed this 28th day of May, 2019 United States Fire Insurance Company Bond #602-113575-6 POWEROF ATTORNEY UNITED STATES FIRE INSURANCE COMPANY PRINCIPAL OFFICE - MORRISTOWN, NEW JERSEY 02450428819 KNOW ALL MEN BY THESE PRESENTS: That United States Fire Insurance Company, a corporation duly organized and existing under the laws of the state of Delaware, has made, constituted and appointed, and does hereby make, constitute and appoint: Christine Harris, Marina Rani!, Odalis Cabrera each, its true and lawful Attorney(s)-In-Fact, with full power and authority hereby conferred in its name, place and stead, to execute, acknowledge and deliver: Any and all bonds and undertakings of surety and other documents that the ordinary course of surety business may require, and to bind United States Fire Insurance Company thereby as fully and to the same extent as if such bonds or undertakings had been duly executed and acknowledged by the regularly elected officers of United States Fire Insurance Company at its principal office, in amounts or penalties not exceeding: Seven Million, Five Hundred Thousand Dollars ($7,500,000). This Power of Attorney limits the act of those named therein to the bonds and undertakings specifically named therein, and they have no authority to bind United States Fire Insurance Company except in the manner and to the extent therein stated. This Power of Attorney revokes all previous Powers of Attorney issued on behalf of the Attorneys -In -Fact named above and expires on January 31, 2020. This Power of Attorney is granted pursuant to Article IV of the By -Laws of United States Fire Insurance Company as now in full force and effect, and consistent with Article III thereof, which Articles provide, in pertinent part: Article IV, Execution of Instruments - Except as the Board of Directors may authorize by resolution, the Chairman of the Board, President, any Vice -President, any Assistant Vice President, the Secretary, or any Assistant Secretary shall have power on behalf of the Corporation: (a) to execute, affix the corporate seal manually or by facsimile to, acknowledge, verify and deliver any contracts, obligations, instruments and documents whatsoever in connection with its business including, without limiting the foregoing, any bonds, guarantees, undertakings, recognizances, powers of attorney or revocations of any powers of attorney, stipulations, policies of insurance, deeds, leases, mortgages, releases, satisfactions and agency agreements; (b) to appoint, in writing, one or more persons for any or all of the purposes mentioned in the preceding paragraph (a), including affixing the seal of the Corporation. Article II1, Officers, Section 3.11, Facsimile Signatures. The signature of any officer authorized by the Corporation to sign any bonds, guarantees, undertakings, recognizances, stipulations, powers of attorney or revocations of any powers of attorney and policies of insurance issued by the Corporation may be printed, facsimile, lithographed orotherwise produced. In addition, if and as authorized by the Board of Directors, dividend warrants or checks, or other numerous instruments similar to one another in form, may be signed by the facsimile signature or signatures, lithographed or otherwise produced, of such officer or officers of the Corporation as from time to time may be authorized to sign such instruments on behalf of the Corporation. The Corporation may continue to use for the purposes herein stated the facsimile signature of any person or persons who shall have been such officer or officers of the Corporation, notwithstanding the fact that he may have ceased to be such at the time when such instruments shall be issued. IN WITNESS WHEREOF, United States Fire Insurance Company has caused these presents to be signed and attested by its appropriate officer and its corporate seal hereunto affixed this 25th day of March, 2019. UNITED STATER FIRF. MST rR A NICE COMPANY /4. t,.7-- .� Anthony R. Slimowicz. Executive Vice President DUAL OBLIGEE RIDER TO PERFORMANCE AND PAYMENT BOND NO.602-113575-6 WHEREAS, on or about the 20"' day of July, 2017, Bofam Construction Company, Inc. as Contractor, entered into a written agreement with St. John Community Development Corporation as Obligee, for the construction of Design -Build Services for St. John Village Apartments 11 Rehabilitation,1445 NW 1" Place, Miami, FL RPQ #2017-02 herein referred to as the Contract, and WHEREAS, the Contractor and United States Fire Insurance Company as Surety, made, executed and delivered to said Obligee their joint and several bond and WHEREAS, the Obligee has requested that Miami -Dade County (hereinafter called "Co - Obligee"), said Co -Obligee having a material interest in the performance of the said contract, be named as Co -Obligee in the Bond and has requested the Contractor and Surety to join with the Obligee in the execution and delivery of this Rider and the Contractor and Surety have agreed to do so upon the conditions herein stated. NOW THEREFORE, in consideration of One Dollar and other good and valuable consideration, receipt of which is hereby acknowledged, the undersigned hereby agree as follows: The aforesaid Bond shall be and it is hereby amended as follows: 1. The name of Miami -Dade County as Co -Obligee, shall be added to said Bond as a named Obligee. 2. The rights of the Co -Obligee shall be subject to the condition precedent that all the Obligee's obligations to the Contractor be performed; provided, however, that the aggregate liability of the Surety under said Bond, to the Obligee and the Co - Obligee, as their interest may appear, is limited to the penal sum of the bond and further, that the Surety may, at its option, make any payments under said Bond jointly to the Obligee and the Co -Obligee; and further provided there shall be no liability under the Bond to the Obligee or to the Co -Obligee, or to either of them, unless payment be made to the Contractor at the time and in the manner provided in the contract. 3. Except as herein modified, said Bond shall be and remain in full force and effect. SIGNED, SEALED AND DATED THIS 28th day of May, 2019. St. John Community Development Corporation By • UNITED STATES FIRE INSURANCE COMPANY MULTIPLE OBLIGEE RIDER (Concurrent Execution) This Rider is executed concurrently with and shall be attached to and form a part of Bond No. 602-113575-6. WHEREAS, on or about the 14th day of May 2019, Bofam Construction Company, Inc. (hereinafter called the "Principal"), entered into a written agreement with St John Community Development Corp. (hereinafter called the "Primary Obligees') for the construction of the Design -Build Services for St John Village Apartments 11 Rehabilitation, 1445 NW 15t Place, Miami, FL, RPQ #2017-02 (hereinafter called the "Contracts); and WHEREAS, Principal is required by the Contract to provide •a Bond and Primary Obligee has requested that The City of Miami and The Omni CRA be named as an additional obligee(s) under the Bond; and WHEREAS, Principal and United States Fire Insurance Company (hereinafter referred to as "Surety") have agreed to execute and deliver this Rider in conjunction Bond No. 602-113575-6 (hereinafter referred to as the "Bond") NOW, THEREFORE, the undersigned hereby agree and stipulate that The City of Miami and The Omni CRA shall be added to said Bond as a named obligee(s) (hereinafter referred to as "Additional Obligee(s)"), subject to the conditions set forth below: 1. The Surety shall not be liable under the Bond to the Primary Obligee, the Additional Obligee(s), or any of them, unless the Primary Obligee, the Additional Obligee(s), or any of them, shall make payments to the Principal (or in the case the Surety arranges for completion of the Contract, to the Surety) strictly in accordance with the terms of said Contract as to payments and shall perform all other obligations to be performed under said Contract at the time and in the manner therein set forth. 2. The aggregate liability of the Surety under the Bond, to any or all of the obligees (Primary and Additional Obligee(s), as their interests may appear, is limited to the penal sum of the Bond; the Additional Obligee(s)' rights hereunder are subject to the same defenses Prindpal and/or Surety have against the Primary Obligee, and the total liability of the Surety shall in no event exceed the amount recoverable from the Principal by the Primary Obligee under the Contract At the Surety's election, any payment due under the Bond may be made by joint check payable to one or more of the obligees. 3. The Surety may, at Its option, make any payments under said Bond by check issued jointly to all of the obligees. Except as herein modified, the Bond shall be and remains in full force and effect. Signed this 22nd •day of November 20 21 . Principal Bofam Construct By GbOiahan A. A Compa , Inc. Inrin, President Surety United Stet Firei urance Company •a • rera, Attorney -In -Fact Bond #602-113575-6 rVRL'AVP A11IJAL LT UNITED STATES FIRE INSURANCE COMPANY PRINCIPAL OFFICE - MORRISTOWN, NEW JERSEY 02450428821 KNOW ALL MEN BY THESE PRESENTS: That United States Fire Insurance Company, a corporation duly organized and existing under the laws of the state of Delaware, has made, constituted and appointed, and does hereby make, constitute and appoint: Christine Harris, Marina Ramil, Odalls Cabrera each, its true and lawful Attorneys) -In -Fact, with full power and authority hereby conferred in its name, place and stead, to execute, acknowledge and deliver. Any and all bonds and undertakings of surety and other documents that the ordinary course of surety business may require, and to bind United States Fire Insurance Company thereby as fully and to the same extent as if such bonds or undertakings had been duly executed and acknowledged by the regularly elected officers of United States Fire insurance Company at its principal office, in amounts or penalties not exceeding: Seven Million, Flve Hundred Thousand Dollars (S7,500,000). This Power of Attorney limits the act of those named therein to the bonds and undertakings specifically named therein, and they have no authority to bind United States Fire Insurance Company except in the manner and to the extent therein stated. This Power of Attorney revokes all previous Powers of Auomey issued on behalf of the Attorneys -In -Fact named above and expires on January 31, 2022. This Power of Attorney is granted pursuant to Article IV of the By -Laws of United States Fire Insurance Company as now in full force and effect, and consistent with Article Ill thereof; which Articles provide, in pertinent part: Article IV, Execution of Instruments - Except as the Board of Directors may authorize by resolution, the Chairman of the Board, President, any Vice -President, any Assistant Vice President, the Secretary, or any Assistant Secretary shall have power on behalf of the Corporation: (a) to execute, affix the corporate seal manually or by facsimile to, acknowledge, verify and deliver any contracts, obligations, instruments and documents whatsoever in connection with its business including, without limiting the foregoing, any bonds, guarantees, undertakings, recognizances, powers of attorney or revocations of any powers of attorney, stipulations, policies of insurance, deeds, leases, mortgages, releases, satisfactions and agency agreements; (b) to appoint, in writing, one or more persons for any or all of the purposes mentioned in the preceding paragraph (a), including affixing the seal of the Corporation. Article III, Officers, Section 3.11, Facsimile Signatures. The signature of any officer authorized by the Corporation to sign any bonds, guarantees, undertakings, recognizances, stipulations, powers of attorney or revocations of any powers of attorney and policies of insurance issued by the Corporation may be printed, facsimile, Lithographed or otherwise produced. In addition, if and as authorized by the Board of Directors, dividend warrants or checks, or other numerous instruments similar to one another in form, may be signed by the facsimile signature or signatures, lithographed or otherwise produced, of such officer or officers of the Corporation as from time to time may be authorized to sign such instruments on behalf of the Corporation. The Corporation may continue to use for the purposes herein stated the facsimile signature of any person or persons who shall have been such officer or officers of the Corporation, notwithstanding the fact that he may have ceased to be such at the time when such instniments shall be issued. IN WITNESS WHEREOF, United States Fire Insurance Company has caused these presents to be signed and attested by its appropriate officer and its corporate seal hereunto affixed this 22p' day of August 2019. State of Pennsylvania ) County of Philadelphia ) UNITED STATES FIRE INSURANCE COMPANY J4 a� Anthony R. Slimowicz, President On this 221d day of August 2019, before me, a Notary public of the State of Pennsylvania, came the above named officer of United States Fire Insurance Company, to me personally known to be the individual and officer described herein, and acknowledged that he executed the foregoing instrument and affixed the seal of United States Fire Insurance Company thereto by the authority of his office. Commonwealth of Pennsylvania — Notary Seal Tamara Watkins, Notary Public Philadelphia County Tamara Watkins (Notary Public) My commission expires August 22, 2023 Commission number 1348843 I, the undersigned officer of United States Fire Insurance Company, a Delaware corporation, do hereby certify that the original Power of Attorney of which the foregoing is a full, true and correct copy is still in force and effect and has not been revoked. IN WITNESS WHEREOF, I have hereunto set my hand and affixed the corporate seal of United States Fire Insurance Company on the22od day of November 20 21 UNITED STATES}FIRE INSURANCE COMPANY \ '. i Al Wright, Senior Vice President Init. Security Bond Associates, Inc. 10131 S.W. 40th Street Miami, Florida 33165 (306)552-6414 'Y!u AI A Document A3I2TM - 2010 Performance Bond CONTRACTOR: (Name, legal status and address) Bofam Construction Company, 1600 NW 3rd Ave., Bldg. D4 Miami, FL 33136 SURETY: (Name, legal status and principal place Inc. of business) United States Fire Insurance Company 305 Madison Ave. Morriston, NJ 07960 OWNER: (Name, legal status and address) St. John Community Development Corporation 1324 NW 3rd Avenue Miami, FL 33136 CONSTRUCTION CONTRACT Date: Amount: $354,250.00 Description: Design -Build Services for St. John Village Apartments II (Name and location) Rehabilitation, 1445 NW 1st Place, Miami, FL RPQ # 2017-02 BOND Date: July 20, 2017 (Not earlier than Construction Contract Date) Amount: $354,250.00 Modifications to this Bond: I81 None 0 See Section 16 CONTRACTOR A Company: Bofam Cons CIPAL (Corporate Seal) ompany, Inc. SURETY Company: United States Fir Signature: - 4'i - Signature: Name Gbolah n A. Akinrin, Name Burto Harris, Attorney-ln-Fact and Title: Prelident and Title: 8v la, Resident Agent #AI11883 (Any additional signatures appear on the last page of this Performance Bond.) (FOR INFORMATION ONLY — Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: (Architect, Engineer or other party.) gate Seal) Company AIA Document Aa121u — 2010. The American Institute of Architects, Bond #602-113575-6 This document has important legal consequences. Consultation with an attorney is encouraged with respell to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. AIA Document A312-2010 combines two separate bonds, a Performance Bond and a Payment Bond, Into one form. This Is not a single combined Performance and Payment Bond. 001110 1 Init. 1 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10), business days of the Surety's receipt of the Owner's notice. If the .Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 52 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. AIA Document A3127" — 2010. The American Institute of Architects. 2 Init. 1 § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 lithe Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. NA Document A312T1/ — 2010. The American Institute of Architects. 3 Init § 16 Modifications to this bond are as follows: *** NONE *** (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) TRACTOR AS PRINCIPAL : ETY Compa . (Cs ate Seal) Compan.. /'orate Seal) Signature: Signature: Name a • e: �� Name . • tile: ess • i ress CAU LION: You should sign an original AIA Contract Document, on which this text appears In RED. An original assures that changes will not tip obscured AIA Document A312". - 2010. The American Institute of Architects. 4 Init. Security Bond Associates, Inc. 10131 S.W. 40th Street Miami, Florida 33165 (305)552-5414 AIA Document A3I2TM - 2010 Payment Bond CONTRACTOR: (Name, legal status and address) Bofam Construction Company, 1600 NW 3rd Ave., Bldg. D4 Miami, FL 33136 OWNER: (Name, legal status and address) St John Community Development 1324 NW 3rd Avenue Miami, FL 33136 CONSTRUCTION CONTRACT Date: Amount: $354,250.00 Inc. Corporation SURETY: (Name, legal status and principal place of business) United States Fire Insurance Company 305 Madison Ave. Morriston, NJ 07960 Description: (Name and location) Design -Build Services for St. John Village Apartments II Rehabilitation, 1445 NW 1st Place, Miami, FL RPQ # 2017-02 BOND Date: July 20, 2017 (Not earlier than Construction Contract Date) Amount: $354,250.00 Modifications to this Bond: I81 None ❑ See Section 18 CONTRACTOR A Company: Bofam Constr Signature: Name Gbola and Title: Press (Any additional INCIPAL (Corporate Seal) ompany, Inc. SURETY Company: (Corporate Seal) United States F . ce Company Signature: /' • an A. Akinrin, Name rton Harris, Attomey-tn-Fact ent and Titl . & Fla. Resident Agent #AI11883 signatures appear on the last page o, this Payment Bond) (FOR INFORMATION ONLY — Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: (Architect, Engineer or other party) Bond #602-113575-6 This document has important legal consequences. Consultation with an attorney Is encouraged with respect to Its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. AIA Document A312-2010 combines two separate bonds, a Performance Bond and a Payment Bond, into one form. This Is not a single combined Performance and Payment Bond. AIA Document A312n, - 2010. The American Institute of Architects, 061110 5 Init. 1 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 6 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the. Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, famished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a.waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attomey's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attomey's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. AIA Document A312"' — 2010. The American Institute of Architects. 6 Init. § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. lithe provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment famished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to famish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. AIA Document A312," — 2010. The American Institute of Architects. 7 tint. t § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: •'• NONE "' (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CTOR AS PRINCIPAL TY Company. (Co to Seal) Compan, ((' rate Seal) Signature: Name a i • e: ss Signature: Name a GAU I ION: You should sign an original AIA Contract Document, on which this text appears In RED. An original assures that changes will not be obscured. AIA Docum.nt A312", — 2010. The American Institute of Architects. 8 Bond# 602-113575-6 POWER OF ATTORNEY UNITED STATES FIRE INSURANCE COMPANY PRINCIPAL OFFICE - MORRISTOWN, NEW JERSEY 02450428818 KNOW ALL MEN BY THESE PRESENTS: That United States Fire Insurance Company, a corporation duly organized and existing under the laws of the state of Delaware, has made, constituted and appointed, and does hereby make, constitute and appoint: Burton Harris, Christine Harris, Marina Rand!, Odalis Cabrera each, its true and lawful Attomey(s)-In-Fact, with full power and authority hereby conferred in its name, place and stead, to execute, acknowledge and deliver: Any and all bonds and undertakings of surety and other documents that the ordinary course of surety business may require, and to bind United States Fire Insurance Company thereby as fully and to the same extent as if such bonds or undertakings had been duly executed and acknowledged by the regularly elected officers of United States Fire Insurance Company at its principal office, in amounts or penalties not exceeding: Seven Million, Five Hundred Thousand Dollars (57,500,000). This Power of Attorney limits the act of those named therein to the bonds and undertakings specifically named therein, and they have no authority to bind United States Fire Insurance Company except in the manner and to the extent therein stated. This Power of Attomey revokes all previous Powers of Attorney issued on behalf of the Attorneys -In -Fact named above and expires on January 31, 2018. This Power of Attorney is granted pursuant to Article IV of the By -Laws of United States Fire Insurance Company as now in full force and effect, and consistent with Article III thereof, which Articles provide, in pertinent part: Article IV, Execution of Instruments - Except as the Board of Directors may authorize by resolution, the Chairman of the Board, President, any Vice -President, any Assistant Vice President, the Secretary, or any Assistant Secretary shall have power on behalf of the Corporation: (a) to execute, affix the corporate seal manually or by facsimile to, acknowledge, verify and deliver any contracts, obligations, instruments and documents whatsoever in connection with its business including, without limiting the foregoing, any bonds, guarantees, undertakings, recognizances, powers of attorney or revocations of any powers of attorney, stipulations, policies of insurance, deeds, leases, mortgages, releases, satisfactions and agency agreements; (b) to appoint, in writing, one or more persons for any or all of the purposes mentioned in the preceding paragraph (a), including affixing the seal of the Corporation. Article lit, Officers, Section 3.11, Facsimile Signatures. The signature of any officer authorized by the Corporation to sign any bonds, guarantees, undertakings, recognizances, stipulations, powers of attorney or revocations of any powers of attorney and policies of insurance issued by the Corporation may be printed, facsimile, lithographed or otherwise produced. In addition, if and as authorized by the Board of Directors, dividend warrants or checks, or other numerous instruments similar to one another in form, may be signed by the facsimile signature or signatures, lithographed or otherwise produced, of such officer or officers of the Corporation as from time to time may be authorized to sign such instruments on behalf of the Corporation. The Corporation may continue to use for the purposes herein stated the facsimile signature of any person or persons who shall have been such officer or officers of the Corporation, notwithstanding the fact that he may have ceased to be such at the time when such instruments shall be issued. IN WITNESS WHEREOF, United States Fire Insurance Company has caused these presents to be signed and attested by its appropriate officer and its corporate seal hereunto affixed this 10th day of March, 2016. UNITED STATES FIRF. INKIER ANC_E COMPANY State of New Jersey} County of Morris } On this 10th day of March 2016, before me, a Notary public of the State of New Jersey, came the above named officer of United States Fire Insurance Company, to me personally known to be the individual and officer described herein, and acknowledged that he executed the foregoing instrument and affixed the seal of United States Fire Insurance Company thereto by the authority of his office. SONIA SCALA -& NOTARY PUBLIC OF NEW JERSEY Sonia Scala (Notary Public) MY COMMISSION EXPIRES3/25/2019 1, the undersigned officer of United States Fire Insurance Company, a Delaware corporation, do hereby certify that the original Power of Attorney of which the foregoing is a full, true and correct copy is still in force and effect and has not been revoked. Anthony R. Slimowicz, Senior Vice President IN WITNESS WHEREOF, 1 have hereunto set my hand and affixed the corporate seal of United States Fire Insurance Company on the20d'day of July 2017 UNITED STATES FIRE INSURANCE COMPANY Al Wright, Senior Vice President EXHIBIT C — CONTINUED INSURANCE REQUIREMENTS FOR A CERTIFICATE OF INSURANCE GRANTEE INSURANCE REQUIREMENTS ST. JOHN COMMUNITY DEVELOPMENT CORPORATION, INC. I. Commercial General Liability A. Limits of Liability Bodily Injury and Property Damage Liability Each Occurrence $1,000,000 General Aggregate Limit $ 2,000,000 Products/Completed Operations $ 1,000,000 Personal and Advertising Injury $1,000,000 B. Endorsements Required City of Miami listed as an Additional Insured OMNI CRA listed as an additional insured Contingent and Contractual Liability Premises and Operations Liability Primary Insurance Clause Endorsement II. Business Automobile Liability A. Limits of Liability Bodily Injury and Property Damage Liability Combined Single Limit Any Auto Including Hired, Borrowed or Non -Owned Autos Any One Accident $ 1,000,000 B. Endorsements Required City of Miami included as an Additional Insured OMNI CRA listed as an additional insured Page 19 of 21 III. Worker's Compensation Limits of Liability Statutory -State of Florida Waiver of subrogation Employer's Liability A. Limits of Liability $1,000,000 for bodily injury caused by an accident, each accident. $1,000,000 for bodily injury caused by disease, each employee $1,000,000 for bodily injury caused by disease, policy limit The above policies shall provide the City of Miami with written Inoticc of cancellation or material change from the insurer not less than (30) days prior to any such cancellation or material change, or in accordance to policy provisions. Companies authorized to do business in the State of Florida, with the following qualifications, shall issue all insurance policies required above: The company must be rated no less than "A-" as to management, and no less than "Class V" as to Financial Strength, by the latest edition of Best's Insurance Guide, published by A.M. Best Company, Oldwick, New Jersey, or its equivalent. All policies and /or certificates of insurance are subject to review and verification by Risk Management prior to insurance approval. Page 20 of 21 ACCORD, ® CERTIFICATE OF LIABILITY INSURANCE °A y o2° ' THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON 'THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(les) must have ADDITIONAL INSURED provisions or be endorsed. ff SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsement(s). PRODUCER HUB International of Florida SW 37 Avenue, Suite #500 Miami FL 33135 CONTACT PAON: Lourdes Cortez INC./i o. Exti: 305-569-6727 FAX , NO: 305-508-6146 I777 ADDRESS: lourdes.cortez@hubintemational.com INSURER(S) AFFORDING COVERAGE NAIC II INSURERA: Nautilus Insurance Company 17370 INSURED STJOH10 St John Community Development Corporation, Inc. P.O. Box 015344 Miami FL 33101-5344 INSURER B INSURER C : INSURER D : INSURER E:. INSURER F : COVERAGES CERTIFICATE NUMBER: 1 THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. OUR ITR TYPE OF INSURANCE INSD SUER WYD - POLICY NUMBER POLICY EFF _ (MMIDD/YYYY) POLICY EXP '(MMIDD/YYYYI LIMITS A X COMMERCIAL GENERALUABIUTY Y GLWF16414402001 11/12/2021 11/12/2022 EACH OCCURRENCE $1,000,000 CLAIMS -MADE X OCCUR DAMAGE TO RENTED PREMISES (Ea occurrence) $ 100.000 MED EXP (Any one person) $ 5,000 PERSONAL & ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES JEC ' PER: LOC GENERAL AGGREGATE $ 2,000,000 PRODUCTS - COMPIOP AGG $ 2,000,000 $ AUTOMOBILE LIABILITY ANY AUTO OWNED SCHEDULED AUTOS NON -OWNED AUTOS ONLY COMBINED SINGLE LIMIT (Ea accident) $ BODILY INJURY (Per person) $ BODILY INJURY Par accident) $ PROPERTY DAMAGE (Per accident) $ i UMBRELLA LIAR EXCESS LIAB J OCCUR CLAIMS -MADE EACH OCCURRENCE $ AGGREGATE $ DED I RETENTION $ I $ WORKERS COMPENSATION - AND EMPLOYERS' LIABILITY YIN ANYPROPRIETOR/PARTNER/EXECUTI VE OFFI(Mandatory In EREXCLUDED7 (Mandatory In NH) DEeC DESCRIPTIe ON DESCRIPTION OF OPERATIONS below N / A PER OTH- I STATUTE I ER EL EACH ACCIDENT $ E.L. DISEASE - EA EMPLOYEE $ E.LDISEASE- POLICYLIMIT $ DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached N more space le required) 10 Units Apartments -1445 NW lst Place, Miami, FL 33136 City of Miami and OMNI CRA, are listed as a Additional Insured with regard General Liability and auto liability coverage when required by written contract, subject to terms, conditions, and exclusions of the policy. The insurance evidenced by this certificate shall be primary and non-contributory to any other insurance available to the additional insured's named above. CERTIFICATE HOLDER CANCELLATION City of Miami /OMNI CRA 1401 N. Miami Avenue, 2ND Floor Miami FL 33136 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE ACORD 25 (2016103) ©1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD EVIDENCE OF PROPERTY INSURANCE DATE (MMlDDIYYYY) 12/2/2021 THIS EVIDENCE OF PROPERTY INSURANCE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE ADDITIONAL INTEREST NAMED BELOW. THIS EVIDENCE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS EVIDENCE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE ADDITIONAL INTEREST. AGENCY HUB International of Florida 777 SW 37th Ave Suite 500 Miami FL 33135 rArNo Ext►i 305-569-6727 FA X No): 305.608-6146 CODE: AD�DREBS: Iourdes.cortez@hubintemational.com SUB CODE: AGENCY STJOHIO CUSTOMER ID #: INSURED St. John Community Development Corporation, Inc. P.O. Box 015344 Miami, FL 33101-5344 COMPANY Scottsdale Insurance Company LOAN NUMBER POLICY NUMBER CPS 7475869 EFFECTIVE DATE 11/12/2021 EXPIRATION DATE 11/12/2022 CONTINUED UNTIL X TERMINATED IF CHECKED THIS REPLACES PRIOR EVIDENCE DATED: PROPERTY INFORMATION LOCATIONIDESCRIPTION 1445 NW 1st PL Miami, FL 33136 -(10 Units) Residential Apartment Building. THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH .THIS EVIDENCE OF PROPERTY INSURANCE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. COVERAGE INFORMATION BASIC X I SPECIAL COVERAGE IPERILS IFORMS AMOUNT OF INSURANCE DEDUCTIBLE Building /Replacement Cost Value/ 90% Coinsurance. Wind & Hail Excluded. $832,887.00 $2,500 nciuding Special Conditions City of Miami and OMNI CRA, are listed as a Additional Insured with regard General Liability and auto liability coverage when required by written contract, subject to terms, conditions, and exclusions of the policy. The insurance evidenced by this certificate shall be primary and non-contributory to any other insurance available to the additional Insured's named above. CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. ADDITIONAL INTEREST NAME AND ADDRESS City of Miami /OMNI CRA 1401 N. Miami Avenue, 2ND Floor Miami, FL 33136 ADDITIONAL INSURED MORTGAGEE LENDERS LOSS PAYABLE LOSS PAYEE LOAN # AUTHORIZED REPRESENTATIVE ACORD 27 (2016/03) © 19932015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD CNA Workers Compensation And Employers Liability Insurance Information Page WORKERS COMPENSATION AND EMPLOYERS LIABILITY POLICY INFORMATION PAGE ■ Policy Information Coverage Provided By Transportation Insurance Company a Stock Insurance Company 151 N Franklin St Chicago, IL 60606 NCCI Carrier Code: 12408 ■ tem 1 Named Insured nd ail ST JOHN COMMUNITY DEVELOPMENTCORPORATION INC PO BOX 015344 MIAMI, FL 33101 Type of Entity: Non -Profit Corporation FEIN Number: 59-2657550 Intrastate ID No.: 091834626 f SS Policy Number Policy Number: WC 5 92239939 Renewal of: WC 5 92239939 Producer Information CS&S/BRAISHFIELD ASSOCIATES -WC 5750 MAJOR BLVD STE 200 ORLANDO, FL 32819-7946 Producer Processing Code: 770-057593 If there are other work places not shown above: See attached Schedule is) 01/17/2022 to 01 /17/2023 at 12:01 a.m. Standard Time at the Insured's mailing address. Anniversary Rating Date: NONE 1 Item 3 A. Part One of this policy applies to the Workers Compensation Law and any Occupational Disease Law of each of the states listed here: States: FL 1 Item 3 B. Part Two of this policy applies to Employers Liability Insurance for work in each state listed in Item 3.A. The limits of our liability are: Bodily Injury by Accident Bodily Injury by Disease Bodily Injury by Disease WC000001 $1,000,000 each accident $ 1,000,000 policy limit $ 1,000,000 each employee Form No: P-300528-A 107-2008) Information Page; Page: 1 of 2 Underwriting Company: Transportation Insurance Company, 151 N Franklin St, Chicago, IL 60606 Policy No: WC 5 92239939 Policy Effective Date: 01 /17/2022 Policy Page: 11 of 39 E Copyright 2008 National Council on Compensation Insurance, Inc. All Rights Reserved. CNA Workers Compensation And Employers Liability Insurance Information Page Item 3 C. Other States Insurance: Part Three of this polip al .lies to the states, if any, listed here: States: All states except AK, ND, OH, WA, WY and states designated in Item 3A of the Information Page Item 3 D. This policy includes these endorsements and schedules: Schedule of Operations, Endorsement Schedule, Named Insured Schedule, Name and Address Schedule and Payment Plan Schedule Item 4 The premium for this policy will be determined by our Manual of Rules, Classifications, Rates and . Rating Plans. All information required below is subject to verification and change by audit. Adjustment of Premium shall be made: At Policy Expiration Classification of Operations: See Attached Schedule of Operations Minimum Premium Estimated Annual Premium Premium Discount Expense Constant Terrorism Premium Catastrophe (O/T Cert Acts of Terror) Total Estimated Annual Premium Total State Taxes/Assessments/Surcharges Total Estimated Cost Deposit Premium Account Number: 3026478439 Countersigned: Date of Issuance: 12/06/2021 Date: Policy Issuance Office: FLORIDA By: Chairman of the Board WC000001 $524 $9,220 $0 $160 $42! $0 $9,422 $0 $9,422.00 $9,422 Authorized Agent Secretary Form No: P-300528-A (07-2008) Information Page; Page: 2 of 2 Underwriting Company: Transportation Insurance Company, 151 N Franklin St, Chicago, IL 60606 Policy No: WC 5 92239939 Policy Effective Date: 01/17/2022 Policy Page: 12 of 39 Copyright 2008 National Council on Compensation Insurance, Inc. All Rights Reserved. REV. HENRY NEVIN — FOUNDER OFFICERS: DOUGLAS BROWN INTERIM CHAIRMAN REV. CECIL DUFFIE 1ST VICE CHAIRMAN WALTER DENNIS 2ND VICE CHAIRMAN EDWINA PACE SECRETARY' ELIJAH 1. BOWDRE ASSISTANT SECRETARY LEHONDRA SWAIN TREASURER ALEX AUGUSTE, CPA ASSISTANT TREASURER BOARD OF DIRECTORS: JAMES ADAMS NELSON ADAMS, 111, M.D. EDWARD BLAIR, IV BETTY BURKE•CLAYTON COREY B. COLLINS, Esq. TROY DUFFIE JAMAAL FAIRLEY ERICK FERNANDEZ GRACE HUMPHREY DONOVAN JACKSON GARFIELD MILLER, Esq. WILL MILLER KADISHA PHELPS, Esq. JANINE PRINGLE CHARLES SCOTT NATASHA ST. CYR T'RAN STUDWELL, Ed.D. ERIC L. HAYNES EXECUTIVE DIRECTOR St John Community Development, Corp. 1311 NW 3b Ave Miami FL 33136 305-372-0682 Phone 305-381-9574 Fax www.stjohncdc.org JOHN Cn tv1hil'NITY I) t•. t i 01 .•r i January 6, 2022 City of Miami 444 SW 2nd Ave Miami, FL 33130 Re: St. John Community Development Corporation To Whom It May Concern: Please be advised that St. John Community Development Corporation, Inc. does not and will not have any owned or leased vehicles. Therefore, automotive insurance coverage is not necessary. Should you have any questions or comments, please do not hesitate to contact me at (305) 372-0682. Sincerely, alie Suarez Comptroller EXHIBIT "D" GRANTEE'S Certificate of Corporate Authorization And Corporate Status Update Page 21 of 21 .CERTIBICATBOF Arnionrrit sr.Mli 6tFLOBITYA J. ) 3S11ilt59-7657.550: COUNTY OF. M.IAMI;XFADE B4RBBY.COTIfl Oat a meniiiiPgthp menihora ofg...JOHN,CPRINIVNITY ARVELOBlvIENT CIORIVRATION; a Florida Fer 6ridigg(10ii.(dic"POM)Iii417, itttitieirtienittitdtegiiS-P;04.3ex 0153444:Mimii.1%3S101 otganikeil ilidniiitiag wider tlte ltrwslit the Site Antiiirsi 2.6*.day,lof Petruary-2621, the. following tr.soltition. was- duly 'pa-146(1.4nd ittiblittili Ittstiki-VBB:the Mowing: I. Dougles.BroWnb Merinos; Moil Iinftlei:Viee,Chairtnan,VnItert)enniii 2).#Viaerhainpan,.1.40olra:Swain.Trealsnror, Ale; Auguste .4404riel**11*-Eftiviiiltv.Pilak,StiarOtarYi Erin1aYtte4Eitdoltive:DittdtOr, OF St IONN'comMUNTrir. DBVIII415NIBM011.1010.71fili,3N1beieby.authonzcEflo_jaynea,Biectitive Oltettof t0tOatt01".nil &PEW& in .OaiinadtiOt with41)-thatOerthio-$564410;.00.grent„rmaciiibythirOinni RettOvelopnrantBisteiet etnnolunitY,14.tievlgritaellt.4BeneY. POW) to. the. g.T,BB1N COM hottiprrY psysvowLgNrC011treftiVr.10.KiNc:' tinit datedoii abkint the dateliereofr 2. ST Jotpi gpMmt.I.NnirpEVg.I.OPMBNT.CORIPORATIONi INC:imthe registered oWnerand operator of a.husittearthat is. physianitfltiented with:the boundariaa.ofthe Omni CM-n(144SW tit pia,et .1fintharteriffithatiald.resolittioni nOW:htfOl (Arco oil cited.. IN WJINBSB:10.1PBB9Folie his -hereunto ha-Oro:I-of the:day aintielft ilittabOvedWritten, (Priiiteti typettor stamped nonitniisioned). Notary Public State of Fforid. Natalia Suarez My Commission GG Nana Expires 02/11/2023 ogo nine: Coen DAM Ninick4halllOon Attie Doi 14 amerWaltar Dennb yip-halt:Op gr. SOW '0711:1.NTIT avuopmENT" crkipokAllk 1N .—IthigWor Profit cottiehitton By 62rown.•0-3.102122 aineDoug1as Brown. Ti ntraminiatilignan 03/02122; Win 030/22 IV, 0/03/22 Pei unie:, elfandriilintin tit . rtitistiro By .Alex A09.06 03108/22 PAIL tioteMlazAtitnite Tillef.Wgivo. HilferreaOrar By eititaiii. A PAce 0/132t22: Priamei EllwIna::Paee 7fitiv,:§Aatay r ai rit-: 4nd. Pn Wet Ban. BMWs T.i4e.....Exe.cuilvelBlre4tor Sworn to and sobitri .d. 'before is.9h,day of Maid? 202a, Ericilnypes,,B)teutive•Director of §T: ,IORN COM.MUNI* DEVELOPMBI4CORPORATION. Itsit.fofl helielf of&iiitentityiikok ( )ptinkihelik knovinly.tne-ot ._____hns proyiderithe following identifitation. • a A C tit Ms. A II _ Palk —State•tif, • mmission:exiilres I i 2 Otintttli tiptd at stattipett sOmtrilssioried 1,11ML 1, ..1J r uetail by tnbty Name DIVISION OF CORPORATIONS �I /1310,1 of "-f1 • u '_'J ilslir_► J! I tug Wit htt Wit rd 11.4n/Q k/h Department of State / Division of Corporations / Search Records / Search ¢y Entity Name / Detail by Entity Name Florida Not For Profit Corporation ST. JOHN COMMUNITY DEVELOPMENT CORPORATION, INC. flllng Information Document Number N12743 FEI/EIN Number 59-2657550 Date Filed 12/24/1985 State FL Status ACTIVE Last Event AMENDMENT Event Date Filed 04/07/1987 Event Effective Date NONE principal Address 1311 N.W. 3 AVENUE MIAMI, FL 33136-2506 Changed: 04/19/2021 Mailing Address P.O. Box 015344 Miami, FL 33101-5344 Changed: 04/19/2021 gggjstered Agent Name & Address HART, BRIAN CARLTON FIELDS 100 S.E. Second Street 4200 MIAMI, FL 33131-2113 Name Changed: 09/12/2019 Address Changed: 09/12/2019 Officer/Director Detail Name & Address Title Chairman httpsJ/search.sunb¢.org/InquiryiCorporationSearchlSearchResultDetail?inquirytype=EntityName&dinectionType=initial&searchNameOrder=STJOHN... 1 /3 U IWG I, J., ,rwi uetaii try tnnty Name ADAMS, JAMES D. St. John Baptist Church 1328 NW 3rd Avnue MIAMI, FL 33136 Title Treasurer SWAIN, LEHONDRA 1940 SW 57th Avenue West Park, FL 33023 Title Secretary PACE, EDWINA 19020 NW 11th Court Miami Gardens, FL 33169 Title Executive Director HAYNES, ERIC L 1324 N.W. 3 AVENUE MIAMI, FL 33136 Title VC MILLER, Ed.D., WILL 16811 NW 24th Avenue Miami, FL 33056 Title 2nd Vice Chairman DENNIS, WALTER 1156 NW 56th Street MIAMI, FL 33127 Annual Reports Report Year 2020 2021 2021 Document tmagea Filed Date 01/13/2020 01/12/2021 04/19/2021 14119/2021 - AMENDED ANNUAL REPORT 01112/20Z1 - ANNUAL REPORT 01/13/2020 - ANNUAL REPORT 09/12/2019 - AMENDED ANNUAL REPORT 99/11/2019 - AMENDED ANNUAL REPORT 08,23/2019 - AMENDED ANNUAL REPORT 01/08/2019 - ANNUAL REPORT View image in PDF format View image in PDF format View image in PDF format View image in PDF format View image in PDF format View image in PDF format View image in PDF format https-i/search .sunbiz. orgilnquiry/CorporationSearch/Sea rchResultDetail?inqu irytype=E ntrtyName&di rectionType=Anibal&sea rchNameOrder-STJOHN . ?l3 L etail by tntity name 01/16/2018 — ANNUAL REPORT 12/0T/2017 —AMENDED ANNUAL REPORT QS/01/2017 — AMENDED ANNUAL REPORT Q1/11/2017 —ANNUAL REPORT Q1/06/2016 —ANNUAL REPORT 02/10/2015 — ANNUAL REPORT Q1/07/2014 — ANNUAL REPORT Q1/04/2013 — ANNUAL REPORT 01/13/2012 — ANNUAL REPORT 11/29/2011 — ANNUAL REPORT P1/10/2011 — ANNUAL REPORT p1/22/2010 — ANNUAL REPORT 01/21/2009 — ANNUAL REPORT 01/14/2008 — ANNUAL REPORT 01/17/2007 — ANNUAL REPORT 01/31/2006 —ANNUAL REPORT Q2/21/2005 — ANNUAL REPORT 02/28/2004 — ANNUAL REPORT 01/21/2003 — ANNUAL REPORT Q2/01/2002 — ANNUAL REPORT 01/29/2001 — ANNUAL REPORT 02/02/2000 — ANNUAL REPORT Q2125/1999 — ANNUAL REPORT D2/03/1998 — ANNUAL REPORT D2/11/1997 — ANNUAL REPORT 01/31/1996 — ANNUAL REPORT 1)2/02/1995 — ANNUAL REPORT Vew image in PDF format View image In PDF format J View image in PDF format J View image in PDF format Vew image in PDF format Vew image in PDF format J Vew image In PDF format J View image in PDF format _ J Vew image in PDF format I View Image in PDF format View image in PDF format View image in PDF format J Vew image in PDF format J View image in PDF format J View image in PDF format I View image in PDF format 1 View image In PDF format View image in PDF format I View image in PDF format I View image In PDF format J View image In PDF format I v _ View image in PDF format I Yew image in PDF format — J View image in PDF format View image in PDF format I View image in PDF format Vew Image in PDF format I cr r httpsJ/sea rch.su nbiz.org/Inquiry/CorporationSearch/SearchResultDetail?inquirytype=EntityName&directionType=Initial&searchNameOrder--STJOHN .. 3/3 130404 litteroat:arld riia40.aUre.00wper.ihip Affidavit L This Ailidavit • is. submitted to the OW REDEVELOPMENT MP:RIM :POMO:1411Y REDEVEL.OPIVIENT AGENCY, a Public Agency and.Body Corporate:created puisinirit to SOtitrir 163.30, Florida tages; velicreupon the undersigned authority, personally Appeared, Eric Hayne,s, ea:Worth* Pir.a0tor(P:9f1lAte gPPreaerttative") ofet.JOHN COMMUNITY DEVELOPMENT COODUTIONA 114Ca Flotid.NOtFw Profit Corporation, whose maiiingaddress isPO..E0X-0.15344, Miami FL.33.101, and (irepfilica.ble)* foldalginploor identification INiumber (FEIN) is59.16515.5.0,,subject to. the penalties prescribed for POW, .depOsei.tridalySV The.Corporate 4.4.1resentative has read the contents of this AffideVit, heatretaal ItcaYiletlga Of the facts contained herein, and states that the facts contained 'herein are true, correetiand complete, 3. The following is a list cirevery !punnet (as defined in Section 1.0:19), Florida Statues to Magda individuals, children firms, associates, 1°14 ventures,. partnerships estates, trustsi buShfess aYliOidat0; fiduciaries, corporations and all other gaups and combinations) as ofithe. date herett hOlding:.5%.1nfiat* of the benef1bia1interest1n thedisclosingentitri (Ifmorespaceisneeded, attach separate slittet)!..ST. JOHN COMMUNITY DEVELOPMENTCORPORATIONANC. 4. Thisaffidavit may be signed. inseveral counterparts,. each ofwhich Shall bt an briiltaatit111110..Vilgik. together shall constitute but one and theiaMedoownent•bindingon all ofthe parties,n9tWithstanding drat fidt.all of the parties have signed the sametounterpart.. Any signature delivered by a party JAY fa.alitiIla, email ot MO 4lettrgnig transmission shall he deemed to_be. an original Signature tothis affidaVit, IN WITNESS WHEREOF the undersigned has ..berennto set its hand as. Of the and YVIV fag /1150v0' ST. JPI1N COMMUNITY DEVELOPIVIENT CORPORATION, I;NO, a Florida Not Forfrofit Corporation 141 HAVREs. Title: Executive D. r4Oor STATEDFLORIDA )•$P: COUNTY OF MIAM1-DADE ). Sworn to and subscribed befOre me this I day of 1\11 ar ,2.O2.by alc PAYI.VS, as Executive DireAtrit 9f sy, JOHN COMMUNITY DEYWRIVIENT CORPORATION, 1NC, a FlOtidtt Not For Profit cOte9rtitiO, on behalf of said entity, wTho •-t ) PrVilagy known to .ind or ( ) has Prcidabcd the folloWing gleridfitatiOn Sunre2_ ger Notary Public State of Florida fikt Natalia Suarez kor MY Commission OG 800503 Expires 02/11/2023 • ag-LO" rY State 6 oxiiti*.g.o.ogsfres mined, typed orsgtompo contriisgoried) catativoto gm:amp tiA3BY1INTG 60ittiort tor Ootwoota...0toto. Loam itul.CoopototivoAgootit§. Theamdersigned certifies lo the best of his or her knowledge and belief,: that (1).140.apprOpriotedfundS have beep paid or will be-pi4i•bypt. on behalf oftAc tuidersigned,lo any person tor infinOneing or attempting to influenecOn officer or employee den agency aNlenitier of COOS* an. officer or employee.olCongress,.or an employee ofaMernberofCongreSs 1i OnneetiO4With *00044 of Any contract the making ofgrant, the Makirtg-Of fIttyloto, the ttotitIg into "91. APY' 00Perative now, and the extosio,. continuation, .foo4witl, mooil.mott PTP*40*bn of any zoniragrank loth. vr. PPOPPra*engreenle.nt (2) IfetW funds Oilier then aPprOpriated "attidS We, been paid .to any torso fQr influencing Or otipmpting.. to influences ai offloor or. .omploy.ext, 7of ay 4go1oy, a 'Member of' Congress, an officer or employee of Congress, or an employee of a Member of Congress in :connecfion with this cottliOct+ grant, Itniht Qr cooperativeogreement, the undersigned libel] complete and submit Stendar4Tbrin-141.iti, i'Di$Olesurg.Forrn to RePort-LObbying," in:4001440 Vvith (3) The 3.410teiguett.sbII tegkiire.thatthelanguage Ott& perii0gatiOn be included in the award.documenti for$All's sub -awards at.alltibrs (includingcsubcontractisub-grarits, ancleontraetS Under OM% Ioans,Oct aOperative agre:emeilts) aridtbetall Sub-rdeipletitS.4411:0000 41ot000 woomflog.lyk Tii4o.foing4i9n is a material representation of act upon-whiah reliance was placedwhen this transaCtioi was made or entered into.. Submission of this certificationis a preeotii§lw *it:ow*. or opitotiog: transaction imposed by Sotloo 05? Title 3.1, U,S COO, Any polo oho to to 00 the iv-quirt:a certification shall $41Afoot. to a. oiy:i111004 f tit loss. titan $10;000 and not tnore Than f 10000 for eaol such failure. ST. MN COMMUNITY DEVELOPMENT COOMATION,liqq. a Florida Not For -Profit Corporation By:, Print One.: . rlaYiles Title: "Executive Director Note if applicable:. In these instances, "All" in the Final Rule is expected to be clarified to show -that it applies to covered contract/grant transactions over $100,000 (per QNIB): CONFLICT OF INTEREST DISCLOSURE AFFXDOlt etiontitt 112, FLORIDA STATUTES TOM FoRmmuST BE sIRTED AND SWOW TO IN THE PRFOKE.OF A NOTARY minx cR OTHER C01.041 AuTIORAZEI.) Tc1ADMJN1STER OATHS. The undersigned, being firstduly Swan; states:. 1:: The. frill legalname. andbu,sinessaddrese of the perm* or entity dentreeting or trensactit.18. business withthe City. of lylituni is:: St. JOhn COmniorrity Pevelopment CorpotatiOnduci a, The business is formed as a: Florida.Not For Pita Corporation: 3. The busirresS was formed or incorporated in the following year and state: 1985, Florida. 4. The business is registered in:the follOwing.state(s): Florida; 5. ,)OR:tORPORATIONS: A. The following trustees; advispry.board members. orptathasingagents of the CRA, City or their $pot4ses or children are officers or. .direotors 011ie corporation: NONE B. The following trusteeS, advISOry beard merebers.or purchasinggents of the ORA, City or. their Spoptes, or children or any cortibinetion thereof hold direct)yofindirectly more than 596 but less than 16% ownershiPin the corporation's stock.NOUE C. Thefollewing trustees, advisory heard mothers or employees of the CRA, City or their spouses,. children or.parents hold directly or indirectly 1.0% or more of the ownership in the corporation's Stock: NONE D, The following trustees, advisory board merribers oremployees City are employees of -or in a contractual relationship with the corporation: NONE 6, Th.Lvit-010 hesigued n scveral.coupteoaos, each orlyhich shall be an original and all of WhichlOigther..$1108 constitute.bufene'And the same docurneut binding on all or the Pattie, Potwithstpudiretbut not all &the parat.lave signed the same counterpart. Any signature delivered by a party by faesii.ajle, email or other electronic transmission shall be deemed to be an original signature to this affidavit. PIONATUREg CONTINMA ST. JOHN COMMUNITY DEVELOPMENT CORPORATION, INC. a Florida Pinked Liability Company BY: Fria- ante; E c LJI1ayncs Title! &motive Dtrector STATE OF 'FLORIDA ); ) 'COIJNTY OF MI-DAD5. SWO01..tb klind ant400-01 'before. me this., i54- day . mar ck) 2031fby MC L, Haynes, as The FiXO0411.4.DiNd.tOrONT.. JOHN COMMUNITY .DgvEWPIVIENT cogeoRmosi, nsto...,.a. Florida No For Profit Corporation, on behalfof said entity, who is personag known 'to the of ) has prkidtteed the following identification 1\1001 I .1 CI Slare."2,. (Printed, ylied bt startled ecktrilidstiOdod • (a) Mitrrif WOE OF EA MET AND SUSPENSION Authority and requirement to debarand suspend! After reasonable notice to an actual or prospective .contreetnal patty, and after reasonable to such tiertyle be heard, The Executive Director,after consultation.with the City Attorney as General Counsel, shall have the authority to -debar a contmettlal party 'fir the causes listed below from consideration for award of CRA contracts The debarment shall be for a Period of not fewer than three. i.eara. The Emetnive Director shall also have the authority .to suspend a contractor from consideration for award of City- oontraotsif there is probable. cause for deberinentPeriding the debarment determination, the authority to debar and suspend contractors shall be exercised in accordance with regulations; which shall be issued by the OhlePr,004t0m-ent CYffie#r after approval by the.Exeoutlye Director; the City Attorney, and the CRA Board or City CoMmission. .(b) Cues fordebantent or suspension include the following: 1. ConviCtiOn for mmission ofa criminal off.ense inoident to obtaining or attempting to obtain public (Federal, state, or local) or priVatecontract or subeontract, or incidentto the performance of such:Oonnnot or stibc-ontrad. 2. -Conviction under Mite or *deft' statutes Of embeoleinent, theft, fbrgoty, bribery falsification of destruction of record & reCeiVingatOlen prOperty,, or any other, afonse ladipati.ag a lack of business integrity or bughteSS libtietty, 3. ConViotiOn under spate or federal oititutt owes arisilfg. but of the ob.411§sion. of bids: t?!. Proposals. 4. ViOlation of oiantroct provisions. -which is regarded by: :the chief PrOegren.lePt Officer to indicative. of non-tespOnSibility. Sueb violation may: include. failkre Without good cause to perform in accordance with the terms and oonditioriS of acontiact or tO perform within thellme limits provided in a c.ontract, provided that failiire: to perfortn caused a*.beYrnfcl titatontrOl ofa party shall not be, considered abasia for debarment.or saspengion. . . 5; Debamtent, proposed for debannent declaration of ineligibilitye voluntaky exclusion frOni covered or. suspensionof the contraotual party by any federal, state,1oJ,or other governmental entity,. 6. Valve certification pursuant to mograph (o) below, 7, Any other cause Judged by the' Exeeative Director to be so serious and compelling as to. affect the responsibility prthe ontracogi party performing CRA and City contracts $. One or more public transactions (Pederol,.Stote; or 1001) terminated for cause or default. 9. Civil judgment rendered forthe CoMiniSsion of frood: Additionally, the undersigned hereby certifies liat neither the 0040'40141 paft$ ar any ofita principal owners or personnelore not presently. indicted for otherwise criminally or civilly charged by a governmental entity (Pplerol, state,.or 1001) with the commission earty 0010 violations set.forthabove. te) Certification: All contracts for neither thexontracfrial party nor any of its principal ownett OF personnel hes been convicted of any of the Violations Set forth above or debarred or suspended as set fbrth in paragraph (b) (). The undersigned'hereby certifies that neither the contractual patty Or any of gapriflapal Qviluers or personnel has been convicted of Any.ofthe violations set forth above, or debarred or suspended as set paragraph (5). IN WITNESS WHEREOF; ihe undersigned has hereunto set its hand at onhe day mid 3?reat. ilt:St.abokig Written. ST. JOAN COMMUNITY DEYELOPMENT-CORFORATION, INC a Florida not for prpfit 'corporation By: Eric L. Naynot, M alter Date: gi 1%1620 / STATE OF FLORIDA COUNTY OF IVIIAMI-DADg.) Sworn and subscribed before me on this 181 day -of March 2031 b$, Brio L. Haynes, the ExecutiveDirector orST. JOHN COMMUNITY DEVELOPWINT CORPORATION, INC„ On behalf of itieh not for profit corporation, who is personally known fo me or who produced a as identification. 1Q,(10 ry Rublic — Sta f Floridp commission expires Zi a 1'0 &tart? (Printed, typed or Stanipedcommistioned 2. SWORN STATEMENT ON hogx EMMY CRIMES SECTION 287,133(3)(0 FLORIDA STATUTES TRLS ?ORM MUST RE STONED AND SWORN TO IN THE PRESENCE OF A. NOTARY PUBLIC OR OTHER OFFICIAL A.UTRORTZED TO ADMIN.ISTER.OATIIS, 1.'This sworn :statement is submitted to the OMNI REDEVELOPMENT DISTRICT COMMUNITY REDEVELOPMENT AGENCY:. a Public Agency .arid Body Corporate treated vitamin to Section 163356, FloridaStatittes. by : Eric L. Haynes, as 8xecutive Director of ST. JOHN COMMUNITY DEVELOPMENT CORPORATION, INC for ST. JOHN COMMUNITY DEVELOPIvIEWf CORPQRAT1O.N, whose business address is: ThIi NAV. 3'd Avenue; Miami, Florida 33136 and 04111'04310s Federal ginptoyet IdamitidAnilstagghor Efi§0.-L26$1550. 2. I understand that a "public .entity brittle as defined in Pat ph n7.133(1).94, Florida Statutes, .means a violation s:4* any state or federal law by a person with respect to and directly related to the 40140On, of busine.sa with any public entity or withal agenc.y orpolitwul subdivision of any other state or the United States, Including, but ;not limited to, any bid Vt. contract for goods. and services to be provided to any publiC entity or an agency or. political .s.tibdiViSiOn ofany other state.0 Qiiho Umoed States. involving4utitrust, fraud, theft, bribery co11.usion racketeeringi conspiraby;biniaterial miSrepreSentatiOtt. 3. understand that'conViotptit'ror "conviction" es defined in Paragraph 287.133(1)(b).Florida Statutes = rIleenS a finding of gkillt or a conviction or apth1ic entity Otjtn0., with or without an adjudication of guilt, m any federal Of State trial court of record. relating to :ohktges brought by indictment or information after July I, 1989,1s:40-$0R of verdibt, nOnjUry trial, or .atitty da plea ofgnilty ornolp QoOtOOdere, 4! 1141dorstalld.lban an''aftIlatp" a definedin Paragraph 187.18.50)(4 Florida Statutes, means: a. A 'predeceSsOr btsitece$Set Of pont* oov)ctopi Oa Pt.00,.OxititY'OritteOr b. An entity under the control of any natural person who is active bite Management Of the entity and who has been convicted of a public entity crime. The term i4affiliate" includes those officers, directors,, executives pgri.nats, shareholders employees, members and agent g who are active in the managementof an affiliate; The Ownership by One perRa OtthareS;ConStittIting a cOntr011inginterest in another perscm, or a pooling of equipment or income atnestigOrons when na for fair market value under an atV'S Ibtlgth agreement, shall bea prima facie case that one person controls another person. A person whoknowIngly enters into a Team with a person who has been convicted of a public entity crime in Florida during the preceding 3.6 months shall be coniideredati aftlifete: RFP for Park East Youth ton* tOP 190-74 5. understand tit.kt "gerSOO”.48.40fitted IiParagraph g87.13(i )(e), Moildo:.$1cOtutOSi MeaPS OhY natural person or entity organized under the laws of any slate Or of the United States with the legal poWer to enter into a binding contract and.which bids. or applies to bid on .contracts for the provisiOn.Of gOods. or services let by a public.entity,:or which otherwise transacts or applies to transact business with a public entity. The term "person* includes. thoseoffic.ers, directors, executives „ partners, shareholders, employees, members, and agents Who are .active in the manageniebt ofayi entity. 1 6. Based ori inforitiedon and Wet theltateluent.dtat I hayeluttrited below is -true in relation to the entity Subinittilig this Swtifn istetettuilit Illitlictite.Which statafitekit ApP1141. Neither the entity submitting this sworn statement, nor any A01, dir0410M, partners, shareholders, cnIployeesitmenthemor agents who are;actiVe in the management bite eh*, pot any affillata Oft entitl, 40001 thetPd With 00.4.01A.'1044 fapeblie entity. critne subsequent :Ia.:Will 1989.. Thisontity submitting this sworn statetnerit, of We OftnOre.otlt4 OftketS, clOackti 01.0.900vgs partners, shereholderst:employees, members, or .agents who are active in the management oftlie entity; Aran affiliate 1;rrthe entity has been obargedwith and convlated'ofa public. entity mite subsequent tO .Iuly. 1, 1989,. The Ofttity*ihttiltdag Uii viroko etetemeiltAt me or MOreOfits officers,: directors, executives, partners, °thielli31der-an*P19Yees, oleibb0, or agebis who art active in the tiletulg.etgent .cif the entity:, or an affiliate ofthe entity has been charged with ,and convicted tif apublie.entity Ohne stibtequenttO MY 100807 floweyori there hes been a subsequent proceedingbeforea Hearing Officer of the Stine of FIONA, -DiVisiOilof "i1A:eitiv. Order entered by the Heatitig. Officer determined that it was not in the .0W:interest tit plat* the entity a:Omitting this sworn statement on the convicted vendor list: [attach a copy Otthe final ordeti This affidavit may he signedin several counterparts; .each ,ofswhich Shell be an otOtial eittl all :of WO together Shall'constitute hut on and the same document binding on all Of thepartiesolotWithstandlngthat not all ofthe partie4 inoie signed the same ouotetiiem Any elt014,41wIellyereil by party by facsiinile, email or other eleetttinle transmission fi.411 be deo* to be ab oilgte$ eigieture,t.o this eMcievit. I UNDERSTAND THAT THE. SUBMISSION OF THIS FORIVLTO THE CONTRACTIDIG OFFILCER Mitt TOP 1p3.41c: 01117.11rirtE0 IN PAIUGRAPII 1 ABOVE rg FOR THAT PUBLIC t NOW ONtile MD, T THIS Ogg IS.. VAUD THA011411 DECEMBER. 31 OF THE CALENDAR YEAR IN WHICH rr IS At,so motsmo Tool Or REQuilati TO 'mom TEE PUBLIC Paul' PRIOR TO ENTERING -MO A CONTAA-CrOT.PXOS$- OF THE THRESHOLD AMOUNT PROVIDED IN SECflON 287 017, $TAirllfrEti,. FOR CATEGORY TWO OF ANY CHANGE IN THE INM FORMTIOIY CONTAINED N THIS VOW ISIONATIME$ CONTINUO] 2 IN WM-SS WIMP-0V; the tmdeiskiled has hereunto set its hand Is of the day and year first abOve writteit $14011RAJOIWIVIUNITY DEVELOPMP.KT COIWORAITIONvINC., a ViorjaWNotkor Profit Corporation WITNESSIM mum**, P.Nath ,.') A' St Iciij gonOupityDevelopment Corporatfoklac. Arta: Edell -waft 1324 NW.34 Mdil4k Alisi%, FLOM 33.1.30: STATE OP FLORIDA ) SS: COUNTY OF MIAMI-DADE ) Sworn to and subscribed before me this day Of March 2or.a.by Frig L.. IlaYhk 4S Executive 'Director of St John Community Development Corpiration, thc., bh behalf Of such not ftit, profit: corporationo who is personally known to me or who produced a as ideljftatiork., -(,110 i'o.ary Public— StAte\Offitific_ h43' commission expli'es• 1/2•3 ,Noto 1(2 guap 2- (Printed, typed OYStaniPed cOnficOisSiOned 41.7,",14^ke..!teNeNewcrts- apT. lititorgublic State of FlanSusrez & ir My Commission OG Expires 02/11/2023 eket.""Avyvews""""elt-ww