Loading...
HomeMy WebLinkAbout26069AGREEMENT INFORMATION AGREEMENT NUMBER 26069 NAME/TYPE OF AGREEMENT MACEDONIA MISSIONARY BAPTIST CHURCH OF MIAMI, INC. DESCRIPTION AMENDMENT NO. 1 TO MFE GRANT FUNDING AGREEMENT/EXTENSION OF TERM/FILE ID: 14315/R-23- 0334/MATTER ID: 25-3114 EFFECTIVE DATE February 9, 2026 ATTESTED BY TODD B. HANNON ATTESTED DATE 4/3/2026 DATE RECEIVED FROM ISSUING DEPT. 4/3/2026 NOTE DOCUSIGN AGREEMENT BY EMAIL CITY OF MIAMI DOCUMENT ROUTING FORM ORIGINATING DEPARTMENT: Office of Management and Budget DEPT. CONTACT PERSON: Gabriel Brito EXT. 305-416-1203 NAME OF OTHER CONTRACTUAL PARTY/ENTITY: Macedonia Missionary Baptist Church of Miami, Inc. (MFE) IS THIS AGREEMENT TO BE EXPEDITED/RUSH YES ENO TOTAL CONTRACT AMOUNT: $397,118.00 FUNDING INVOLVED? ®YES NO TYPE OF AGREEMENT: ❑ MANAGEMENT AGREEMENT ❑ PROFESSIONAL SERVICES AGREEMENT ® GRANT AGREEMENT ❑ EXPERT CONSULTANT AGREEMENT ❑ LICENSE AGREEMENT ❑ PUBLIC WORKS AGREEMENT ❑ MAINTENANCE AGREEMENT ❑ INTER -LOCAL AGREEMENT ❑ LEASE AGREEMENT ❑ PURCHASE OR SALE AGREEMENT OTHER: (PLEASE SPECIFY): AMENDMENT #1 TO THE MIAMI FOR EVERYONE (MFE) GRANT PURPOSE OF ITEM (DETAILED SUMMARY): Approval of an amendment to the MFE Grant Agreement with Macedonia Missionary Baptist Church of Miami, Inc. (MMBCM) to extend the grant teen through August 31, 2026. MMBCM, a not -for -profit organization providing daily social services and educational programming in the West Grove community, is constructing a new classroom annex funded by the grant. The organization requested the extension due to delays related to seasonal slowdowns, labor availability, archaeological monitoring, and permitting. The proposed amendment will: I.) modify the term referenced in Section 2 of the Agreement, effectively providing an extension through August 31, 2026; and II.) add Section 37 and Exhibit H, "Anti -Human Trafficking Affidavit." COMMISSION APPROVAL DATE: 07/27/20203 FILE ID: 14315 ENACTMENT NO: R-23-0334 IF THIS DOES NOT REQUIRE COMMISSION APPROVAL, PLEASE EXPLAIN: ROUTING INFORMATION Date PLEASE PRINT AND SIGN APPROVAL BY DEPARTMENTAL DIRECTOR March 27, 2026 I 09:20:33 EDT PRINT: MARIE "MAGGIE" SIGNATURE: GOUIN ,—Signed by: `-7„/4_____ SUBMITTED TO RISK MANAGEMENT March 27, 2026 1 09:25:53 EDT PRINT: DAVID RUIZ SIGNATURE: —.,F�easltwre5 9 "—DocuSigned by: Fmktei �_ March 31, 2026 I 17:19:01 EDT SUBMITTED TO CITY ATTORNEY March 31, 2026 I 17:24:59 EDT PRINT: GEORGE SIGNATURE: 270051'1IN K. WYSONG III (—DocuSignedby: 1 a�{,6r , . 0tisbl4 Ill `— az4se._ APPROVAL BY ASSISTANT CITY MANAGER March 31, 2026 I 17:26:23 EDT PRINT: ERICA T. PASCHAL SIGNATURE: DARLING, CPA, CFO ,—DocuSigned by: e-t4: 1. Paocived `--- APPROVAL BY DEPUTY CITY MANAGER April 1, 2026 I 11:34:50 EDT PRINT: NATASHA SIGNATURE: He5e 13-54$c... COLEBROOK-WILLIAMS ,—DocuSigned by: N4 C(i—(t;,(,(;,z �4-Bten99-7-aDEA4-rs... RECEIVED BY CITY MANAGER April 2, 2026 1 13:48:24 EDT PRINT: JAMES REYES SIGNATURE: Sign A.6gSf,F9rFAaZg SUBMITTED TO THE CITY CLERK April 3, 2026 I 10:16:44 EDT PRINT: TODD B. SIGNATURE: HANNON ,—DocuSigned by: '- E 46 D 7560 D C F 14 59... PLEASE ATTACH THIS ROUTING FORM TO ALL DOCUMENTS THAT REQUIRE EXECUTION BY THE CITY MANAGER AMENDMENT NO. 1 TO THE MIAMI FOR EVERYONE ("MFE") GRANT FUNDING AGREEMENT WITH MACEDONIA MISSIONARY BAPTIST CHURCH OF MIAMI, INC This First Amendment to the MACEDONIA MISSIONARY BAPTIST CHURCH OF MIAMI, INC. Miami For Everyone ("MFE") Grant Funding Agreement ("Amendment No. 1") is entered into the tday of , 2026 between the City of Miami, a municipal corporation of the State of Florida ("CITY") and M EDONIA MISSIONARY BAPTIST CHURCH OF MIAMI, INC a Florida Not For Profit Corporation ("RECIPIENT"). RECITALS WHEREAS, the City created the Miami For Everyone ("MFE") Program to assist communities facing the long-term complications resulting from declared emergencies and to address the specific needs of the most vulnerable residents and businesses, through a strategy of focusing the provision of support towards priorty areas of need that will further stabilize economic conditions within City Districts; and WHEREAS, pursuant to Resolution No. 23-0334 adopted on July 27th, 2023 ("R-23- 0334"), the City Commission awarded RECIPIENT Three Hundred Ninety -Seven Thousand One Hundred Eighteen and 00/100 Dollars ($397,118.00) in Miami For Everyone Funds ("MFE") in order to construct and complete a new classroom annex at the Macedonia owned property located at 3515 S. Douglas Road ("Project"); and WHEREAS, RECIPIENT executed the MFE Grant Funding Agreement ("Agreement") with the CITY dated March 20, 2024 ("Effective Date") for the use of the MFE Funds pursuant to the terms of the Agreement and applicable laws, rules, and regulations; and WHEREAS, Section 2 of the Agreement establishes a term beginning on February 26th, 2024, and ending on February 26th, 2025 ("Term"); and WHEREAS, the RECIPIENT has experienced several delays due to required archaeological monitoring, seasonal slowdowns, labor availability, and permitting, has reviewed their project schedule, and has provided a written letter to the CITY requesting a term extension through August 31, 2026; and WHEREAS, this Amendment No. 1 only amends the Term of the Grant Agreement, while adding Section 37 and "Exhibit H", and does not increase the total MFE Funds that were approved and awarded pursuant to R-23-0334; and NOW, THEREFORE, in consideration for the covenants set forth herein and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows: 1. All of the above recitals are true and correct in all respects and are incorporated by reference herein as though set forth in full herein. Page I of 4 2. Section 2 of the Agreement, titled "TERM", shall be removed and replaced in its entirety as fi�llows; 3, "2. 'I'ERM; 'Me tern of this Agreement shall commence on February 26th, 2024, and shall continue until August 3 I'', 2026." Section 37 will be added to the Agreement, as follows: 37. ANTI -HUMAN TRAFFICKING. The RECIPIENT confirms and certifies that it is not in violation of Section 787.06, Florida Statutes, and that it does not and shall not use "coercion" for labor or services as defined in Section 787.06, Florida Statutes. The PROVIDER shall execute and submit to the CITY an Affidavit, of even date herewith, in compliance with Section 787.06(13), Florida Statutes, attached and incorporated herein as Exhibit "I -I". If the PROVIDER fails to comply with the terms of this Section, the City may suspend or terminate this Agreement immediately, without prior notice, and in no event shall the CITY be liable to PROVIDER for any additional compensation or for any consequential or incidental damages. 4. Except as modified herein, all other terms and conditions of the Agreement, shall remain unmodified and in full force and effect. 5. This First Amendment may be executed in any number of counterparts, each of which so executed shall be deemed to be an original, and such counterparts shall together constitute but one and the same Amendment. The parties shall be entitled to sign and transmit an electronic signature of this Amendment (whether by facsimile, PDF or other email transmission), which signature shall be binding on the party whose name is contained therein. Any party providing an electronic signature agrees to promptly execute and deliver to the other parties an original signed Amendment upon request. 6. This First Amendment may not be amended, suspended, superseded or otherwise modified except by a written instrument, expressly identifying the modifications made and signed by the authorized representative of each of the parties. Remainder of page intentionally left blank [Signatures on the Following Page] Page 2 of 4 IN WITNESS WHEREOF. the parties hereto have caused this First Amendment to be executed by their respective officials thereunto duly authorized on the date above written. ATTEST: Signature CITY: CITY OF MIAMI, a municipal Corporation of the State of Florida Signed by: April 2, 2026 1 13:48:24 EDT —A6&C25e 7c 4472 James Reyes City Manager Date: PROVIDER: MACEDONIA MISSIONARY BAPTIST CHURCH OF MIAMI, INC. a Florida Not For Profit Corporation By: Opte. Print Name: eihriA.- u Lb/ / SO A{ Title: 0,144.40 ATTEST: DocuSigned by: Signed by: F115 Todd Hannon City Clerk h-I , 2026 1 10:16:44 EDT Date: APPROVED AS TO INSURANCE APPROVED AS TO FORM AND REQUIREMENTS DocuSigned by: FratAk 27, 2026 1 09:25:53 EDT David Ruiz Interim Director Date: CORRECTNESS: ,—DocuSigned by: at-brOt .f U11(1( 2026 `-8R776F9FF8R24RR 17:24:59 EDT George K. Wysong III Date: City Attorney Matter ID: 25-3114 March 31, 2026 1 17:19:01 EDT Page 3 of 4 EXHIBIT H ANTI -HUMAN TRAFFICKING AFFIDAVIT l . The undersigned affirms, certifies, attests, and stipulates as follows: a. The entity is a non -governmental entity authorized to transact business in the State of Florida. b. The nongovernmental entity is either executing, renewing, or extending a contract (including, but not limited to, any amendments, as applicable) with the City of Miami ("City") or one of its agencies, authorities, boards, trusts, or other City entity which constitutes a governmental entity as defined in Section 287.138(1), Florida Statutes (2024). c. The nongovernmental entity is not in violation of Section 787.06, Florida Statutes (2024), titled "Human Trafficking." d. The nongovernmental entity does not use "coercion" for labor or services as defined in Section 787.06, Florida Statutes (2024). 2. Under penalties of perjury, pursuant to Section 92.525, Florida Statutes, 1 declare the following: a. I have read and understand the foregoing Anti -Human Trafficking Affidavit and that the facts, statements and representations provided in Section 1 are true and correct. b. I am an officer or a representative of the nongovernmental entity authorized to execute this Anti -Human Trafficking Affidavit. FURTHER AFFIANT SAYETH NAUGHT. Nongovernmental Entity:—y SS��K i34,51- Ace Name: (A�r)Lyip u c Officer Title: K*-c C Signature of Officer: I Office Address: 3S S S Lt) 37 it ve, y l Dom«` E. 3/1-3 Email Address: 11N Q prtace .jK Main Phone Number: , •!�ys=Cy�'S i , A'U a 44 , Crtw( 1 — 71v a p 3vS s/9 Page 4 of 4 / A� o® CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) 03/11/2026 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Sovereign Insurance Group 801 Cassatt Road Suite 202 Berwyn PA 19312 CONTACT Mike Belardo NAME: PHONE o, Ext): (800) 222-4478 FAX No): (610) 535-6810 E-MAIL MBelardo@sovinsurance.com ADDRESS: INSURER(S) AFFORDING COVERAGE NAIC # INSURERA: Guideone Elite Insurance Company 42803 INSURED Macedonia Missionary Baptist Church of Miami Inc 3515 SW 37th Ave Miami FL 33133 INSURER B : GuideOne Insurance Company INSURER C: INSURER D : INSURER E : INSURER F : COVERAGES CERTIFICATE NUMBER: 25-26 GL/Auto w/AI REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL INSD SUBR WVD POLICY NUMBER POLICY EFF (MM/DD/YYYY) POLICY EXP (MM/DD/YYYY) LIMITS A X COMMERCIAL GENERAL LIABILITY Y 001275976 09/24/2025 09/24/2026 EACH OCCURRENCEDAMAGE $ 1,000,000 CLAIMS -MADE X OCCUR TO RETED PREMISES (Ea occurrence) $ 1,000,000 X Sexual Misconduct: MED EXP (Any one person) $ 10,000 $250,000/$500,000 PERSONAL&ADVINJURY $ 1,000,000 GENIIAGGREGATE P POLICY OTHER: LIMIT APPLIES JECT PRO PER: LOC GENERAL AGGREGATE $ 3,000,000 PRODUCTS - COMP/OPAGG $ 3,000,000 $ B AUTOMOBILE X _ LIABILITY ANY AUTO OWNED AUTOS ONLY HIRED AUTOS ONLY )/ /• ...,/ /• SCHEDULED AUTOS NON -OWNED AUTOS ONLY Y 001829494 12/31/2025 12/31/2026 COMBINED SINGLE LIMIT (Ea accident) $ 1,000,000 BODILY INJURY (Per person) $ BODILYINJURY(Peraccident) $ PROPERTY DAMAGE (Per accident) $ Underinsured motorist $ INCLUDED UMBRELLA LIAB EXCESS LIAB OCCUR CLAIMS -MADE EACH OCCURRENCE $ AGGREGATE $ DED RETENTION $ $ WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below Y / N N /A PER STATUTE OTH- ER E.L. EACH ACCIDENT $ E.L. DISEASE - EA EMPLOYEE $ E.L. DISEASE - POLICY LIMIT $ DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) Certificate holder is an additional insured to the General Liability policy only to the extent provided in the attached form. Certificate holder is listed as primary and non-contributory basis effective 02/26/2026 to the General Liability policy. Certificate holder is an additional insured to the Auto policy via endorsement CERTIFICATE HOLDER CANCELLATION I THE CITY OF MIAMI 444 SW 2ND AVE Miami FL 33130 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE a/ i, c ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD ADDITIONAL COVERAGES Ref # Description Medical payments Coverage Code MEDPM Form No. Edition Date Limit 1 1,000 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref # Description PIP -Basic Coverage Code PIP Form No. Edition Date Limit 1 10,000 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref # Description DEATH BENEFITS Coverage Code DTBEN Form No. Edition Date Limit 1 5,000 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref # Description Uninsured motorist combined single limit Coverage Code UMCSL Form No. Edition Date Limit 1 1,000,000 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref # Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref # Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref # Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref # Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref # Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref # Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref # Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium OFADTLCV Copyright 2001, AMS Services, Inc. POLICY NUMBER: 00-1275-976 FAITHGUARD GENERAL LIABILITY ENDORSEMENT THIS DOCUMENT IS AN ENDORSEMENT THAT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE FORM A. Incidental Medical Malpractice The following is added to 1. Insuring Agreement of Section I - Coverage A - Bodily Injury And Property Damage Liability: Damages because of "bodily injury" include incidental medical malpractice damages sustained because of the administration of or failure to administer first aid including the use of automated external defibrillators. B. Expected Or Intended Injury - Property Damage Exception The following is added to Exclusion a. Expected Or Intended Injury of Paragraph 2. Exclusions under Section I - Coverage A - Bodily Injury And Property Damage Liability: This exclusion does not apply to "property damage" resulting from the use of reasonable force to protect persons or property. C. Aircraft, Auto Or Watercraft Exclusion g. Aircraft, Auto Or Watercraft of Paragraph 2. Exclusions under Section I - Coverage A - Bodily Injury And Property Damage Liability is amended as follows: 1. Transportation Of Students Exclusion With respect to the transportation of students, the first paragraph of Exclusion g. is replaced by the following: "Bodily injury" or "property damage" arising out of the ownership, maintenance, use or entrustment to others of any aircraft, "auto" or watercraft owned or operated by or rented or loaned to or hired by any insured. Use includes operation and "loading or unloading". Hired includes any contract to furnish transportation of students to and from school. 2. Non -Owned Watercraft Exception Paragraph (2) of Exclusion g. is replaced by the following: (2) A watercraft you do not own that is: (a) Any length; and (b) Not being used to carry persons or property for a charge; 3. Detached Owned Trailers Exception This exclusion does not apply to any "auto" you own that is: a. A trailer with a load capacity of 2,000 pounds or less that is designed primarily for travel on public roads; and Includes copyrighted material of Insurance Services Office, Inc., with its permission. GCG 25 10 07 14 Copyright 2014 GuideOne Insurance Page 1 of 9 b. Not attached to any other "auto" or "mobile equipment"; when such trailer is not provided Liability Coverage by any other Coverage Part or insurance policy. D. Extended Property Damage In Section 1 - Coverages, Section III - Limits Of Insurance, Section IV - Conditions and the definition of "insured contract" in the Definitions section; except where it is used in the term "hostile fire", the word fire is changed to: fire, explosion, smoke or leaks from automatic fire protective systems. E. Incidental Publishing, Broadcasting Or Telecasting Exception The following is added to Exclusion j. Insureds In Media And Internet Type Businesses of Paragraph 2. Exclusions under Section 1 - Coverage B - Personal And Advertising Injury Liability: This exclusion does not apply to publishing, broadcasting or telecasting that is incidental to your business. F. Athletic Activities - Excess Medical Payments The following is added to 1. Insuring Agreement of Section 1- Coverage C - Medical Payments: When "bodily injury" is caused by an accident that results from practicing, instructing or participating in any physical exercises or games, sports or athletic contests, whether on a formal or informal basis, we will pay medical expenses on an excess payment basis. This insurance is therefore excess over any other primary insurance available that would also be covered under Coverage C - Medical Payments. However, this provision does not apply to the extent Coverage C - Medical Payments has been excluded from coverage by the attachment of a separate endorsement to the Commercial General Liability Coverage Part. G. Additional Payment For Loss Of Life The following is added to 1. Insuring Agreement of Section 1- Coverage C - Medical Payments: When a covered "bodily injury" to a claimant results in loss of life within one year from the date of the accident, at your option, we will pay up to $10,000 per each deceased person. We will pay this amount in addition to any payments under Paragraphs a., b. and c. of this Insuring Agreement. Our obligation for payment shall be to: 1. The parent or guardian if the deceased was a minor; 2. The surviving spouse, if any; or 3. A person authorized by law, or legally entitled, to receive such payment. However, this provision does not apply to the extent Coverage C - Medical Payments has been excluded from coverage by the attachment of a separate endorsement to the Commercial General Liability Coverage Part. H. Amended Exclusions Under Coverage C - Medical Payments Paragraph 2. Exclusions of Section 1 - Coverage C - Medical Payments is amended as follows: 1. Exclusion a. Any Insured is replaced by the following: To any insured, except "volunteer workers" and any persons designated as an insured under Paragraph L. Who Is An Insured - Broadened of this endorsement. Includes copyrighted material of Insurance Services Office, Inc., with its permission. GCG 25 10 07 14 Copyright 2014 GuideOne Insurance Page 2 of 9 2. Exclusion c. Injury On Normally Occupied Premises is replaced by the following: To a person injured on that part of premises you own or rent that the person normally occupies. However, this exclusion does not apply to a person injured while engaged in a church sponsored activity authorized by you. 3. Exclusion e. Athletics Activities is deleted in its entirety. However, Paragraphs 1., 2. and 3. immediately above do not apply to the extent Coverage C - Medical Payments has been excluded from coverage by the attachment of a separate endorsement to the Commercial General Liability Coverage Part. I. Additional Exclusions The following exclusions are added to Paragraph 2. Exclusions under Coverage A - Bodily Injury And Property Damage Liability, Paragraph 2. Exclusions under Coverage B - Personal And Advertising Injury Liability and Paragraph 2. Exclusions under Coverage C - Medical Payments of Section I - Coverages: This insurance does not apply to: 1. Counseling Activities Any "bodily injury", "property damage", "personal and advertising injury" or mental or emotional pain or anguish, sustained by any person arising out of, or resulting from: a. Counseling or guidance of a person in exchange for a payment or fee; b. Professional activities conducted by a psychiatrist or psychologist; or c. Professional activities conducted by a licensed mental health care practitioner or licensed counseling practitioner. However, if your "minister" is a licensed mental health care practitioner or licensed counseling practitioner, this exclusion does not apply to such professional activities that attend to the spiritual needs of a person if conducted for you or on your behalf. 2. Misconduct, Molestation Or Harassment Any "bodily injury", "personal and advertising injury", mental or emotional pain or anguish, or any defamation or slander, sustained by any person arising out of or resulting from any actual or alleged act of "sexual misconduct or sexual molestation" or "sexual harassment" of any kind. We have no right or duty to investigate, settle, defend or pay any claim or "suit" asserting any act of "sexual misconduct or sexual molestation", "sexual harassment" or any breach of duty contributing to or arising from such act. 3. Health Services If any college or school is operated by you or on your behalf, and that college or school owns or operates an infirmary with facilities for lodging and treatment or a public clinic or hospital, this insurance does not apply to "bodily injury', "property damage" or "personal and advertising injury" caused by: a. The rendering or failure to render: (1) Medical, surgical, dental, X-ray or nursing service, treatment, advice or instruction, or the related furnishing of food or beverages; (2) Any health or therapeutic service, treatment, advice or instruction; or (3) Any service, treatment, advice or instruction for the purpose of appearance or skin enhancement, hair removal or replacement or personal grooming. Includes copyrighted material of Insurance Services Office, Inc., with its permission. GCG 25 10 07 14 Copyright 2014 GuideOne Insurance Page 3 of 9 b. The furnishing or dispensing of drugs or medical, dental or surgical supplies or appliances; or c. The handling or treatment of dead bodies, including autopsies, organ donation or other procedures. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence" which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved that which is described in Paragraph a., b. or c. However, this exclusion does not apply to your school nurse (other than a nurse practitioner) or a student nurse, while acting within the scope of his or her duties as directed by you. 4. Corporal Punishment "Bodily injury", "property damage" or "personal and advertising injury" to any student arising out of any corporal punishment administered by or at the direction of any insured. However, this exclusion does not apply to the extent coverage for corporal punishment has been added by the attachment of a separate endorsement to the Commercial General Liability Coverage Part. J. Supplementary Payments - Broadened Paragraph 1. of Section 1 - Coverages - Supplementary Payments - Coverages A and B is amended as follows: 1. Cost Of Bail Bonds The maximum amount we will pay for the cost of bail bonds as described in Subparagraph b. is increased to $1,000. 2. Expenses Incurred By The Insured The maximum amount we will pay for loss of earnings incurred by the insured at our request to assist us in the investigation or defense of a claim or "suit", as described in Subparagraph d., is increased to $500 a day. 3. The following is added: Damage To Personal Property Of Others With respect to any claim we investigate or settle, or any "suit' against an insured we defend, we will also pay up to $1,000 for "property damage" to personal property of others while in the temporary care, custody or control of an insured and caused by any person participating in your organized activities. For purposes of this supplementary payment, "property damage" does not include disappearance, wrongful abstraction or loss of use. This supplementary payment shall only be paid on or for the account of the owner and only when other coverage or insurance is unavailable. This payment will not reduce the limits of insurance. K. Product Recall Expenses As an additional supplementary payment, we will reimburse you for "product recall expenses" that you incur because of a "product recall" of "your product'. The most we will pay for all "product recall expenses" initiated during the policy period is $25,000. The policy period under which "product recall expenses" will be paid shall be determined by the policy that is in effect when the "product recall" was first initiated. Includes copyrighted material of Insurance Services Office, Inc., with its permission. GCG 25 10 07 14 Copyright 2014 GuideOne Insurance Page 4 of 9 A complete accounting of "product recall expenses" must be provided upon our request, including receipts for all expenses that you incur. We will reimburse "product recall expenses" only if the expenses are incurred and reported to us within one year of the date the "product recall" was initiated. Our obligation under this additional supplementary payment shall only apply if the "product recall expenses" are initiated in the "coverage territory" during the policy period because: 1. You determine that the "product recall" is necessary; or 2. An authorized government entity has ordered you to conduct a "product recall". However, this additional supplementary payment does not apply to "product recall expenses" arising out of the product expiration or shelf life, a defect known by you prior to the time "your product" leaves your control or possession, or the defense of a claim or "suit" against you for liability arising out of a "product recall". This payment will not reduce the limits of insurance. L. Who Is An Insured - Broadened Each of the following is added as an insured to Section II - Who Is An Insured: 1. Your Minister, Leaders And Members a. Your "minister" but only with respect to his or her duties as such for you. b. Any of your trustees or officials; members of your boards, committees, councils, deaconry or vestry; your religious education coordinator and any religious education teachers; but only with respect to their duties as such. c. Any of your religious organization's members, but only with respect to their liability for your activities or activities they perform on your behalf, at your direction and within the scope of their duties. 2. Student Teachers Any student teacher teaching as part of their educational requirements, but only with respect to their duties as such. 3. Hierarchical Governing Bodies All hierarchical governing bodies concerned with the adoption and enforcement of needful laws and regulations, doctrine and worship for the established denomination of which you are a member, but only with respect to liability arising out of the ownership, maintenance and use of the property by you at the locations designated in the Commercial General Liability Coverage Part Declarations and operations necessary and incidental thereto. However, any coverage we provide will be strictly on an excess basis over any other insurance for any such hierarchical governing body described in this paragraph. 4. Other Authorized Organizations Any church organization authorized and controlled by you. M. Additional Insureds Required By Written Contract 1. Section II - Who Is An Insured is amended to include as an additional insured the following person(s) or organization(s) when you have agreed, in a written contract, that such person or organization be added as an additional insured on your policy, provided the written contract is initiated prior to an "occurrence" resulting in damages. Includes copyrighted material of Insurance Services Office, Inc., with its permission. GCG 25 10 07 14 Copyright 2014 GuideOne Insurance Page 5 of 9 a. Owners Of Leased Land Any person or organization from whom you lease land but only with respect to liability arising out of the ownership, maintenance or use of that part of the land leased to you. With respect to the insurance afforded to these additional insureds, this insurance does not apply to: (1) Any "occurrence" which takes place after you cease to lease that land; or (2) Structural alterations, new construction or demolition operations performed by or on behalf of the additional insured. b. State Or Governmental Agency Or Subdivision Or Political Subdivision - Permits Or Authorizations Any state or governmental agency or subdivision or political subdivision, but only with respect to operations performed by you or on your behalf for which the state or governmental agency or subdivision or political subdivision has issued a permit or authorization. With respect to the insurance afforded these additional insureds, this insurance does not apply to: (1) "Bodily injury', "property damage" or "personal and advertising injury" arising out of operations performed for the federal government, state or municipality; or (2) "Bodily Injury' or "property damage" included within the "products -completed operations hazard". c. Mortgagee, Assignee Or Receiver Any person or organization but only with respect to their liability as mortgagee, assignee or receiver and arising out of the ownership, maintenance or use of the premises by you. The insurance does not apply to structural alterations, new construction and demolition operations performed by or for that person or organization. d. Co -Owner Of Insured Premises Any person or organization but only with respect to their liability as co-owner of the premises. However, i. A person or organization is an additional insured under this provision only for that period of time required by the written contract; ii. No such person or organization is an insured under this provision if such person or organization is included as an insured by an endorsement issued by us and attached to the Commercial General Liability Coverage Form; iii. The insurance afforded to such additional insured only applies to the extent permitted by law; and iv. The insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. 2. With respect to the insurance afforded to these additional insureds, identified in Paragraph M.1. of this endorsement, the following is added to Section III - Limits Of Insurance: The most we will pay on behalf of the additional insured is the amount of insurance: Includes copyrighted material of Insurance Services Office, Inc., with its permission. GCG 25 10 07 14 Copyright 2014 GuideOne Insurance Page 6 of 9 a. Required by the contract or agreement; or b. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This provision shall not increase the applicable Limits of Insurance shown in the Declarations. N. Professional Health Care Services Providers 1. With respect to "employees" or "volunteer workers" who are providing professional health care services, Paragraph 2.a.(1)(d) of Section II - Who Is An Insured is deleted. 2. The following is added to Section II - Who Is An Insured: No professional health care services provider is an insured with respect to his or her providing or failure to provide professional health care services, except for your school nurse (other than a nurse practitioner) and a student nurse while acting within the scope of his or her duties as directed by you. However, this provision does not apply to any person included as an insured for professional health care services by attachment of a separate endorsement that modifies the Commercial General Liability Coverage Form. O. Newly Acquired Or Formed Organizations 1. The following is added to Paragraph 3. of Section II - Who Is An Insured: Coverage provided to a newly acquired or formed organization under this provision is afforded only when the newly acquired or formed organization operates or conducts the same or similar business as you. 2. Paragraph 3.a. of Section II - Who Is An Insured is replaced by the following: Coverage under this provision is afforded only until the 365th day after you acquire or form the organization or the end of the policy period, whichever is earlier; P. Limits Of Insurance Paragraph 1. under Section III - Limits Of Insurance is replaced by the following: The Limits of Insurance shown in the Declarations and the rules below fix the most we will pay regardless of the number of: 1. Insureds; 2. Claims made or "suits" brought; 3. Persons or organizations making claims or bringing "suits"; or 4. Policies involved. Q. Non -Stacking Of Limits The following is added to Section III - Limits Of Insurance: If two or more policies or Coverages issued by us apply to the same insured and these policies or Coverages also apply to the same claim or "suit", the maximum amount we will pay as damages under all of the policies or Coverages will not exceed the highest applicable Limit of Insurance that applies to any one of the policies or Coverages. Includes copyrighted material of Insurance Services Office, Inc., with its permission. GCG 2510 07 14 Copyright 2014 GuideOne Insurance Page 7 of 9 This condition does not apply to any insurance that was purchased specifically to apply in excess of the applicable Limits of Insurance shown in the Declarations. R. Counseling Services The following is added to the list of offenses included within the definition of "personal and advertising injury" in the Definitions section: Wrongful acts, errors or omissions resulting from counseling services: 1. That attend to the spiritual needs of a person, and are performed by: a. A "minister" employed by you, but only for counseling services that are within the scope of his or her duties for you; b. Your "employee" or "volunteer worker", but only if acting under the direction and control of your employed "minister" and within the scope of his or her duties as your "employee" or "volunteer worker"; or c. A person in training to become a licensed or non -licensed counselor, but only if acting: (1) Under the direction and control of your employed "minister" or your principal (if you operate a school); and (2) Within the scope of his or her duties as a counselor in training. 2. That are performed by a school counselor employed by you, if you operate a college or school, but only while acting within the scope of his or her duties as your "employee" and while providing to your students counseling or academic guidance, other than the creation, implementation and maintenance of an educational program. However, "personal and advertising injury" does not include any injury arising from "sexual misconduct or sexual molestation", "sexual harassment", or counseling services that provide advice or assistance regarding charitable contributions, finance, insurance, investment, law, real estate or tax. S. Additional Definitions The following is added to the Definitions section: 1. "Minister" means a person: a. Employed by; b. Duly assigned to; or c. Duly appointed by you to attend to the spiritual needs of the congregation. 2. "Product recall" means the recall or withdrawal of "your product" from the market or from use by any other person or organization because of a known or suspected defect in "your product" which has caused or is reasonably expected to cause "bodily injury" or physical injury to tangible property other than "your product". 3. "Product recall expenses" mean those reasonable and necessary expenses paid and directly related to a "product recall". 4. "Sexual harassment" means unwelcome sexual advances, requests for sexual favors, or other verbal, visual or physical conduct of a sexual nature when such conduct: Includes copyrighted material of Insurance Services Office, Inc., with its permission. GCG 25 10 07 14 Copyright 2014 GuideOne Insurance Page 8 of 9 a. Is linked implicitly or explicitly with a decision affecting a term or condition of any individual's employment; b. Interferes with any individual's job performance; c. Creates an intimidating, hostile or offensive working environment for any individual; or d. Arises out of or is related to an unlawful employment practice as codified at 42 U.S.C. § 20OOe et seq., or any similar state, municipal or local code, regulation or ordinance. 5. "Sexual misconduct or sexual molestation" means any activity which is sexual in nature (whether permitted or not permitted); and includes, but is not limited to: sexual assault, sexual battery, sexual relations, sexual acts, sexual activity, sexual handling, sexual massage, sexual exploitation, sexual exhibition, sexual stimulation, fondling, intimacy, exposure of sexual organs, lewd or lascivious behavior or indecent exposure, fornication, unauthorized touching, or the photographic, video or other reproduction of sexual activity. However, "sexual misconduct or sexual molestation" does not include employment -related "sexual harassment". Includes copyrighted material of Insurance Services Office, Inc., with its permission. GCG 25 10 07 14 Copyright 2014 GuideOne Insurance Page 9 of 9 / A� o® CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) 02/25/2026 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Roe Insurance Inc. 9851 State Road 54 New Port Richey FL 34655 CONTACT Gertrude Rosencrans NAME: PHONE (727) 376-0030 FAX (727) 376-2262 (A/C, No, Ext): (A/C, No): E-MAIL trudy@roeins.com ADDRESS: y@ INSURER(S)AFFORDING COVERAGE NAIC # INSURERA: James River Insurance INSURED Neiel Group, LLC 4314 Blonigen Ave Orlando FL 32812 INSURER B : Evanston Insurance Company INSURER C: American Builders Insurance Company 11240 INSURER D : INSURER E : INSURER F : COVERAGES CERTIFICATE NUMBER: MASTER CERT 26-27 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL INSD SUBR WVD POLICY NUMBER POLICY EFF (MM/DD/YYYY) POLICY EXP (MM/DD/YYYY) LIMITS A X COMMERCIAL GENERAL LIABILITY 001291983 03/26/2026 03/26/2027 EACH OCCURRENCEDAMAGE $ 1000000 CLAIMS -MADE X OCCUR TO RETED PREMISES (Ea occurrence) $ 100,000 MED EXP (Any one person) $ 5,000 PERSONAL &ADV INJURY $ 1'000,000 GEN'L X AGGREGATE POLICY OTHER: LIMIT APPLIES JECT PRO-LOC PER: GENERAL AGGREGATE $ 2,000,000 PRODUCTS -COMP/OPAGG $ 2'000,000 Employee Benefits $ 0 AUTOMOBILE _ LIABILITY ANY AUTO OWNED AUTOS ONLY HIRED AUTOS ONLY SCHEDULED AUTOS NON -OWNED AUTOS ONLY COMBINED SINGLE LIMIT (Ea accident) $ BODILY INJURY (Per person) $ BODILY INJURY (Per accident) $ PROPERTY DAMAGE (Per accident) $ $ B X UMBRELLA LIAB EXCESS LIAB X OCCUR CLAIMS -MADE EZXS3194884 03/26/2026 03/26/2027 EACH OCCURRENCE $ 5000000 AGGREGATE $ 5,000,000 DED X RETENTION $ 10,000 $ C WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below Y/N N N /A WCV023690309 03/15/2026 03/15/2027 X PER STATUTE OTH ER E.L. EACH ACCIDENT 1,000,000 $ E.L. DISEASE - EA EMPLOYEE $ 1'000,000 E.L. DISEASE - POLICY LIMIT 10, 00000 $ , DESCRIPTION OF OPERATIONS / LOCATIONS /VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) Workers Compensation applies to Florida operations only. CITY OF MIAMI IS INCLUDED AS ADDITIONAL INSURED AS REQUIRED BY WRITTEN CONTRACT ON PRIMARY AND NON-CONTRIBUTORY BASIS. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN CITY OF MIAMI ACCORDANCE WITH THE POLICY PROVISIONS. 444 SW 2ND AVE AUTHORIZED REPRESENTATIVE ,^,� Miami FL 33130 {5� I ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD AC -ORE) CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DDIYYYY) 02/09/2026 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER StateFarm Henry Wahl 417 S Summerlin Avenue CONTACT Henryahl NAME: ry PH NQ Extl: 407-895-5285 FAX No): E-M oFSS. henry.wahl.bxik@statefarm.com OO o Orlando FL 328013011 INSURER(S) AFFORDING COVERAGE NAIC # INSURER A: State Farm Mutual Automobile Insurance Company 25178 INSURED NEIEL GROUP LLC 4314 BLONIGEN AVE ORLANDO FL 328128002 INSURER B: INSURER C: INSURERD: INSURER E : INSURERF: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. 'NSR LTR TYPE OF INSURANCE AUL]'SUB INSD WVD POLICY NUMBER -FUMY EFF (MM/DD/YYYY) l'ULR:Y EXP (MM/DD/YYYY) LIMITS COMMERCIAL GENERAL LIABILITY OCCUR EACH OCCURRENCE $ CLAIMS -MADE DAMAGE TO RENTED PREMISES,(Ea occurrence) MED EXP (Any one person) $ $ GEN'L PERSONAL & ADV INJURY $ AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ PRO- POLICY JECT LOC PRODUCTS - COMP/OP AGG $ OTHER: $ A AUTOMOBILE LIABILITY ANY AUTO SCHEDULED AUTOS NON -OWNED AUTOS ONLY Y Y J68 5175-D21-59K 10/21/2025 04/21/2026 COMBINED SINGLE LIMIT (Ea accident) $ BODILY INJURY (Per person) $ 1,000,000 OWNED AUTOS ONLY HIRED AUTOS ONLY v /\ X BODILY INJURY (Per accident) $ 1,000,000 r-TMU<' TY1JAMAUE (Per accident) $ 1,000,000 $ UMBRELLA LIAB EXCESS LIAB OCCUR CLAIMS -MADE EACH OCCURRENCE $ AGGREGATE $ DED I I RETENTION $ $ WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE /M OFFICER/MEMBER EXCLUDED? (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS Y / N N / A PER H STATUTE ER $ E.L. EACH ACCIDENT E.L. DISEASE - EA EMPLOYEE $ $ below E.L. DISEASE - POLICY LIMIT $ DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) CITY OF MIAMI IS INCLUDED AS ADDITIONAL INSURED AS REQUIRED BY WRITTEN CONTRACT ON PRIMARY AND NON-CONTRIBUTORY BASIS. CONTIGENT & CONTRACTUAL LIABILITY INCLUDED AS PER POLICY FORMS. PREMISES AND OPERATIONS LIABILITY INCLUDED AS PER POLICY FORMS, EXPLOSION, COLLAPSE AND UNDERGROUND HAZARD INCLUDED AS PER POLICY FORMS. PRIMARY INSURANCE CLAUSE ENDORSEMENT INCLUDED PER POLICY TERMS. COMPLETED OPERATIONS EXTENDED FOR (3) YEARS AFTER PROJECT COMPLETION AS LONG AS THIS POLICY IS RENEWED FOR (3) YEARS. (30) DAYS NOTICE OF CANCELLATION EXCEPT FOR (10) DAYS FOR NON-PAYMENT. CERTIFICATE HOLDER CANCELLATION CITY OF MIAMI 444 SW 2ND AVE 4TH FLOOR MIAMI FL 33130 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE This form was system -generated on 02/09/2026 ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD 1001486 2005 155279 205 01-19-2023 *ALLV Document A312TM Performance Bond CONTRACTOR: (Name, legal status and address) Neiel Group, LLC 4314 Blonigen Ave. Orlando, FL 32812 2010 Bond No. 18L006673 SURETY: (Name, legal status and principal place of business) The Ohio Casualty Insurance Company 62 Maple Avenue Keene, NH 03431 OWNER: (Name, legal status and address) Macedonia Missionary Baptist Church of Miami, Inc. 3515 Douglas Road Miami, FL 33133 CONSTRUCTION CONTRACT Date: August 21, 2023 Amount: $397,118.00 Description: Interior Renovation Scope of Work for Macedonia Missionary Baptist (Name and location) Church of Miami, 3515 Douglas Road, Miami, FL 33133 BOND Date: June 26, 2025 (Not earlier than Construction Contract Date) Amount: $397,118.00 Modifications to this Bond: 0 None 0 See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Neiel Group, LLC _ The Ohio Casualty Insurance Company Signature: Name and Title: Signature: Name Od and Title: Attornea/-In-Fact (Any additional signatures appear on the last page of this Performance Bond.) (FOR INFORMATION ONLY— Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: (Architect, Engineer or other parry.) Security Bondex Associates, LLC 10131 SW 40th Street Miami, FL 33165 (305)552-5414 This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. AIA Document A312-2010 combines two separate bonds, a Performance Bond and a Payment Bond, into one form. This is not a single combined Performance and Payment Bond. Init. AIA Document A312TM — 2010. The American Institute of Architects. 061110 1 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. Init. AIA Document A312TM - 2010. The American Institute of Architects. § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. Init. AIA Document A312TM — 2010. The American Institute of Architects. § 16 Modifications to this bond are as follows: ** See Additional Obligee Rider Attached *** (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Hen ,' am . an/ ' rincipal Name and Title: Address 4314 Blonigen Ave, Orlando FL 32812 Address CAUTION: You should sign an original AIA Contract Document, on which this text appears in RED. An original assures that changes will not be obscured. Init. AIA Document A3I2TM - 2010. The American Institute of Architects. Security Bondex Associates, LLC 10131 SW 40th Street Miami, FL 33165 (305)552-5414 Document A312 TM - 2010 Payment Bond CONTRACTOR: (Name, legal status and address) Neiel Group, LLC 4314 Blonigen Ave. Orlando, FL 32812 Bond No. 18L006673 SURETY: (Name, legal status and principal place of business) The Ohio Casualty Insurance Company 62 Maple Avenue Keene, NH 03431 OWNER: (Name, legal status and address) Macedonia Missionary Baptist Church of Miami, Inc. 3515 Douglas Road Miami, FL 33133 CONSTRUCTION CONTRACT Date: August 21, 2023 Amount: $397,118.00 Description: Interior Renovation Scope of Work for Macedonia Missionary Baptist (Name and location) Church of Miami, 3515 Douglas Road, Miami, FL 33133 BOND Date: June 26, 2025 (Not earlier than Construction Contract Date) Amount: $397,118.00 Modifications to this Bond: 0 None 0 See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: Neiel Group, LLC The Ohio Casualty Insurar}ce,Coynpany Signature: " �/ Signature: Name Name O` al i b ra and Title: and Title: Attorney- Fact (Any additional signatures appear on the last page of this Payment Bond.) (Corporate Seal) (FOR INFORMATION ONLY— Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: (Architect, Engineer or other party.) This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. AIA Document A312-2010 combines two separate bonds, a Performance Bond and a Payment Bond, into one form. This is not a single combined Performance and Payment Bond. Init. AIA Document A312TM — 2010. The American Institute of Architects. 061110 5 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following teens. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. Init. AIA Document A312TM - 2010. The American Institute of Architects. § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Clain; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. Init. AIA Document A312TM — 2010. The American Institute of Architects. § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: ** See Additional Obligee Rider Attached *** (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: �/ /% Signature: Name and Title: Henry amaan/ rincipal Name and Title: Address 4314 Blonigen Ave, Orlando FL 32812 Address CAUTION: You should sign an original AIA Contract Document, on which this text appears in RED. An original assures that changes will not be obscured. Init. AIA Document A312TM — 2010. The American Institute of Architects. 8 Liberty Mutual SURETY RIDER ADDING ADDITIONAL OBLIGEE This rider is to be attached to and form a part of Performance and Payment bonds No. 18L006673 dated June 26, 2025 executed by The Ohio Casualty Insurance Company , a New Hampshire insurance company, as surety (the "Surety"), on behalf of Neiel Group, LLC , as principal (the "Principal"), in favor of Macedonia Missionary Baptist Church of Miami, Inc. , as obligee (the "Primary Obligee"). WHEREAS, the Principal has by written agreement dated the August 21, 2023 , entered into a contract (the "Contract") with the Primary Obligee for: Interior Renovation Scope of Work for Macedonia Missionary Baptist Church of Miami, 3515 Douglas Road, Miami, FL 33133 WHEREAS, the Primary Obligee has requested that the Principal and the Surety execute and deliver to the Primary Obligee the Bond in connection with the Contract. WHEREAS, the Primary Obligee has requested that the Principal and the Surety execute and deliver to the Primary Obligee this Rider to add additional obligee(s) (the Additional Obligee(s)) under the Bond. NOW THEREFORE, the undersigned hereby agree and stipulate that The City of Miami shall be added to the Bond as Additional Obligee(s), subject to the conditions set forth below: 1. The Surety shall not be liable under the Bonds to the Primary Obligee and/or the Additional Obligee(s) unless the Primary Obligee and/or the Additional Obligee(s) shall make payments to the Principal strictly in accordance with the terms of the Contract, and shall perform all other obligations to be performed under said Contract in accordance with the Contract terms. 2. The aggregate liability of the Surety hereunder to the Primary Obligee and/or the Additional Obligee(s) shall be limited to the penal sum of the Bonds and Surety upon making payment hereunder shall be subrogated to and entitled to an assignment of all rights of the payee with respect to the particular obligation discharged by the payment, either against the Principal or any other party liable to the payee on the discharged obligation. 3. The Additional Obligee(s) rights hereunder are subject to the same defenses Principal and/or Surety have against the Primary Obligee, and the total liability of the Surety shall in no event exceed the amount recoverable from the Principal by the Primary Obligee under the Contract. At the Surety's election, any payment due under the Bond may be made by joint check payable to the Primary and/or any Additional Obligee(s). This Rider is effective June 26, 2025 IN WITNESS WHEREOF, said Principal and the Surety have caused these presents to be duly signed this26th day of June , 2025 Neiel Group, LLC (Principal) The Ohio Casualty Insurance Company (Surety) LMS-21319e 12/19 By: `f%r Title: iSrincipal Date: 06/26/2025 By: Title:Odalis C br ra, Attorney -In -Fact Date:June 26, 025 Liberty Mutual. SURETY This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated, Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the "Companies"), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, Marina M. Remit; Odalis Cabrera Certificate No: 8211219-969495 Bond No. 18L006673 all of the city of Miami state of FL each Individually if there be more than one named, Its true and lawful attorney -in -fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies In their own proper persons. IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 17th day of January , 2024 . By: State of PENNSYLVANIA County of MONTGOMERY ss On this 17th day of January , 2024 before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance Company, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at Plymouth Meeting, Pennsylvania, on the day and year first above written, Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company Commonwealth of Pennsylvania - Notary Seal Teresa Pestella, Notary Public Montgomery County My commission expires March 28, 2026 Commission number 1128044 Member, Pennsylvania Association of Notaries By: David M, Carey, Assistant Secretary erde Pelalla. Notary Public erese Pastella, Public This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows: ARTICLE IV — OFFICERS: Section 12, Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the President may prescribe, shall appoint such attorneys -In -fact, as may be necessary to act In behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact, subject to the limitations set forth In their respective powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such Instruments and to attach thereto the seal of the Corporation. When so executed, such instruments shall be as binding as If signed by the President and attested to by the Secretary, Any power or authority granted to any representative or attorney -in -fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority. ARTICLE XIII — Execution of Contracts: Section 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shall appoint such attorneys -in -fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -In -fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such Instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation — The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such attorneys -in - fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Authorization — By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any power of attorney Issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed, 1, Renee C. Llewellyn, the undersigned, Assistant Secretary, The Ohlo Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF, I have hereunto set my hand sod affixed the seals of said Companies this 26th day of June , 2025 . Renee C. Llewellyn, Assistant Secretary LMS-12873 LMIC OCIC WAIC Multi Co 02/21 Olivera, Rosemary From: Brito, Gabriel Sent: Friday, April 3, 2026 12:01 PM To: Hannon, Todd; Olivera, Rosemary; Ewan, Nicole Subject: MFE Grant Amendment #1 — Macedonia Missionary Baptist Church of Miami, Inc. Attachments: Docusign_Miami_For_Everyone_Gra nt_Amendment_A#1.pdf RE: MFE Grant Amendment #1 — Macedonia Missionary Baptist Church of Miami, Inc. Hello All, Please find attached a fully executed copy of the above referenced First Grant Amendment from Docusign that is to be considered an original for your records. Thank you for your prompt attention to this matter. 4( ) - # Ik. ( — ) II GabrielJ. Brito CIP Budget Coordinator Office of Management & Budget 444 SW 2 Avenue, 5th Floor Miami, Florida 33130 Phone: 305.416.1203 Gbrito@miamigov.com i