Loading...
HomeMy WebLinkAbout12-00824 07-30-2012 Legislation with attachmentCity of Miami Legislation CRA Resolution City Hall 3500 Pan American Drive Miami, FL 33133 www.miamigov.com File Number: 12-00824 Final Action Date: A RESOLUTION OF THE BOARD OF COMMISSIONERS OF THE SOUTHEAST OVERTOWN/PARK WEST COMMUNITY REDEVELOPMENT AGENCY (THE "CRA") AUTHORIZING THE EXECUTIVE DIRECTOR TO EXECUTE A SETTLEMENT AGREEMENT, IN SUBSTANTIALLY THE FORM ATTACHED, WITH MIAMI-DADE COUNTY (THE "COUNTY") AND THE CITY OF MIAMI (THE "CITY") TO RESOLVE THE DISPUTE BETWEEN THE CRA, THE CITY AND THE COUNTY REGARDING OWNERSHIP OF BLOCK 45 AND BLOCK 56, NORTH CITY OF MIAMI, ACCORDING TO THE PLAT THEREOF RECORDED IN PLAT BOOK "B', AT PAGE 41 OF THE PUBLIC RECORDS OF MIAMI-DADE COUNTY, FLORIDA AND PORTIONS OF BLOCK 36 OF P.W. WHITES RE -SUB, ACCORDING TO THE PLAT THEREOF, RECORDED IN PLAT BOOK "B" AT PAGE 34 OF THE PUBLIC RECORDS OF MIAMI-DADE COUNTY, FLORIDA, WHICH THE COUNTY CLAIMS REVERTED TO THE COUNTY; AUTHORIZING THE EXECUTIVE DIRECTOR TO EXECUTE AND AMEND ALL DOCUMENTS NECESSARY FOR SAID PURPOSE, IN FORM ACCEPTABLE TO THE SPECIAL COUNSEL. WHEREAS, the Southeast Overtown/Park West Community Redevelopment Agency ("CRA") is responsible for carrying out community redevelopment activities and projects within its Redevelopment Area in accordance with its approved Redevelopment Plan; and WHEREAS, a dispute with Miami -Dade County, Florida (the "County") and the City of Miami (the "City") regarding ownership of Block 45 and Block 56, NORTH CITY OF MIAMI, according to the Plat thereof, recorded in Plat Book "B", at Page 41 of the Public Records of Miami -Dade County, Florida and portions of Block 36 of P.W. Whites Re -Sub, according to the Plat thereof, recorded in Plat Book "B", at Page 34 of the Public Records of Miami -Dade County, Florida, which the County claims reverted to the County; and has prevented the CRA from proceeding with redevelopment activities with respect to the property affected by the following lawsuits (the "Pending Litigation"): (i) Action styled City of Miami, et al., vs. Miami -Dade County, Case No. 07-46851 CA 31, filed in the 11th Judicial Circuit in and for Miami -Dade County, Florida. (ii) Action styled Miami -Dade County, Plaintiff, vs. City of Miami and Southeast Overtown/Park West Community Redevelopment Agency, Defendants, Case No. 01- 13810, filed in the 11th Judicial Circuit in and for Miami -Dade County, Florida. WHEREAS, it is in the best interest of the CRA to resolve the Pending Litigation in accordance with the terms of the Settlement Agreement in substantially the attached form (the "Settlement Agreement") with the City and the County; and WHEREAS, the Board of Commissioners wish to authorize the Executive Director to execute the Settlement Agreement in substantially the form attached and further authorizing the Executive Director to execute all documents necessary to implement the Settlement Agreement in substantially City of Miami Page 1 of 2 File Id: 12-00824 (Version: 1) Printed On: 7/20/2012 File Number: 12-00824 the form attached to the Settlement Agreement and any amendments thereto that the Executive Director deems appropriate to implement the Settlement Agreement in form acceptable to the Special Counsel. NOW, THEREFORE, BE IT RESOLVED BY THE BOARD OF COMMISSIONERS OF THE SOUTHEAST OVERTOWN/PARK WEST COMMUNITY REDEVELOPMENT AGENCY: Section 1. The recitals and findings contained in the Preamble to this Resolution are adopted by reference and incorporated herein as if fully set forth in this Section. Section 2. The Executive Director is hereby authorized to execute the Settlement Agreement in substantially the form attached and further authorized to execute all documents necessary to implement the Settlement Agreement in substantially the form attached to the Settlement Agreement and any amendments thereto that the Executive Director deems appropriate to implement the Settlement Agreement in form acceptable to the Special Counsel. Section 3. This resolution shall become effective immediately upon its adoption. APPROVED AS TO FORM AND CORRECTNESS: William R. Bloom SPECIAL COUNSEL City of Miami Page 2 of 2 File Id: 12-00824 (Version: 1) Printed On: 7/20/2012 IN THE CIRCUIT COURT OF THE 11TH JUDICIAL CIRCUIT IN AND FOR MIAMI- DADE COUNTY, FLORIDA GENERAL JURISDICTION DIVISION CASE NO. 07-46851 CA 31 CITY OF MIAMI, et al., Plaintiffs, vs. MIAMI-DADE COUNTY, Defendant. SETTLEMENT AGREEMENT Plaintiffs, City of Miami (the "City") and the Southeast Overtown/Park West Community Redevelopment Agency (the "CRA"), and Defendant, Miami -Dade County (the "County"; together with the CRA and the City, the "Parties"), agree to the following terms in full and complete settlement of this suit: 1. Within fifteen (15) days after fully binding approval of this Settlement Agreement has been obtained from the Boards of the City, the CRA and the County (the "Effective Date"), the CRA shall deliver the following documents (collectively, the "CRA Documents") to the County Attorney (the "Escrow Agent"): a. Four (4) counterpart originals of this Settlement Agreement duly executed by counsel to the CRA. b. Two (2) counterpart originals of the Dismissal with Prejudice of the pending litigation in the form attached to this Settlement Agreement as Exhibit "A" (the "Dismissal") duly executed by counsel to the CRA. c. A counterpart of the Declaration of Restrictive Covenants in the form attached hereto as Exhibit "B" to this Settlement Agreement (the "Declaration") duly executed by the CRA. d. A counterpart of the Declaration of Restrictive Covenants in the form of Exhibit "C" to this Settlement Agreement (the "Block 36 Declaration") duly executed by the CRA. e. Two (2) releases of the City and the County in the form attached hereto as Exhibit "D" to this Settlement Agreement (the "CRA Release") duly executed by the CRA. f. A counterpart of the Declaration of Restrictive Covenants in the form of Exhibit "E" to this Settlement Agreement (the "Block 25 Declaration"). A counterpart of the Declaration of Restrictive Covenants in the form of g. Exhibit "F" to this Settlement Agreement (the "Block 9 Declaration"). 2. Within fifteen (15) days of the Effective Date, the City shall deliver the following documents (the "City Documents") to Escrow Agent: a. Four (4) counterpart originals of this Settlement Agreement duly executed by counsel to the City. b. Two (2) counterpart originals of the Dismissal duly executed by counsel to the City. 2 c. Two (2) releases of the County and the CRA in the form attached hereto as Exhibit "G" to this Settlement Agreement (the "City Release") duly executed by the City. d. A quit claim deed from the City to the CRA in the form attached hereto as Exhibit "H" to this Settlement Agreement (the "City Deed") duly executed by the City. 3. Within fifteen (15) days of the Effective Date the County shall deliver the following documents (collectively, the "County Documents") to Escrow Agent: a. Four (4) counterpart originals of this Settlement Agreement duly executed by counsel to the County. b. Two (2) releases of the City and the CRA in the form attached hereto as Exhibit "I" to this Settlement Agreement (the "County Release") duly executed by the County. c. A quit claim deed from the County to the CRA in the form attached hereto as Exhibit "J" to this Settlement Agreement (the "County Deed") duly executed by the County. d. The counterpart of the Declaration duly executed by the County. e. The counterpart of the Block 36 Declaration duly executed by the County. f. The Block 25 Declaration duly executed by the County. g. The Block 9 Declaration duly executed by the County. 4. Upon receipt by Escrow. Agent of the CRA Documents, the City Documents and the County Documents, Escrow Agent shall promptly proceed as follows: 3 a. File one fully executed Settlement Agreement with the court in the pending action. b. File one fully executed Dismissal with the court in the pending action. c. Record the following documents in the following order in the Public Records of Miami -Dade County, Florida: i, The Dismissal. ii. The City Deed. iii. The Declaration. iv. The Block 36 Declaration. v. The Block 25 Declaration. vi. The Block 9 Declaration. vii. The County Deed. d. Deliver to the City, the County Release, the CRA Release and the Settlement Agreement. e. Deliver to the County, the City Release, the CRA Release and the Settlement Agreement. f. Deliver to the CRA, the City Release, the County Release and the Settlement Agreement. 5. If the Escrow Agent does not receive all of the CRA Documents, the City Documents and the County Documents within fifteen (15) days of the Effective Date, as such deadline may be extended by the written agreement of all Parties, the Escrow Agent shall return to the respective Parties any documents previously executed and delivered to Escrow Agent in 4 connection herewith. In such event, any of the Parties may pursue appropriate action to enforce the teiiiis of this Settlement Agreement. 6. The CRA and the County shall each pay one half of the cost incurred by Escrow Agent to record the Dismissal, the City Deed, the County Deed, the Declaration, the Block 36 Declaration, the Block 25 Declaration and the Block 9 Declaration, by forwarding such payment within ten days of request of same by the County. 7. Within thirty (30) days of the date Escrow Agent records the Dismissal, the City Deed, the Declaration, the Block 36 Declaration, the Block 25 Declaration, the Block 9 Declaration and the County Deed, which shall be recorded in this order, the CRA shall conduct a solicitation, in accordance with Section 163.380, Florida Statutes, (the "Developer Opportunity") to transfer fee simple title to the real property described on Exhibit "K" attached to this Settlement Agreement (the "Property") to a developer (the "Developer") for development of the Property. The CRA, at its option, may include a portion of Block 46 NORTH, CITY OF MIAMI, according to the Plat thereof, recorded in Plat Book "B" at page 41 of the Public Records of Miami -Dade County, Florida, in the Developer Opportunity. The City, the County and the CRA agree that they have not, and will not, take any action to affect title to the Property prior to the conveyance of the Property to the Developer selected pursuant to the Developer Opportunity including, without limitation, executing any leases. The City, the County and the CRA agree that they have not, and will not, take any action to approve (including any contingent approvals) any lease, lien, agreement, development plan or encumbrance relating to the Property prior to the conveyance of the Property to the Developer selected pursuant to the Developer Opportunity, other than as specifically set forth and outlined herein. The City and the CRA agree that should they settle, in whole or in part, the case styled Southeast Overtown/Park West 5 Community Development Agency vs. Poinciana Village of Miami, Ltd., Case No. 02-06846 CA 09 or City of Miami vs. Sawyers Walk, Ltd., Case No. 00-28860 CA 09, or procure any full or partial releases of the City and/or the CRA in connection with same in any manner, that such settlement or releases, i) shall include the release of the County if the City and/or the CRA are released in connection therewith, and ii) shall not encumber, lease or lien the Property in connection with such settlement. The CRA shall select the Developer no later than 90 days from the date of the CRA solicitation. In the event that such Developer is not selected within 90 days, or no bids are received, the CRA may repeat the solicitation (within 30 days) and attempt to select (within 90 days) as set forth herein. If no developer is selected by the CRA after the second solicitation, as evidenced by the failure to forward the selected Developer to the County as set forth in paragraph 8 herein, that portion of the Property consisting of Blocks 45 and 56 NORTH, CITY OF MIAMI, according to the Plat thereof, recorded in Plat Book "B" at Page 41 of the Public Records of Miami -Dade County, Florida (the "Reverter Property") shall revert to the County at its option upon the County providing written notice to the CRA Executive Director, via certified mail. The CRA shall forthwith provide a special warranty deed to the County conveying the Reverter Property to the County within 10 days of receipt of the County's request. In such event, the Declaration shall terminate and be of no further force and effect upon the recording of the special warranty deed. At a minimum, the Development Opportunity and the resulting development agreement between the CRA and the Developer (the "Development Agreement") shall include the following requirements: a. Compliance with the terms, conditions and time frames of the Declaration. 6 b. Elements preserving the history of the Overtown area, while incorporating the theme of "Live, Work and Play," including entertainment venues and restaurants with outdoor dining to the fullest extent practicable. c. Information regarding job opportunities for local area residents and businesses to allow them to participate in the construction of the development, including at least two (2) local job fairs prior to the commencement of each development phase. d. Information as to job opportunities for local residents and local businesses post -construction, including newly generated trade and service related jobs, including at least one (1) local job fair upon the completion of each development phase. e. Phasing of construction, with a preference on the completion of the Retail Component, as defined in the Declaration prior to the Residential Component, as defined in the Declaration. f. The requirement that the Developer execute and deliver to the City, the County and the CRA, as a condition of the award in accordance with the Development Opportunity, an indemnification and hold harmless agreement substantially in the form of Exhibit "L" to this Settlement Agreement (the "Indemnification Agreement"). g. To the extent required by the City of Miami Zoning Code, the Developer shall plat each development site. h. The term of the Development Agreement shall commence on the date it is signed by the Developer and the CRA and shall end thirty (30) years from the date the last affordable/workforce housing unit receives its Certificate of Occupancy or as required by applicable law, whichever is longer. i. The Developer must provide evidence of available financial resources acceptable to the CRA, prior to the commencement of construction of each phase of the project. 8. The CRA shall, within five days of the selection of the Developer by the Board of Commissioners of the CRA, advise the County in writing (the "Notice") by hand delivery or by certified mail; return receipt requested, addressed to the County Mayor, or in the alternative, to the County Mayor's designee as provided in writing to the CRA Executive Director of the Developer selected by the CRA pursuant to the Development Opportunity. Such Developer shall be selected no later than 90 days from the date of the issuance of the Development Opportunity. The Notice shall be deemed delivered upon the date delivered, if by hand delivery or the date that the return receipt is executed. The Board of County Commissioners must approve or reject the Developer selected by the CRA and consider any proposed variances to the Declaration as provided in Paragraph 22 within forty five (45) days from the date of delivery of the Notice (unless the Commission is in recess during such period in which instance an additional day will be added for each day of recess) (the "Approval Period"). If the Board of County Commissioners does not approve or reject the Developer selected by the CRA within the Approval Period, the selection by the CRA shall be deemed approved by the County. The Notice must specifically state that failure by the Board of County Commissioners to approve or reject the Developer selected by the CRA within 45 days of the date of delivery of the Notice shall result in the Developer being deemed approved. In the event the Board of County Commissioners rejects the Developer selected by the CRA within the Approval Period, the CRA shall issue a new 8 Developer Opportunity within thirty (30) days from the date of such rejection. The process shall continue until the Developer is approved or deemed approved by the Board of County Commissioners. The County waives any Committee review (if applicable) for approvals required under this Settlement Agreement and attached Declaration, and all such approvals may be presented directly to the Board of County Commissioners. The CRA shall enter into the Development Agreement with the Developer within ninety (90) days of the date of approval or deemed approval of the Developer by the Board of County Commissioners. If the CRA and the Developer are not able to finalize the Development Agreement on terms acceptable to the CRA within 90 days of the approval or deemed approval of the Developer by the Board of County Commissioners, then the CRA shall terminate negotiations and the CRA shall issue a new Developer Opportunity for the Property within 30 days from the event of the 90 day period. The City acknowledges and agrees that it does not have any approval rights with respect to the selection of the Developer. 9. The CRA previously issued a request for proposals with respect to proposed development of the property more particularly described on Exhibit "M" attached to this Settlement Agreement (the "Block 36 Property"). The CRA has represented that based upon the evaluations of all responses submitted to the CRA in response to the request for proposals, the proposal submitted by The Gatehouse Group, LLC, a Commonwealth of Massachusetts limited liability company ("Gatehouse") was given the highest rating and pursuant to CRA Resolution Number (attached as Exhibit "MM")the Board of Commissioners of the CRA authorized the Executive Director of the CRA (the "Executive Director") to negotiate the definitive terms of a development agreement for the Block 36 Property (the "Block 36 Development Agreement") with Gatehouse, to transfer fee simple title to the Block 36 Property 9 to Gatehouse, together with other property. No later than 90 days of the date Escrow Agent records the Dismissal, the City Deed, the Declaration, the Block 36 Declaration and the County Deed, in accordance with Paragraph 4, the CRA shall either enter into the Block 36 Development Agreement with Gatehouse, or its affiliate, or if the CRA and Gatehouse, or its affiliate, are unable to finalize the Block 36 Development Agreement in accordance herewith, provide written notice that such negotiations are terminated. Within five days of the termination of negotiations or entry into the agreement, the CRA. shall provide to the County by certified mail, return receipt requested, addressed to the County Mayor, or in the alternative, to the County Mayor's designee, the fully executed Block 36 Development Agreement with Gatehouse, or its affiliate, or alternatively, written notice of the termination of the negotiations. 10. The County . agrees that no approval from the County of the selection of Gatehouse or its affiliate as the developer of Block 36 shall be required if the CRA enters into the Block 36 Development Agreement with Gatehouse, or its affiliate. If the CRA finalizes the Block 36 Development Agreement with Gatehouse, or its affiliate, it shall be deemed the "Block 36 Developer" for purposes of this Settlement Agreement. If the CRA and Gatehouse, or its affiliate, are not able to finalize the Block 36 Development Agreement on terms acceptable to the CRA not later than ninety (90) days of the recordation as set forth in paragraph 9 herein, then within thirty (30) days from the date the CRA terminates negotiations with Gatehouse, or its affiliate, the CRA shall conduct a solicitation, in accordance with Section 163.380, Florida Statutes (the "Block 36 Developer Opportunity") to transfer fee simple title to the Block 36 Property to a developer (the "Block 36 Developer") for the development of the Block 36 Property. The CRA shall advise the County in writing (the "Block 36 Notice") by hand delivery or by certified mail, return receipt requested, addressed to the County Mayor, or in the 10 alternative, to the County Mayor's designee as provided in writing to the Executive Director of the Block 36 Developer selected by the CRA pursuant to the Block 36 Development Opportunity within five days of such selection. The Board of Commissioners of the CRA shall select the Block 36 Developer no later than 90 days from the date of the Block 36 Developer Opportunity. The Block 36 Notice shall be deemed delivered upon the date delivered, if by hand delivery or the date that the return receipt is executed. In the event that the Block 36 Developer is not selected within 90 days, or no bids are received, the CRA may repeat the solicitation (within 30 days) and attempt to select (within 90 days) as set forth herein. If no developer is selected by the CRA after the second solicitation, as evidenced by the failure to forward the selected Developer to the County as set forth in this paragraph 10 herein, the Block 36 Property shall revert to the County at its option upon the County providing written notice to the CRA Executive Director, via certified mail. The CRA shall forthwith provide a special warranty deed to the County conveying the Block 36 Property to the County within 10 days of receipt of the County's request. 11. The Board of County Commissioners must approve or reject the Block 36 Developer selected by the CRA and consider any proposed variances to the Block 36 Declaration as provided in Paragraph 23 within forty five (45) days from the date of delivery of the Block 36 Notice (unless the Commission is in recess during such period in which instance an additional day will be added for each day of recess) (the "Block 36 Approval Period"). If the Board of County Commissioners does not approve or reject the Block 36 Developer selected by the CRA within the Block 36 Approval Period, the selection by the CRA shall be deemed approved by the Board of County Commissioners. The Block 36 Notice must specifically state that failure by the Board of County Conunissioners to approve or reject the Block 36 Developer selected by the CRA within 45 days of the date of delivery of the Block 36 Notice shall result in the Block 36 11 Developer being deemed approved by the Board of County Commissioners. In the event the Board of County Commissioners rejects the Block 36 Developer selected by the CRA within the Block 36 Approval Period, the CRA shall issue a new Block 36 Developer Opportunity within thirty (30) days from the date of such rejection. The process shall continue until the Block 36 Developer is approved or deemed approved by the Board of County Commissioners. The County waives any Committee review (if applicable) for approvals required under this Settlement Agreement and attached Block 36 Declaration, and all such approvals may be presented directly to the Board of County Commissioners. The CRA shall enter into the Block 36 Development Agreement with the Block 36 Developer within ninety (90) days of the approval or deemed approval by the Board of County Commissioners of the Block 36 Developer. If the CRA and the Block 36 Developer are not able to finalize the Block 36 Development Agreement on terms acceptable to the CRA within 90 days of the approval or deemed approval of the Developer by the Board of County Commissioners, then the CRA shall terminate negotiations and the CRA shall issue a new Block 36 Developer Opportunity for the Block 36 Property within 30 days from the end of the 90 day period. The City acknowledges and agrees that it does not have any approval rights with respect to the selection of the Block 36 Developer. 12. The City, the County and the CRA agree that they have not, and will not, take any action to affect title to the Block 36 Property prior to the conveyance of the Block 36 Property to the Block 36 Developer, as hereinafter defined, including, without limitation, executing any leases other than the possible recording of the proposed plat for Lyric Subdivision (the "Lyric Plat") and the possible execution of the Block 36 Development Agreement with Gatehouse, or its affiliate, provided same is consistent with this Settlement Agreement and the Block 36 Declaration and expressly conditioned upon the execution of this Settlement Agreement. The 12 City, the County and the CRA agree that they have not, and will not, take any action to approve (including any contingent approvals) any lease, lien, agreement, development plan or encumbrance relating to the Block 36 Property prior to the conveyance of the Block 36 Property to the Block 36 Developer, other than as specifically set forth and outlined herein. At a minimum, the Block 36 Development Agreement between the CRA and the Block 36 Developer shall include the following requirements: a. Compliance with the terms, conditions and time frames of the Block 36 Declaration. b. Elements preserving the history of the Overtown area, while incorporating the theme of "Live, Work and Play," including entertainment venues and restaurants with outdoor dining to the fullest extent practicable. c. Information regarding job opportunities for local area residents and businesses to allow them to participate in the construction of the development, including at least two (2) local job fairs prior to the commencement of each development phase. d. Information as to job opportunities for local residents and local businesses post -construction, including newly generated trade and service related jobs, including at least one (1) local job fair upon the completion of each development phase. e. To the extent required by the City of Miami Zoning Code, the Block 36 Developer shall plat each development site. 13 f. The Block 36 Developer must provide evidence of available financial resources acceptable to the CRA, prior to the commencement of construction of each phase of the project. 13. In addition to the absolute prohibition in paragraphs 7 and 11 above, no interim or alternative use or agreement shall be made, or approved with respect to the Property and the Block 36 Property by, or at the request of, the CRA at any time, without the written approval of the County Mayor or his designee, which may be withheld in his sole and absolute discretion except for the existing parking licenses with respect to the Block 36 Property and the Property. Any monies paid to the CRA relating to any approved interim use of the Property and the Block 36 Property (excluding any existing revenues derived from the Property and the Block 36 Property), shall be divided equally between the County and the CRA. No interim use shall be permitted that affects or impacts the timeframes set forth in the Declaration and the Block 36 Declaration. 14. The Parties agree that in the event the terms and provisions of this Settlement Agreement conflict with the terms and provisions of any interlocal agreements between the City and the County or any interlocal agreements between the Parties regarding development of the Property, the Block 36 Property, or any portion thereof, or the selection of the Developer and the Block 36 Developer, by the Board of the County, the terms and provisions of this Settlement Agreement shall control. 15. It is understood that notwithstanding any provision herein, the County, the City, and the CRA shall not be liable to any other party or person for the exercise of its governmental authority, regulatory powers, and/or police powers. The County, the City, and the CRA retain all of their sovereign prerogatives and rights under Florida laws, and shall in no way be estopped or 14 otherwise prevented from withholding or refusing to issue any approvals of application or be liable for same, or to grant any approvals of applications for building, zoning, planning or development under present or future laws and ordinances of whatever nature. 16. The CRA shall have the obligation to enforce compliance by the Developer with the provisions of the Declaration. In the event that the Developer fails to comply with the timelines in the Declaration, the CRA shall have the obligation to procure the completion of the construction of the development in accordance with the terms set forth in the Declaration. The CRA may satisfy this obligation by enforcing the terms and provisions of the Declaration. The County shall also have the right to enforce the terms of the Declaration, this Settlement Agreement, and including the CRA's obligation set forth in this paragraph, by motion filed with this Court, including but not limited to the right to take over the construction of the project on the Property if this Court deems the remedy appropriate. The Parties retain all rights to object to any remedy sought by any other Party, including objections to any motion by the County to take over the construction of the project on the Property. The parties agree that the Court retains jurisdiction to enforce the terms of this Settlement Agreement and the Declaration; provided, however, that such jurisdiction applies to new obligations under this Settlement Agreement and the Declaration, and that all issues regarding ownership and reverter under the subject lawsuit have been resolved with finality upon recordation of the documents hereunder. 17. The CRA shall have the obligation to enforce compliance by the Block 36 Developer with the provisions of the Block 36 Declaration. In the event that the Block 36 Developer fails to comply with the timelines in the Block 36 Declaration, the CRA shall have the obligation to procure the completion of the construction of the development in accordance with the terms set forth in the Block 36 Declaration. The CRA may satisfy this obligation by 15 enforcing the terms and provisions of the Block 36 Declaration. The County shall also have the right to enforce the terms of the Block 36 Declaration, this Settlement Agreement, and including the CRA's obligation set forth in this paragraph, by motion filed with this Court, including but not limited to the right to take over the construction of the project on the Block 36 Property if this Court deems the remedy appropriate. The Parties retain all rights to object to any remedy sought by any other Party, including objections to any motion by the County to take over the construction of the project on the Block 36 Property. The parties agree that the Court retains jurisdiction to enforce the terms of this Settlement Agreement and the Block 36 Declaration; provided, however, that such jurisdiction applies to new obligations under this Settlement Agreement and the Block 36 Declaration, and that all issues regarding ownership and reverter under the subject lawsuit have been resolved with finality upon recordation of the documents hereunder. 18. Any default by any developer under the terms of the Declaration shall not be deemed to be a default by any developer under the terms of the Block 36 Declaration, and any default by any developer under the terms of the Block 36 Declaration shall not be deemed a default by any developer under the terms of the Declaration. 19. Notwithstanding any other provision set forth herein, in the event that vertical construction (defined as physical structures actually being constructed on the Reverter Property in accordance with an approved site plan) has not commenced on the Reverter Property within three years from the date that the CRA executed the Development Agreement with the Developer, the Reverter Property shall revert to the County upon written notice by the County to the Executive Director of the CRA at any time prior to the commencement of the vertical construction. Notice of the exercise of the reverter shall be provided by hand delivery or by 16 certified mail, return receipt requested, from the County Mayor, or in the alternative, the County Mayor's designee, to the Executive Director of CRA. Within ten days of receipt of such notice, the CRA shall provide the County with a special warranty deed transferring all title and interest of the CRA in and to the Reverter Property to the County, which the County shall record. In such event, the Declaration shall terminate and be of no further force and effect upon the recording of the special warranty deed. 20. Notwithstanding any other provision set forth herein, in the event that vertical construction (defined as physical structures actually being constructed on the Block 36 Property in accordance with an approved site plan) has not commenced on the Block 36 Property within three years from the later to occur of (i) the date the Escrow Agent records the documents in accordance with Paragraph 4 of this Settlement Agreement or (ii) the execution of the Block 36 Development Agreement by the CRA and the Block 36 Developer, the Block 36 Property shall revert to the County upon written notice by the County to the Executive Director of the CRA at any time prior to the commencement of the vertical construction. Notice of the exercise of the reverter shall be provided by hand delivery or by certified mail, return receipt requested, from the County Mayor, or in the alternative, the County Mayor's designee to the Executive Director of CRA. Within ten days of receipt of such notice, the CRA shall provide the County with a special warranty deed transferring all title and interest of the CRA in and to the Block 36 Property to the County, which the County shall record. In such event the Block 36 Declaration shall terminate and be of no further force and effect upon the recording of the special warranty deed. 21. This Settlement Agreement is contingent upon full and binding approval of the respective Boards of the County, the City, and the CRA. Upon approval of this Settlement 17 Agreement by all of the respective Boards of the County, the City and the CRA, this Settlement Agreement shall be binding on the Parties, and any of the Parties may seek enforcement of this Settlement Agreement and compel the other Parties to execute and deliver the CRA Documents, the City Documents and the County Documents, respectively, which are required to be executed and delivered to implement the settlement contemplated by this Settlement Agreement. 22. The CRA and the County acknowledges that the time frames and development requirements of the Declaration represent the reasonable opinion of the CRA and the County as to what may reasonably be developed on the Property within the time frames set forth in the Declaration. In the event the Developer selected by the CRA in response to the Developer Opportunity proposed variance from the requirements of the Declaration, which variances have been approved by the Board of Commissioners of the CRA in light of market conditions and information provided by the Developer, the Board of County Commissioners shall consider such variances at the time the Board of County Commissioners is requested by the CRA to approve the Developer and such variances shall be outlined to the County in the Notice to the County. The County agrees to reasonably consider such variances at the time it acts on the approval of the Developer, with no obligation on the part of the Board of County Commissioners to approve any such variances from the Declaration. If the Board of County Commissioners approves the Developer and some or all of the variances requested by the Developer, the County and the CRA shall execute an amendment to the Declaration to reflect the variances approved by the Board of County Commissioners. 23. The CRA and the County acknowledges that the time frames and development requirements of the Block 36 Declaration represent the reasonable opinion of the CRA and the County as to what may reasonably be developed on the Block 36 Property within the time frames 18 set forth in the Block 36 Declaration. In the event the Block 36 Developer selected by the CRA in response to the Block 36 Developer Opportunity proposed variance from the requirements of the Block 36 Declaration, which variances have been approved by the Board of Commissioners of the CRA in light of market conditions and information provided by the Block 36 Developer, the Board of County Commissioners shall consider such variances at the time the Board of County Commissioners is requested by the CRA to approve the Block 36 Developer and such variances shall be outlined to the County in the Block 36 Notice to the County. The County agrees to reasonably consider such variances at the time it acts on the approval of the Block 36 Developer, with no obligation on the part of the Board of County Commissioners to approve any such variances from the Block 36 Declaration. If the Board of County Commissioners approves the Block 36 Developer and some or all of the variances requested by the Block 36 Developer, the County and the CRA shall execute an amendment to the Block 36 Declaration to reflect the variances approved by the Board of County Commissioners. 24. To the extent that this Settlement Agreement, the Declaration, or the Block 36 Declaration require construction, and regardless of the notation of the "preparer" contained upon same, both the CRA and the County equally participated in the drafting of such documents, and accordingly, such documents shall not be construed in favor of, or against, either party. 25. his Settlement Agreement may be executed in counterparts. [SIGNATURE PAGES TO FOLLOW] 19 DATED this day of , 2012. MIAMI-DADE COUNTY ATTORNEY'S OFFICE This Settlement Agreement has been approved on by Resolution No. of the Board of County Commissioners of Miami -Dade County, Florida. A certified copy of said resolution is attached hereto as Exhibit N. This Settlement Agreement has been approved on R.A. CUEVAS, JR. Miami -Dade County Attorney Stephen P. Clark Center 111 NW 1st St., Ste. 2810 Miami, FL 33128 By: Debra Herman Assistant County Attorney Attorney for Defendant CITY OF MIAMI ATTORNEY'S OFFICE 444 S.W. 2nd Ave, Suite 945 Miami, Florida 33130 By: Henry J. Hunnefeld, Esq. Assistant City Attorney Attorney for Plaintiff, City of Miami SOUTHEAST OVERTOWN/PARK WEST COMMUNITY REDEVELOPMENT AGENCY By: William R. Bloom, Esq. Attorney for Plaintiff, Southeast Overtown/Park West Community Redevelopment 20 by Resolution No. of the City of Miami, Miami -Dade County, Florida. A certified copy of said resolution is attached hereto as Exhibit O. This Settlement Agreement has been approved on by Resolution No, of the Southeast Overtown Park/West Community Redevelopment Agency, an agency of the State of Florida, in Miami, Miami -Dade County, Florida. A certified copy of said resolution is attached hereto as Exhibit P. 21 EXHIBIT A Dismissal with Prejudice IN THE CIRCUIT COURT OF THE 1 lth JUDICIAL CIRCUIT IN AND FOR MIAMI-DADE COUNTY, FLORIDA GENERAL JUDICIAL DIVISION CASE NO. 07-46851 CA 31 CITY OF MIAMI, et. al., Plaintiff, vs. NOTICE OF DISMISSAL WITH PREJUDICE AND DISCHARGE MIAMI-DADE COUNTY, OF LIS PENDENS Defendant. YOU ARE HEREBY NOTIFIED that Plaintiff, City of Miami, et. al. dismisses with prejudice in the above -styled action, pursuant to Rule 1.420(a)(1), Florida Rules of Civil Procedure. Each side will bear its own costs and attorney fees. Furthermore, Plaintiff discharges the Notice of Lis Pendens filed in this action and recorded in Official Records Book , page of the Public Records of Miami -Dade County, Florida. Dated: , 2012 CITY OF MIAMI ATTORNEY'S OFFICE 444 S.W. 2nd Ave, Suite 945 Miami, Florida 33130 By: Henry J. Hunnefeld, Esq. Assistant City Attorney Attorney for Plaintiff, City of Miami 1 Copies to: SOUTHEAST OVERTOWN/PARK WEST COMMUNITY REDEVELOPMENT AGENCY By: William R. Bloom, Esq. Attorney for Plaintiff, Southeast Overtown/Park West Community Redevelopment R.A. Cuevas, Jr. Debra Herman Miami -Dade County Attorney's Office Miami -Dade County Attorney Stephen P. Clark Center 111 NW 1st St., Ste. 2810 Miami, FL 33128 2 EXHIBIT B Declaration of Restrictive Covenant This Instrument was prepared by Debra Herman, Esq. Miami -Dade County Attorney Office Stephen P. Clark Center 111 N. W. 1st Street Suite 2800 Miami, Florida 33128 DECLARATION OF RESTRICTIONS THIS DECLARATION OF RESTRICTIONS (the "Declaration") is made as of , 2012 by and between Miami -Dade County, Florida, a political subdivision of the State of Florida (the "County") and the Southeast Overtown/Park West Community Redevelopment Agency, a public agency and body corporate to Section 163.356, Florida Statutes (the "CRA"). RECITALS A. The County and the CRA hold or claim fee simple title interest in and to the land in Miami -Dade County, Florida, legally described in Composite Exhibit "1" attached hereto. B. The CRA is the owner of fee simple title to that certain real property located in Miami -Dade County, Florida which is more particularly described on Exhibit "2" attached hereto and made a part hereof (properties described in Exhibits "1" and "2" collectively referred to herein as the "Property"). C. In accordance with the terms of the settlement agreement dated as of , 2012 by and between the City of Miami, a municipal corporation (the "City"), the County and the CRA (the "Settlement Agreement"), the County has agreed to quit claim its interest in the Property described in Exhibit "1" to the CRA after the recordation of this Declaration. D. The City has quit claimed its interest in the property described in Exhibit "1" to the CRA. NOW THEREFORE, in consideration of the foregoing and other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the County and the CRA, as the current owners of the Property, agree as follows: 1 1. Recitals. The recitals to the Declaration are true and correct and incorporated herein by reference. 2. Development Restrictions. The CRA and the County agree that the Property shall be developed as a mixed use development project (the "Project") that will consist of: (a) a retail, office, hotel and/or permitted institutional component containing a minimum of 150,000 square feet and a minimum of structural parking spaces no less than as required by the applicable building codes (the "Retail Component") and (b) residential housing, consisting of a minimum of fifty (50) units (the "Residential Component"). 3. Residential Restrictions. (a) The CRA and the County agree that: (i) ten percent (10%) of the units comprising the Residential Component shall be made available for individuals and/or families earning thirty percent (30%) or less of the AMI; (ii) seventy percent (70%) of the units comprising the Residential Component shall be made available for individuals and/or families earning more than thirty percent (30%) of AMI up to eighty percent (80%) of AMI; and (iii) twenty percent (20%) of the units comprising the Residential Component shall be made available for individuals and/or families earning more than eighty percent (80%) of AMI and less than one hundred forty percent (140%) of AMI. (b) "AMI" shall mean the median family income for Miami -Dade County as published annually by the U.S. Department of Housing and Urban Development. (c) In the event that Developer, as hereinafter defined, exceeds the requirements in Section 3(A)(i) same will reduce the requirement with respect to Section 3(A)(ii). (d) In the event Developer exceeds the requirements in Section 3(A)(i) and 3(A)(ii), in the aggregate, same will reduce the requirements in Section 3(A)(iii) (i.e., if the percentage of units comprising the Residential Component meeting the requirement of Sections 3(A)(i) and 3(A)(ii) exceeds eighty percent (80%), the percentage of units comprising the Residential Component which meet the requirements of Section 3(A)(iii) shall be reduced accordingly. (e) The CRA shall endeavor to select a Developer, who will attempt to exceed the minimum standards set forth in Sections 3(A)(i) and 3(A)(ii) above (i.e. maximize the percentage of the units comprising Residential Component made available to individuals and/or families earning less than eighty percent (80%) of AMI). 4. Selection of Developer. The CRA shall conduct a solicitation, in accordance with Section 163.380, Florida Statutes, (the "Development Opportunity") to select a developer for the Project (the "Developer") in accordance with the terms of the Settlement Agreement. The CRA shall, within five days of the selection of the Developer by the Board of Commissioners of the CRA, advise the County by hand delivery or by certified mail, return 2 receipt requested, addressed to the County Mayor or its designee (the "Notice") of the Developer selected by the Board of Commissioners of the CRA pursuant to the Developer Opportunity. The Notice shall be deemed delivered to the County on the day hand delivered or the date the return receipt is executed. In such event, the Board of County Commissioners must approve or reject the Developer selected by the Board of Commissioners of the CRA and consider any proposed variances to this Declaration as provided in Section 23 within forty five (45) days from the date of delivery of the Notice (unless the Commission is in recess during such period in which instance an additional day will be added for each day of recess) (the "Approval Period"). If the Board of County Commissioners does not approve or reject the Developer selected by the CRA within the Approval Period, the selection by the CRA shall be deemed approved by the Board of County Commissioners. In the event the Board of County Commissioners rejects the Developer selected by the CRA within the Approval Period, the CRA shall issue a new Developer Opportunity within thirty (30) days from the date of such rejection. The process shall continue until the Developer is approved or deemed approved by the Board of County Commissioners. The Development Opportunity will require the Developer to diligently pursue the simultaneous development of the Residential Component and the Retail Component, with a preference on completion of the Retail Component first. The Development Opportunity shall not require that any component or phase of the Project be completed before construction on another component or phase can commence. 5. Development Agreement. The CRA shall enter into a development agreement (the "Development Agreement") with the Developer, approved or deemed approved by the Board of County Commissioners within ninety (90) days from the date the Developer is approved or deemed approved by the Board of County Commissioners. If the CRA does not enter into the Development Agreement with the Developer approved or deemed approved by the Board of County Commissioners within the ninety (90) day period, the CRA shall terminate negotiations with such Developer and issue a new Developer Opportunity within thirty (30) days from the end of such ninety (90) day period. 6. Land Use and Zoning Approvals. The Developer shall obtain all applicable land use and zoning approvals for the Project (the "Approvals") within twelve (12)) months from the date of execution of the Development Agreement by the CRA and the Developer (the "Effective Date"). 7. Construction. The Developer must commence vertical construction (defined as physical structures actually being constructed on the Property in accordance with an approved site plan) within twenty four (24) months of the Effective Date. The Developer must substantially complete construction of the Retail Component within twenty-four (24) months after commencement of vertical construction (the "Retail Completion Date"). The Developer shall commence vertical construction (defined as physical structures actually being constructed on the Property in accordance with an approved site plan) of the Residential Component within twenty-four (24) months after the Effective Date and must substantially complete construction of the Residential Component within twenty four (24) months after the Effective Date (the "Residential Completion Date"). Either the Retail or Residential Completion Dates shall be evidenced by one or more temporary or permanent certificates of occupancy (or their equivalent) for all buildings comprising the particular component. Both the Retail and Residential Completion Dates shall automatically be extended one day for each day of Unavoidable Delay. 3 The term "Unavoidable Delay" means delays due to area wide strikes, acts of God, floods, hurricanes, casualties, fires, and acts of the public enemy. The term Unavoidable Delay shall not include delays caused by any governmental entity acting in its proprietary or regulatory capacity or delays caused by lack of funds. 8. Compensation. A. Beginning sixty (60) days from Effective Date, the Developer shall separately pay to each of the County and the CRA each year for twenty-five (25) years a sum of money, commencing at One Hundred Forty Thousand and No/100 Dollars ($140,000.00) on an annual basis for the first five years, and increasing by 3% per year for each year thereafter. The term "Project Payment" shall mean the then current annual payment due from the Developer to the County and the CRA. All subsequent Project Payments shall be due on the anniversary of the first payment. B. The Project Payment shall be increased by ten percent (10%) if the Developer does not obtain the Approvals by the Approval Date, as same may be extended. C. The Project Payment shall be increased by ten percent (10%) if the Developer does not complete construction of the Residential Component by the Residential Completion Date, as same may be extended as a result of Unavoidable Delays, until the Developer has completed the Residential Component. Completion of the Residential Component shall mean temporary or permanent certificates of occupancy (or their equivalent) have been issued for not less than fifty (50) residential units. D. The Project Payment shall be increased by ten percent (10%) if the Developer does not complete construction of the Retail Component by the Retail Completion Date, as same may be extended as a result of Unavoidable Delays, until the Developer has completed the Retail Component. Completion of the Retail Component shall mean temporary or permanent certificates of occupancy (or their equivalent) have been issued for not less than One Hundred Fifty Thousand (150,000) square feet. E. In the event that the Retail Component exceeds Three Hundred Thousand (300,000) square feet of space, then in such event, commencing upon the date of issuance of one or more certificates of occupancy (or their equivalent) for not less than Three Hundred Thousand (300,000) square feet of space, the Project Payment shall thereafter be increased by twenty-five percent (25%). F. In the event Developer fails to make any Project Payment within ten (10) days of when due Developer shall pay to each of the County and the CRA a late fee equal to five percent (5%) of the Project Payment then due. G. In the event that Developer fails to make any Project Payment within thirty (30) days of when due such Project Payment shall bear interest at twelve percent (12%) per annum from the date due until paid. H. Nothing contained herein shall prevent or otherwise prohibit either the CRA or the County (through their Boards), upon application by the Developer, from waiving 4 their rights to one or more Project Payments, including portions of Project Payments, or penalties thereon. In such event, the approval of the CRA shall not be required if the County chooses to waive its rights, nor shall the approval of the County be required in the event the CRA elects to waive its rights. 9. Developer Default. A. In the event the Developer (i) does not obtain the Approvals in the timeframe provided in Section 6 of this Declaration, (ii) fails to achieve substantial completion of the Retail Component by the Retail Completion Date, as same may be extended as a result of Unavoidable Delays, (iii) fails to achieve substantial completion of the Residential Component by the Residential Completion Date, as same may be extended as a result of Unavoidable Delays, or (iv) fails to make any Project Payment when due, the CRA and the County (as applicable) may declare the Developer in default by sending a Notice of Default (the "Default Notice"). The Default Notice shall be hand delivered to the Developer or mailed to the Developer by certified mail, return receipt requested. The Default Notice shall be deemed delivered upon the date received if hand delivered, or if mailed, on the date the return receipt is executed or the date delivery is refused. Upon receipt, or deemed receipt, of the Default Notice, the Developer shall have ninety (90) days to cure (the "Default Cure Period"). Extensions of the Default Cure Period shall not be unreasonably withheld, conditioned or delayed for good cause shown, in the sole discretion of the CRA if the CRA has issued the Default Notice, or in the sole discretion of the County if the County has issued the Default Notice. B. In the event the Default Notice is issued pursuant to Section 9(A)(i), the Developer may extend the timeframe in which to obtain the Approvals for six (6) months by paying to each of the County and the CRA Two Hundred Fifty Thousand and No/100 Dollars ($250,000.00) on or before the end of the Default Cure Period, as same may have been extended in accordance with the last sentence of Section 9(A). The extension of the Approval Period pursuant to this Section 9(B) to cure a default pursuant to Section 9(A)(i) is a one time right of the Developer and may not be utilized in connection with any subsequent default pursuant to Section 9(A)(i). C. In the event the Default Notice is issued pursuant to Section 9(A)(ii), the Developer may extend the Retail Completion Date, as same may have been extended as a result of Unavoidable Delays, for an additional six (6) months by paying to each of the County and the CRA Two Hundred Fifty Thousand and No/100 Dollars ($250,000.00) on or before the end of the Default Cure Period, as same may have been extended in accordance with the last sentence of Section 9(A). The extension of the Retail Completion Date pursuant to this Section 9(C) to cure a default pursuant to Section 9(A)(ii) is a one time right of the Developer and may not be utilized in connection with any subsequent default pursuant to Section 9(A)(ii). D: In the event the Default Notice is issued pursuant to Section 9(A)(iii), the Developer may extend the Residential Completion Date, as same may have been extended as a result of Unavoidable Delays, for an additional six (6) months by paying to each of the County and the CRA Two Hundred Fifty Thousand and No/100 Dollars ($250,000.00) on or before the end of the Default Cure Period, as same may have been extended in accordance with the last sentence of Section 9(A). The extension of the Residential Completion Date pursuant to 5 this Section 9(D) to cure a default pursuant to Section 9(A)(iii) is a one time right of the Developer and may not be utilized in connection with any subsequent default pursuant to Section 9(A)(iii). E. In the event the Default Notice is issued pursuant to 9(A)(i) (ii) or (iii) of this Declaration, and is not cured prior to the end of the Default Cure Period, as same may be extended, in accordance with the last sentence of Section 9(A), the Project Payment shall be accelerated and be immediately due and payable in full to the CRA and the County, and title to any portion(s) of the Property which have not been improved with buildings shall automatically revert back to the CRA, subject to the rights of the County set forth in the Declaration and Settlement Agreement and pending the selection of another Developer as set forth therein (the "Reverter Property"). F. If the Default Notice is issued pursuant to Section 9(A)(iv) and same is not cured within the Default Cure Period, then all remaining Project Payments together with a fifteen percent (15%) penalty shall be automatically accelerated and shall be deemed immediately due and payable to the County and the CRA. In such event, the County and the CRA shall have the right to pursue any and all remedies against the Developer for the outstanding amounts. G. The Developer shall be liable to the County and the CRA for all reasonable attorneys fees and costs incurred by the County and the CRA as a result of a Developer Default. H. Any payments made to the County and the CRA pursuant to Section 9(B), 9(C) and 9(D) shall not constitute a Project Payment and shall not be credited against any Project Payment. 10. Reverter RFP. In the event any portion of the Property reverts to the CRA, the CRA shall issue a new Developer Opportunity with respect to the Reverter Property, in accordance with Section 4 of the Declaration, within ninety (90) days from the date the CRA acquires the Reverter Property, and shall provide Notice to the County of the Developer selected for its Approval as set forth herein and in the Settlement Agreement. In the event the Board of County Commissioners rejects the Developer selected by the CRA within the new Approval Period, the CRA shall issue a new Developer Opportunity within thirty (30) days from the date of such rejection. The process shall continue until the Developer is approved or deemed approved by the Board of County Commissioners. The CRA shall enter into a Development Agreement with the Developer approved or deemed approved by the Board of County Commissioners within ninety (90) days of the date the Developer is approved or deemed approved by the Board of County Commissioners. If the CRA does not enter into the Development Agreement with the Developer approved or deemed approved by the Board of County Commissioners within the ninety (90) day period, the CRA shall terminate negotiations with such Developer and issue a New Developer Opportunity within thirty (30) days of the end of such ninety (90) day period. The new Developer shall be bound by the terms of this Declaration. To the extent that any portion of the Property reverts to the CRA after seven 7 years from the date of this Declaration, then, in such event, if such portion of the Property that reverts to the CRA consists of any portions of Block 45 and Block 56 NORTH, CITY OF 6 MIAMI, according to the Plat thereof, as recorded in Plat Book "B" at Page 41 of the Public Records of Miami -Dade County, Florida, same shall automatically revert from the CRA to the County without any further action required by the CRA, free and clear of all claims by the CRA and free and clear of this Declaration. If requested by the County, the CRA shall convey such portion of the Property to the County by quit claim deed. In the event of such reversion, this Declaration shall automatically terminate. 11. Notwithstanding any other provision set forth herein, in the event that vertical construction (defined as physical structures actually being constructed on the Property in accordance with an approved site plan) has not commenced on the Property within three years from the Effective Date, then Block 45 and Block 56 NORTH, CITY OF MIAMI, according to the Plat thereof, as recorded in Plat Book "B" at Page 41 of the Public Records of Miami -Dade County, shall revert to the County upon written notice by the County to the Executive Director of the CRA at any time prior to the commencement of the vertical construction. If requested by the County, the CRA and the Developer shall provide the County with a special warranty deed transferring all title and interest in and to such portion of the Property to the County, free and clear of all claims and encumbrances and free and clear of this Declaration, which the County shall record. In such event this Declaration shall terminate upon the recording of the special warranty deed. 12. No Limitation of Remedies. Nothing contained herein shall be construed as limiting the rights and remedies of the County, the City or the CRA set forth in the Settlement Agreement. ' 13. County Inspection. Prior to completion of construction of the Project, the County and the CRA shall have the right, but not the obligation, at any time during normal business hours, to enter and inspect the Property to determine whether the requirements of this Declaration are being complied to by the Developer. 14. Covenant Running with the Land. This Declaration shall constitute a covenant running with the land and shall be binding on the CRA and its successors and assigns having an interest in the Property. This Declaration is for the benefit of, and limitation upon, all present and future owners of the Property and for the benefit of the County and the CRA. 15. Term. This Declaration is to run with the land for a period of thirty (30) years and shall be automatically extended for additional ten (10) year periods until thirty (30) years from the issuance of the last temporary certificate of occupancy (or its equivalent) for the last building comprising the Project. 16. Modification. Provided that the Developer is not in default beyond the applicable grace periods and is current with all of its payment obligations to the CRA and the County, this Declaration may be modified, amended or released with respect to the Property, or any portion thereof, by written instrument executed and recorded by the then owner(s) of the fee simple title to the Property, the CRA and the County with the approval of the respective Boards of the CRA and the County. Notwithstanding the foregoing, the Executive Director of the CRA (the "Executive Director") may unilaterally, without the consent of the County being required, modify this Declaration with respect to the following quantifiable requirements, by an amount 7 not to exceed 25 percent of such number or 25 percent of such percentages, as follows: (a) the number of square feet, and number of residential units in Section 2 ; (b) the time frames set forth in Sections 6 and 7; and (c) the number of residential units or number of retail square feet in Sections 8(C) and (D). Additionally, the Executive Director may modify this Declaration in any other non -substantive manner without the consent of the County, provided such modifications are in writing. Any modifications, amendments, or releases shall be evidenced by a recorded amendment to this Declaration executed by all required parties thereto. 17. Successor to the CRA. In the event of a termination of the CRA, the City shall be successor to CRA. for all purposes under this Declaration. In such event, all references in this Declaration to the CRA shall be deemed references to the City, all references in this Declaration to the approval by the Board of the CRA shall be deemed references to the Board of the City and all references in this Declaration to the Executive Director of the CRA shall be deemed references to the Mayor of the City for all purposes under the Declaration. Any Developer, other than the City, the County, and the CRA, may not assign, convey, or transfer the right to develop the Property, or any portion thereof, without written approval by the respective Boards of the County and the CRA, which may be withheld in their sole and absolute discretion, unless such consent is not required under the Settlement Agreement. To the extent that such entity is controlled by the Developer, in lieu of the foregoing, the County Mayor or County Mayor's designee together with the Executive Director may approve same in writing. Notwithstanding the foregoing, upon the issuance of a Certificate of Occupancy (CO) (or its equivalent) for the Retail Component or any portion thereof or the Residential Component, or any portion thereof, the Developer is permitted to transfer any interest in that completed Component of the Property subject to any remaining financial obligation to the CRA or County. 18. Enforcement. The County and the CRA shall be entitled to enforce this Declaration against any person violating or attempting to violate, any of the terms and provisions contained in this Declaration by appropriate action at law or in equity. The prevailing party in any action or suit pertaining to or arising out of this Declaration shall be entitled to recover, in addition to costs and disbursements allowed by law, such sum as the court may adjudge to be reasonable for the services of an attorney. This Section shall be in addition to any other remedies available at law, in equity, or both, and including the enforcement rights set forth in the Settlement Agreement. 19. Election of Remedies. All rights, remedies and privileges granted herein shall be deemed to be cumulative and the exercise of any one or more shall neither be deemed to constitute an election of remedies, nor shall it preclude the party exercising the same from exercising such other additional rights, remedies or privileges. 20. Severability. Invalidation of any one of these covenants, by judgment of Court, shall not affect any of the other provisions which shall remain in full force and effect. 21. Sovereign Rights. The Developer and its successors, and assigns acknowledge that this Declaration does not obligate the County, the City and the CRA in any manner other than as specifically set forth herein. The County, the City, and the CRA shall not be liable to any other person for the exercise of its governmental authority, regulatory powers, and/or police powers. The County, the City and the CRA retain all of their sovereign 8 prerogatives and rights under Florida laws, and shall in no way be estopped or otherwise prevented from withholding or refusing to issue any approvals of applications, or be liable for same, or to grant any approvals of applications for building, zoning, planning or development under present or future laws and ordinances of whatever nature. 22. Governing Law. This Declaration shall be construed and governed in accordance with the laws of the State of Florida, without application of conflict of laws principles. Venue shall be in the Circuit Court in and for Miami -Dade County, Florida or the Federal District Court of the Southern District of Florida. 23. The CRA and the County acknowledges that the time frames and development requirements of the Declaration represent the reasonable opinion of the CRA and the County as to what may reasonably be developed on the Property within the time frames set forth in the Declaration. In the event the Developer selected by the CRA in response to the Developer Opportunity proposed variance from the requirements of the Declaration, which variances have been approved by the Board of Commissioners of the CRA in light of market conditions and information provided by the Developer, the Board of County Commissioners shall consider such variances at the time the Board of County Commissioners is requested by the CRA to approve the Developer and such variances shall be outlined to the County in the Notice to the County. The County agrees to reasonably consider such variances at the time it acts on the approval of the Developer, with no obligation on the part of the Board of County Commissioners to approve any such variances from the Declaration. If the Board of County Commissioners approves the Developer and some or all of the variances requested by the Developer, the County and the CRA shall execute an amendment to the Declaration to reflect the variances approved by the Board of County Commissioners. [SIGNATURE PAGES TO FOLLOW] 9 IN WITNESS THEREOF the County and the CRA have executed this Declaration as of the date first above written. Witnesses: CRA: Southeast Overtown/Park West Community Redevelopment Agency, a public agency and body corporate created pursuant to Section 163.356, Florida Statutes By: Printed Name: Clarence E. Woods, III Executive Director Printed Name: ATTEST: Clerk of the Board Approved for legal sufficiency By: William R. Bloom, Esq. Holland & Knight LLP Special Counsel Witnesses: COUNTY: MIAMI-DADE COUNTY, a political subdivision of the State of Florida By: Printed Name: Printed Name: ATTEST: Harvey Ruvin, Clerk By: Deputy Clerk Approved for legal sufficiency County Attorney By: 10 STATE OF FLORIDA ) ss. COUNTY OF MIAMI-DADE The foregoing instrument was acknowledged before me this , 2012, by Clarence E. Woods, III, Executive Director Overtown/Park West Community Redevelopment Agency, on behalf of the personally known to me or has produced identification. (SEAL) day of of the Southeast Agency. He is as Notary Public -State of Commission Number: 11 Exhibit 1 Legal Description Lots 1 through 12 inclusive, Block 45, NORTH, CITY OF MIAMI, according to the Plat thereof as recorded in Plat Book `B" at Page 41 of the Public Records of Miami -Dade County, Florida. Lots 1 through 12 inclusive, Block 56, NORTH, CITY OF MIAMI, according to the Plat thereof, as recorded in Plat Book `B" at Page 41 of the Public Records of Miami -Dade County, Florida. 12 Exhibit 2 Legal Description Lots 1 through 20 inclusive, Block 55, NORTH, CITY OF MIAMI, according to the Plat thereof, as recorded in Plat Book "B" at Page 41 of the Public Records of Miami Dade County, Florida. 13 EXHIBIT C BLOCK 36 DECLARATION OF RESTRICTIVE COVENANT This Instrument was prepared by Debra Herman, Esq. Miami -Dade County Attorney Office Stephen P. Clark Center 111 N.W. 1st Street Suite 2800 Miami, Florida 33128 DECLARATION OF RESTRICTIONS THIS DECLARATION OF RESTRICTIONS (the "Declaration") is made as of , 2012 by and between Miami -Dade County, Florida, a political subdivision of the State of Florida (the "County") and the Southeast Overtown/Park West Community Redevelopment Agency, a public agency and body corporate to Section 163.356, Florida Statutes (the "CRA"). RECITALS A. The County and the CRA hold or claim fee simple title interest in and to the land in Miami -Dade County, Florida, legally described in Composite Exhibit "1" attached hereto (the "Property"). B. In accordance with the terms of the settlement agreement dated as of , 2012 by and between the City of Miami, a municipal corporation (the "City"), the County and the CRA (the "Settlement Agreement"), the County has agreed to quit claim its interest in the Property to the CRA after the recordation of this Declaration. C. The City has quit claimed its interest in the Property to the CRA. NOW THEREFORE, in consideration of the foregoing and other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the County and the CRA, as the current owners of the Property, agree as follows: 1. Recitals. The recitals to the Declaration are true and correct and incorporated herein by reference. 2. Development Restrictions. The CRA and the County agree that the Property shall be developed as (a) a retail, office, hotel and/or permitted institutional component containing a minimum of 30,000 square feet and a minimum of structural parking spaces no less 1 than as required by the applicable building codes, including a parking garage (the "Retail Component") and (b) a parking garage containing a minimum of three hundred (300) parking spaces (the "Parking Component") (collectively the "Project"). 3. Selection of Developer. The County agrees that no approval from the County shall be required if the CRA enters into the Block 36 Development Agreement, as defined in the Settlement Agreement, with The Gatehouse Group, LLC, a Commonwealth of Massachusetts limited liability company ("Gatehouse"), or its affiliate. If the CRA finalizes the Block 36 Development Agreement with Gatehouse, or its affiliate, Gatehouse, or its affiliate, shall be deemed the Developer for the purpose of this Declaration. If the CRA and Gatehouse are not able to finalize the Block 36 Development Agreement on terms acceptable to the CRA, then with thirty (30) days from the date the CRA terminates negotiations with Gatehouse, the CRA shall conduct a solicitation, in accordance with Section 163.380, Florida Statutes, (the "Development Opportunity") to select a developer for the Project (the "Developer") in accordance with the terms of the Settlement Agreement. The CRA shall, within five days of the selection of the Developer by the Board of Commissioners of the CRA, advise the County by hand delivery or by certified mail, return receipt requested, addressed to the County Mayor or its designee (the "Notice") of the Developer selected by the CRA pursuant to the Developer Opportunity. The Notice shall be deemed delivered to the County on the day hand delivered or the date the return receipt is executed. In such event, the Board of County Commissioners must approve or reject the Developer selected by the CRA and consider any proposed variances to the Declaration as provided in Section 15 within forty five (45) days from the date of delivery of the Notice (unless the Commission is in recess during such period in which instance an additional day will be added for each day of recess) (the "Approval Period"). If the Board of County Commissioners does not approve or reject the Developer selected by the CRA within the Approval Period, the selection by the CRA shall be deemed approved by the Board of County Commissioners. In the event the Board of County Commissioners rejects the Developer selected by the CRA within the Approval Period, the CRA shall issue a new Developer Opportunity within thirty (30) days from the date of such rejection. The process shall continue until the Developer is approved or deemed approved by the Board of County Commissioners. The Development Opportunity will require the Developer to diligently pursue the simultaneous development of the Parking Component and the Retail Component, with a preference on completion of the Parking Component first. The Development Opportunity shall not require that any component or phase of the Project be completed before construction on another component or phase can commence. 4. Development Agreement. The CRA shall enter into a development agreement (the "Development Agreement") with the Developer, approved or deemed approved by the Board of County Commissioners within ninety (90) days from the date the Developer is approved or deemed approved by the Board of County Commissioners. If the CRA does not enter into the Development Agreement with the Developer approved or deemed approved by the Board of County Commissioners within the ninety (90) day period, the CRA shall terminate negotiations with such Developer and issue a new Developer Opportunity within thirty (30) days from the end of such ninety (90) day period. 5. The Developer shall obtain all applicable land use and zoning approvals for the Project (the "Approvals") within twelve months from the later to occur of (i) execution of 2 the Development Agreement by the CRA and the Developer or (ii) the date this Declaration is recorded (the "Effective Date"); 6. Construction. The Developer must commence vertical construction (defined as physical structures actually being constructed on the Property in accordance with an approved site plan) within twenty four (24) months of the Effective Date. The Developer must substantially complete construction of the Retail Component within twenty-four (24) months from commencement of vertical construction (the "Retail Completion Date"). The Developer shall commence vertical construction (defined as physical structures actually being constructed on the Property in accordance with an approved site plan) of the Parking Component within twenty-four (24) months after the Effective Date and must substantially complete construction of the Parking Component within twenty-four (24) months from commencement of vertical construction (the "Parking Completion Date"). Either the Retail or Parking Completion Dates shall be evidenced by one or more temporary or permanent certificates of occupancy (or their equivalent) for all buildings comprising the particular component. Both the Retail and Parking Completion Dates shall automatically be extended one day for each day of Unavoidable Delay. The term "Unavoidable Delay" means delays due to area wide strikes, acts of God, floods, hurricanes, casualties, fires, and acts of the public enemy. The term Unavoidable Delay shall not include delays caused by any governmental entity acting in its proprietary or regulatory capacity or delays caused by lack of funds. 7. Developer Default. A. In the event the Developer (i) does not obtain the Approvals in the timeframe provided in Section 5 of this Declaration, (ii) fails to achieve substantial completion of the Retail Component by the Retail Completion Date, as same may be extended as a result of Unavoidable Delays, or (iii) fails to achieve substantial completion of the Parking Component by the Parking Completion Date, as same may be extended as a result of Unavoidable Delays, the CRA and the County (as applicable) may declare the Developer in default by sending a Notice of Default (the "Default Notice"). The Default Notice shall be hand delivered to the Developer or mailed to the Developer by certified mail, return receipt requested. The Default Notice shall be deemed delivered upon the date received if hand delivered, or if mailed, on the date the return receipt is executed or the date delivery is refused. Upon receipt, or deemed receipt, of the Default Notice, the Developer shall have ninety (90) days to cure (the "Default Cure Period"). Extensions of the Default Cure Period for good cause shown shall be in the sole discretion of the CRA if the CRA has issued the Default Notice, or in the sole discretion of the County if the County has issued the Default Notice. B. In the event the Default Notice is issued pursuant to Section 7(A)(i), the Developer may extend the timeframe in which to obtain the Approvals for six (6) months by paying to each of the County and the CRA Two Hundred Fifty Thousand and No/100 Dollars ($250,000.00) on or before the end of the Default Cure Period, as same may have been extended in accordance with the last sentence of Section 7(A). The extension of the Approval Period pursuant to this Section 7(B) to cure a default pursuant to Section 7(A)(i) is a one time right of the Developer and may not be utilized in connection with any subsequent default pursuant to Section 7(A)(i). 3 C. In the event the Default Notice is issued pursuant to Section 7(A)(ii), the Developer may extend the Retail Completion Date, as same may have been extended as a result of Unavoidable Delays, for an additional six (6) months by paying to each of the County and the CRA Two Hundred Fifty Thousand and No/100 Dollars ($250,000.00) on or before the end of the Default Cure Period, as same may have been extended in accordance with the last sentence of Section 7(A). The extension of the Retail Completion Date pursuant to this Section 7(C) to cure a default pursuant to Section 7(A)(ii) is a one time right of the Developer and may not be utilized in connection with any subsequent default pursuant to Section 7(A)(ii). D. In the event the Default Notice is issued pursuant to Section 7(A)(iii), the Developer may extend the Parking Completion Date, as same may have been extended as a result of Unavoidable Delays, for an additional six (6) months by paying to each of the County and the CRA Two Hundred Fifty Thousand and No/100 Dollars ($250,000.00) on or before the end of the Default Cure Period, as same may have been extended in accordance with the last sentence of Section 7(A). The extension of the Parknig Completion Date pursuant to this Section 7(D) to cure a default pursuant to Section (A)(iii) is a one time right of the Developer and may not be utilized in connection with any subsequent default pursuant to Section 7(A)(iii). E. In the event the Default Notice is issued pursuant to 7(A)(i) (ii) or (iii) of this Declaration, and is not cured prior to the end of the Default Cure Period, as same may be extended, in accordance with the last sentence of Section 7(A), title to any portion(s) of the Property which have not been improved with buildings shall automatically revert back to the CRA, subject to the rights of the County set forth in the Declaration and Settlement Agreement and pending the selection of another Developer as set forth therein (the "Reverter Property"). F. The Developer shall be liable to the County and the CRA for all reasonable attorneys fees and costs incurred by the County and the CRA as a result of a Developer Default. 8. Reverter RFP. In the event any portion of the Property reverts to the CRA, the CRA shall issue a new Developer Opportunity with respect to the Reverter Property, in accordance with Section. 3 of the Declaration, within ninety (90) days from the date the CRA acquires the Reverter Property, and shall provide Notice to the County of the Developer selected for its Approval as set forth herein and in the Settlement Agreement. In the event the Board of County Commissioners rejects the Developer selected by the CRA within the new Approval Period, the CRA shall issue a new Developer Opportunity within thirty (30) days from the date of such rejection. The process shall continue until the Developer is approved or deemed approved by the Board of County Commissioners. The CRA shall enter into a Development Agreement with the Developer approved or deemed approved by the Board of County Commissioners within ninety (90) days of the date the Developer is approved or deemed approved by the Board of County Commissioners. If the CRA does not enter into the .Development Agreement with the Developer approved or deemed approved by the Board of County Commissioners within the ninety (90) day period, the CRA shall terminate negotiations with such Developer and issue a New Developer Opportunity within thirty (30) days of the end of such ninety (90) day period. The new Developer shall be bound by the terms of this Declaration. To the extent that any portion of the Property reverts to the CRA after seven (7) years from the date of this Declaration, then, in such event, if such portion of the Property that 4 reverts to the CRA consists of any portions of Block 36, same shall automatically revert from the CRA to the County without any further action required by the CRA, free and clear of all claims by the CRA and free and clear of this Declaration. If requested by the County, the CRA shall convey such portion of the Property to the County by special warranty deed. Notwithstanding the foregoing, if the Parking Component has been completed, title to any portion of Block 36 which has not been developed shall remain vested in the CRA subject to this Declaration. 9. Notwithstanding any other provision set forth herein, in the event that vertical construction (defined as physical structures actually being constructed on the Property in accordance with an approved site plan) has not commenced on the Property within three years from the Effective Date, the Property shall revert to the County upon written notice by the County to the Executive Director of the CRA at any time prior to the commencement of the vertical construction. If requested by the County, the CRA and the Developer shall provide the County with a special warranty deed transferring all title and interest in and to the Property to the County, free and clear of all claims and encumbrances and free and clear of this Declaration, which the County shall record. In such event this Declaration shall terminate upon the recording of the special warranty deed. 10. Modification, Provided that the Developer is not in default beyond the applicable grace periods and is current with all of its payment obligations to the CRA and the County, this Declaration may be modified, amended or released with respect to the Property, or any portion thereof, by written instrument executed and recorded by the then owner(s) of the fee simple title to the Property, the CRA and the County with the approval of the respective Boards of the CRA and the County. Notwithstanding the foregoing, the Executive Director of the CRA (the "Executive Director") may unilaterally, without the consent of the County being required, modify this Declaration with respect to the following quantifiable requirements, by an amount not to exceed 25 percent of such number or 25 percent of such percentages, as follows: (a) the number of parking spaces in Section 2; (b) the time frames set forth in Sections 5 and 6; and (c) the number of retail square feet in Section 2. Additionally, the Executive Director may modify this Declaration in any other non -substantive manner without the consent of the County, provided such modifications are in writing. Any modifications, amendments, or releases shall be evidenced by a recorded amendment to this Declaration executed by all required parties thereto. 11. No Limitation of Remedies. Nothing contained herein shall be construed as limiting the rights and remedies of the County, the City or the CRA set forth in the Settlement Agreement. 12. County Inspection. Prior to completion of construction of the Project, the County and the CRA shall have the right, but not the obligation, at any time during normal business hours, to enter and inspect the Property to determine whether the requirements of this Declaration are being complied to by the Developer. 13. Covenant Running with the Land. This Declaration shall constitute a covenant running with the land and shall be binding on the CRA and its successors and assigns having an interest in the Property. This Declaration is for the benefit of, and limitation upon, all. present and future owners of the Property and for the benefit of the County and the CRA. 5 14. Term. This Declaration is to run with the land for a period of thirty (30) years and shall be automatically extended for additional ten (10) year periods until thirty (30) years from the issuance of the last temporary certificate of occupancy (or its equivalent) for the last building comprising the Project. 15. The CRA and the County acknowledges that the time frames and development requirements of the Declaration represent the reasonable opinion of the CRA and the County as to what may reasonably be developed on the Property within the time frames set forth in the Declaration. In the event the Developer selected by the CRA in response to the Developer Opportunity proposed variance from the requirements of the Declaration, which variances have been approved by the Board of Commissioners of the CRA in light of market conditions and information provided by the Developer, the Board of County Commissioners shall consider such variances at the time the Board of County Commissioners is requested by the CRA to approve the Developer and such variances shall be outlined to the County in the Notice to the County. The County agrees to reasonably consider such variances at the time it acts on the approval of the Developer, with no obligation on the part of the Board of County Commissioners to approve any such variances from the Declaration. If the Board of County Commissioners approves the Developer and some or all of the variances requested by the Developer, the County and the CRA shall execute an amendment to the Declaration to reflect the variances approved by the Board of County Commissioners. [SIGNATURE PAGES TO FOLLOW] 6 IN WITNESS THEREOF the County and the CRA have executed this Declaration as of the date first above written. Witnesses: CRA: Southeast Overtown/Park West Community Redevelopment Agency, a public agency and body corporate created pursuant to Section 1 63 .3 5 6, Florida Statutes By: Printed Name: Clarence E. Woods, III Executive Director Printed Name: ATTEST: Clerk of the Board Approved for legal sufficiency By: William R. Bloom, Esq. Holland & Knight LLP Special Counsel Witnesses: COUNTY: Printed Name: Printed Name: MIAMI-DADE COUNTY, a political subdivision of the State of Florida By: ATTEST: Harvey Ruvin, Clerk By: Deputy Clerk Approved for legal sufficiency County Attorney By: 7 STATE OF FLORIDA ) ss. COUNTY OF MIAMI-DADE ) The foregoing instrument was acknowledged before me this , 2012, by Clarence E. Woods, III, Executive Director Overtown/Park West Community Redevelopment Agency, on behalf of the personally known to me or has produced identification. (SEAL) day of of the Southeast Agency. He is as Notary Public -State of Commission Number: 8 Exhibit 1 Legal Description Block 36, Lots 1 through 11 inclusive, less the West 40 feet of Lot 11; the North 15.4 feet of Lot 12, less the East 11 feet of the North 15.4 feet of Lot 12; The South 9.8 feet of Lot 12, less the East 11 feet of Lot 12; Lot 13 through 19 inclusive, Less the West 40 feet of Lots 11, 14, 19 and less the East 11 feet of Lot 13; Lots 22 through 27 inclusive, less the West 40 feet of Lots 22 and 27; Lots 30 through 35 inclusive, Less the West 40 feet of Lots 30 and 35; The South 10 feet of Lot 36 and the North 20 feet of Lot 37, less the West 7.5 feet thereof; The South 5 feet of Lot 37, Lots 38 through 43 inclusive, less the West 40 feet of Lots 38 and 43; Lots 44 and 45 inclusive, Less the West 7.5 feet thereof; Lot 46 Less the West 40 feet thereof; and Lots 47 and 48 inclusive, Less that portion of Lots 1, 8, 9, 16, 17, 24, 32, 33, 40, 41 and 48 for RAPID TRANSIT R/W, All of Block 36, of "P.W. WHITES RE -SUB.", according to the Plat thereof as recorded in Plat Book "B", at Page 34, of the Public Records of Miami -Dade County, Florida. 9 EXHIBIT D CRA Release of County and City RELEASE (Release by the CRA) KNOW ALL MEN BY THESE PRESENTS that the SOUTHEAST OVERTOWN/PARK WEST COMMUNITY REDEVELOPMENT AGENCY, a public agency and body corporate created pursuant to Section 163.356, Florida Statutes (the "CRA") for and in consideration of Ten and 00/100 Dollars ($10.00), and other good and valuable consideration, received from or on behalf of the CITY OF MIAMI, a Florida municipal corporation (the "City") and MIAMI-DADE COUNTY, FLORIDA, a political subdivision of the State of Florida (the "County") and, the receipt and adequacy of which is hereby acknowledged, remises, releases, acquits, satisfies, and forever discharges the City and the County and each of their respective officers, directors, commissioners, agents and employees (collectively, the "Released Parties") of and from all, and all manner of action and actions, cause and causes of action, suits, debts, dues, sums of money, accounts, agreements, promises, damages, judgments, executions, claims and demands whatsoever, in law or in equity, which the CRA ever had, now has, or which the CRA hereafter can, shall or may have, against said Released Parties, for, upon or by reason of any matter, cause or thing whatsoever, from the beginning of the world to the date of these presents relating to or arising out of, directly or indirectly: (i) Matters raised and the matters that could have been raised in the action styled City of Miami, et al. vs. Miami -Dade County Case No. 07-46851 CA 31, filed in the 1 lth Judicial Circuit in and for Miami -Dade County, Florida. (ii) Matters raised and matters that could have been raised in the action styled Miami - Dade County, Plaintiff vs. City of Miami and Southeast Overtown/Park West Community Redevelopment Agency, Defendants, Case No. 01-13810 CA 08, filed in the llth Judicial Circuit in and for Miami -Dade County, Florida. This Release is executed in accordance with the terms of that Settlement Agreement dated , 2012 by and between the County, the City and the CRA (the "Settlement Agreement"). This Release shall not release the Released Parties from their respective obligations under the Settlement Agreement or the Declaration of Restrictions executed in connection therewith, which obligations are not subject to this Release. The CRA hereby represents and warrants that the CRA is not relying upon any statements or representations (whether express or implied) of the Released Parties, their employees and attorneys regarding this Release and that the CRA is entering into this Release under their own free will believing that this Release to be in its best interest. The terms of this release are contractual and not a mere recital. This Release shall be governed by and construed in accordance with the laws of the State of Florida. IN WITNESS WHEREOF, the CRA has executed this Release this day of , 2012. SOUTHEAST OVERTOWN/PARK WEST COMMUNITY REDEVELOPMENT AGENCY, a public agency and body corporate created pursuant to Section 163.356, Florida Statutes By: Clarence E. Woods, III Executive Director Approved as to Form and Correctness Attest: Holland & Knight LLP, Special Counsel Priscilla A. Thompson, Clerk of the Board 2 EXHIBIT E BLOCK 25 DECLARATION OF RESTRICTIVE COVENANT This Instrument was prepared by Debra Herman, Esq. Miami -Dade County Attorney Office Stephen P. Clark Center 111 N. W. 1st Street Suite 2800 Miami, Florida 33128 DECLARATION OF RESTRICTIONS THIS DECLARATION OF RESTRICTIONS (the "Declaration") is made as of , 2012 by and between Miami -Dade County, Florida, a political subdivision of the State of Florida (the "County") and the Southeast Overtown/Park West Community Redevelopment Agency, a public agency and body corporate to Section 163.356, Florida Statutes (the "CRA"). RECITALS D. The CRA is the owner of that certain real property legally described on Exhibit "A" attached hereto (the "Property"). E. In accordance with the terms of the settlement agreement dated as of , 2012 by and between the City of Miami, a municipal corporation (the "City"), the County and the CRA (the "Settlement Agreement"), the CRA has agreed to impose certain restrictions on the Property, as hereinafter provided. NOW THEREFORE, in consideration of the foregoing and other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the County and the CRA, as the current owners of the Property, agree as follows: 1. Recitals. The recitals to the Declaration are true and correct and incorporated herein by reference. 2. Development Restrictions. The CRA and the County agree that the Property shall be developed in two phases. Phase I shall consist of between 90-100 affordable rental units with approximately 5,000 square feet of commercial space along Northwest 2nd Avenue and a sufficient number of parking spaces to comply with the applicable zoning ("Phase I"). Phase II shall consist of approximately 80-120 residential units with a sufficient number of 3 parking spaces to comply with the applicable zoning ("Phase II; together with Phase I, the "Project"). 3. Residential Restrictions on Phase I. The CRA and the County agree that: not less than fifty percent (50%) of the residential units shall be made available for rent to individuals and/or families whose gross income is sixty percent (60%) or below AMI and the balance of the residential units will be made available for rent to individuals and/or families whose gross income is one hundred twenty percent (120%) or below AMI. "AMP shall mean the median family income for Miami -Dade County as published annually by the U.S. Department of Housing and Urban Development. 4. Selection of Developer. The CRA has selected Gatehouse Group, LLC, a Massachusetts limited liability company ("Gatehouse") to develop the Project after conducting a solicitation in accordance with Section 163.380, Florida Statutes. If the CRA and Gatehouse, or its affiliate, are not able to finalize the development agreement for the Property on terms acceptable to the CRA on or before thirty (30) days from the date hereof, the CRA shall terminate negotiations with Gatehouse and within thirty (30) days from the date the CRA terminates negotiations with Gatehouse, the CRA shall conduct a solicitation, in accordance with Section 163.380, Florida Statutes, (the "Developer Opportunity") to select a developer for the Project. The CRA shall within five (5) days of selection of the Developer by the Board of Commissioners of the CRA, advise the County by hand delivery or certified mail, return receipt requested, addressed to the County Mayor, or its designee (the "Notice") of the Developer selected by the CRA pursuant to the Developer Opportunity. The County shall have no approval rights with respect to the Developer selected by the CRA pursuant to the Developer Opportunity. The Developer Opportunity shall require the Developer to diligently pursue development of the Project and require the Developer to comply with the terms and provisions of this Declaration. 5. Development Agreement. The CRA shall enter into a development agreement (the "Development Agreement") with the Developer, approved by the Board of Commissioners of the CRA within ninety (90) days from the date the Developer is approved by the Board of Commissioners of the CRA in accordance with the Developer Opportunity. If the CRA does not enter into the Development Agreement with the Developer approved by the Board of Commissioners of the CRA within the ninety (90) day period, the CRA shall terminate negotiations with such Developer and issue a new Developer Opportunity within thirty (30) days from the end of such ninety (90) day period. The CRA shall continue the process until a Development Agreement is executed between the Developer and the CRA. If the Development Agreement is terminated at any time after it is executed and prior to Completion, as hereinafter defined, the CRA shall within thirty (30) days thereafter issue a new Developer Opportunity. 6. Approvals. The Developer shall obtain all applicable land use and zoning approvals for Phase I (the "Approvals") within twelve months from the later to occur of (i) execution of the Development Agreement by the CRA and the Developer or (ii) the date the Board of Commissioners of the CRA approves ("Bond Issue Approval") the terms of a loan (the "CRA Bond Issue") to be obtained by the CRA which shall be secured by tax increment revenues in accordance with the authorization obtained from the County pursuant to Resolution 4 7. Construction of Phase I. A. The Developer must commence vertical construction (defined as physical structures actually being constructed on the Property in accordance with an approved site plan) of Phase I within twenty four (24) months of the Effective Date. The Developer must substantially complete construction of Phase I within twenty-four (24) months from commencement of vertical construction (the "Completion Date"). Completion Date shall be evidenced by one or more temporary or permanent certificates of occupancy (or their equivalent) for all buildings comprising Phase I. The Completion Date shall automatically be extended one day for each day of Unavoidable Delay, The term "Unavoidable Delays" shall mean delays beyond the control of the Developer (other than delays in connection with obtaining licenses, permits and approvals from any governmental authority relating to the Project) including, without limitation, civil commotion, war, invasion, rebellion, hostility, military or usurped power, sabotage, insurrection, strikes or lockouts on an area wide basis and not specific to the Project, riots, hurricanes, floods, earthquakes, casualties, acts of the public enemy, epidemics, quarantines, restrictions, embargos and area wide governmental restrictions. B. If the Developer fails to achieve completion of Phase I by the Completion Date, Developer shall pay to the CRA One Thousand and No/100 Dollars ($1,000.00) per day thereafter until completion of Phase I. C. Prior to commencing vertical construction of Phase I the Developer shall provide to the CRA a payment and performance bond in form and substance satisfactory to the CRA in amount equal to one hundred percent (100%) of the construction costs for Phase I, which shall be issued by a surety having a credit rating of "A" or higher with a financial strength of X or higher. 8. Construction of Phase II. A. The Developer must commence vertical construction (defined as physical structures actually being constructed on the Property in accordance with an approved site plan) of Phase II within seventy-two (72) months of the Effective Date. The Developer must substantially complete construction of Phase II within thirty-six (36) months from commencement of vertical construction (the "Phase II Completion Date"). Phase II Completion Date shall be evidenced by one or more temporary or permanent certificates of occupancy (or their equivalent) for all buildings comprising Phase II. The Phase II Completion Date shall automatically be extended one day for each day of Unavoidable Delay. B. If the Developer fails to achieve completion of Phase II by the Phase II Completion Date, Developer shall pay to the CRA One Thousand and No/100 Dollars ($1,000.00) per day thereafter until completion of Phase II. C. Prior to commencing vertical construction of Phase II the Developer shall provide to the CRA a payment and performance bond in form and substance satisfactory to the CRA in amount equal to one hundred percent (100%) of the construction costs for Phase II, which shall be issued by a surety having a credit rating of "A" or higher with a financial strength of X or higher. 5 9. Developer Default. A. In the event the Developer (i) has not obtained the Approvals in the timeframe provided in Section 6 of this Declaration; (ii) fails to commence vertical construction of Phase I within the timeframe provided in Section 7 of this Declaration or (iii) fails to commence vertical construction of Phase II within the timeframe provided in Section 8 of this Declaration, as same may be extended as a result of Unavoidable Delays, the CRA may declare the Developer in default by sending a Notice of Default (the "Default Notice"). The Default Notice shall be hand delivered to the Developer or mailed to the Developer by certified mail, return receipt requested. The Default Notice shall be deemed delivered upon the date received if hand delivered, or if mailed, on the date the return receipt is executed or the date delivery is refused. Upon receipt, or deemed receipt, of the Default Notice, the Developer shall have ninety (90) days to cure (the "Default Cure Period"). Extensions of the Default Cure Period for good cause shown shall be in the sole discretion of the CRA. B. In the event the Default Notice is issued pursuant to Section 9(A)(i) or (ii) of this Declaration, and is not cured prior to the end of the Default Cure Period, as same may be extended in accordance with the last sentence of Section 9(A), the Developer shall be in default under this Declaration and the Development Agreement and the CRA shall have the right to terminate the Development Agreement and proceed in accordance with Section 10. C. In the event the Default Notice is issued pursuant to Section 9(A)(iii) of this Declaration, and is not cured prior to the end of the Default Cure Period, as same may be extended in accordance with the last sentence of Section 9(A), the Developer shall be in default under this Declaration and the Development Agreement and the CRA shall have the right to terminate the Development Agreement with respect to Phase II and proceed in accordance with Section 10 with respect to Phase II. 10. New Developer Opportunity. In the event that the Development Agreement is terminated for any reason, the CRA shall issue a new Developer Opportunity with respect to the Property, in accordance with Section 4 of the Declaration, within thirty (30) days from the date the CRA terminates the Development Agreement, and shall provide Notice to the County of the Developer selected by the CRA in accordance with Section 4. The CRA shall enter into a Development Agreement with the Developer approved by the Board of Commissioners of the CRA within ninety (90) days of the date the Developer is approved by the Board of Commissioners of the CRA. If the CRA does not enter into the Development Agreement with the Developer approved by the Board of Commissioners of the CRA within the ninety (90) day period, the CRA shall terminate negotiations with such Developer and issue a new Developer Opportunity within thirty (30) days of the end of such ninety (90) day period. The new Developer shall be bound by the terms of this Declaration. 11. Modification. This Declaration may be modified, amended or released with respect to the Property, or any portion thereof, by written instrument executed and recorded by the then owner(s) of the fee simple title to the Property, the CRA and the County with the approval of the respective Boards of the CRA and the County. Notwithstanding the foregoing, the Executive Director of the CRA (the "Executive Director") may unilaterally, without the 6 consent of the County being required, modify this Declaration with respect to the following quantifiable requirements, by an amount not to exceed 25 percent of such number or 25 percent of such percentages, as follows: (a) the time frames set forth in Sections 6, 7 and 8; and (c) the number of residential units in Section 2. Additionally, the Executive Director may modify this Declaration in any other non -substantive manner without the consent of the County, provided such modifications are in writing. Any modifications, amendments, or releases shall be evidenced by a recorded amendment to this Declaration executed by all required parties thereto. 12. No Limitation of Remedies. Nothing contained herein shall be construed as limiting the rights and remedies of the County, the City or the CRA set forth in the Settlement Agreement. 13. County Inspection. Prior to completion of construction of the Project, the County and the CRA shall have the right, but not the obligation, at any time during normal business hours, to enter and inspect the Property to determine whether the requirements of this Declaration are being complied to by the Developer. 14. Covenant Running with the Land. This Declaration shall constitute a covenant running with the land and shall be binding on the CRA and its successors and assigns having an interest in the Property. This Declaration is for the benefit of, and limitation upon, all present and future owners of the Property and for the benefit of the County and the CRA. 15. Term. This Declaration is to run with the land until March 30, 2030 at which time it will be of no further force and effect. [SIGNATURE PAGES TO FOLLOW] 7 IN WITNESS THEREOF the County and the CRA have executed this Declaration as of the date first above written. Witnesses: CRA: Southeast Overtown/Park West Community Redevelopment Agency, a public agency and body corporate created pursuant to Section 1 63 .3 5 6, Florida Statutes By: Printed Name: Clarence E. Woods, III Executive Director Printed Name: ATTEST: Clerk of the Board Approved for legal sufficiency By: William R. Bloom, Esq. Holland & Knight LLP Special Counsel Witnesses: COUNTY: Printed Name: Printed Name: 8 MIAMI-DADE COUNTY, a political subdivision of the State of Florida By: ATTEST: Harvey Ruvin, Clerk By: Deputy Clerk Approved for legal sufficiency County Attorney By: STATE OF FLORIDA ) ss. COUNTY OF MIAMI-DADE The foregoing instrument was acknowledged before me this day of , 2012, by Clarence E. Woods, III, Executive Director of the Southeast Overtown/Park West Community Redevelopment Agency, on behalf of the Agency. He is personally known to me or has produced as identification. (SEAL) Notary Public -State of Commission Number: 9 Exhibit "A" Legal Description Lots 5 through 17, inclusive, less the West 7.5 feet of the South 50 feet of Lot 10, all of Block 25, of NORTH, CITY OF MIAMI, according to the Plat thereof as recorded in Plat Book B, Page 41, of the Public Records of Miami - Dade County, Florida. 10 EXHIBIT F BLOCK 9 DECLARATION OF RESTRICTIVE COVENANT This Instrument was prepared by Debra Herman, Esq. Miami -Dade County Attorney Office Stephen P. Clark Center 111 N. W. 1st Street Suite 2800 Miami, Florida 33128 DECLARATION OF RESTRICTIONS THIS DECLARATION OF RESTRICTIONS (the "Declaration") is made as of , 2012 by and between Miami -Dade County, Florida, a political subdivision of the State of Florida (the "County") and the Southeast Overtown/Park West Community Redevelopment Agency, a public agency and body corporate to Section 163.356, Florida Statutes (the "CRA"). RECITALS F. The CRA is the owner of that certain real property legally described on Exhibit "A" attached hereto (the "Property"). G. In accordance with the terms of the settlement agreement dated as of , 2012 by and between the City of Miami, a municipal corporation (the "City"), the County and the CRA (the "Settlement Agreement"), the CRA has agreed to impose certain restrictions on the Property, as hereinafter provided. NOW THEREFORE, in consideration of the foregoing and other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the County and the CRA, as the current owners of the Property, agree as follows: 1. Recitals. The recitals to the Declaration are true and correct and incorporated herein by reference, 2. Development Restrictions. The CRA and the County agree that the Property shall be developed as residential housing project consisting of not less than seventy (70) affordable units and approximately 5,000 square feet of ground floor commercial space with a sufficient number of parking spaces to comply with applicable zoning (the "Project"). 3. Residential Restrictions. The CRA and the County agree that: not less than fifty percent (50%) of the residential units shall be made available for individuals and/or 11 families whose gross income is sixty percent (60%) or below AMI and the balance of the residential units will be made available for individuals and/or families whose gross income is one hundred twenty percent (120%) or below AMI. "AMI" shall mean the median family income for Miami -Dade County as published annually by the U.S. Department of Housing and Urban Development. 4. Selection of Developer. The CRA has selected Carlisle Development Group, LLC, a Florida limited liability company ("Carlisle") to develop the Project after conducting a solicitation in accordance with Section .163.380, Florida Statutes. If the CRA and Carlisle, or its affiliate, are not able to finalize the development agreement for the Property on terms acceptable to the CRA on or before thirty (30) days from the date hereof, the CRA. shall terminate negotiations with Carlisle and within thirty (30) days from the date the CRA terminates negotiations with Carlisle, the CRA shall conduct a solicitation, in accordance with Section 163.380, Florida Statutes, (the "Developer Opportunity") to select a developer for the Project. The CRA shall within five (5) days of selection of the Developer by the Board of Commissioners of the CRA, advise the County by hand delivery or certified mail, return receipt requested, addressed to the County Mayor, or its designee (the "Notice") of the Developer selected by the CRA pursuant to the Developer Opportunity. The County shall have no approval rights with respect to the Developer selected by the CRA pursuant to the Developer Opportunity. The Developer Opportunity shall require the Developer to diligently pursue development of the Project and require the Developer to comply with the terms and provisions of this Declaration. 5. Development Agreement. The CRA shall enter into a development agreement (the "Development Agreement") with the Developer, approved by the Board of Commissioners of the CRA within ninety (90) days from the date the Developer is approved by the Board of Commissioners of the CRA in accordance with the Developer Opportunity. If the CRA does not enter into the Development Agreement with the Developer approved by the Board of Commissioners of the CRA within the ninety (90) day period, the CRA shall terminate negotiations with such Developer and issue a new Developer Opportunity within thirty (30) days from the end of such ninety (90) day period. The CRA shall continue the process until a Development Agreement is executed between the Developer and the CRA. If the Development Agreement is terminated at any time after it is executed and prior to Completion, as hereinafter defined, the CRA shall within thirty (30) days thereafter issue a new Developer Opportunity. 6. Approvals. The Developer shall obtain all applicable land use and zoning approvals for the Project (the "Approvals") within twelve months from the later to occur of (i) execution of the Development Agreement by the CRA and the Developer or (ii) the date the Board of Commissioners of the CRA approves ("Bond Issue Approval") the terms of a loan (the "CRA Bond Issue") to be obtained by the CRA which shall be secured by tax increment revenues in accordance with the authorization obtained from the County pursuant to Resolution 7. Construction. A. The Developer must commence vertical construction (defined as physical structures actually being constructed on the Property in accordance with an approved site plan) within twenty four (24) months of the Effective Date. The Developer must 12 substantially complete construction of the Project within twenty-four (24) months from commencement of vertical construction (the "Completion Date"). Completion Date shall be evidenced by one or more temporary or permanent certificates of occupancy (or their equivalent) for all buildings comprising the Project. The Completion Date shall automatically be extended one day for each day of Unavoidable Delay. The term "Unavoidable Delays" shall mean delays beyond the control of the Developer (other than delays in connection with obtaining licenses, permits and approvals from any governmental authority relating to the Project) including, without limitation, civil commotion, war, invasion, rebellion, hostility, military or usurped power, sabotage, insurrection, strikes or lockouts on an area wide basis and not specific to the Project, riots, hurricanes, floods, earthquakes, casualties, acts of the public enemy, epidemics, quarantines, restrictions, embargos and area wide governmental restrictions. B. If the Developer fails to achieve Completion by the Completion Date, Developer shall pay to the CRA One Thousand and No/100 Dollars ($1,000.00) per day thereafter until Completion. C. Prior to commencing vertical construction the Developer shall provide to the CRA a payment and performance bond in form and substance satisfactory to the CRA in amount equal to one hundred percent (100%) of the constructions costs for the Project, which shall be issued by a surety having a credit rating of "A" or higher with a financial strength of X or higher (the "Payment and Performance Bond"). 8. Developer Default. A. In the event the Developer (i) has not obtained the Approvals in the timeframe provided in Section 6 of this Declaration or (ii) fails to commence vertical construction within the timeframe provided in Section 7 of this Declaration, as same may be extended as a result of Unavoidable Delays, the CRA may declare the Developer in default by sending a Notice of Default (the "Default Notice"). The Default Notice shall be hand delivered to the Developer or mailed to the Developer by certified mail, return receipt requested. The Default Notice shall be deemed delivered upon the date received if hand delivered, or if mailed, on the date the return receipt is executed or the date delivery is refused. Upon receipt, or deemed receipt, of the Default Notice, the Developer shall have ninety (90) days to cure (the "Default Cure Period"). Extensions of the Default Cure Period for good cause shown shall be in the sole discretion of the CRA. B. In the event the Default Notice is issued pursuant to Section 8(A)(i) or (ii) of this Declaration, and is not cured prior to the end of the Default Cure Period, as same may be extended in accordance with the last sentence of Section 8(A), the Developer shall be in default under this Declaration and the Development Agreement and the CRA shall have the right to terminate the Development Agreement and proceed in accordance with Section 9. 9. New Developer Opportunity. In the event that the Development Agreement is terminated for any reason, the CRA shall issue a new Developer Opportunity with respect to the Property, in accordance with Section 4 of the Declaration, within thirty (30) days from the date the CRA terminates the Development Agreement, and shall provide Notice to the County of the Developer selected by the CRA in accordance with Section 4. The CRA shall enter 13 into a Development Agreement with the Developer approved by the Board of Commissioners of the CRA within ninety (90) days of the date the Developer is approved by the Board of Commissioners of the CRA. If the CRA does not enter into the Development Agreement with the Developer approved by the Board of Commissioners of the CRA within the ninety (90) day period, the CRA shall terminate negotiations with such Developer and issue a new Developer Opportunity within thirty (30) days of the end of such ninety (90) day period. The new Developer shall be bound by the terms of this Declaration. 10. Modification. This Declaration may be modified, amended or released with respect to the Property, or any portion thereof, by written instrument executed and recorded by the then owner(s) of the fee simple title to the Property, the CRA and the County with the approval of the respective Boards of the CRA and the County. Notwithstanding the foregoing, the Executive Director of the CRA (the "Executive Director") may unilaterally, without the consent of the County being required, modify this Declaration with respect to the following quantifiable requirements, by an amount not to exceed 25 percent of such number or 25 percent of such percentages, as follows: (a) the time frames set forth in Sections 5 and 6; and (c) the number of residential units in Section 2. Additionally, the Executive Director may modify this Declaration in any other non -substantive manner without the consent of the County, provided such modifications are in writing. Any modifications, amendments, or releases shall be evidenced by a recorded amendment to this Declaration executed by all required parties thereto. 11. No Limitation of Remedies. Nothing contained herein shall be construed as limiting the rights and remedies of the County, the City or the CRA set forth in the Settlement Agreement. 12. County Inspection. Prior to completion of construction of the Project, the County and the CRA shall have the right, but not the obligation, at any time during normal business hours, to enter and inspect the Property to determine whether the requirements of this Declaration are being complied to by the Developer. 13. Covenant Running with the Land. This Declaration shall constitute a covenant running with the land and shall be binding on the CRA and its successors and assigns having an interest in the Property. This Declaration is for the benefit of, and limitation upon, all present and future owners of the Property and for the benefit of the County and the CRA. 14. Term. This Declaration is to run with the land until March 30, 2030 at which time it will be of no further force and effect. [SIGNATURE PAGES TO FOLLOW] 14 IN WITNESS THEREOF the County and the CRA have executed this Declaration as of the date first above written. Witnesses: CRA: Southeast Overtown/Park West Community Redevelopment Agency, a public agency and body corporate created pursuant to Section 163.356, Florida Statutes By: Printed Name: Clarence E. Woods, III Executive Director Printed Name: ATTEST: Clerk of the Board Approved for legal sufficiency By: William R. Bloom, Esq. Holland & Knight LLP Special Counsel Witnesses: COUNTY: MIAMI-DADE COUNTY, a political subdivision of the State of Florida Printed Name: Printed Name: By: ATTEST: Harvey Ruvin, Clerk By: Deputy Clerk Approved for legal sufficiency County Attorney By: 15 STATE OF FLORIDA ) ss. COUNTY OF MIAMI-DADE The foregoing instrument was acknowledged before me this , 2012, by Clarence E. Woods, III, Executive Director Overtown/Park West Community Redevelopment Agency, on behalf of the personally known to me or has produced identification. (SEAL) day of of the Southeast Agency. He is as Notary Public -State of Commission Number: 16 Exhibit "A" Legal Description Lots 8, 9, 10, and 11, Block 9, SOST'S Subdivision, according to the Plat thereof, as recorded in Plat Book "B", at Page 27, of the Public Records of Miami -Dade County, Florida. 17 #11366155_v3 Exhibit "G" City Release of County and CRA RELEASE (Release by the City) KNOW ALL MEN BY THESE PRESENTS that the CITY OF MIAMI, a Florida municipal corporation (the "City") for and in consideration of Ten and 00/100 Dollars ($10.00), and other good and valuable consideration, received from or on behalf of MIAMI-DADE COUNTY, FLORIDA, a political subdivision of the State of Florida (the "County") and SOUTHEAST OVERTOWN/PARK WEST COMMUNITY REDEVELOPMENT AGENCY, a public agency and body corporate created pursuant to Section 163.356, Florida Statutes (the "CRA"), the receipt and adequacy of which is hereby acknowledged, remises, releases, acquits, satisfies, and forever discharges the CRA and the County and each of their respective officers, directors, commissioners, agents and employees (collectively, the "Released Parties") of and from all, and all manner of action and actions, cause and causes of action, suits, debts, dues, sums of money, accounts, agreements, promises, damages, judgments, executions, claims and demands whatsoever, in law or in equity, which the City ever had, now has, or which the City hereafter can, shall or may have, against said Released Parties, for, upon or by reason of any matter, cause or thing whatsoever, from the beginning of the world to the date of these presents relating to or arising out of, directly or indirectly: (i) Matters raised and the matters that could have been raised in the action styled City of Miami, et al. vs. Miami -Dade County Case No. 07-46851 CA 31, filed in the l lth Judicial Circuit in and for Miami -Dade County, Florida. (ii) Matters raised and matters that could have been raised in the action styled Miami - Dade County, Plaintiff vs. City of Miami and Southeast Overtown/Park West Community Redevelopment Agency, Defendants, Case No. 01-13810 CA08, filed in the 1 lth Judicial Circuit in and for Miami -Dade County, Florida. This Release is executed in accordance with the terms of that Settlement Agreement dated , 2012 by and between the County, the City and the CRA (the "Settlement Agreement"). This Release shall not release the Released Parties from their respective obligations under the Settlement Agreement or the Declaration of Restrictions executed in connection therewith, which obligations are not subject to this Release. The City hereby represents and warrants that the City is not relying upon any statements or representations (whether express or implied) of the Released Parties, their employees and attorneys regarding this Release and that the City is entering into this Release under their own free will believing that this Release to be in its best interest. The terms of this release are contractual and not a mere recital. 18 This Release shall be governed by and construed in accordance with the laws of the State of Florida. IN WITNESS WHEREOF, the City has executed this Release this day of , 2012. CITY OF MIAMI, FLORIDA, a municipal corporation of the State of Florida By: Johnny Martinez City Manager Approved as to Form and Correctness Attest: Julie O. Bru, City Attorney Priscilla A. Thompson, City Clerk 19 Prepared by: William R. Bloom, Esq. Holland & Knight LLP 701 Brickell Avenue, Suite 3000 Miami, FL 33131 EXHIBIT H City Deed QUIT CLAIM DEED THIS DEED, made this day of , 2012, between the CITY OF MIAMI, FLORIDA, a municipal corporation of the State of Florida (the "Grantor") and SOUTHEAST OVERTOWN/PARK WEST COMMUNITY REDEVELOPMENT AGENCY, a public agency and body corporate created pursuant to Section 163.356, Florida Statutes (the "Grantee") whose address is 49 NW 5th Street, Suite 100, Miami, FL 33128, Attention: Pieter Bockweg, Executive Director. WITNES SETH: The Grantor for and in consideration of the sum of Ten Dollars ($10.00) to it in hand pay the Grantee, receipt of which is hereby acknowledged, and other good and valuable consideration, does hereby grant, bargain and sell to the Grantee, its successors and assigns forever, all right, title and interest, if any, of the Grantor in and to the following land situate, lying and being in Miami -Dade County, Florida. See Exhibit "A" attached hereto and made a part hereof (the "Property") This Quit Claim Deed is given in accordance with the terms and conditions of that Settlement Agreement (the "Settlement Agreement") dated , 2012 by and between Grantor, Grantee and Miami -Dade County, a political subdivision of the State of Florida (the "County") and is intended to release all of Grantor's right, title and interest, if any, in the Property without representation or warranty, express or implied, except that this Quit Claim Deed has been duly authorized and executed. 1 IN WITNESS WHEREOF, the said Grantor has signed and sealed these presents the day and year first above written. Signed, sealed and delivered in our presence: Print Name Print Name CITY OF MIAMI, FLORIDA, a municipal corporation of the State of Florida By: Johnny Martinez City Manager Approved as to Form and Correctness Attest: Julie O. Bru, City Attorney Priscilla A. Thompson, City Clerk STATE OF FLORIDA COUNTY OF MIAMI-DADE SS The foregoing instrument was acknowledged before me this _ day of 2012, by Johnny Martinez, as City Manager of the City of Miami, Florida, a municipal corporation of the State of Florida, on behalf of said municipal corporation. He is personally known to me or has produced as identification. NOTARY PUBLIC State of Florida at Large My Commission Expires: 2 EXHIBIT A Legal Description Block 36, Lots 1 through 11 inclusive, less the West 40 feet of Lot 11; the North 15.4 feet of Lot 12, less the East 11 feet of the North 15.4 feet of Lot 12; The South 9.8 feet of Lot 12, less the East 11 feet of Lot 12; Lot 13 through 19 inclusive, Less the West 40 feet of Lots 11, 14, 19 and less the East 11 feet of Lot 13; Lots 22 through 27 inclusive, less the West 40 feet of Lots 22 and 27; Lots 30 through 35 inclusive, Less the West 40 feet of Lots 30 and 35; The South 10 feet of Lot 36 and the North 20 feet of Lot 37, less the West 7.5 feet thereof; The South 5 feet of Lot 37, Lots 38 through 43 inclusive, less the West 40 feet of Lots 38 and 43; Lots 44 and 45 inclusive, Less the West 7.5 feet thereof; Lot 46 Less the West 40 feet thereof; and Lots 47 and 48 inclusive, Less that portion of Lots 1, 8, 9, 16, 17, 24, 32, 33, 40, 41 and 48 for RAPID 'TRANSIT R/W, All of Block 36, of "P.W. WHITES RE -SUB.", according to the Plat thereof as recorded in Plat Book `B", at Page 34, of the Public Records of Miami -Dade County, Florida. Lots 1 through 12 inclusive, Block 45, NORTH, CITY OF MIAMI, according to the Plat thereof as recorded in Plat Book `B" at Page 41 of the Public Records of Miami -Dade County, Florida. Lots 1 through 12 inclusive, Block 56, NORTH, CITY OF MIAMI, according to the Plat thereof, as recorded in Plat Book `B" at Page 41 of the Public Records of Miami -Dade County, Florida. 3 EXHIBIT I County Release of City and CRA POINCIANA/SAWYER'S WALK RELEASE (Release from County) KNOW ALL MEN BY THESE PRESENTS that MIAMI-DADE COUNTY, FLORIDA, a political subdivision of the State of Florida (the "County") for and in consideration of Ten and 00/100 Dollars ($10.00), and other good and valuable consideration, received from or on behalf of the CITY OF MIAMI, a Florida municipal corporation (the "City") and SOUTHEAST OVERTOWN/PARK WEST COMMUNITY REDEVELOPMENT AGENCY, a public agency and body corporate created pursuant to Section 163.356, Florida Statutes (the "CRA"), the receipt and adequacy of which is hereby acknowledged, remises, releases, acquits, satisfies, and forever discharges the CRA and the City and each of their respective officers, directors, commissioners, agents and employees (collectively, the "Released Parties") of and from all, and all manner of action and actions, cause and causes of action, suits, debts, dues, sums of money, accounts, agreements, promises, damages, judgments, executions, claims and demands whatsoever, in law or in equity, which the County ever had, now has, or which the County hereafter can, shall or may have, against said Released Parties, for, upon or by reason of any matter, cause or thing whatsoever, from the beginning of the world to the date of these presents relating to or arising out of, directly or indirectly: (i) Matters raised and the matters that could have been raised in the action styled City of Miami, et al. vs. Miami -Dade County Case No. 07-46851 CA 3.1, filed in the l lth Judicial Circuit in and for Miami -Dade County, Florida. (ii) Matters raised and matters that could have been raised in the action styled Miami - Dade County, Plaintiff vs. City of Miami and Southeast Overtown/Park West Community Redevelopment Agency, Defendants, Case No. 01-13810 CA08, filed in the l lth Judicial Circuit in and for Miami -Dade County, Florida. This Release is executed in accordance with the terms of that Settlement Agreement dated , 2012 by and between the County, the City and the CRA (the "Settlement Agreement"). This Release shall not release the Released Parties from their respective obligations under the Settlement Agreement or the Declaration of Restrictions executed in connection therewith, which obligations are not subject to this Release. The County hereby represents and warrants that the County is not relying upon any statements or representations (whether express or implied) of the Released Parties, their employees and attorneys regarding this Release and that the County is entering into this Release under their own free will believing that this Release to be in its best interest. The terms of this release are contractual and not a mere recital. This Release shall be governed by and construed in accordance with the laws of the State of Florida. 1 IN WITNESS WHEREOF, the County has executed this Release this day of , 2012. MIAMI-DADE COUNTY, FLORIDA, a MIAMI-DADE COUNTY, FLORIDA political subdivision of the State of Florida a political subdivision of the State of Florida By: Name: ATTEST: HARVEY RUVIN, CLERK By: Deputy Clerk Title: Approved by the County Attorney's Office as to form and legal sufficiency 2 Prepared by: William R. Bloom, Esq. Holland & Knight LLP 701 Brickell Avenue, Suite 3000 Miami, FL 33131 EXHIBIT J County Deed QUIT CLAIM DEED THIS DEED, made this — day of , 2012, between MIAMI-DADE COUNTY, FLORIDA, a political subdivision of the State of Florida (the "County") (the "Grantor") and SOUTHEAST OVERTOWN/PARK WEST COMMUNITY REDEVELOPMENT AGENCY, a public agency and body corporate created pursuant to Section 163.356, Florida Statutes (the "Grantee") whose address is 49 NW 5th Street, Suite 100, Miami, FL 33128, Attention: Pieter Bockweg, Executive Director. WITNESSETH: The Grantor for and in consideration of the sum of Ten Dollars ($10.00) to it in hand pay the Grantee, receipt of which is hereby acknowledged, and other good and valuable consideration, does hereby grant, bargain and sell to the Grantee, its successors and assigns forever, all right, title and interest, if any, of the Grantor in and to the following land situate, lying and being in Miami -Dade County, Florida. See Exhibit "A" attached hereto and made a part hereof (the "Property") This Quit Claim Deed is given in accordance with the terms and conditions of that Settlement Agreement (the "Settlement Agreement") dated , 2012 by and between Grantor, Grantee and Miami -Dade County, a political subdivision of the State of Florida (the "County") and is intended to release all of Grantor's right, title and interest, if any, in the Property, including, without limitation, any reversionary interests of Grantor in the Property, without representation or warranty, express or implied, except that this Quit Claim Deed has been duly authorized and executed. The Quit Claim Deed shall not release any rights of Grantor: (i) under the terms of that Declaration of Restrictions dated , 2012 by and between Grantor and Grantee; and (ii) under the terms of that Settlement Agreement entered in Case No. 07-46851 filed in the Circuit Court of the 1 lth Judicial Circuit in and for Miami -Dade County, Florida by and between Grantor, Grantee and the City of Miami. 1 IN WITNESS WHEREOF, the said Grantor has signed and sealed these presents the day and year first above written. MIAMI-DADE COUNTY, FLORIDA MIAMI-DADE COUNTY, FLORIDA, a a political subdivision of the State of Florida political subdivision of the State of Florida ATTEST: HARVEY RUVIN, CLERK By: Deputy Clerk 2 By: Name: Title: Approved by the County Attorney's Office as to form and legal sufficiency EXHIBIT A Legal Description Block 36, Lots 1 through 11 inclusive, less the West 40 feet of Lot 11; the North 15.4 feet of Lot 12, less the East 11 feet of the North 15.4 feet of Lot 12; The South 9.8 feet of Lot 12, less the East 11 feet of Lot 12; Lot 13 through 19 inclusive, Less the West 40 feet of Lots 11, 14, 19 and less the East 11 feet of Lot 13; Lots 22 through 27 inclusive, less the West 40 feet of Lots 22 and 27; Lots 30 through 35 inclusive, Less the West 40 feet of Lots 30 and 35; The South 10 feet of Lot 36 and the North 20 feet of Lot 37, less the West 7.5 feet thereof; The South 5 feet of Lot 37, Lots 38 through 43 inclusive, less the West 40 feet of Lots 38 and 43; Lots 44 and 45 inclusive, Less the West 7.5 feet thereof; Lot 46 Less the West 40 feet thereof; and Lots 47 and 48 inclusive, Less that portion of Lots 1, 8, 9, 16, 17, 24, 32, 33, 40, 41 and 48 for RAPID TRANSIT R/W, All of Block 36, of "P.W. WHITES RE -SUB.", according to the Plat thereof as recorded in Plat Book `B", at Page 34, of the Public Records of Miami -Dade County, Florida. Lots 1 through 12 inclusive, Block 45, NORTH, CITY OF MIAMI, according to the Plat thereof as recorded in Plat Book `B" at Page 41 of the Public Records of Miami -Dade County, Florida. Lots 1 through 12 inclusive, Block 56, NORTH, CITY OF MIAMI, according to the Plat thereof, as recorded in Plat Book `B" at Page 41 of the Public Records of Miami -Dade County, Florida. EXHIBIT K Legal Description Lots 1 through 12 inclusive, Block 45, NORTH, CITY OF MIAMI, according as recorded in Plat Book `B" at Page 41 of the Public Records of Miami -Dade Lots 1 through 12 inclusive, Block 56, NORTH, CITY OF MIAMI, according as recorded in Plat Book `B" at Page 41 of the Public Records of Miami -Dade Lots 1 through 20 inclusive, Block 55, NORTH, CITY OF MIAMI, according as recorded in Plat Book `B" at Page 41 of the Public Records of Miami Dade 4 to the Plat thereof County, Florida. to the Plat thereof, County, Florida. to the Plat thereof, County, Florida. EXHIBIT L Indemnification Agreement This Indemnification Agreement (this "Agreement"), dated this day of , 2012, is executed by [ ., a (the "Indemnitor"), in favor of CITY OF MIAMI, a Florida municipal corporation (the "City"), MIAMI-DADE COUNTY, FLORIDA, a political subdivision of the State of Florida (the "County") and SOUTHEAST OVERTOWN/PARK WEST COMMUNITY REDEVELOPMENT AGENCY, a public agency and body corporate created pursuant to Section 163.356, Florida Statutes (the "CRA;" and together with the City and the County, individually and collectively, the "Indemnitee"). RECITALS A. City previously issued a request for proposals (as may have been amended from time to time, the "Poinciana RFP") with respect to that certain real property located in Miami - Dade County, Florida more particularly described on Exhibit "A" attached hereto and made a part hereof (the "Poinciana Village Project"). B. A response to the Poinciana RFP was submitted by Indian River Investments of Miami, Inc., a Florida corporation ("Indian River"), acting in the capacity of general partner on behalf of Poinciana Village of Miami, Ltd., a Florida limited partnership ("Poinciana"). C. Pursuant to the Poinciana RFP, the City selected Poinciana as the successful proposer for the Poinciana Village Project. D. The City Commission subsequently approved Poinciana as the successful proposer with respect to both the Poinciana RFP and the Poinciana Village Project. E. The Poinciana Village Project is subject to that certain Southeast Overtown/Park West Lease and Development Agreement dated June 15, 1988, as amended by Amendment No. 1 dated February 17, 1989, as amended by Amendment No. 2, dated July 13, 1989, as amended by Amendment No. 3, dated January 11, 1990, as amended by an Amendment dated September 23, 1998; and as assigned from the City to the CRA by that certain Assignment of Leases dated January 9, 1996 (collectively the "Poinciana Lease"). F. The City issued an additional request for proposals (as same may have been amended from time to time, the "Sawyer's Walk RFP") with respect to that certain real property located in Miami -Dade County, Florida, more particularly described on Exhibit `B", attached hereto and made a part hereof (the "Sawyer's Walk Project"). G. The sole response to the Sawyer's Walk RFP was submitted by Sawyer's Walk Ltd., a Florida limited partnership ("Sawyer's Walk") with respect to the Sawyer's Walk Project. 5 H. Pursuant to City of Miami Resolution No. 91-509 (the "Resolution"), the City selected Sawyer's Walk as the developer of the Sawyer's Walk Project subject to the satisfaction of certain conditions as set in the Resolution. I. Subsequently, the following litigation was commenced with respect to the Poinciana Village Project: Southeast Overtown/Park West Community Redevelopment Agency v. Poinciana Village of Miami, Ltd., Case No. 02-06846 CA 9, filed in the Circuit Court of the 11th Judicial Circuit in and for Miami -Dade County, Florida (the "Poinciana Litigation"); J. Subsequently, the following litigation was commenced with respect to the Sawyer's Walk Project: The City of Miami vs. Sawyer's Walk, Ltd., Case No. 00-28860 CA 9, filed in the llth Judicial Circuit in and for Miami -Dade County, Florida (the "Sawyer's Walk Litigation"). K. Sawyer's Walk, Poinciana, the CRA and the City entered into that certain settlement agreement dated as of January 27, 2005 with respect to the Poinciana Litigation and the Sawyer's Walk Litigation, as amended, (the "Settlement Agreement"). L. The transaction contemplated by the Settlement Agreement was never consummated. M. The CRA issued a request for proposals (the "New RFP") with respect to that certain real property located in Miami -Dade County, Florida more particularly described on Exhibit "C" attached hereto (the "New Project"). N. As a condition of awarding the New Project to Indemnitor pursuant to the New RFP, Indemnitor has agreed to execute this Agreement in favor of the Indemnified Parties, as hereinafter defined. NOW THEREFORE, in consideration of other agreements and other good and valuable consideration, the sufficiency and receipt of which are hereby acknowledged, Indemnitor, intending to be legally bound, agrees as follows: 1. Recitals. The foregoing recitals are true and correct and are hereby incorporated into, and constitute a part of, this Agreement. 2. Indemnity. Indemnitor hereby agrees to indemnify, defend and hold harmless each Indemnitee and their officers, directors, commissioners, agents and employees (collectively, the "Indemnified Parties") from and against any claim, loss, demand, damage, liability, obligation, suit, cause of action, cost or expense (including fees, costs and disbursements of attorneys and other professionals and court costs, both prior to and on appeal and regardless of whether an action or lawsuit is actually instituted or filed) by Sawyer's Walk, Indian River Investment Communities, Inc., a Florida corporation ("Communities"), Indian River, Poinciana, and/or any partner, shareholder, investor, employee, or any of them, and any of their successors and assigns, based upon, directly or indirectly, the Sawyer's Walk RFP, the Poinciana Litigation, the Sawyer's Walk Litigation and/or the Settlement Agreement, including, without limitation, claims raised or that could have been raised by Indian River, Communities, 6 Poinciana and Sawyer's Walk or any of their partners, shareholders or investors in the Poinciana Litigation and/or the Sawyer's Walk Litigation. 3. Release. Indemnitor hereby remises, releases, acquits, satisfies, and forever discharges each of the Indemnified Parties, of and from all, and all manner of action and actions, cause and causes of action, suits, debts, dues, sums of money, accounts, agreements, promises, damages, judgments, executions, claims and demands whatsoever, in law or in equity, which Indemnitor ever had, now has, or which Indemnitor hereafter can, shall or may have, against the Indemnified Parties, for, upon or by reason of any matter, cause or thing whatsoever, from the beginning of the world to the date of these presents relating to or arising out of, directly or indirectly, to the Poinciana Village Project, the Sawyer's Walk Project, the Poinciana Lease, the Sawyer's Walk RFP and the Settlement Agreement. 4. Governing Law. This Agreement shall be governed by and interpreted in accordance with the laws of the State of Florida without giving effect to the choice of law provisions thereof. 5. Counterparts. This Agreement may be executed in two or more counterparts, each of which shall be binding as of the date first written above, and all of which shall constitute one and the same instrument. Each such copy shall be deemed an original, and it shall not be necessary in making proof of this Agreement to produce or account for more than one such counterpart. IN WITNESS WHEREOF, the Buyer has executed this Indemnity and Release Agreement dated the date written above. Witnesses INDEMNITOR: Print Name Print Name STATE OF FLORIDA ) SS COUNTY OF MIAMI-DADE a By: Name: Title: The foregoing instrument was acknowledged before me this _ day of , 2012 by , as , a , on behalf of said . He/She is personally known to me or has produced as identification. 7 NOTARY PUBLIC State of Florida at Large My Commission Expires: 8 EXHIBIT A POINCIANA VILLAGE PROJECT LEGAL DESCRIPTION sting a tract or parcel of land containing 1.21353 &Cr45 5l,'i33 3q. tr:.1 out of lots t thru e2 ant lots 16 and 17,block 46 R of "It.t. Poulton Subdivisiol a according cco to the, plat th.teof recorded in plat book A, pivot public records of Dad* coanty, Florsde. Also being a part :of lots 6 and 1 to include a portion eta 20 foot :tight of Way according to the plat of Osorge C. sotlaSuivsion tharsot raco.Ydt4 in plat troop 1, p ce 14 ottha Pi blic record. of talt County, Tlorida 1 t ing.bare particularly de.Crlbad by mates and bounds as folio.. SLd1NtaNC at A point of imte.;.eetti'l of the fist !tight Af Stay Lire on tits 3r3 .M' nua s:rd the 5o4t.h Right of Uay lino of VW 4th -8troet, said point being 10.40' fatt taster1y and 12.50 feet Southerly frog% the t ortbwrt corner of Let t0 of said "A.10. Rnowitor't ,yubdivtetoS's thane° Ca1ttr1y along said South tight of Nay lino of tc'tr 4th Street , x distance of 340.17 fait t:o a corner: thane* Southerly 14*Vtn9 said 8oi.th Right of May lino of .'tW Sth Street and par*Lt4i with the west Right..of key !fins of 101 20 Avenue, , a distan0e of 10.27 feat to * .corntr,• thence tyratsrty pe:rpsnaiouiskt to said Right of Way of Nw 1ni avenue, a di*tanaa of 19.00 feet to a corns: t thence Southerly arellea with said Right of Way of NW 2nd avenue, 1 distant* of 7'7..00 feet to a cornet's thence i;eitcriy psre11$1 with the Right of Nay of t:St 7th S_rt' t e a dr+ttants Of 190,43 fiat to a. corner) thence Southerly prrpandioultr to said Right of say of NW 1th Street, a distance 4f 13.O0 Lett to a corner; thence Weattrly walla), with said 1110t of way of taw 7th Street., e dietime. of 130.33 tett to s corner, the sits bain9 .in t\a Vitt tight of Nay lino of VW 3r4 avenue) thine• Northerly klonq er t4 ta.at not 0 1ta" of Nw 3rl Avenue, a dlitarlca of 170.24 test to the tb Or orLn$01041Nthesis Geof the tract t herein assoribe8 conta3:rin 1..23.353 Cr*aSt (53473) Sq• Ft.) of 1an3. Being a tract or parcel of land ovnte .n tng i.g1 6 51 acrce (93, 710 Sq. Ft,) Out of lots 1 thru 4, lots 11 L 1? and lots 16 ihru 2, block 4 6 N of N1►,« L « X,aowltea n s_ u aiSivi s i orgy" tocordinq to the plat thereof recorded in past books g, page 41 of the public records of Dade 'County, Florida, Also being a port of hates 1 thru 6 to Include a portion of a.20 foot right of way according to the p1.st of George C. holies Sabdivielon thereof recorded Le plt+t bokok page, 16 of the public records of bade Cornty, 1•J.criaa 8 being more pa.rtioula.rly ass,rri.bed by :setae and hounds as fellow's! 19CCINIgItM at a point of intersection of the North Right of way line of .W 7th Street and the Est Right of Way line :of 111 3rd >,vunue; said Point being 10.00 feet tasterrly f.xoa. the Southwest Corner of lot 11 of *mid "ll..L_ Rfaa,.rlto.:n Bubdtvi+elion": theme Northerly along maid East Right of Way of NW 3rd Avenue, a distance off 117.11 feet t4 a Corner f thence Easterly leaving said .East Right of Way of NW 3rd Avenue and parallel with said North Right of Way of 7th. €tr:e:et. s a distance of '1 3D . 33 feet to a corner, thence Northerly perpendicular to Avid Right of Way of NW 7cf Street, a distance of 13.03 feet to a corner tho7ec Easterly parallel 'with said Right of Kay :of 11`W 7th Street, b dietenee of i341,83 feet to A corner; thence Northerly parellft3 with the Right of .Pay of NW end avenue, a diat.amCa of 77.00 feet to as corner; thence Easterly perpendicular to said NW 2nj kivaue, a distance of 19.00 feet to a comer; tht-, ` Northerly parallel with said .Right of Way of law xnd A:ventas e distance of fO.27 feat to a comer, the S 6111.1. being in. tha.so'a_T1 Right 4151 Way line of NW eth s.hse.ts themes Easterly "'Jong, maid South Right of Nay Ssi a .of NW •8th Street, a diltiancei Of 1 3/. 4g feet Lb a y?t'tier, the same being at a point of intersection of said Noath Right. of I ty line of NW 8t.h Street i the West Right of Way liner of said Ns .tad. Ave. sue, thence southerly along said West ltlsi+tt of Way line of Nit grid Avenue, a diaatst,oe of ten.45 fe¢t to s corner, the same being at a point of i,.tersection rf said HeAt Right ot.Way line of 114 2n•i hvenue and said North 'P LIht of 'Waay lint of !aw 7th street; thence 'Westerly along said North Right of Way lies of Ow 7th Street, a distance of 477.63 feet to the POINT of g£czimxtrc of the t,ratct a1e;:ea ;n described cortainini within these :totes and Rounds 't ..9111S2 aeces (03,571 51. rt.) of land« 10 EXHIBIT B SAWYER'S WALK PROJECT LEGAL DESCRIPTION Lots 1 through 12, Inclusive, of the. Public5Norm CITY o Y OF lam MIA�.ed 1,Ca rd Florida, tolth Plat thereof, as regarded in Plat Book "8", page Lots 1 through 20, Indus o f the ublicRecord c MiO MIAMI-Dade County,according to the Plat thereof, 0recorded In Plat Book "8", page 41 Lots 1 through 12, inclusive, Block P56, ublic NORTH cm' OF Re;ordofMiami-Dade AI,County,ing Floo rida, Plat the reof, as recorded in Plat I aok "B", p� 41 of the 11 12 Exhibit C Lots 1 through 12 inclusive, Block 45, NORTH, CITY OF MIAMI, according to the Plat thereof as recorded in Plat Book `B" at Page 41 of the Public Records of Miami -Dade County, Florida. Lots 1 through 12 inclusive, Block 56, NORTH, CITY OF MIAMI, according to the Plat thereof, as recorded in Plat Book `B" at Page 41 of the Public Records of Miami -Dade County, Florida. Lots 1 through 20 inclusive, Block 55, NORTH, CITY OF MIAMI, according to the Plat thereof, as recorded in Plat Book `B" at Page 41 of the Public Records of Miami Dade County, Florida. 13 EXHIBIT M Legal Description Block 36, Lots 1 through 11 inclusive, less the West 40 feet of Lot 11; the North 15.4 feet of Lot 12, less the East 11 feet of the North 15.4 feet of Lot 12; The South 9.8 feet of Lot 12, less the East 11 feet of Lot 12; Lot 13 through 19 inclusive, Less the West 40 feet of Lots 11, 14, 19 and less the East 11 feet of Lot 13; Lots 22 through 27 inclusive, less the West 40 feet of Lots 22 and 27; Lots 30 through 35 inclusive, Less the West 40 feet of Lots 30 and 35; The South 10 feet of Lot 36 and the North 20 feet of Lot 37, less the West 7.5 feet thereof; The South 5 feet of Lot 37, Lots 38 through 43 inclusive, less the West 40 feet of Lots 38 and 43; Lots 44 and 45 inclusive, Less the West 7.5 feet thereof; Lot 46 Less the West 40 feet thereof; and Lots 47 and 48 inclusive, Less that portion of Lots 1, 8, 9, 16, 17, 24, 32, 33, 40, 41 and 48 for RAPID TRANSIT R/W, All of Block 36, of "P.W. WHITES RE -SUB.", according to the Plat thereof as recorded in Plat Book "B", at Page 34, of the Public Records of Miami -Dade County, Florida. 14 EXHIBIT MM Gatehouse Resolution 15 EXHIBIT N County Approval Resolution 16 EXHIBIT 0 City Approval Resolution 17 EXHIBIT P CRA Approval Resolution 18 #11342893 v3