Loading...
HomeMy WebLinkAboutPre AttachmentCity of Miami Certified Copy City Hall 3500 Pan American Drive Miami, FL 33133 www.miamigov.com File Number: 05-00536 Enactment Number: R-05-0357 A RESOLUTION OF THE MIAMI CITY COMMISSION, WITH ATTACHMENT(S), AUTHORIZING THE CITY MANAGER TO: (A) CONVEY, WITH PARCEL REVERTER PROVISIONS, ELEVEN (11) CITY OF MIAMI ("CITY") OWNED PARCELS OF LAND DIRECTLY TO THE DEVELOPERS, AS DESCRIBED IN "ATTACHMENT A," ATTACHED AND INCORPORATED ("DEVELOPERS"), FOR THE CONSTRUCTION OF AFFORDABLE HOUSING FOR ELIGIBLE LOW AND MODERATE INCOME PERSONS, (B) CONVEY CERTAIN CITY -OWNED PARCELS OF LAND DIRECTLY TO THE CITY DEPARTMENT OF OFF-STREET PARKING ("DOSP"), AS DESCRIBED IN "ATTACHMENT B," ATTACHED AND INCORPORATED, FOR THE CONSTRUCTION OF PARKING LOTS, CURRENTLY SUBJECT TO ASSIGNMENT TO THE MODEL CITY COMMUNITY REVITALIZATION DISTRICT TRUST ("TRUST"), PURSUANT TO THE INTERLOCAL COOPERATION AGREEMENT BETWEEN THE TRUST AND THE. CITY DATED SEPTEMBER 25, 2003, AND (C) AMENDING THE INTERLOCAL COOPERATION AGREEMENT TO PROVIDE FOR THE DELETION OF SUCH PARCELS FROM EXHIBIT "A" OF SAID AGREEMENT TO REFLECT: (1) THE CONVEYANCE OF ELEVEN (11) PARCELS DIRECTLY TO THE DEVELOPERS, FOR THE DEVELOPMENT OF AFFORDABLE HOUSING, (2) THE CONVEYANCE OF CERTAIN PARCELS DIRECTLY TO DOSP, FOR THE CONSTRUCTION OF PARKING LOTS, AND (3) THE CONVEYANCE OF FIVE (5) PARCELS TO PALMETTO HOMES OF MIAMI, INC., FOR THE CONSTRUCTION OF AFFORDABLE HOUSING, AS DESCRIBED IN "ATTACHMENT C," ATTACHED AND INCORPORATED, FOR THE CONSTRUCTION OF AFFORDABLE HOUSING, APPROVED BY THE CITY COMMISSION AT ITS APRIL 28, 2005, MEETING, SUBJECT TO THE TERMS AS STATED HEREIN; FURTHER AUTHORIZING THE CITY MANAGER TO EXECUTE THE NECESSARY DOCUMENTS, FOR SAID PURPOSE. WHEREAS, pursuant to Resolution No. 04-0374, adopted June 10, 2004, the City Commission adopted the City of Miami's ("City") Five Year Consolidated Plan re-establishing eight (8) Neighborhood Development Zones in the City; and WHEREAS, the City Commission identified the Model City Community Revitalization Zone ("Zone") as one of the areas to undergo comprehensive redevelopment; and WHEREAS, the City and the Model City Community Revitalization Trust ("Trust") entered into an interlocal cooperation agreement ("Agreement"), dated September 23, 2003, to set forth the cooperative relationship between the City and the Trust and the respective duties, obligations and procedures to be followed by the parties for planning and implementation of revitalization efforts for the redevelopment of the Zone and for the conveyance of certain City -owned parcels of land to the Trust; and WHEREAS, in order to expedite the redevelopment of the Zone, the Trust by Resolution, at its May City of Miami Page I of 3 R-05-0357 File Number: 05-00536 Enactment Number: R-05-0357 16, 2005 meeting, authorized the City to convey certain parcels, currently subject to conveyance to the Trust pursuant to the Agreement directly to the Developers, as described in "Attachment A," attached hereto, for the construction of affordable housing and to the City Department of Off -Street Parking ("DOSP") and further amend the Agreement to provide for the deletion of such lots from Exhibit "A" of the Agreement and as otherwise required; NOW, THEREFORE, BE IT RESOLVED BY THE COMMISSION OF THE CITY OF MIAMI, FLORIDA: Section 1. The recitals and findings contained in the Preamble to this Resolution are adopted by reference and incorporated as if fully set forth in this Section. Section 2. The City Manager is authorized{1} to: (a) convey, with parcel reverter provisions, eleven (11) parcels of City -owned land directly to the Developers, as described in "Attachment A," attached and incorporated, for the construction of affordable housing for eligible low and moderate income persons, (b) convey certain City -owned parcels of land directly to the DOSP, as described in "Attachment B," attached and incorporated, for the construction of parking lots, currently subject to assignment to the Trust pursuant to the Agreement between the Trust and the City dated September 25, 2003, and (c) amending the Agreement to reflect: (1) the conveyance of eleven (11) parcels directly to the Developers for the construction of affordable housing, (2) the conveyance of certain parcels to DOSP for the construction of parking lots, and (3) the conveyance of five (5) parcels to Palmetto Homes of Miami, Inc., as described in "Attachment C," attached and incorporated, for the construction of affordable housing approved by the City Commission at its April 28, 2005 meeting, subject to the following terms: (1) the terms of the conveyances to the Developers will be subject to the requirements of Section 3 of the Housing and Urban Development Act of 1968, as amended, 12 U.S.C. 1701u (Section 3), (2) the Developers will work with the President/CEO of the Trust to identify qualified local members of the Zone, particularly residents of the 33142 zip code, to work on the construction of the homes on a priority basis, (3) the first priority homebuyers for the proposed homes will be individuals and families displaced from the City's Miami Limited Buildings, and (4) the sales price of the homes must comply with the affordable housing sales price approved by the City Commission. Section 3. The City Manager is further authorized{1} to execute the necessary documents, for said purpose. Section 4. This Resolution shall become effective immediately upon its adoption and signature of the Mayor.{2} Date: MAY 26, 2005 Mover: COMMISSIONER ALLEN Seconder: COMMISSIONER WINTON Vote: AYES: 5 - COMMISSIONER GONZALEZ, WINTON, SANCHEZ, REGALADO AND ALLEN Action: ADOPTED City of Miami Page 2 of 3 R-05-0357 File Number: 05-00536 Enactment Number: R-05-0357 Date: Action: JUNE 1, 2005 SIGNED BY THE MAYOR I, Priscilla A. Thompson, City Clerk of the City of Miami, Florida, and keeper of the records thereof, do hereby certify that this constitutes a true and correct copy of Resolution No. R-05-0357, with attachments, passed by the City Commission on 5/26/2005. April 08, 2008 Date Certified {1} The herein authorization is further subject to compliance with all requirements that may be imposec City Attorney, including but not limited to those prescribed by applicable City Charter and Code provisio {2} If the Mayor does not sign this Resolution, it shall become effective at the end of ten (10) calends from the date it was passed and adopted. If the Mayor vetoes this Resolution, it shall become e immediately upon override of the veto by the City Commission. City of Miami Page 3 of 3 R-05-0357 ATTACHMENT "A" PROPERTIES TO BE CONVEYED TO DEVELOPERS PARCELS/LOTS TO BE CONVEYED TO MIAMI DREAM HOME INVESTMENT GROUP, INC ADDRESSES 1 parcel @ 6020 N.W. 1 parcel @ 1612 N.W. 1 parcel @ 1543 N.W. 1 parcel @ 1535 N.W. 1 parcel @ 1525 N.W. 1 parcel @ 1477 N.W. 15 Avenue (2 lots/homes) 60 Street (2 lots/homes) 59 Street (1 lot/home) 58 Terrace (3 lots/homes) 60 Street (1 lot/home) 60 Street (1 lot/home) Total 6 parcels containing 10 lots suitable for the construction of affordable housing PARCELS TO BE CONVEYED TO PALMETTO HOMES OF MIAMI, INC ADDRESSES 1 parcel @ 1575 N.W. 58 Street (1 lot/home) 1 parcel @ 1466 N.W. 61 Street (1 lot/home) 1 parcel @ 1468 N.W. 61 Street (1 lot/home) 1 parcel @ 1418 N.W. 60 Street (1 lot/home) 1 parcel @ 1288 N.W.55 Street (1 lot/home) Total 5 parcels containing 5 lots suitable for the construction of affordable housing ATTACHMENT "II" Parcels to be conveyed to the City of Miami Department of Off -Street Parking for the construction of parking lots Addresses 5575 N.W. 17 Avenue 5601 NW. 17 Avenue 5901-5923 N.W. 17 Avenue 1630 N.W. 58 Terrace 1620-24 N.W. 58th Street THE ADDRESSES ABOVE WILL BE TO YIELD A TOTAL OF 100+ PUBLIC PARKING SPACES ATTACHMENT "C" Parcels previously approved by the City to be conveyed to Palmetto Homes of Miami, Inc. for the construction of affordable housing 5812 N.W. 15 Avenue (1 lot/home) 1513 N.W. 58 Street (1 lot/home) 1527 N.W. 58 Street (3 lots/homes) 1611 N.W. 58 Street (1 lot/home) 1615 N.W. 58 Street (1 lot/home) 1621 N.W. 58 Street (1 lot/home) ement Prepared By .1 Rodin To: 1I, MENENDEZ, ESQ. t1).OF iMIAMI :L FTORNEY'S OFFICE LYD AVENUE , i:ORIDA 33130-191 u .;I1 I1IHi Intl Ill 11111111111 Hill I1I!J 11 (I: FT N 2e-rrR1.:'1b69' OF Bk 23°1 7 F'9s ,-s3E3 - 365 (3v9 g,E(-ORDER 09,'2E /2005 t 1 GEED v0(. TAX. 0.60 SURTAa: t:t, 45 HAFtVE( FL1VI1,1 CLERY I F ::DUF1 11IAI1I--DADE LOUI11 r Ft ORIDA fy- This Quit -Claim Deed, is made this 11 day of September 2005, by the City of Miami, a municipal corporation of the State of Florida, whose post office address is 444 S.W. 2'd Avenue, Miarni, Florida 33130, hereinafter called the "Grantor", to Miami Dream Homes Investment Group, Inc., a Florida corporation, whose address 220 N.W 130w Avenue, Miami, Florida 33182, hereinafter called the 'Grantee". Witnesseth: That the Grantor; for and in consideration of the sum of Ten Dollars ($10.00) and other 'aivable consideration, the receipt of which is hereby acknowledged, does hereby remise, release, convey :and quit -claim unto the Grantee forever, all of the Grantor's right, title and interest in that certain land ;situate in Miami -Dade County, Florida, hereinafter referred to as the "Property", to wit: Lots 19 and 20, Block 12, of ORANGE HEIGHTS, according to the Plat thereof, as recorded in Plat Book 14, Page 62, of the Public Records of Dade County, Florida, a.k.a. 6020 N.W. 15 Avenue, Miami, Florida. and Lots 12 and 13, Block 13, of ORANGE HEIGHTS, according to the Plat thereof, as recorded in Plat Book 14, Page 62, of the Public Records of Dade County, Florida, a.k.a. 1612 N.W. 60 Srreet, Miami, Florida. and Lot 24, Block 13. of ORANGE HEIGHTS, according to the Plat thereof, as recorded in Plat Book 14, Page 62, of the Public Records of Dade County. Florida, a.k.a. 1543 N.W. 59 Street, Miami, Florida. and Lots 11, 12 and 13, Block 14, of ORANGE HEIGHTS, according tc the Plat thereof, as recorded in Plat Book 14, Page 62, of the Public Records of Dade County, Florida, a.k.a. 1535 N W. 58 Terrace, Miami, Florida. and Lot 15, Block 12, of ORANGE HEIGHTS, according to the. Plat thereof, as recorded in Plat Book 14, Page 62, of the Public Records of Dade County, Florida, a.k.a. 1525 N W 60 Street, Miarni, Florida. and Lot 25, Block 9, of ORANGE HEIGHTS, according to the Plat thereof, as recorded in Plat Book 14, Page 62, of the Public Records of Dade County, Florida, a.k.a. 1477 N.W. 60 Street, Miarni, Florida. Subject to: 1. Conditions; restrictions; easements, irr Cations and reservations reference is not intended to reimpose same: Applicable zoning ordiner :;des, rules and es•ulations, Faxes and assessments e. urre _,cat and 21i sucsequent e record, though this `4 GQ �` I fit£' pg \, C . leg _: ` ;�, ‘-‘.„ The Property is being taken by the Grantee "as is" with the Grantee being solely responsible for the removal of any environmental contamination if present on the Property; and 5. The title to the Property shall immediately and automatically revert to and vest in the Grantor in the event that: (1) the Grantee has not commenced construction, to the satisfaction of the Grantor in its sole judgment, of a minimum of (10) ten single-family homes or a combination of (10) ten townhomes and condominiums, hereinafter referred to as the "Homes", on the Property within twelve (12) months from the date hereof and/or (2) the construction of the Homes has not been completed, as evidenced by the issuance of Certificates of Occupancy, and all such single family homes have not been sold to qualified Low Income homebuyers (as defined in the HOME Investment Partnerships Program Regulations, 24 C iF.R. Part 92) by April 30, 2008, or such later date as may be .approved by the City Commission of the City of Miami. 6. The sales price of the Homes shall not exceed $236,000.00 per unit. 7. The Property is subject to all restrictions as stated in Resolution 05-03 5 7 adopted by the City Commission on May 26, 2005. To Have and To Hold, the same together with all and singular tenements, hereditaments and appurtenances thereto belonging or in anywise appertaining, and all the estate, right, title, interest, lien, equity, and claim whatsoever of the Grantor, either in law or in equity, to the use, benefit and behalf of the. Grantee forever. IN WITNESS WHEREOF, the said Grantor has signed and sealed these presents the day and year first written above. igned, sealed and delivered in our presence: 1 Print Name: c l� ci.le n� Print Name: APPROVED AS TO FORM AND ..7J ORRNANDEZ KRl\-t City Attorney CITY OF MLAMI, a municipal corporation of the State of Florida By JO IOLA Ci i,nager ATTEST: PRIS ILLA A TI1Oir'IP'$ON City Clerk ACKNOWLEDGMENT ATE OF FLORIDA )SS OUNTY OF MIAMI-DADF ,j t' ?'381 7 F G 33cS PAGE Before me, the undersigned authority, personally appeared Joe Arriola, as City Manager of the City of Miami, to me well known to be the person described in and who executed the foregoing instrument and who acknowledged to and before me that he executed said instrument under oath, and for the purposes therein expressed. Witness my hand and official sea in the County and State las •foresaid this + day of September, 2005 RINTED, STAMPED OR TYPED SI!- NATURE O OTA PUBLIC NAME OF NOTARY PUBLIC S ATE OF FLORIDA My COnimission Expires: KRM — Miami Dream Homes Ofelia E. Perez ?a Commission t4D0224 3 l9 may.;::; Expires: Jul 26, 2007 pa•; Bonded ThTu or. °: Atlanti c Bonding Co , Inc. C� v� pi\l4)E '43 :'4 0T.T"e City of Miami Certified Copy City Hall 3500 Pan American Drive Miami, FL 33133 www.miamigov.com File Number: 06-00819 Enactment Number: R-06-0329 A RESOLUTION OF THE MIAMI CITY COMMISSION, WITH ATTACHMENT(S), AMENDING RESOLUTION NO. 05-0357, ADOPTED MAY 26, 2005, BY AMENDING THE ATTACHMENT HERETO, TO REFLECT THAT THE PARCEL OF LAND CONVEYED TO MIAMI DREAM HOME INVESTMENT GROUP, INC., LOCATED AT 1525 NORTHWEST 60 STREET, MIAMI, FLORIDA, WILL BE DEVELOPED AS A NEW CONSTRUCTION MULTI -FAMILY RENTAL PROJECT CONSISTING OF SEVEN (7), UNITS FOR LOW INCOME PERSONS, AS SPECIFIED IN "ATTACHMENT A," ATTACHED AND INCORPORATED; FURTHER CLARIFYING THAT SAID PROPERTY WILL BE CONVEYED TO THE CITY OF MIAMI UPON ISSUANCE OF A CERTIFICATE OF OCCUPANCY FOR SAID PROJECT; AUTHORIZING THE CITY MANAGER TO EXECUTE THE NECESSARY DOCUMENT(S), FOR SAID PURPOSE. WHEREAS, pursuant to Resolution No. 05-0357, adopted May 26, 2005, the City Commission approved the conveyance of, with parcel reverter conditions, eleven parcels of City of Miami ("City") owned land directly to developers, for the construction of affordable housing for eligible low and moderate income persons; and WHEREAS, six (6) of the eleven parcels of City -owned land were conveyed to Miami Dream Home Investment Group, Inc.; and WHEREAS, the Administration is recommending that the parcel of land located at 1525 Northwest 60 Street, Miami, Florida, be developed as a new construction multi -family rental project consisting of seven (7) units for low income persons; and WHEREAS, said property will be conveyed to the City upon issuance of a certificate of occupancy for said project; NOW, THEREFORE, BE IT RESOLVED BY THE COMMISSION OF THE CITY OF MIAMI, FLORIDA: Section 1. The recitals and findings contained in the Preamble to this Resolution are adopted by reference and incorporated as if fully set forth in this Section. Section 2. Resolution No. 05-0357, adopted May 26, 2005, is amended by amending the attachment hereto, to reflect that the parcel of land conveyed to Miami Dream Home Investment Group, Inc., located at 1525 Northwest 60 Street, Miami, Florida, will be developed as a new construction multi -family rental project consisting of seven (7) units for low income persons, as specified in "Attachment A," attached and incorporated, and clarifying that said property will be conveyed to the City upon issuance of a certificate of occupancy for said project. Section 3. The City Manager is authorized{1} to execute the necessary document(s), for said purpose. City of Miami Page 1 of 2 R-06-0329 File Number: 06-00819 Enactment Number: R-06-0329 Section 4. This Resolution shall become effective immediately upon its adoption and signature of the Mayor. {2) Date: MAY 25, 2006 Mover: COMMISSIONER SPENCE-JONES Seconder: VICE-CHAIRMAN SANCHEZ Vote: AYES: 5 - COMMISSIONER GONZALEZ, WINTON, SANCHEZ, REGALADO AND SPENCE-JONES Action: ADOPTED Date: Action: MAY 31, 2006 SIGNED BY THE MAYOR I, Priscilla A. Thompson, City Clerk of the City of Miami, Florida, and keeper of the records thereof, do hereby certify that this constitutes a true and correct copy of Resolution No. R-06-0329, with attachments, passed by the City Commission on 5/25/2006. April 08, 2008 Date Certified {1} The herein authorization is further subject to compliance with all requirements that may be imposed by the City Attorney, including but not limited to those prescribed by applicable City Charter and Code provisions. {2} If the Mayor does not sign this Resolution, it shall become effective at the end of ten (10) calendar days from the date it was passed and adopted. If the Mayor vetoes this Resolution, it shall become effective immediately upon override of the veto by the City Commission. City of Miami Page 2 of 2 R-06-0329 ATTACHMENT "A" PROPERTIES 70 BE CONVEYED TO DEVELOPERS PARCELS/LOTS TO BE CONVEYED TO MIAMI DREAM HOME INVESTMENT GROUP, INC. ADDRESSES 1 parcel @ 6020 N.W. 15 Avenue (2 lots/homes) 1 parcel a 1612 N.W. 60 Street (2 lots/homes) 1 parcel as 1543 N.W. 59 Street (1 lot/home) 1 parcel © 1535 N.W. 58 Terrace (3 lots/homes) 1 parcel @ 1525 N.W. 60 Street (1 gem} iMulti- Family Rental Proiect: 7 units for low income persons)" 1 parcel @ 1477 N.W. 60 Street (1 IoVhome) Total 6 parcels containing 10 lots suitable for the construction of affordable housing " Property to be conveyed to the City of Miami upon issuance of a Certificate of Occupancy for said project PARCELS TO BE CONVEYED TO PALMETTO HOMES OF MIAMI, INC. ADDRESSES 1 parcel a 1575 N.W. 58 Street (1 lot/home) 1 parcela 1466 N.W. 61 Street (1 lot/home) 1 parcel ©1468 N.W. 61 Street (1 lot/home) 1 parcel @ 1418 N.W. 60 Street (1 lot/home) 1 parcel @ 1288 N.W.55 Street (1 lot/home) Total 5 parcels containing 5 lots suitable for the construction of affordable housing Vori (.1; 7l„1 ;nstrumerl Prpa'CJ Nv 3;z turn7o ;LEIv'ETE'ICHIN, ESQ_ 'JTY OF NI1 A. N1 I 017 Y ATTORNEY'S (F"ICE, 444 C W ?`c AVENUE 'V91Ar11 FLORJ0A:;31 {-7910 CORRECTIVE QUIT CLAIM DEED This Corrective Quit -Claim Deed, ;s made as of This 5 day of July, 2006, by the City of Miami, a municipal corporation of the State of Florida, whose post office address is 444 S W 2nd Avenue, Miami; Florida 33130, hereinafter called the "Grantor", to Miami Dream Homes Investment Group, Inc., a Florida corporation, whose address is 220 N W. I30`' Avenue, Miami, Florida 33182, hereinafter called the "Grantee" Witnesseth: That the Grantor, for and in consideration of the sum of Ten Dollars ($10.00) and other valuable consideration, the receipt of which is hereby acknowledged, does hereby realise, release, convey and quit -claim unto the Grantee forever, all of the Grantor's right, title and interest in that certain land situated in Miami -Dade County, Florida, hereinafter referred to as the "Property", to wit. Lots 19 and 20, Block 12, of ORANGE HEIGHTS, according to the Plat thereof, as recorded in Plat Book 14, Page 62, of the Public Records of Dade County, Florida, a.k.a 6020 N W. 15 Avenue, Miami, Florida. and J Lots J 2 and 13, Block 13, of ORANGE HEIGHTS, according to the Plat thereof, as recorded in Plat Book 14, Page 62, of the Public Records of Dade County, Florida, e k.a. 1612 N.W. 60 Street, Miami, Florida. and Lot 24, Block 13, of ORANGE HEIGHTS, according to the Plat thereof, as recorded in Plat Book 14, Page 62, of the Public Records of Dade County, Florida, a.k.a. 1543 N.W. 59 Street, Miami, Florida. and ✓ ✓ ✓ Lots 11, 12 and 13, Block 14, of ORANGE HEIGHTS, according to the Plat thereof, as recorded in Plat Book 14, Page 62, of the Public Records of Dade County, Florida, a.k a 1535 N.W. 58 Ten -ace, Miami, Florida and THIS DEED CORRECTS CONDITIONS/RESTRICTIONS NO. 5 AND 7 STATED IN THAT CERTAIN QUIT CLAIM DEED DATED SEPTEMBER 27, 2005, RECORDED SEPTEMBER 28, 2005, IN OFFICIAL RECORDS BOOK 23817, AT PAGE 3363, OF THE PUBLIC RECORDS OF MIAMI-DADE COUNTY, FLORIDA. t Document 43137 1.o1 Block 12, of flR_.ANClEl 1ILiGHI S ac_ lung to the Plat thereof; as recorded in Plat Book 14, Page. 62, of the Public Records of Dade County, Florida, a k a _1525 N \tJ 60 Street, Miami, Florida and Lot 23, Block 9, of ORANGE HEIGHTS, according to the Plat thereof, as recorded in Plat Book 14, Page 62, of the Public Records of Dade County, Florida, a k a 1477 N W 60 Street, Miami, Florida Subject to: Conditions; restrictions, easements, limitations and reservations of record, though this reference is not intended to reimpose same; Applicable zoning ordinances, codes, rules and regulations, Taxes and assessments for the current year and all subsequent years; The Property is being taken by the Grantee "as is" with the Grantee being solely responsible for the removal of any environmental contamination if present on the. Property; and The title to the Property shall immediately and automatically revert to and vest in the Grantor in the event that: (A) within six (6) months from the date of this Corrective Quit Claim Deed, or such later date as may be approved by the City Commission of the City of Miami, the Grantee has not commenced construction, to the satisfaction of the Grantor in its sole judgment, of a minimum of nine (9) single-family homes, or a combination of nine (9) townhomes and condominiums (hereinafter referred to as the "Homes"), on the Property, or (B) within six (6) months from the date of this Corrective Quit Claim Deed, or such later date as may be approved by the City Commission of the City of Miami, the Grantee has not commenced construction, to the satisfaction of the Grantor in its sole judgment, of a seven (7) unit multi- family rental project on the parcel located at Lot 15, Block 12, of ORANGE HEIGHTS, according to the Plat thereof, as recorded in Plat Book 14, Page 62, of the Public Records of Dade County, Florida, a.k.a. 1525 N.W. 60 Street, Miami, Florida, or (C) on or before April 30, 2008, or such later date as may be approved by the City Commission of the City of Miami: (i) the construction of all of the Homes has not been completed, as evidenced by the issuance of Certificates of Occupancy, or (ii) all such single family Homes have not been sold to qualified Low Income homebuyers (as defined in the HOME Investment Partnerships Program Regulations, 24 CFR Part 92), or (iii) the construction of the seven (7) unit multi- family rental project has not been completed, as evidenced by the issuance of all required Certificates of Occupancy, or (iv) the Grantee has not conveyed to the Grantor by Special Warranty Deed the seven (7) unit multi- family rental project and the parcel located at Lot 15, Block 12, of ORANGE HEIGHTS, according to the Plat thereof, as recorded in Plat Book 14, Page 62, of the Public Records of Dade County, Florida, a.k.a. 1525 N.W 60 Street; Miami, Florida. 6 The sales price for each of the Homes shall not exceed S236,000 00 per unit. Page 2 of 3 it Document 43; 37 .1( • The i' it, i)' is ilJ(0: tG all J estn -ions OS Statf li_'S1_>l'-lion ( -U' 5 ! adopted _)tv Col-ruTuSs)on on May Lc, 2005 an , .solution 06-0329 ac,opted b'y the C')Iy Conrunissinn on l`.'ay 25 2006. To Have and To rin.'d, the same Together with all and singular tenements, bereditannents and appurtenances thereto belonging or in anywise appertaining, and all the estate, right, title; interest, hen, equity, and clanri whatsoever of the Grantor, either )n la'k or in equity; to the use, bene.ft and behalf of the Grantee fore' er TN WITNESS WHEREOF, the said Grantor has signed and sealed these presents the day and year first written above. Signed, sealed and delivered your pre, int Name el,4 fe6le� Print Name: APPROVED AS TO FORM AND CO IS S STATE OF FLORIDA ) )SS COUNTY OF MIAMI-DADE ) CITY OF MIAMI, a municipal corporation of the State of Florida By Pedro G. Herriaez City Manager ATTEST: t, PRISCILLA A. THOMPS9 City Clerk ACKNOWLEDGMENT Before me, the undersigned authority, personally appeared :Itm;-Es a, as City Manager of the City of Miami, to nie well known to be the person described in and who executed the foregoing instrument and who acknowledged to and before me that he executed said instrument under oath, and for the purposes therein expressed Witness my hand and official seal in the County and State last aforesaid this G day of AIJSa;'( , 2006. PRINTED, STAMPED OR TYPED NAME OF NOTARY PUBLIC My Commission Expires. it Document 43137 SIG ATURE OF N ARY PUBLIC STATE OF FLORIDA :'I3I2 3ordej I'hn „la;�tic i_.ondm_ Co , lnc Page 3 of 3 City of Miami Certified Copy City Hall 3500 Pan American Drive Miami, FL 33133 www.miamigov.com File Number: 07-00306 Enactment Number: R-07-0133 A RESOLUTION OF THE MIAMI CITY COMMISSION, WITH ATTACHMENT(S), MODIFYING CONDITION/ RESTRICTION NO. 5 OF THE CORRECTIVE QUIT CLAIM DEED, DATED JULY 5, 2006, FROM THE CITY OF MIAMI TO MIAMI DREAM HOMES INVESTMENT GROUP, INC. TO PROVIDE THAT CONSTRUCTION ON THE PROPERTY LISTED IN EXHIBIT "A," ATTACHED AND INCORPORATED, OF ONE SINGLE FAMILY HOME MUST COMMENCE NO LATER THAN JULY 1, 2007; STATING THE INTENTION OF THE CITY COMMISSION RELATED TO THE CONVEYANCE OF TITLE TO THE PROPERTIES LISTED ON EXHIBIT "A"; CONFIRMING THE REVERSION TO THE CITY OF MIAMI OF TITLE TO ONE VACANT PARCEL OF LAND LOCATED AT 1477 NORTHWEST 60 STREET, MIAMI FLORIDA, LISTED ON EXHIBIT "B," ATTACHED AND INCORPORATED; AUTHORIZING THE CITY MANAGER TO EXECUTE ALL NECESSARY DOCUMENTS FOR SAID PURPOSE. WHEREAS, pursuant to Resolution No. 05-0357, adopted May 26, 2005, the City Commission approved the conveyance, with title reverter conditions, of eleven parcels of City of Miami ("City") owned land directly to developers, for the construction of affordable housing for eligible low and moderate income persons; and WHEREAS, six (6) of the eleven parcels of City -owned land were conveyed to Miami Dream Homes Investment Group, Inc. (the "Properties") for the new construction of affordable single family homes; and WHEREAS, pursuant to Resolution No. 06-0329, adopted May 25, 2006, the City Commission approved the development as a new construction multi- family rental project, consisting of seven (7) units for low income persons, of the parcel of land located at 1525 Northwest 60 Street, Miami, Florida; and WHEREAS, the Properties were conveyed to Miami Dream Homes Investment Group, Inc. ("Miami Dream Homes") by Quit Claim Deed dated September 27, 2005 and Corrective Quit Claim Deed dated July 5, 2006; and WHEREAS, due to the delay in obtaining permits from the Department of Water and Sewer and the Department of Environmental Resource Management, Miami Dream Homes was unable to start construction as required by the quit claim deeds; and WHEREAS, the Administration recommends modifying the Corrective Quit Claim Deed to Miami Dream Homes to provide that construction on the Properties of one (1) single family home must commence no later July 1, 2007; and WHEREAS, the Administration also recommends confirming that title to the property located at 1477 Northwest 60 Street Miami, Florida, previously conveyed to Miami Dream Homes, has reverted to the City; City of Miami Page 1 of 3 R-07-0133 File Number: 07-00306 Enactment Number: R-07-0133 NOW, THEREFORE, BE IT RESOLVED BY THE COMMISSION OF THE CITY OF MIAMI, FLORIDA: Section 1. The recitals and findings contained in the Preamble to this Resolution are adopted by reference and incorporated as if fully set forth in this Section. Section 2. The modification of Condition/ Restriction No. 5 of the Corrective Quit Claim Deed dated July 5, 2006, from the City to Miami Dream Homes, to provide that construction of one (1) single family home on the property listed on Exhibit "A," attached and incorporated, must commence no later than July 1, 2007, is approved. Section 3. It is in the intention of the City Commission that title to the parcels described in Exhibit "A," attached and incorporated, except for the parcel located at 1477 Northwest 60 Street Miami, Florida, shall be deemed to have remained in Miami Dream Homes from the date of conveyance, and that the extension of time granted herein to commence construction shall be deemed to have been made on or before January 5, 2007. Section 4. The reversion of title to City of the parcel of land located at 1477 Northwest 60 Street Miami, Florida, listed in Exhibit "B," attached and incorporated, is confirmed. Section 5. The City Manager is authorized {1} to execute all necessary documents for said purpose. Section 6. This Resolution shall become effective immediately upon its adoption and signature of the Mayor.{2} Date: MARCH 8, 2007 Mover: COMMISSIONER SPENCE-JONES Seconder: VICE-CHAIRMAN SANCHEZ Vote: AYES: 5 - COMMISSIONER GONZALEZ, SARNOFF, SANCHEZ, REGALADO AND SPENCE-JONES Action: ADOPTED WITH MODIFICATIONS Date: MARCH 12, 2007 Action: SIGNED BY THE MAYOR City of Miami Page 2 of 3 R-07-0133 File Number: 07-00306 Enactment Number: R-07-0133 I, Priscilla A. Thompson, City Clerk of the City of Miami, Florida, and keeper of the records thereof, do hereby certify that this constitutes a true and correct copy of Resolution No. R-07-0133, with attachments, passed by the City Commission on 3/8/2007. April 08, 2008 Date Certified {1} The herein authorization is further subject to compliance with all requirements that may be imposed by the City Attorney, including but not limited to those prescribed by applicable City Charter and Code provisions. {2} If the Mayor does not sign this Resolution, it shall become effective at the end of ten (10) calendar days from the date it was passed and adopted. If the Mayor vetoes this Resolution, it shall become effective immediately upon override of the veto by the City Commission. City of Miami Page 3 of 3 R-07-0133 EXHIBIT "A" EXTENDING START DATE CONSTRUCTION FOR THE PARCELS OF LAND CONVEYED TO M1AMI DREAM HOMES INVESTMENT GROUP, INC. ADDRESSES 1 parcel @ 6020 N.W. 15 Avenue (2 lots/ townhomes) 1 parcel @ 1600 and 1610 N.W. 60 Street (2 lots/2 homes) 1 parcel @ 1543 N.W. 59 Street (1 lot/1 home) 1 parcel @ 1533, 1535 and 1545 N.W. 58 Terrace (3 lots/3 homes) 1 parcel @ 1525 N.W. 60 Street (Multi- Family Rental Project: 7 units for low income personsl THIS DOCL7AE NT !S A SUBSTITUTION TC) ORIGINAL BACKUP. ORIGINAL CAN BE SEEN AT END OF THIS DOCUMENT it:Document 68697 1 6 7 - ?lb 30Cr (7?-11t.,h� � U EXHIBIT "A" EXTE SING START DATE CONSTRUCTION FOR THE PARCELS OF LAND CON YED TO MIAMI DREAM HOMES INVESTMENT GROUP, INC, ADDRESSES 1 parcel @ 6020 N.W. 15 venue (2 lots/homes) 1 parcel @ 1612 N.W. 60 St ; =t (2 lots/homes) 1 parcel @ 1543 N.W. 59 Stree 1 lot/home) 1 parcel @ 1535 N.W. 58 Terrace lots/homes) 1 parcel @ 1525 N.W. 60 Street (Mu '- Family Rental Project: 7 units for low Income persons) SUSTIT1 d �. Sri EXHIBIT "B" REVERTING ONE PARCEL OF LAND TO CITY OF MIAMI ADDRESS 1477 N.W. 60 Street (1 lot/home) , THIS DOCLINgLiql T.) A SUBSTITUTION TO ORIGINAL BACKUT1'. C.:RiGINAL CAN BE SEEN AT END OF THIS DOCUMENT 401IIMINY meme.--earmaaacc / EXHIBIT "8" REVERTING ONE PARCEL OF LAND TO CITY OF MIAMI ADDRESS 1477 N.W. 60 Street (1 ID •me) _AL MIAMI DREAM HOMES INVESTMENT GROUP, INC. March 28, 2008 Doliila Pinkhasov, Contract Compliance Officer City of Miami 444 SW 2"tl Avenue Miami, Florida 33133 Dear Ms Pinkhasov: We are requesting an extension of the completion date (sale houses) requirement from April 30, 2008 to December 31, 2008 for the following properties: 1. 1533 NW 58th Terrace (House is 100% complete with a Certificate of Occupancy ) 2. 1543 NW 59'h Street (House is 95% complete) 3. 1600 NW 60th Street (House is 95% complete) 4. 1610 NW 60`h Street (House is 95% complete) As you are aware Miami Dade County has changed their policy of providing 2n4 mortgages to low income buyers giving priority to Dade County infill program. This has created problems with all City owned land projects. All of our properties have contracts and the clients have been approved by Sun -Trust Bank. Two of the properties 1533 NW 58`h Terrace (Ms. Tanya Johnson) and 1600 NW 601h Street (Ms. Vicky Jones) have been approved by the City of Miami as well. We are working very close with Mayor Diaz, Commissioner Spence -Jones and City Manager Pete Hernandez to close as soon as possible. However, since the contract states that we must have a project completion date before April 30, 2008 and the City's definition of completion date is the sale of the house we want to make sure we de not have a problem at time of closing if Miami Dade County does not close on these loans by April 30. 2008. We are also requesting an extension of completion date for the property located at 6020 NW 151h Avenue from April 30, 2008 to December 31, 2008. This property is in the class 11 permit process. If you need additional information please do not hesitate to contact me. Francisco J Abella Secretary/Treasurer 22C N.W. 133th Averue kliam;, FL. 33162 ❑censeo o Lnsuree Phone. 76 -26 L5a72 Fax. 30 - 98-6431 MIAMI DREAM HOMES INVESTMENT GROUP, INC. January 31, 2008 George Mensah Assistant Director City of Miami Department of Community Development 444 SW 2nd Avenue Miami, Florida 33130 Dear Mr. Mensah: Vie have received you letter dated January 10, 2008 reference our agreement with the City of Miami for the construction of a 7 unit building. In the letter you mentioned that we are going to be in default of our executed agreement since we will not complete the building by April 30, 2008 as agreed. You are correct. We will not complete construction by April 30, 2008. We are requesting that the City grant us an extension through December 31, 2008 to complete the construction of the building. Attach please find the revised Development Schedule completing the project by December 31, 2008. As we explained to our Contract Compliance Analyst, Do(lila Pinkhasov, the Architect for this building was selected by the City of Miami not Miami Dream Homes. When we applied for funding to the City we had prepare the building design and we were working on the elevation and other plan work. The Loan Committee approved this project with a condition that an elevator be installed since it was going to be an "Elderly building". After the Loan Committee approved the project the City of Miami hired Arcon Engineering. We provided all of our design work as well as any other work we had completed to Arcon Engineering. The City paid 100% of the fees directly to the Architect rr.:.iking it very hard for us to request faster turn around as well as quality of work. These plans have been going to the City for more than a year. Two months ago the Zoning Department advised us that we had to apply for a Class II permit since the building was in a special district. We have completed the Class II permit and supplied the City with all the information. 220 N.W 130th Avenue Miami. FL 33182 L,censeo 6 Insured Phone: 786-281-5972 Fax' 305-698-6431 We have been working with Christine Morales, who has been our savior, and we Hope to have approved plans next week. We hope that you approve our request. If you have any questions please do not hesitate to contact Francisco J. Abella at 786-281-5972. rely, Jo - M. Reguefro, President Honorable Commissioner Spence -Jones Pete Hernandez, City Manager Hector Mirabile, Director Department of Community Development Elaine Black, Liberty City Trust Christine Morales, Assistant Director Building Department Dollila Pinkhasov, Contract Compliance Officer v"