HomeMy WebLinkAboutExhibit700710. FORM OF PERFORMANCE BOND (Page 1of 2)
BY THIS BOND, We , as Principal,
hereinafter called Contractor, and , as Surety, are bound
to the City of Miami, Florida, as Obligee, hereinafter called City, in the amount of
Dollars ($ ) for the payment whereof Contractor
and Surety bind themselves, their heirs, executors, administrators, successors and assigns,
jointly and severally.
WHEREAS, Contractor has by written agreement entered into a Contract, Bid/Contract
No: 06-07-012, awarded the
day of , 20 , with City which
Contract Documents are by reference incorporated herein and made a part hereof, and
specifically include provision for liquidated damages, and other damages identified, and for the
purposes of this Bond are hereafter referred to as the "Contract";
THE CONDITION OF THIS BOND is that if Contractor:
1. Performs the Contract between Contractor and City for construction of
, the Contract being made a
part of this Bond by reference, at the times and in the manner prescribed in the Contract;
and
2. Pays City all losses, liquidated damages, expenses, costs and attorney's fees including
appellate proceedings, that City sustains as a result of default by Contractor under the
Contract; and
3.Performs the guarantee of all Work and materials furnished under the Contract for the
time specified in the Contract; then THIS BOND IS VOID, OTHERWISE IT REMAINS IN
FULL FORCE AND EFFECT.
4. Whenever Contractor shall be, and declared by City to be, in default under the Contract,
City having performed City obligations thereunder, the Surety may promptly remedy the
default, or shall promptly:
4.1. Complete the Project in accordance with the terms and conditions of the
Contract Documents; or
Flagami/West End Phase II and Fairlawn Phase IIB Sewer Improvements Bid No.: 06-07-012
Page 158
00710. FORM OF PERFORMANCE BOND (Page 2 of 2)
4,2. Obtain a bid or bids for completing the Project in accordance with the terms
and conditions of the Contract Documents, and upon determination by Surety
of the lowest responsible Bidder, or, if City elects, upon determination by City
and Surety jointly of the lowest responsible Bidder, arrange for a contract
between such Bidder and City, and make available as work progresses (even
though there should be a default or a succession of defaults under the Contract
or Contracts of completion arranged under this paragraph) sufficient funds to
pay the cost of completion less the balance of the Contract Price; but not
exceeding, including other costs and damages for which the Surety may be
liable hereunder, the amount set forth in the first paragraph hereof. The term
"balance of the Contract Price," as used in this paragraph, shall mean the total
amount payable by City to Contractor under the Contract and any amendments
thereto, less the amount properly paid by City to Contractor.
No right of action shall accrue on this bond to or for the use of any person or corporation
other than City named herein.
The Surety hereby waives notice of and agrees that any changes in or under the
Contract Documents and compliance or noncompliance with any formalities connected
with the Contract or the changes does not affect Surety's obligation under this Bond.
Signed and sealed this day of , 20
WITNESSES:
Secretary By:
(CORPORATE SEAL)
(Name of Corporation)
(Signature)
(Print Name and Title)
IN THE PRESENCE OF: INSURANCE COMPANY:
By:
Agent and Attorney -in -Fact
Address:
(Street)
(City/State/Zip Code)
Telephone No.:
Flagami/West End Phase II and Fairlawn Phase IIB Sewer Improvements Bid No.: 06-07-012
Page 159
00720. FORM OF PAYMENT BOND (Page 1of 2)
BY THIS BOND, We , as Principal,
hereinafter called Contractor, and , as Surety, are bound
to the City of Miami, Florida, as Obligee, hereinafter called City, in the amount of
Dollars ($ ) for the payment whereof
Contractor and Surety bind themselves, their heirs, executors, administrators, successors and
assigns, jointly and severally.
WHEREAS, Contractor has by written agreement entered into a Contract, Bid/Contract
No. 06-07-012, awarded the day of , 20 , with City which
Contract Documents are by reference incorporated herein and made a part hereof, and
specifically include provision for liquidated damages, and other damages identified, and for the
purposes of this Bond are hereafter referred to as the "Contract";
THE CONDITION OF THIS BOND is that if Contractor:
1. Pays City all losses, liquidated damages, expenses, costs and attorney's fees including
appellate proceedings, that City sustains because of default by Contractor under the
Contract; and
2. Promptly makes payments to all claimants as defined by Florida Statute 255.05(1) for all
labor, materials and supplies used directly or indirectly by Contractor in the performance
of the Contract;
THEN CONTRACTOR'S OBLIGATION SHALL BE VOID; OTHERWISE, IT SHALL
REMAIN IN FULL FORCE AND EFFECT SUBJECT, HOWEVER, TO THE
FOLLOWING CONDITIONS:
2.1. A claimant, except a laborer, who is not in privity with Contractor and who has
not received payment for its labor, materials, or supplies shall, within forty-five
(45) days after beginning to furnish labor, materials, or supplies for the
prosecution of the work, furnish to Contractor a notice that he intends to look to
the bond for protection.
2.2. A claimant who is not in privity with Contractor and who has not received
payment for its labor, materials, or supplies shall, within ninety (90) days after
performance of the labor or after complete delivery of the materials or supplies,
deliver to Contractor and to the Surety, written notice of the performance of the
labor or delivery of the materials or supplies and of the nonpayment.
2.3. No action for the labor, materials, or supplies may be instituted against
Contractor or the Surety unless the notices stated under the preceding
conditions (2.1) and (2.2) have been given.
2.4. Any action under this Bond must be instituted in accordance with the longer of
the applicable Notice and Time Limitations provisions prescribed in Section
255.05(2), or Section 95,11,Florida Statutes.
Flagami/West End Phase II and Fairlawn Phase IIB Sewer Improvements Bid No.: 06-07-012
Page160
00720. FORM OF PAYMENT BOND (Page 2 of 2)
The Surety hereby waives notice of and agrees that any changes in or under the
Contract Documents and compliance or noncompliance with any formalities connected
with the Contract or the changes does not affect the Surety's obligation under this Bond.
Signed and sealed this day of , 20
ATTEST:
(Secretary)
(Corporate Seal)
IN THE PRESENCE OF:
By:
By:
Contractor
(Name of Corporation)
(Signature)
(Print Name and Title)
day of , 20
INSURANCE COMPANY:
Agent and Attorney -in -Fact
Address:
(Street)
(City/State/Zip Code)
Telephone No.:
Flagami/West End Phase II and Fairlawn Phase IIB Sewer Improvements Bid No.: 06-07-012
Page ]61
00721. CERTIFICATE AS TO CORPORATE PRINCIPAL
, certify that I am the Secretary of the
corporation named as Principal in the foregoing Performance and Payment Bond (Performance
Bond and Payment Bond); that , who signed the Bond(s) on behalf
of the Principal, was then of said corporation; that I know his/her signature; and
his/her signature thereto is genuine; and that said Bond(s) was (were) duly signed, sealed and
attested to on behalf of said corporation by authority of its governing body.
(SEAL)
Secretary (on behalf of)
Corporation
STATE OF FLORIDA
SS
COUNTY OF MIAMI-DADE )
Before me, a Notary Public duly commissioned, qualified and acting personally, appeared
to me well known, who being by me first duly
sworn upon oath says that he/she has been authorized to execute the foregoing Performance and
Payment Bond (Performance Bond and Payment Bond) on behalf of Contractor named therein in
favor of City.
Subscribed and Sworn to before me this day of , 20
My commission expires:
Notary Public, State of Florida at Large
Bonded by
Flagami/West End Phase II and Fairlawn Storm Sewer Improvements Phase IIB Bid No. 06-07-012
Page 162
00735. PERFORMANCE AND PAYMENT GUARANTY FORM
UNCONDITIONAL/IRREVOCABLE LETTER OF CREDIT: (Page 1 of 2)
Date of Issue
Issuing Bank's No.
Beneficiary: Applicant:
City of Miami
444 SW 2nd Avenue
Miami, Florida 33130
Amount:
in United States Funds
Expiry:
(Date)
Bid/Contract Number
We hereby authorize you to draw on
(Bank, Issuer name)
at by order
(branch address)
of and for the account of
(contractor, applicant, customer)
up to an aggregate amount, in United States Funds, of available by your
drafts at sight, accompanied by:
1. A signed statement from the City Manager or his authorized designee, that the drawing is
due to default in performance of certain obligations on the part of
(contractor, applicant, customer) agreed upon by and between the City of Miami, Florida
and (contractor, applicant, customer), pursuant to Bid/Contract No.
for (name of project) and Section 255.05, Florida Statutes.
Drafts must be drawn and negotiated not later than
(expiration date)
Flagami/West End Phase II and Fairlawn Storm Sewer Improvements Phase IIB Bid No. 06-07-012
Page 163
00735. PERFORMANCE AND PAYMENT GUARANTY FORM
UNCONDITIONAL/IRREVOCABLE LETTER OF CREDIT: (Page 2 of 2)
Drafts must bear the clause: "Drawn under Letter of Credit No. (Number), of
(Bank name) dated
This Letter of Credit shall be renewed for successive periods of one (1) year each unless we
provide the City of Miami with written notice of our intent to terminate the credit herein extended,
which notice must be provided at least thirty (30) days prior to the expiration date of the original
term hereof or any renewed one (1) year term. Notification to the City that this Letter of Credit will
expire prior to performance of the Contractor's obligations will be deemed a default.
This Letter of Credit sets forth in full the terms of our undertaking, and such undertaking shall not in
any way be modified, or amplified by reference to any documents, instrument, or agreement
referred to herein or to which this Letter of Credit is referred or this Letter of Credit relates, and any
such reference shall not be deemed to incorporate herein by reference any document, instrument,
or agreement.
We hereby agree with the drawers, endorsers, and bona fide holders of all drafts drawn under and
in compliance with the terms of this credit that such drafts will be duly honored upon presentation
to the drawee.
Obligations under this Letter of Credit shall be released one (1) year after the Final Completion of
the Project by the
(contractor, applicant, customer)
This Credit is subject to the "Uniform Customs and Practice for Documentary Credits," International
Chamber of Commerce (1993 revision), Publication No. 500 and to the provisions of Florida law. If
a conflict between the Uniform Customs and Practice for Documentary Credits and Florida law
should arise, Florida law shall prevail. If a conflict between the law of another state or country and
Florida law should arise, Florida law shall prevail.
Authorized Signature
Flagami/West End Phase 11 and Fairlawn Storm Sewer Improvements Phase IIB Bid No. 06-07-012
Page 164
1
Section 5 — Reports
1. Flagami West End Geotechnical Report -Atlantic
2. Flagami West End/Fairlawn Geotechnical Report-ATC
3. Flagami West End Utility Matrix
4. Flagami Utility Softdig Locations
5. Fairlawn Utility Matrix
6. Fairlawn Utility Softdig Locations
Flagaminest End Phase II and Fairlawn Storm Sewer Improvements Phase IIB Bid No. 06-07-012
Page 165