Loading...
HomeMy WebLinkAboutExhibit-SUBFM# 443911-1-52-01 Page 1 of 13 THIS DOCUMENT IS A SUBSTITUTION TO ORIGINAL. BACKUP ORIGINAL CAN BE SEEN AT THE END OF THIS DOCUMENT OFF -SYSTEM CONSTRUCTION AND MAINTENANCE AGREEMENT Between STATE OF FLORIDA, DEPARTMENT OF TRANSPORTATION ("DEPARTMENT") and The City of Miami, a Miami -Dade County, Florida municipality ("The City") THIS AGREEMENT is made and entered into as of August 22, 2023, by and through the STATE OF FLORIDA DEPARTMENT OF TRANSPORTATION, an agency of the State of Florida (the "Department"), and The City of Miami a municipality (the "City"), collectively referred to as the "Parties." RECITALS A. Upon approval of the Department's Work Program by the State of Florida Legislature, and adoption by the Department Secretary, the Department shall complete the various projects included in the Department Work Program; and B. Included in the Department Work Program is Project Number FM# 443911-1-52-01, SR- 5 from South of NE 5th Street to South of NE 1 l th Street (the "Project"). A portion of the Project includes work on NE 10th street, in the City of Miami, Miami -Dade County, Florida, a road not on the State Highway System (See Attachment A); and C. The City is the holder of ownership rights to NE 10th Street, a road not on the State Highway System; and D. The Parties agree that it is in the best interest of each party for the Department to undertake and to complete all aspects of the Project, including but not limited to, the design, construction, construction inspection, maintenance during construction, utilities, easements, and other associated tasks; and E. The Parties further agree that it is in the best interest of each party to enter into this Agreement in order to allow the Department to construct and complete the Project. Rev. 6/22 1 14974 Exhibit -SUB FM# 443911-1-52-01 Page 2 of 13 THIS DOCUMENT IS A SUBSTITUTION TO ORIGINAL. BACKUP ORIGINAL CAN BE SEEN AT THE END OF THIS DOCUMENT TERMS NOW THEREFORE, in consideration of the premises, the mutual covenants and other valuable considerations contained herein, the receipt and sufficiency of which are hereby acknowledged, the Parties agree as follows: 1. The recitals in this Agreement are true and correct, and incorporated into and made a part hereof. 2. The Parties agree that the Department intends to undertake and complete Project Number FM# 443911-1-52-01 which generally includes the following: • Milling and resurfacing of the roadway pavement • Upgrading the curb ramps according to the American with Disabilities Act • Upgrading the drainage system by replacing the two drainage pumps and installing drainage pipes and inlets according to plans. • Upgrading the signing and pavement markings; and • Upgrading the pedestrian signals at the intersections to meet standards. The Project shall include improvements on NE loth Street, from Sta 120+66.43 to Sta 120+95.31 and extending approximately 32 feet west of the FDOT right of way (for purposes of this agreement, the "Off -System Project Limits"). The work within the Off -System Project Limits shall include, but may not be limited to the following (hereinafter referred to as the "Local Roadway Improvements"): a) Installation of drainage inlet structures S-57 and S-59 b) Installation of 14" x 23: elliptical pipes connecting new drainage inlets to existing drainage structures. c) Installation of curb and gutter along NE loth Street The Project shall further include all activities associated with or arising out of the construction of the Local Roadway Improvements. In the event that the Project requires the acquisition of additional right-of-way within the Off -System Project Limits, the Depaitiiient shall acquire such right-of-way in order to complete the Project. The City shall cooperate with and shall support the Department's work efforts in this regard. Rev. 6/22 2 FM# 443911-1-52-01 Page 3 of 13 THIS DOCUMENT IS A SUBSTITUTION TO ORIGINAL. BACKUP ORIGINAL CAN BE SEEN AT THE END OF THIS DOCUMENT The Department will design and construct the Project in accordance with all applicable federal and state laws and regulations and in accordance with Department design and construction standards as set forth in the Department's guidelines, standards, and procedures. The Department shall have final decision authority with respect to the design, the design review process, and construction of the Local Roadway Improvements, and the relocation of any utilities that the Department may determine to be required. 3. The Parties acknowledge and agree that the City will review the Project Design Plans ("Project Design Plans") and shall submit its comments, if any, via Electronic Reviewer Comments ("ERC"). The Department shall provide the City access to the ERC, and the Department shall use the ERC to submit the Project Design Plans for the City to review. When the Department places the Project Design Plans in the ERC, the Department will designate a Comment Due Date and a Response Due Date. The City shall submit its comments with regards to the Project Design Plans on or before the Comment Due Date, and the Department shall respond to the City's comments, if any, on or before the Response Due Date. If the City does not submit its comments by the Comment Due Date, the City will be deemed to have approved the Project Design Plans submitted by the Department. The review process for the Project Design Plans will be deemed concluded when the Department has submitted the Final Project Design Plans to the ERC, and the Comment Due Date and Response Due Date for the Final Project Design Plans have passed, and the Department has addressed all of the City's comments that were submitted through the ERC. Once the review process is concluded, the Department will construct the Project in accordance with the Final Project Design Plans submitted through the ERC. The City acknowledges and agrees that, during construction of the Local Roadway Improvements, the Department will only utilize the services of law enforcement officers when required by the Department's Standard Specifications for Road and Bridge Construction, and no additional requirements will be imposed. No further agreements or permits shall be required for production or construction of this Project. Major modifications of the approved Project Design Plans must be submitted to the City for review. A "Major Modification" is any modification that materially alters the kind or nature of the work depicted in the approved Project Design Plans, or that alters the integrity or maintainability of the Local Roadway Improvements, or related components. The City 's review shall be within the reasonable time schedule proposed by the Department, in order to avoid delay Rev. 6/22 3 FM# 443911-1-52-01 Page 4 of 13 THIS DOCUMENT IS A SUBSTITUTION TO ORIGINAL. BACKUP ORIGINAL CAN BE SEEN AT THE END OF THIS DOCUMENT to the Department's construction contract. In the event that any Major Modifications are required during construction, the Department shall be entitled to proceed with the modifications that are necessary to complete the construction of the Project, and shall, upon identifying the need for a Major Modification, immediately notify the City of the required changes prior to proceeding with implementation of the same. It is specifically understood and agreed that any such changes during construction shall not delay nor affect the timely construction schedule of the Project. 4. The City agrees to fully cooperate with the Department in the construction, reconstruction and relocation of utilities that are located within the City's right-of-way, within the Off -System Project Limits. The utility relocations, if any, which may be required by the Department for the purposes of the Project, shall be done in accordance with the Department's guidelines, standards and procedures. The Department shall submit the proposed utility relocation schedule to the City. Utility relocations, if any, shall be done in accordance with the provisions of Chapter 337, F. S. Additionally, the City agrees to fully cooperate with the Department in the removal of any encroachments or permitted improvements, and in the modification of any driveway connections, located within the City's right-of-way, within the Off -System Project Limits, that are in conflict with the Project, and the City hereby authorizes the Department to take any legal action necessary to effectuate the removal of any such conflicting encroachments or permitted improvements, and to effectuate the modification of any such driveway connections. The Department shall coordinate with the City for said removals or modifications, at no cost to the City. 5. The City agrees to perpetually maintain the Local Roadway Improvements. To maintain means to perform normal maintenance operations for the preservation of the Local Roadway Improvements, which shall include but is not limited to, roadway surfaces, shoulders, roadside structures, drainage, signing and pavement markers, lighting, and such traffic control devices as are necessary for the safe and efficient use of the Local Roadway Improvements. Additionally, the Parties understand and agree that the Department shall transfer any permit(s) required for the construction of the Local Roadway Improvements, if any, to the City as the operational maintenance entity, and the City agrees to accept said transfer and to be fully responsible to comply with all operational and maintenance conditions of the permit(s), at its sole cost and expense. Rev. 6/22 4 FM# 443911-1-52-01 Page 5 of 13 THIS DOCUMENT IS A SUBSTITUTION TO ORIGINAL. BACKUP ORIGINAL CAN BE SEEN AT THE END OF THIS DOCUMENT Notwithstanding the requirements hereof, maintenance during construction shall be the responsibility of the Department and its Contractor, as set forth in paragraph 9 of this Agreement. 6. The Parties acknowledge and agree that the City 's right-of-way and the improvements and structures located within the City's right-of-way, are and will remain under the ownership of the City, and that the Department will not have any ownership interest in the right-of-way, improvements, or structures located thereon or installed therein pursuant to this Project. 7. The Department shall require its construction Contractor to maintain, at all times during construction, Commercial General Liability insurance providing continuous coverage for all work or operations performed under the construction contract. Such insurance shall be no more restrictive than that provided by the latest occurrence form edition of the standard Commercial General Liability Coverage Form (ISO Form CG 00 01) as filed for use in the State of Florida. The limits of coverage shall not be less than $1,000,000 for each occurrence and not less than a $5,000,000 annual general aggregate, inclusive of amounts provided by an umbrella or excess policy, or such other minimum insurance coverage that may be required by the Department for the construction of the Project, in accordance with the Department's Standards and Specifications for Road and Bridge Construction. The Department shall further cause its Contractor to name the City and the Department as additional insured Parties on the afore -stated policies, and to provide evidence of Workers' Compensation Insurance in accordance with the laws of the State of Florida and in amounts sufficient to secure the benefit of the Florida Workers' Compensation law for all employees. 8. The Department shall notify the City at least 48 hours before beginning construction within the City's right-of-way. Such notification may be provided via email to the Department of Resiliency and Public Works, and the notice requirements set forth in paragraph 20 shall not apply to this paragraph. The Department agrees that the City may, at reasonable times during the construction of the Local Roadway Improvements, inspect the Contractor's construction site and perform such tests as are reasonably necessary to determine whether the goods or services required to be provided by the Contractor, pursuant to the Contractor's Construction Agreement with the Department, conform to the terms of said Construction Agreement. Upon request by the City, the Department shall coordinate with its Contractor to provide access to the City for performance of said inspections. During the construction work related to the Project, the City shall fully cooperate with any such Rev. 6/22 5 FM# 443911-1-52-01 Page 6 of 13 THIS DOCUMENT IS A SUBSTITUTION TO ORIGINAL. BACKUP ORIGINAL CAN BE SEEN AT THE END OF THIS DOCUMENT work being performed by the Department and the Department's contractors. The City shall not commit nor permit any act which may delay or interfere with the performance of any such work by the Department or the Department's contractors, unless the Department agrees in writing that the City may commit, or permit said act. 9. Maintenance during construction within the Off -System Project Limits, commencing as of the first date of construction, shall be the responsibility of the Department's Contractor. Notwithstanding, neither the Department nor its Contractor shall be responsible for mowing or removing litter during construction of the Project. After completion of construction, the City shall assume all maintenance responsibilities for the Local Roadway Improvements. Upon completion of construction, the Department is required to invite the City on the Final Inspection of the work within the Off -System Project Limits and will incorporate legitimate City concerns that are within the scope of the contract into the final Project punch list to be corrected by the Contractor. Notice for Final Inspection shall be delivered via email to the Department of Resiliency and Public Works and the notice provision of paragraph 20 shall not be applicable. However, if the City does not attend the Final Inspection, the Department shall proceed to conduct the Final Inspection, finalize the Project punch list, and issue a Notice of Final Acceptance to its Contractor. The Final Inspection shall be performed, and the Notice of Final Acceptance shall be issued in accordance with the Department's Standard Specifications for Road and Bridge Construction and the Construction Project Administration Manual (CPAM). Upon issuance of the Notice of Final Acceptance to the Contractor, the Department shall provide a copy of said notice to the City As of the date of the Notice of Final Acceptance, the City shall be immediately responsible for the maintenance of the Local Roadway Improvements and shall further accept the Local Roadway Improvements. The Department, however, shall have the right to assure completion of any punch list by the Contractor. Notwithstanding the issuance of the Notice of Final Acceptance, the City may notify the Department Project Manager of deficiencies in the Local Roadway Improvements that may be covered by the warranty provisions in the contract between the Department and its Contractor. The Department shall enforce the warranty if remedial action is required by the warranty provisions, as determined by the Department. Upon completion of all work related to construction of the Project, the Department will be required to submit to the City final as -built plans for the Local Roadway Improvements and an Rev. 6/22 6 FM# 443911-1-52-01 Page 7 of 13 THIS DOCUMENT IS A SUBSTITUTION TO ORIGINAL. BACKUP ORIGINAL CAN BE SEEN AT THE END OF THIS DOCUMENT engineering certification that construction was completed in accordance with the plans. Additionally, the Department shall vacate those portions of the City's right-of-way used to construct the Local Roadway Improvements, and shall remove the Department's property, machinery, and equipment from said portions of the City's right-of-way. Furthermore, the Department shall restore those portions of the City's right-of-way disturbed by Project construction activities to the same or better condition than that which existed immediately prior to commencement of the construction of the Project. 10. Upon submission by the Department of a deed, with accompanying sketch and legal description, for the transfer to the City of any additional right-of-way acquired by the Department within the Off -System Project Limits, the City shall forthwith submit the same to its governing board or commission for approval and acceptance of such additional right-of-way. 11. This Agreement shall become effective as of the date both parties hereto have executed the Agreement. Prior to commencement of construction, the Department may in its sole discretion teiiiiinate this Agreement if it determines that it is in the best interest of the public to do so. If the Department elects to terminate this Agreement, the Department shall deliver foiiiial notice of termination to the City as set forth in paragraph 20 of this Agreement. 12. In the event that any election, referendum, approval, ratification, notice or other proceeding, or authorization is required to carry out the Project, the City agrees to expeditiously initiate and consummate, as provided by law, all actions necessary with respect to any such matters, with time being of the essence. 13. The Department may utilize federal funds to design and construct the Project. In the event that the Project shall be constructed using federal funds, all costs incurred must be in conformity with applicable federal and state laws, regulations, and policies and procedures. 14. The Department's performance and obligations under this Agreement are contingent upon an annual appropriation by the Legislature. If the Department's funding for this Project is in multiple fiscal years, funds approval from the Department's Comptroller must be received each fiscal year prior to costs being incurred. 15. In the event that this Agreement is in excess of $25,000, and the Agreement has a term for a period of more than one year, the provisions of Section §339.135(6)(a), Florida Statutes, are hereby incorporated into this Agreement and are as follows: Rev. 6/22 7 FM# 443911-1-52-01 Page 8 of 13 THIS DOCUMENT IS A SUBSTITUTION TO ORIGINAL. BACKUP ORIGINAL CAN BE SEEN AT THE END OF THIS DOCUMENT "The department, during any fiscal year, shall not expend money, incur any liability, or enter into any contract which, by its terms, involves the expenditure of money in excess of the amounts budgeted as available for expenditure during any such fiscal year. Any contract, verbal or written, made in violation of this subsection is null and void, and no money may be paid on such contract. The department shall require a statement from the comptroller of the department that funds are available prior to entering into any such contract or other binding commitment of funds. Nothing herein contained shall prevent the making of contracts for periods exceeding 1 year, but any contract so made shall be executory only for the value of the services to be rendered or agreed to be paid for in succeeding fiscal years; and this paragraph shall be incorporated verbatim in all contracts of the department which are for an amount in excess of $25, 000 and which have a term for a period of more than 1 year." 16. The Department is a state agency, self -insured and subject to the provisions of Section 768.28, Florida Statutes. Nothing in this Agreement shall be deemed or otherwise interpreted as waiving the Department's sovereign immunity protections, or as increasing the limits of liability as set forth in Section 768.28, Florida Statutes. 17. A modification or waiver of any of the provisions of this Agreement shall be effective only if made in writing and executed with the same formality as this Agreement. 18. This Agreement shall be governed by the laws of the State of Florida. Any provision hereof found to be unlawful or unenforceable shall be severable and shall not affect the validity of the remaining portions hereof. Venue for any and all actions arising out of or in any way related to the interpretation, validity, performance or breach of this Agreement shall lie exclusively in a state court of appropriate jurisdiction in Leon County, Florida. 19. No term or provision of this Agreement shall be interpreted for or against any party because that party's legal counsel drafted the provision. 20. In accordance with Executive Order No. 11-02 the Department's Vendor/Contractor(s) shall utilize the U.S. Department of Homeland Security's E-Verify system, in accordance with the terms governing use of the system, to confirm the employment eligibility of. i. all persons employed by the Vendor/Contractor during the term of the Contract to perform employment duties within Florida; and ii. all persons, including subcontractors, assigned by the Vendor/Contractor to perform work pursuant to the contract with the Department. Rev. 6/22 8 FM# 443911-1-52-01 Page 9 of 13 THIS DOCUMENT IS A SUBSTITUTION TO ORIGINAL. BACKUP ORIGINAL CAN BE SEEN AT THE END OF THIS DOCUMENT 21. All notices required pursuant to the terms hereof, shall be in writing and shall be sent by first class United States Mail, facsimile transmission, hand delivery or express mail. Notices shall be deemed to have been received by the end of five (5) business days from the proper sending thereof unless proof of prior actual receipt is provided. Unless otherwise notified in writing, notices shall be sent to the following: To the City: Arthur Noriega Miami City Manager 444 SW 2nd Ave Miami, FL, 33130 To the Department: Director of Transportation Operations State of Florida, Department of Transportation 1000 N.W. 111 th Avenue Miami, Florida 33172 22. The City, by and through Resolution No. , attached hereto as Exhibit has duly authorized the execution and delivery of this Agreement and agrees to be bound by the terms hereunder, and has further authorized the Mayor or his designee to take all necessary steps to effectuate the terms of this Agreement. Rev. 6/22 9 FM# 443911-1-52-01 Page 10 of 13 THIS DOCUMENT IS A SUBSTITUTION TO ORIGINAL. BACKUP ORIGINAL CAN BE SEEN AT THE END OF THIS DOCUMENT IN WITNESS WHEREOF, the parties hereto have executed this Agreement on the dates exhibited, by the signatures below. STATE OF FLORIDA DEPARTMENT OF TRANSPORTATION By: By: Name: Title: Name: Title: Director of Transportation Operations Date: Date: Attest: Name: Title: Approved as to form and legality: Department Legal Review: By: Name: Rev. 6/22 10 THIS DOCUMENT IS A SUBSTITUTION TO ORIGINAL. BACKUP ORIGINAL CAN BE SEEN AT THE END OF THIS DOCUMENT CITY OFMIAMI, a Florida municipal corporation ATTEST: BY: Todd B. City Clerk Arthur . iega City Manager APPROVED AS TO LEGAL FORM AND APPROVED AS TO INSURANCE CORRECTNESS: BY: Victoria Mendez \//�ri/ City Attorney #23-2455 REQUIREMENTS: BY: Anne -Marie Sharpe, Director Risk Management THIS DOCUMENT IS A SUBSTITUTION TO ORIGINAL. BACKUP ORIGINAL CAN BE SEEN AT THE END OF THIS DOCUMENT ATTACHMENT A ATTACHMENT A LEGEND Limits of Ott System Agreement 14264' L EXIST IS" PIPE ql a Itl rI; ui 7 lfip NI I\ I, +86 F. 259 TYPE T A C OH V1 5 H]— 2431LT3 ELLIP PIPE EXIST. 42" PIPE /HH2— PAY L 1E 0 O 1,2 pV�F t3xr-- - . ( C/D1 � FOC(D1-- ----e FO (B) ____ BFO 7 _..�,{�11 .--®--�-6101-0-- 0 (To kEP.ArED el ce' LT D GF{S - f� JQ r US-1/SR-5 (5B) N SR-5 15 4 +15 a/ 24a4.u2'4] LT. ae.7 s r 1,81 ;US-1/SR-5 (NB) ®— ur-' " s FM 4,12' e E DETECTABLE Id/AMU,. REP1ACrD1 +87 8 11131N1311113 PVERS DETECTABLE / 6S I I MILLI. 5 RESURFACINL ® OCP EL RDRI/I.TI(111 1,17 PT F 7853RI. -VVN63 EO':. 42'°1°E EE„IJ HST 'T'. + JJ 4 ,. E Ty),sT. DETECTAELE WARNING (TO BE REPL4(.FD) IIAT _a P r r n ao TA +EXIST. 994 A E/IST. IS" PIPE 9PEN1 ,1S ,E FL9325eo 143 6 TO uF REMOVED 3.e JT T. END' THE 1 14.11-f EXIST CURE STA 5 3. I, Se LI f I I IP. PIPE LT -01 2'� LT. +77 3.068L 1T E 51 T9' =4 -.Pa TT' 4fi53 4T- a V1R1Z H Tl ADJ11S U L X +5I0 PT ST. 3.85 TJ 4J w +1 /.al J4JJR HT 45 rT1 - kr. vHn—� „4I PP I, EX1ST. D=TECT 43LE (T0 DC 4EPLACL D) THIS DOCUMENT IS A SUBSTITUTION TO ORIGINAL BACKUP ORIGINAL CAN BE SEEN AT THE END OF THIS DOCUMENT 81.F J PIPE HE In ED CONS, 36 P v 31.94 Lf DR}�"PIPE-- LT Vm64 ApE MTER- E yu 256 TYPE F 13 la L +8688 Eal GTYPEF 8 T]\ 8VLLE, TA +77 72, 72 kT. 63 -2 oFeet 8- -eEDn N.. BFOCLO-7---h El l%Y---- HAT, E T4I' T. CURB,..„,— 1 +2. JT CR I N L T 6;.. —D_VEIO ND C TYPE F 64 RT FDOT 1T 725 ar1g -- 1 s EIsr DPnI �aEEL TO L_ VjAra DIP CONST_30" PIP RRV LINE +84.83 8.1.518 PT 82oT9 RT. OL8IEXIST. WVT .I ' Q - ,F 1 JU Y IDNASDi fi EXIST QEX TORM IAHT CTDB) TA 4 2CURS Q' ( 8 ADJUSTED J dYTOBY COJTRAFP�� ' /IST . 0ck1ST. SF Fk VALVE (TO RE AIJl1STEDB /�1/ASS]'ra35 BY� ¢ . BS RTm HAURICE A. FFRRE PARK - eu loco Ex]SC orC"FABL NARRI1,18 CUR\ F E2 88 PC = PT = 124+8_.94 RT) Z ENGINEER OF RECORD DESCRIPTIoN DATE LA,IPTEY, P.E. PTOE LICENSE NUYBER 68,1 Eau AssnaATES Imc. 14750 Idel. 77TH C61,T, ELITTF� -o LSF3X EVENT F £t Jnm'80XZ9£Bv11' CoUNTY FINANCIAL PRoJECT ID SR 5 ROADWA Y PLANS SHEET NO. 15 FM# 443911-1-52-01 Page 1 of 13 SUBSTITUTED OFF -SYSTEM CONSTRUCTION AND MAINTENANCE AGREEMENT Between STATE OF FLORIDA, DEPARTMENT OF TRANSPORTATIO ("DEPARTMENT") and The City of Miami, a Miami -Dade County, Florida muni► • ality ("The City") THIS AGREEMENT is made and entered into as of August 22, 2 ' 3, by and through the STATE OF FLORIDA DEPARTMENT OF TRANSPORTATION, an gency of the State of Florida (the "Department"), and The City of Miami a municipality (t ' "City"), collectively referred to as the "Parties." CITALS A. Upon approval of the Depa ent' s Work Program by the State of Florida Legislature, and adoption by the Department Secreta , the Department shall complete the various projects included in the Department Work Program; a B. Included in the De rtment Work Program is Project Number FM# 443911-1-52-01, SR- 5 from South ofNE 5th Street t ► outh ofNE l l th Street (the "Project"). A portion of the Project includes work on NE 10th street, i e City of Miami, Miami -Dade County, Florida, a road not on the State Highway System (See • achment A); and C. The is the holder of ownership rights to NE loth Street, a road not on the State Highway System- . nd D. he Parties agree that it is in the best interest of each party for the Department to undertake . d to complete all aspects of the Project, including but not limited to, the design, construction, construion inspection, maintenance during construction, utilities, easements, and other associated task • and E. The Parties further agree that it is in the best interest of each party to enter into this Agreement in order to allow the Department to construct and complete the Project. Rev. 6/22 1 FM# 443911-1-52-01 Page 2 of 13 SUBSTITUTED TERMS NOW THEREFORE, in consideration of the premises, the mutual covenants a other valuable considerations contained herein, the receipt and sufficiency of which are hereby knowledged, the Parties agree as follows: 1. The recitals in this Agreement are true and correct, and incorporated i . • and made a part hereof. 2. The Parties agree that the Department intends to undertake and co plete Project Number FM# 443911-1-52-01 which generally includes the following: • Milling and resurfacing of the roadway pavement • Upgrading the curb ramps according to the America ith Disabilities Act • Upgrading the drainage system by replacing the o drainage pumps and installing drainage pipes and inlets according to plans. • Upgrading the signing and pavement mar gs; and • Upgrading the pedestrian signals at the ' tersections to meet standards. The Project shall include improvem- is on NE l0th Street, from Sta 120+66.43 to Sta 120+95.31 and extending approx ately 32 feet west of the FDOT right of way (for purposes of this agreement, the "Off-S . em Project Limits"). The work within the Off -System Project Limits shall include, but not be limited to the following (hereinafter referred to as the "Local Roadway Impr• ements"): a) Installation drainage inlet structures S-57 and S-59 b) Installati•. of 14" x 23: elliptical pipes connecting new drainage inlets to existing draina • structures. c) Inst- ation of curb and gutter along NE loth Street The P eject shall further include all activities associated with or arising out of the construction f e Local Roadway Improvements. In the event that the Project requires the acquisition of dditional right-of-way within the Off -System Project Limits, the Department shall acquire such right-of-way in order to complete the Project. The City shall cooperate with and shall support the Department' s work efforts in this regard. Rev. 6/22 2 FM# 443911-1-52-01 Page 3 of 13 SUBSTITUTED The Department will design and construct the Project in accordance with all applicable eral and state laws and regulations and in accordance with Department design and co . .'ruction standards as set forth in the Department' s guidelines, standards, and procedures. Th • epartment process, and shall have final decision authority with respect to the design, the design revi construction of the Local Roadway Improvements, and the relocation of a► utilities that the Department may determine to be required. 3. The Parties acknowledge and agree that the City will review the Proj : Design Plans ("Project Design Plans") and shall submit its comments, if any, via Ele onic Reviewer Comments ("ERC"). The Department shall provide the City access to the use the ERC to submit the Project Design Plans for the Ci places the Project Design Plans in the ERC, the Departm and a Response Due Date. The City shall submit its c Plans on or before the Comment Due Date, and comments, if any, on or before the Response D by the Comment Due Date, the City will b RC, and the Depai tiuent shall to review. When the Department t will designate a Comment Due Date ments with regards to the Project Design Department shall respond to the City's Date. If the City does not submit its comments eemed to have approved the Project Design Plans submitted by the Department. The revie process for the Project Design Plans will be deemed concluded when the Department has bmitted the Final Project Design Plans to the ERC, and the Comment Due Date and Resp se Due Date for the Final Project Design Plans have passed, and the Department has addre ERC. Once the review p accordance with the acknowledges and a Department will Department' s requireme or cons ed all of the City's comments that were submitted through the cess is concluded, the Department will construct the Project in al Project Design Plans submitted through the ERC. The City ees that, during construction of the Local Roadway Improvements, the my utilize the services of law enforcement officers when required by the tandard Specifications for Road and Bridge Construction, and no additional will be imposed. No further agreements or permits shall be required for production ction of this Project. Maj ► modifications of the approved Project Design Plans must be submitted to the City for r� iew. A "Major Modification" is any modification that materially alters the kind or nature of the work depicted in the approved Project Design Plans, or that alters the integrity or maintainability of the Local Roadway Improvements, or related components. The City 's review shall be within the reasonable time schedule proposed by the Department, in order to avoid delay Rev. 6/22 3 FM# 443911-1-52-01 Page 4 of 13 SUBSTITUTED to the Department's construction contract. In the event that any Major Modifications are re ► fired during construction, the Department shall be entitled to proceed with the modificatio that are necessary to complete the construction of the Project, and shall, upon identifying tr need for a Major Modification, immediately notify the City of the required changes prior to - oceeding with implementation of the same. It is specifically understood and agreed that any ch changes during construction shall not delay nor affect the timely construction schedule o e Project. 4. The City agrees to fully cooperate with the Department in the const Lion, reconstruction and relocation of utilities that are located within the City' s right -of- ay, within the Off -System Project Limits. The utility relocations, if any, which may be re. d ired by the Department for the purposes of the Project, shall be done in accordance with the epartment' s guidelines, standards and procedures. The Department shall submit the propose ' utility relocation schedule to the City. Utility relocations, if any, shall be done in accordanc- • ith the provisions of Chapter 337, F. S. Additionally, the City agrees to fully cooperate ith the Department in the removal of any encroachments or permitted improvements, anthe modification of any driveway connections, located within the City' s right-of-way, with' the Off -System Project Limits, that are in conflict with the Project, and the City hereby aut sizes the Department to take any legal action necessary to effectuate the removal of any such nflicting encroachments or permitted improvements, and to effectuate the modi ation of any such driveway connections. The Department shall coordine with the City for said removals or modifications, at no cost to the City. 5. The City agrees to perp: ally maintain the Local Roadway Improvements. To maintain means to perform normal aintenance operations for the preservation of the Local Roadway Improvements, w ch shall include but is not limited to, roadway surfaces, shoulders, roadside structures, dr. ' age, signing and pavement markers, lighting, and such traffic control devices as are necessfor the safe and efficient use of the Local Roadway Improvements. Additio lly, the Parties understand and agree that the Department shall transfer any permit(s) req ed for the construction of the Local Roadway Improvements, if any, to the City as the erational maintenance entity, and the City agrees to accept said transfer and to be fully responsible to comply with all operational and maintenance conditions of the permit(s), at its sole cost and expense. Rev. 6/22 4 FM# 443911-1-52-01 Page 5 of 13 SUBSTITUTED Notwithstanding the requirements hereof, maintenance during construction shall ., the responsibility of the Department and its Contractor, as set forth in paragraph 9 of this A_ eement. 6. The Parties acknowledge and agree that the City 's right-of-way and the impro ments and structures located within the City' s right-of-way, are and will remain under the ' ership of the City, and that the Department will not have any ownership interest improvements, or structures located thereon or installed therein pursuant 7. The Department shall require its construction Contractor to mai n, i the right-of-way, this Project. at all times during construction, Commercial General Liability insurance providing ontinuous coverage for all work or operations performed under the construction contract. • ch insurance shall be no more restrictive than that provided by the latest occurrence form tion of the standard Commercial General Liability Coverage Form (ISO Form CG 00 01) . s filed for use in the State of Florida. The limits of coverage shall not be less than $1,000,0 $5,000,000 annual general aggregate, inclusive o policy, or such other minimum insurance cove the construction of the Project, in accordanc for Road and Bridge Construction. The for each occurrence and not less than a mounts provided by an umbrella or excess ge that may be required by the Department for ith the Department' s Standards and Specifications epartment shall further cause its Contractor to name the City and the Department as add onal insured Parties on the afore -stated policies, and to provide evidence of Workers' Co ► pensation Insurance in accordance with the laws of the State of Florida and in amounts suff lent to secure the benefit of the Florida Workers' Compensation law for all employees. 8. The Department shall n► ify the City at least 48 hours before beginning construction within the City' s right-of-way. Such notification may be provided via email to the Department of Resiliency and P • lic Works, and the notice requirements set forth in paragraph 20 shall not apply to this • agraph. The Depar ent agrees that the City may, at reasonable times during the construction of the Local Roadw. Improvements, inspect the Contractor' s construction site and perform such tests as are reas► ably necessary to determine whether the goods or services required to be provided by the ntractor, pursuant to the Contractor' s Construction Agreement with the Department, conform to the terms of said Construction Agreement. Upon request by the City, the Department shall coordinate with its Contractor to provide access to the City for performance of said inspections. During the construction work related to the Project, the City shall fully cooperate with any such Rev. 6/22 5 FM# 443911-1-52-01 Page 6 of 13 SUBSTITUTED work being performed by the Department and the Department' s contractors. The City sh not commit nor permit any act which may delay or interfere with the performance of any s h work by the Department or the Department' s contractors, unless the Department agrees i riting that the City may commit, or permit said act. 9. Maintenance during construction within the Off -System Project Limits, co ' encing as of the first date of construction, shall be the responsibility of the Department's Contractor. Notwithstanding, neither the Department nor its Contract. . shall be responsible for mowing or removing litter during construction of the Project. Afte completion of construction, the City shall assume all maintenance responsibilities for the Ls al Roadway Improvements. Upon completion of construction, the Department is requ' - d to invite the City on the Final Inspection of the work within the Off -System Project Li • s and will incorporate legitimate City concerns that are within the scope of the contract into e final Project punch list to be corrected by the Contractor. Notice for Final Inspection sha • e delivered via email to the Department of Resiliency and Public Works and the no e provision of paragraph 20 shall not be applicable. However, if the City does not : ttend the Final Inspection, the Department shall proceed to conduct the Final Inspectio finalize the Project punch list, and issue a Notice of Final Acceptance to its Contractor. e Final Inspection shall be performed, and the Notice of Final Acceptance shall be issued ' accordance with the Department's Standard Specifications for Road and Bridge Const ction and the Construction Project Administration Manual (CPAM). Upon issuance of the N s ce of Final Acceptance to the Contractor, the Department shall provide a copy of said notice o the City As of the date of the Notice of Final Acceptance, the City shall be immediately responsible for the maintenance of the Local Roadway Improvements and shall further accept e Local Roadway Improvements. The Department, however, shall have the right to assure cpletion of any punch list by the Contractor. Notwithstanding the issuance of the Notice ► Final Acceptance, the City may notify the Department Project Manager of deficiencies in t . Local Roadway Improvements that may be covered by the warranty provisions in the tract between the Department and its Contractor. The Department shall enforce the warranty if remedial action is required by the warranty provisions, as determined by the Department. Upon completion of all work related to construction of the Project, the Department will be required to submit to the City final as -built plans for the Local Roadway Improvements and an Rev. 6/22 6 FM# 443911-1-52-01 Page7of13 SUBSTITUTED engineering certification that construction was completed in accordance with the ans. Additionally, the Department shall vacate those portions of the City' s right-of-wa used to construct the Local Roadway Improvements, and shall remove the Departmen property, machinery, and equipment from said portions of the City' s right-of-way. F . hermore, the Department shall restore those portions of the City's right-of-way di rbed by Project construction activities to the same or better condition than that which exi • ed immediately prior to commencement of the construction of the Project. 10. Upon submission by the Department of a deed, with accompanyin:. etch and legal description, for the transfer to the City of any additional right-of-way acqui 6' by the Department within the Off -System Project Limits, the City shall forthwith submit e same to its governing board or commission for approval and acceptance of such additio right-of-way. 11. This Agreement shall become effective as of the d - both parties hereto have executed the Agreement. Prior to commencement of construct , the Department may in its sole discretion terminate this Agreement if it determines that ' is in the best interest of the public to do so. If the Department elects to terminate this Agre ent, the Department shall deliver formal notice of termination to the City as set forth in pa graph 20 of this Agreement. 12. In the event that any election, refere r 4 um, approval, ratification, notice or other proceeding, or authorization is required to carry ut the Project, the City agrees to expeditiously initiate and consummate, as provided by , all actions necessary with respect to any such matters, with time being of the essence. 13. The Department may u ze federal funds to design and construct the Project. In the event that the Project shall be c► structed using federal funds, all costs incurred must be in conformity with applicable federa . nd state laws, regulations, and policies and procedures. 14. The Departm: is performance and obligations under this Agreement are contingent upon an annual app •priation by the Legislature. If the Department' s funding for this Project is in multiple fiscal y: rs, funds approval from the Department' s Comptroller must be received each fiscal year prio o costs being incurred. 15. I' the event that this Agreement is in excess of $25,000, and the Agreement has a term for a period of more than one year, the provisions of Section §339.135(6)(a), Florida Statutes, are hereby incorporated into this Agreement and are as follows: Rev. 6/22 7 FM# 443911-1-52-01 Page 8 of 13 SUBSTITUTED "The department, during any fiscal year, shall not expend money, incur any liability, or nter into any contract which, by its terms, involves the expenditure of money in excess of th, 'mounts budgeted as available for expenditure during any such fiscal year. Any contra. , verbal or written, made in violation of this subsection is null and void, and no money may . e paid on such contract. The department shall require a statement from the comptroller oft e department that funds are available prior to entering into any such contract or other b ding commitment of funds. Nothing herein contained shall prevent the making of contract for periods exceeding 1 year, but any contract so made shall be executory only for the value ,fthe services to be rendered or agreed to be paid for in succeeding fiscal years; and this p ragraph shall be incorporated verbatim in all contracts of the department which are for s amount in excess of $25, 000 and which have a term for a period of more than 1 year." 16. The Department is a state agency, self -insured and s eject to the provisions of Section 768.28, Florida Statutes. Nothing in this Agreement shall s deemed or otherwise interpreted as waiving the Department' s sovereign immunity protect ' s, or as increasing the limits of liability as set forth in Section 768.28, Florida Statutes. 17. A modification or waiver of any of the ovisions of this Agreement shall be effective only if made in writing and executed with t same formality as this Agreement. 18. This Agreement shall be govern , by the laws of the State of Florida. Any provision hereof found to be unlawful or unenf► ceable shall be severable and shall not affect the validity of the remaining portions hereof. enue for any and all actions arising out of or in any way related to the interpretation, valid , performance or breach of this Agreement shall lie exclusively in a state court of approp' ate jurisdiction in Leon County, Florida. 19. No term or provi ' sn of this Agreement shall be interpreted for or against any party because that party's legal c', nsel drafted the provision. 20. In accordae with Executive Order No. 11-02 the Department's Vendor/Contractor(s) shall utilize e U.S. Department of Homeland Security's E-Verify system, in accordance with the ter i governing use of the system, to confirm the employment eligibility of. i. all persons employed by the Vendor/Contractor during the term of the Contract to perform employment duties within Florida; and ii. all persons, including subcontractors, assigned by the Vendor/Contractor to perform work pursuant to the contract with the Department. Rev. 6/22 8 FM# 443911-1-52-01 Page 9 of 13 SUBSTITUTED 21. All notices required pursuant to the terms hereof, shall be in writing and shall be sent b first class United States Mail, facsimile transmission, hand delivery or express mail. Notic- '. shall be deemed to have been received by the end of five (5) business days from the proper se r ling thereof unless proof of prior actual receipt is provided. Unless otherwise notified in writ g, notices shall be sent to the following: To the City: Arthur Noriega Miami City Manager 444 SW 2nd Ave Miami, FL, 33130 To the Department: Director of Transportation Oper ions State of Florida, Department Transportation 1000 N.W. 111th Avenue Miami, Florida 33172 22. The City, by and through Resoluti ► No. , attached hereto as Exhibit " has duly authorized the execut n and delivery of this Agreement and agrees to be bound by the terms hereunder, and has er authorized the Mayor or his designee to take all necessary steps to effectuate the terms o ' this Agreement. Rev. 6/22 9 FM# 443911-1-52-01 Page 10 of 13 SUBSTITUTED IN WITNESS WHEREOF, the parties hereto have executed this Agreement on the ates exhibited, by the signatures below. STATE OF FLORIDA DEPARTMENT OF TRANSPO ' ATION By: By: Name: Title: Name: Title: Director of Tr. sportation Operations Date: Date: Attest: Name: Title: Approved as to form and legality: Department Legal Review: By: Name: Rev. 6/22 10 SUBSTITUTED ATTACHM .'T A ATTACHMENT A JA LEGEND Limits of Ott System Agreement . EXIST. a2" PIPE RAY vH 1 �NL 0O I'A TrOC(aDl-- -- 8F0 (D) -_ VYEF.N I/AR4(((4 8 N] e -®--� ere- -- TO EP.a�ED, o �'�iSq � � FOCIDI 34 4'6'5 2 1 o ./ (5 (NB) NlI TC ,,L,. ,,SED 142 NI V �yjItl I EASTIS" PIPE SPEN 10* LE uA I0 1STA EXIST / TO 3F REMOVED FAID C3 iLT _II T JST CURE A C JR. V a TYPE F 4' ] 0\_,3 fl I*P. SIPF T -01.93 T. si I TEr1 ANLC NI ] • -VVN63 Ey 42, o]E &E1 J Ei IH� TA.+ SI. Ce,i L STA. JJ 04 ETy),oT. DETECTNGLE WARNING OLD BE REPLACED) BE*, CSO IY F -7Z30 PATCH EXIST. POUR as �19 .STA. +3,-.8� E. +15 J/ 1a.96' LT. Z4a3 22' LT. DETECTABLE IdIARNIN6 EXIST 2T REPI ACED) 8 L 8,9 El 1113NI3111e EVERS DEEDAIPTIoN NAERIAISS 5 RESJNFACINC .LARD parr J.3RI �,�/4ti 'p 76.S3' RI. 46 5.' NT. EXIST. �� r�2�i 7.2CORSI SIS PIPE T. **SS I P, LE* 58 SCFTT 385 JJ 44 w i4 J3 HT. VH27 EXJST. DETECT., (TU DE 0EPLACLD) *JAR Ce NST. 30 PIP Q, E0")ST. WV (T0 0 SD) .I ©LY - F A 2D0TF2NDI" D UNASD, - 11 C)E*ST STODD IAD ITS 0 ADJUSTED BY CONTRACTOR) C)LXIST I* ATO Fk B *METEDEYFPL, .i15 ckIST. SF lA/VE (FO EL .18J )STED B /pl/ASTS]4'a35 8' � �� OAURICE A. FFRRE PARK 3' DE CA nE kEcok2 LAD**, P.E. PT* JCEILSE NURSER 68,1 iO.AL ASSOCIATES T, SLIITF11,11,11 LADES FL ASS* JO SUBSTITUTED 132 E8 36" 23PF 91.94 —1.Tg ,HH,yR, _gFO*LIC. LAS F3s PIPE T. NHI �i 4#1,1M CATER E(44uT&6 TYPE 122 1s.13 LT. +3188LI Pre ITINS 00 63, ~281 TI LAkT. E 4ar`• D -soysr rr6a .F _ --EDDY 1T 725 arlg am �® j4' ��� ®� I� J� lsr DPAI aREJ.RT CI FAN F ELTe6 t-ilk" ENISI. DETECTABLE WARNING - o e RE REAL**13*1 .� +12,6 6./1 6LI I** AT 0./2 LT. (22 )O0 1 P DEV, 5 ]2'2 END C TYPE F HA ET.CORD R 6N RT J4" DIP / Ex1SC **CT WARNING CONST-30" PIPE / ,ALD DC P.EPLACLD) (BJ 6[.4P„sL, H3N luC 82019/ RT. D EX,T DUES A-4122 SJCV RT. 93 8 Rra LPF3X TALE F TC *If T_9 £PSN11 ARAD SE 5 CURL F C2 T) 2- u, 88 I PC = 12 5 - PT = 124+62.94 ROADI _i Y P/Z,AJVS SHEET 15